Search results for: racial projects

Authors: Hafiz Usama Imad, Muhammad Akram Akhund, Tauha Hussain Ali, Ali Raza Khoso, Fida Hussain Siddiqui

Abstract:

Construction industry plays a significant role in fulfilling the major requirements of the human being. It is one of the major constituents of every developed country. Although the construction industry of both the developing and developed countries encompasses a major part of the economy, and millions of rupees are utilized every year on various kinds of construction projects. But, this industry is facing numerous hurdles in terms of its budget and timely completion. Construction projects generally consist of several phases like planning, designing, execution, and finishing. This research study aims to determine the significant factors of time overrun in pre-construction planning (PCP) phase of construction projects in Pakistan. Questionnaires were distributed by various means and responses of respondents were compiled and collected data were then analyzed through a statistical technique using SPSS version 24. Major causes of time overrun in pre-construction planning phase; which is an extremely important phase of construction projects, were revealed. The research conclusion will provide a pathway for stakeholders to pay attention to the mentioned causes to overcome the major issue of time overrun.

Keywords: construction industry, Pakistan, pre-construction planning phase, time overrun

Procedia PDF Downloads 222

Authors: Laura Florez

Abstract:

The construction industry is labour intensive, and the behaviour and management of workers have a direct impact on the performance of construction projects. One of the issues it currently faces is how to recruit and maintain its workers. Construction is known as an industry where workers face the problem of short employment durations, frequent layoffs, and periods of unemployment between jobs. These challenges not only creates pressures on the workers but also project managers have to constantly train new workers, face skills shortage, and uncertainty on the quality of the workers it will attract. To consider worker’s needs and project managers expectations, one practice that can be implemented is to schedule construction projects to maintain a stable workforce. This paper proposes a mixed integer programming (MIP) model to schedule projects with the objective of maximising social sustainability of construction projects, that is, maximise labour stability. Aside from the social objective, the model accounts for equipment and financial resources required by the projects during the construction phase. To illustrate how the solution strategy works, a construction programme comprised of ten projects is considered. The projects are scheduled to maximise labour stability while simultaneously minimising time and minimising cost. The tradeoff between the values in terms of time, cost, and labour stability allows project managers to consider their preferences and identify which solution best suits their needs. Additionally, the model determines the optimal starting times for each of the projects, working patterns for the workers, and labour costs. This model shows that construction projects can be scheduled to not only benefit the project manager, but also benefit current workers and help attract new workers to the industry. Due to its practicality, it can be a valuable tool to support decision making and assist construction stakeholders when developing schedules that include social sustainability factors.

Keywords: labour stability, mixed-integer programming (MIP), scheduling, workforce management

Procedia PDF Downloads 219

Authors: Rungrot Trongsakul

Abstract:

This paper was aimed to study the model of education cooperation during Thailand and neighbor countries, especially the countries which the territory-cohesion border with Thailand used “Soft Power” to enhance the good relationship. This research employed qualitative method, analyzed and synthesized the content of cooperation projects, policies, laws, relevant theories, relevant research papers and documents and used SWOT analysis. The research findings revealed that Thailand’s education cooperation projects with neighbor countries had two characteristics: 1) education cooperation projects/programs were a part in economic cooperation projects, and 2) there were directly education cooperation projects. The suggested education cooperation model was based on the concept of “Soft Power”, thus the determination of action plans or projects as key factors of public and private organizations should be based on sincere participation among people, communities and relevant organizations of the neighbor countries. Adoption of education-cultural exchange, learning and sharing process is a key to strengthen good relationship of the countries’ cooperation. The roles of education in this included sharing and acceptance of culture and local wisdom, human resource development, knowledge management, integration and networking building could enhance relationship between agents of related organizations of Thailand and neighbors countries.

Keywords: education, soft-power, relationship, cooperation, Thailand neighboring countries

Procedia PDF Downloads 333

Authors: Medya Fathi

Abstract:

When public transportation projects were delivered through design-bid-build and later design-build, governments found a serious issue: inadequate funding. With population growth, governments began to develop new arrangements in which the private sectors were involved to cut the financial burden. This arrangement, known as Public-Private Partnership (PPP), has its own risks; however, performance outputs can motivate or discourage its use. On top of such output's list are time and budget, which can be affected by the type of project delivery methods. Project completion within or ahead of schedule as well as within or under budget is among any owner’s objectives. With a higher application of PPP in the highway industry in the US and insufficient PPP research, the current study addresses the schedule and cost performance of PPP highway projects and determines which one outperforms the other. To meet this objective, after collecting performance data of all PPP projects, schedule growth and cost growth are calculated, and finally, statistical analysis is conducted to evaluate the PPP performance. The results and conclusions will be provided. This study can assist practitioners in applying PPP for transportation projects by showing its ability to save time and/or cost.

Keywords: cost, delivery method, highway, public-private partnership, schedule, transportation

Procedia PDF Downloads 140

Authors: James Wapyer, Simon A. Kawagle

Abstract:

The current downturn in the metal and oil prices has significantly affected the mineral and petroleum sectors of Papua New Guinea. The sectors have not grown substantially in the last three years compared to previous years. Resources of several projects have not been proved up as well as feasibility studies not undertaken on advanced projects. In the 2012-2015 periods, however, development licences for four projects have been granted - the Solwara-1 project in the Manus Basin, the Woodlark project, the Crater Mountains project and the Stanley gas-condensate project. There has been some progress on three advanced projects – Frieda River copper-gold porphyry, Mount Kare gold, and the Wafi-Golpu projects. The oilfields are small by world standard but have been high rates of production. The developments of liquefied natural gas projects are progressing well and the first LNG project with ExxonMobil and partners shipped its first cargo in May 2014, the second with Total and partners involving Elk-Antelope gas-condensate fields is in its development stage, and the third with Horizon Oil and partners involving gas fields in the western Papuan basin is in the planning stage. Significantly, in the years 2012-2015, the country has exported liquefied natural gas, nickel, cobalt and chromium, and has granted exploration licences for iron-sands and coal measures for the first time.

Keywords: exploration, mineral, Papua New Guinea, petroleum

Procedia PDF Downloads 243

Authors: Karun Karki

Abstract:

The Lhotshampa are Bhutanese people of Nepali origin who have been in Bhutan since the early 1600s. A significant number of these people migrated to Bhutan in the nineteenth century. The 1958 Nationality Law of Bhutan granted citizenship to many Lhotshampa people; however, in the late 1970s, the government of Bhutan introduced a series of laws and policies intended for the socio-political and cultural exclusion of the Lhotshampa due to their ancestry. These exclusionary policies and ethnic and racial injustices not only removed the rights and citizenship of the Lhotshampa but also forcibly displaced thousands of families with no choice but to seek refuge in Nepal. In this context, racism becomes a biopolitical tool designed to govern and regulate populations in a way that determines who may live and who must die. The governance and the management of the population, what Stephan Scheel terms as biopolitical bordering, depends on boundaries between residents and non-residents, citizens and non-citizens, and emigrants and immigrants. Drawing on Foucault’s biopolitics and Mbembe’s necropolitics, this paper argues that the concept of racism should be examined within the context of political discourses because it is intertwined with the colonial project, enslavement, and diaspora. This paper critically explores ethnic and racial injustices the Lhotshampa people experienced and the ways in which they negotiated and resisted such injustices in their resettlement processes, including before displacement, in refugee camps, and after the third-country resettlement. Critical examination of these issues helps shed light on the notion of racial difference that justifies dehumanization, discrimination, and racist attitudes against the Lhotshampa people. The study's findings are critical in promoting human rights, social justice, and the health and well-being of the Lhotshampa community in the context of trauma and stressors in their resettlement processes.

Keywords: lhotshampa people, bhutanese refugees, racism, dehumanization, social justice, biopower, necropower

Procedia PDF Downloads 27

Authors: K. W. A. M. Kokila, Matsui Kenichi

Abstract:

Sri Lanka’s disaster management policy aims to protect lives and developments in disaster affected areas by effectively using resources for disaster risk reduction, emergency management, and community awareness. However, funding for these action programs has posed a serious challenge to the country’s economy. This paper examines the extent to which private-public partnerships (PPPs) can facilitate and expedite disaster management works. In particular, it discusses the results of the questionnaire survey among policymakers, government administrators, NGOs, and private businesses. This questionnaire was conducted in 2017. All respondents were selected based on their experience in PPP projects in the past. The survey focused on clarifying the effectiveness of past PPP projects as well as their efficiency and transparency. The respondents also provided their own opinions and suggestions to improve the future PPP projects in Sri Lanka. The questionnaire was distributed to fifteen persons. The results show that almost all respondents think that PPP projects are beneficial and important for future disaster risk management in Sri Lanka. The respondents, however, showed some reservation about effectiveness and transparency of the PPP process. This paper also discusses the results on the respondents’ perceptions about their capacity regarding human resources and management. This paper, overall, sheds light on technological, financial and human resource management practices in developed countries as well as policy and legislation provisions regarding PPP projects.

Keywords: disaster management, policy, private public partnership, projects

Procedia PDF Downloads 134

Authors: Rene A. Salmingo

Abstract:

In pursuing higher educational institution’s transition to sustainable future, this research initiative was conducted. The study aimed to determine the level of sustainability, environmental impact and life cycle phase assessment of the industrial technology research projects at the Institute of Information Technology, Carlos Hilado Memorial State College (CHMSC), Alijis Campus, Bacolod City, Negros Occidental, Philippines. The research method was descriptive utilizing a researcher made questionnaire to assess the ten (10) industrial technology completed research projects. Mean was used to treat the data and instrument for Good and Scates’ validity through revisions and consultations from the environmental experts, technology specialists; and Cronbach Alpha was used to measure reliability. Results indicated that the level of sustainability and life cycle phase assessment was very high while the environmental impact of the industrial research projects was rated low. Moreover, the current research projects and environmental education courses in the college were relevant to support sustainable industrial technology research projects in the future. Hence, this research initiative will contribute to the transformation of CHMSC as a greening higher educational institution and as a center for sustainable development in the region.

Keywords: environmental impact, industrial technology research projects, life cycle phase assessment, sustainability

Procedia PDF Downloads 163

Authors: Abdelouahab Errida, Bouchra Lotfi, Elalami Semma

Abstract:

In this paper, we try to address the topic of multiple change management by adopting an engineered research methodology, conducted within a Moroccan company during its implementation of several change projects that aim at improving its supply chain management performance. Firstly, we present the key concepts related to our research, namely change management, multiproject management and supply chain management. Then, we try to assess how the change management and multi-project management are applied in this company. Finally, we try to propose an approach that will help managers in dealing with multiple change projects. This approach proposes to integrate change management, project management and multi-project management for managing change projects according to three organizational levels: executive level, project portfolio level and change project level.

Keywords: change management, multi-project management, project management, change portfolio, supply chain management,

Procedia PDF Downloads 192

Authors: Juha Kettunen

Abstract:

The purpose of this study is to develop a framework for the assessment of research and development projects. The assessment map is developed in this study based on the strategy map of the balanced scorecard approach. The assessment map is applied in a project that aims to reduce the inequality and risk of exclusion of young people from disadvantaged social groups. The assessment map denotes that not only funding but also necessary skills and qualifications should be carefully assessed in the implementation of the project plans so as to achieve the objectives of projects and the desired impact. The results of this study are useful for those who want to develop the implementation of the Erasmus+ Programme and the project teams of research and development projects.

Keywords: non-formal learning, youth work, social inclusion, innovation

Procedia PDF Downloads 268

Authors: Mohammad Lemar Zalmai, Mustafa Nabi Kocakaya, Cemil Akcay, Ekrem Manisali

Abstract:

In recent years, the Building Information Modeling (BIM) approach has been developed expeditiously. As people see the benefits of this approach, it has begun to be used widely in construction projects and some countries made it mandatory to get more benefits from it. To promote the implementation of BIM in construction projects, it will be helpful to get some relevant information from surveys and interviews. The purpose of this study is to research the current adoption and implementation of BIM in public projects in Turkey. This study specified the challenges of BIM implementation in Turkey and proposed some solutions to overcome them. In this context, the challenges for BIM implementation and the factors that affect the BIM usage are determined based on previous academic researches and expert opinions by conducting interviews and questionnaire surveys. Several methods are used to process information in order to obtain weights of different factors to make BIM widespread in Turkey. This study concluded interviews' and questionnaire surveys' outcomes and proposed some suggestions to promote the implementation of BIM in Turkey. We believe research findings will be a good reference for boosting BIM implementation in Turkey.

Keywords: building information modelling, BIM implementations, Turkish construction industry, Turkish government sector projects

Procedia PDF Downloads 110

Authors: Mohammad Mahdi Hajiali

Abstract:

Many of construction projects estimated in Iran have been influenced by the limitations of financial resources. As for Iran, a country that is developing, and to follow this development-oriented approach which many numbers of projects each year run in, if we can reduce the cost of projects by applying a method we will help greatly to minimize the cost of major construction projects and therefore projects will finish faster and more efficiently. One of the components of transportation infrastructure are roads that are considered to have a considerable share of the country budget. In addition, major budget of the related ministry is spending to repair, improve and maintain roads. Value Engineering is a simple and powerful methodology over the past six decades that has been successful in reducing the cost of many projects. Specific solution for using value engineering in the stage of project implementation is called value engineering change proposal (VECP). It was tried in this research to apply VECP in one of the road-building projects in Iran in order to enhance the value of this kind of projects and reduce their cost. In this case study after applying VECP, an idea was raised. It was about use of concrete pavement instead of hot mixed asphalt (HMA) and also using fiber in order to improve concrete pavement performance. VE group team made a decision that for choosing the best alternatives, get expert’s opinions in pavement systems and use Fuzzy TOPSIS (Technique for Order of Preference by Similarity to Ideal Solution) for ranking opinions of the experts. Finally, Jointed Plain Concrete Pavement (JPCP) was selected. Group also experimented concrete samples with available fibers in Iran and the results of experiments showed a significant increment in concrete specifications such as flexural strength. In the end, it was shown that by using of fiber-reinforced concrete pavement instead of asphalt pavement, we can achieve a significant saving in cost, time and also increment in quality, durability, and longevity.

Keywords: road-building projects, value engineering change proposal (VECP), Jointed Plain Concrete Pavement (JPCP), Fuzzy TOPSIS, fiber-reinforced concrete

Procedia PDF Downloads 160

Authors: Madeline Phillips, Luis Mendez

Abstract:

The 21st century has seen an increase in the amount and variety of psychological research on Latinx, the largest minority group in the U.S., with great variability from the individual’s cultural origin (e.g., ethnicity) to region (e.g., nationality). We were interested in exploring how scientists recruit, conduct and report research on Latinx samples. Ethnicity and race are important components of individuals and should be addressed to capture a broader and deeper understanding of psychological research findings. In order to explore Latinx/Hispanic work, the Journal of Latinx Psychology (JLP) and Hispanic Journal of Behavioral Sciences (HJBS) were analyzed for 1) measures of ethnicity and race in empirical studies 2) nationalities represented 3) how researchers reported ethnic-racial demographics. The analysis included publications from 2013-2018 and revealed two common themes of reporting ethnicity and race: overrepresentation/underrepresentation and overgeneralization. There is currently not a systematic way of reporting ethnicity and race among Latinx/Hispanic research, creating a vague sense of what and how ethnicity/race plays a role in the lives of participants. Second, studies used the Hispanic/Latinx terms interchangeably and are not consistent across publications. For the purpose of this project, we were only interested in publications with Latinx samples in the U.S. Therefore, studies outside of the U.S. and non-empirical studies were excluded. JLP went from N = 118 articles to N = 94 and HJBS went from N = 174 to N = 154. For this project, we developed a coding rubric for ethnicity/race that reflected the different ways researchers reported ethnicity and race and was compatible with the U.S. census. We coded which ethnicity/race was identified as the largest ethnic group in each sample. We used the ethnic-racial breakdown numbers or percentages if provided. There were also studies that simply did not report the ethnic composition besides Hispanic or Latinx. We found that in 80% of the samples, Mexicans are overrepresented compared to the population statistics of Latinx in the US. We observed all the ethnic-racial breakdowns, demonstrating the overrepresentation of Mexican samples and underrepresentation and/or lack of representation of certain ethnicities (e.g., Chilean, Guatemalan). Our results showed an overgeneralization of studies that cluster their participants to Latinx/Hispanic, 23 for JLP and 63 for HJBS. The authors discuss the importance of transparency from researchers in reporting the context of the sample, including country, state, neighborhood, and demographic variables that are relevant to the goals of the project, except when there may be an issue of privacy and/or confidentiality involved. In addition, the authors discuss the importance to recognize the variability within the Latinx population and how it is reflected in the scientific discourse.

Keywords: Latinx, Hispanic, race and ethnicity, diversity

Procedia PDF Downloads 83

Authors: Ronaldo Seroa Da Motta, Gabriela Santiago

Abstract:

The main contribution of this study is the identification of the factors influencing the environmental licensing process of infrastructure projects in Brazil. These factors will be those that reflect the technical characteristics of the project, the corporate governance of the entrepreneur, and the institutional and regulatory governance of the environmental agency, including the number of interventions by non-licensing agencies. The model conditions these variables to the licensing processing time of 34 infrastructure projects. Our results indicated that the conditions would be more sensitive to the type of enterprise, complexity as in gas pipelines and hydroelectric plants in the most vulnerable biome with a greater value of the enterprise or the entrepreneur's assets, together with the number of employees of the licensing agency. The number of external interventions by other non-licensing institutions does not affect the licensing time. Such results challenge the current criticism that environmental licensing has been often pointed out as a barrier to speed up investments in infrastructure projects in Brazil due to the participation of civil society and other non-licensing institutions.

Keywords: environmental licensing, condionants, Brazil, timing process

Procedia PDF Downloads 106

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 476

Authors: Nnadi Ezekiel Ejiofor

Abstract:

In Enugu, Nigeria, this study investigates the connection between strategic leadership and project management sustainability, with an emphasis on building projects in the State. The study set out to accomplish two specific goals: first, it sought to establish a link between creative project management and resource efficiency in construction projects in Enugu State, Nigeria; and second, it sought to establish a link between innovative thinking and waste minimization in those same projects. A structured questionnaire was used to collect primary data from 45 registered construction enterprises in the study area as part of the study's descriptive research approach. Due to the nonparametric nature of the data, Spearman Rank Order Correlation was used to evaluate the acquired data. The findings demonstrate that creative project management had a significant positive impact on resource efficiency in construction projects carried out by architecture firms in Enugu State, Nigeria (r =.849; p.001), and that innovative thinking had a significant impact on waste reduction in those same projects (r =.849; p.001). It was determined that strategic leadership had a significant impact on the sustainability of project management, and it was thus advised that project managers should foresee, prepare for, and effectively communicate present and future developments to project staff in order to ensure that the objective of sustainable initiatives, such as recycling and reuse, is implemented in construction projects.

Keywords: construction, project management, strategic leadership, sustainability, waste reduction

Procedia PDF Downloads 23

Authors: Sungik Kang, Ja-Hoon Koo

Abstract:

Globally, urban environments have become unequal, and cities have been segmented by income class. It is predicted that urban inequality has arisen by urban redevelopment and reconstruction projects that improve the urban environment and innovate cities. This study aims to analyze the occurrence and characteristics of urban inequality by using the housing price and sale price and demonstrating the correlation with the urban redevelopment project. This study measures 14 years of urban inequality index for 25 autonomous districts in Seoul and analyzes the correlation between urban inequality with urban redevelopment projects. As a conclusion of this study, first, the urban inequality index of Seoul has been continuously rising since 2015. Trends from 2006 to 2019 have been in U-curved shape in between 2015. In 2019, Seoul's urban inequality index was 0.420, a level similar to that of the 2007 financial crisis. Second, the correlation between urban redevelopment and urban inequality was not statistically significant. Therefore, we judged that urban redevelopment's scale or project structure has nothing with urban inequality. Third, while district designation of urban reconstruction temporarily alleviates urban inequality, the completion of the project increases urban inequality. When designating a district, urban inequality is likely to decrease due to decreased outdated housing transactions. However, the correlation with urban inequality increases as expensive houses has been placed after project completion.

Keywords: urban inequality, urban redevelopment projects, urban reconstruction projects, housing price inequality, panel analysis

Procedia PDF Downloads 179

Authors: Abdullah Almusharraf, Andrew Whyte

Abstract:

The sub-task pattern in terms of the deviations and defects should be identified and understand in order to improve the quality practices in construction projects. Therefore, the sub-task susceptibility to exposure to deviations and defects have been evaluated and classified via six classifications that have proposed in this study. 34 case studies on specific sub-task (from compression member in construction concrete structure) have been collected from seven construction projects in order to examined study’s classifications. The study revealed that the sub-task has high sensitive to deviation where (91%) of the cases recorded as deviations, however, only (19%) of cases recorded as defects. Another findings were that the actual work during the execution process has high source of deviation for this sub-task (74%) while only (26%) of the deviation source was due to both design documentations with the actual work. These findings significantly imply that it could be used the study’s classifications to determine the pattern of each sub-task and develop the proactive actions to overcome issues of the sub-task deviations and defects.

Keywords: sub-tasks, deviations, defects, quality, construction projects

Procedia PDF Downloads 407

Authors: Arsalan Salahi

Abstract:

Today, the number of changes in the construction industry and urban mass house building is increasing, which makes you need to pay more attention to targeted planning for human resource management and training. The human resources working in the construction industry have various problems and deficiencies, and in order to solve these problems, there is a need for basic management and training of these people in order to lower the construction costs and increase the quality of the projects, especially in mass house building projects. The success of any project in reaching short and long-term professional goals depends on the efficient combination of work tools, financial resources, raw materials, and most importantly, human resources. Today, due to the complexity and diversity of each project, specialized management fields have emerged to maximize the potential benefits of each component of that project. Human power is known as the most important resource in construction projects for its successful implementation, but unfortunately, due to the low cost of human power compared to other resources, such as materials and machinery, little attention is paid to it. With the correct management and training of human resources, which depends on its correct planning and development, it is possible to improve the performance of construction projects. In this article, the training and motivation of construction industry workers and their effects on the effectiveness of projects in this industry have been researched. In this regard, some barriers to the training and motivation of construction workers and personnel have been identified and solutions have been provided for construction companies. Also, the impact of workers and unskilled people on the efficiency of construction projects is investigated. The results of the above research show that by increasing the use of correct and basic training for human resources, we will see positive results and effects on the performance of construction projects.

Keywords: human resources, construction industry, principled training, skilled and unskilled workers

Procedia PDF Downloads 55

Authors: Natalia Rudeli, Elisabeth Viles, Adrian Santilli

Abstract:

Delays in the construction industry are a global phenomenon. Many construction projects experience extensive delays exceeding the initially estimated completion time. The main purpose of this study is to identify construction projects typical behaviors in order to develop a prognosis and management tool. Being able to know a construction projects schedule tendency will enable evidence-based decision-making to allow resolutions to be made before delays occur. This study presents an innovative approach that uses Cluster Analysis Method to support predictions during Earned Value Analyses. A clustering analysis was used to predict future scheduling, Earned Value Management (EVM), and Earned Schedule (ES) principal Indexes behaviors in construction projects. The analysis was made using a database with 90 different construction projects. It was validated with additional data extracted from literature and with another 15 contrasting projects. For all projects, planned and executed schedules were collected and the EVM and ES principal indexes were calculated. A complete linkage classification method was used. In this way, the cluster analysis made considers that the distance (or similarity) between two clusters must be measured by its most disparate elements, i.e. that the distance is given by the maximum span among its components. Finally, through the use of EVM and ES Indexes and Tukey and Fisher Pairwise Comparisons, the statistical dissimilarity was verified and four clusters were obtained. It can be said that construction projects show an average delay of 35% of its planned completion time. Furthermore, four typical behaviors were found and for each of the obtained clusters, the interim milestones and the necessary rhythms of construction were identified. In general, detected typical behaviors are: (1) Projects that perform a 5% of work advance in the first two tenths and maintain a constant rhythm until completion (greater than 10% for each remaining tenth), being able to finish on the initially estimated time. (2) Projects that start with an adequate construction rate but suffer minor delays culminating with a total delay of almost 27% of the planned time. (3) Projects which start with a performance below the planned rate and end up with an average delay of 64%, and (4) projects that begin with a poor performance, suffer great delays and end up with an average delay of a 120% of the planned completion time. The obtained clusters compose a tool to identify the behavior of new construction projects by comparing their current work performance to the validated database, thus allowing the correction of initial estimations towards more accurate completion schedules.

Keywords: cluster analysis, construction management, earned value, schedule

Procedia PDF Downloads 234

Authors: Rodrigo Buaiz Boabaid

Abstract:

Tokenization of Blue Bonds is an emerging Green Finance tool that has the potential to scale Blue Carbon Projects to fight climate change. This innovative solution has a huge potential to democratize the green finance market and catalyze innovations in the climate change finance sector. Switzerland has emerged as a leader in the Green Finance space and is well-positioned to drive the adoption of Tokenization of Blue & Green Bonds. This unique approach has the potential to unlock new sources of capital and enable global investors to participate in the financing of sustainable blue carbon projects. By leveraging the power of blockchain technology, Tokenization of Blue Bonds can provide greater transparency, efficiency, and security in the investment process while also reducing transaction costs. Investments are in line with the highest regulations and designed according to the stringent legal framework and compliance standards set by Switzerland. The potential benefits of Tokenization of Blue Bonds are significant and could transform the way that sustainable projects are financed. By unlocking new sources of capital, this approach has the potential to accelerate the deployment of Blue Carbon projects and create new opportunities for investors to participate in the fight against climate change.

Keywords: blue bonds, blue carbon, tokenization, green finance

Procedia PDF Downloads 56

Authors: Ringisai Abigail Mawondo-Dhliwayo, Kahilu Kajimo-Shakantu

Abstract:

Due to financial challenges which governments in general face, it is becoming more difficult for many to continually use their limited resources to undertake infrastructural development. Governments increasingly now need other delivery approaches, in particular, the Public-Private Partnerships which make it possible for the public sector to achieve infrastructural development without incurring any/minimum cost. The literature reviewed outlined that benefits of PPPs include timely delivery of quality projects with cost limits. The methodology utilized for the empirical study comprised six interviews and sixty questionnaires which were undertaken and administered by construction consultants and government officials involved in PPPs projects. The results obtained showed that PPPs are not widely used in Zimbabwe although the need for their use exists. The study also found some challenges which prevent or derail the rate at which PPPs are utilized, of which the primary one was a political influence. It is concluded that despite limitations, PPPs remain the most effective and viable option for the delivery of government projects. The study recommends that policy and framework for the implementation of PPPs be developed. More useful information could have been obtained if final users of PPPs projects were included in the sample for data collection.

Keywords: construction projects, procurement, public private partnerships, public sector

Procedia PDF Downloads 227

Authors: EMMANUEL DWAMENA SASU

Abstract:

International climate policy actions require countries under Paris Agreement to design instruments, provide support (financial and technical), and strengthen institutional capacity with tendency to transcending policy formulation to implementation and sustainability. Changes associated with moisture depletion has been a growing phenomenon; especially in developing countries with projected global GDP drop from 7% to 2% between 2005 and 2050. These developments have potential to adversely affect food production in feeding the growing world population, with corresponding rise in global hunger. Incongruously, there is global absence of a harmonized policy direction; capable of providing the required indicators on climate policies for monitoring sustainability of international agricultural development projects. We conduct extensive review and synthesis on existing limitations on global climate policy governance, agricultural food security and sustainability of international agricultural development projects, and conjecture the role of non-state and sub-national climate stakeholder engagements, and monitoring and evaluation strategies for improved climate policy action for sustaining international agricultural development projects.

Keywords: climate policy, agriculture, development projects, sustainability

Procedia PDF Downloads 100

Authors: Mamoon Mousa Atout

Abstract:

Projects managers in construction industry usually face a difficult organizational environment especially if the project is unique. The organization lacks the processes to practice construction management correctly, and the executive’s technical managers who have lack of experience in playing their role and responsibilities correctly. Project managers need to adopt best practices that allow them to do things effectively to make sure that the project can be delivered without any delay even though the executive’s technical managers should follow a certain process to avoid any factor might cause any delay during the project life cycle. The purpose of the paper is to examine the awareness level of projects managers about construction management processes, tools, techniques and implications to complete projects on time. The outcome and the results of the study are prepared based on the designed questionnaires and interviews conducted with many project managers. The method used in this paper is a quantitative study. A survey with a sample of 100 respondents was prepared and distributed in a construction company in Dubai, which includes nine questions to examine the level of their awareness. This research will also identify the necessary benefits of processes of construction management that has to be adopted by projects managers to mitigate the maximum potential problems which might cause any delay to the project life cycle.

Keywords: construction management, project objectives, resource planing and scheduling, project completion

Procedia PDF Downloads 369

Authors: Alireza Ghaffari, Hassan Saghi

Abstract:

Project management is more complex than managing the day-to-day affairs of an organization. When the project dimensions are broad and multiple projects have to be monitored in different locations, the integrated management becomes even more complicated. One of the main concerns of project managers is the integrated project management, which is mainly rooted in the lack of accurate and accessible information from different projects in various locations. The collection of dispersed information from various parts of the network, their integration and finally the selective reporting of this information is among the goals of integrated information systems. It can help resolve the main problem, which is bridging the information gap between executives and senior managers in the organization. Therefore, the main objective of this study is to design and implement an important subset of a project management information system in order to successfully control the cost of construction projects so that its results can be used to design raw software forms and proposed relationships between different project units for the collection of necessary information.

Keywords: financial performance, cost subsystem, PMIS, project management

Procedia PDF Downloads 77

Authors: Wang Liguang, Zhang Xueqing

Abstract:

The build-operate-transfer (BOT) project delivery system has provided effective routes to mobilize private sector funds, innovative technologies, management skills and operational efficiencies for public infrastructure development and have been widely used in China during the last 20 years. Many BOT projects in China will be smoothly transferred to the government soon and the transfer stage, which is considered as the last stage, must be studied carefully and handled well to achieve the overall success of BOT projects. There will be many issues faced by both the public sector and private sector in the transfer stage of BOT projects, including project post-assessment, technology and documents transfer, personal training and staff transition, etc. and sometimes additional legislation is needed for future operation and management of facilities. However, most previous studies focused on the bidding, financing, and building and operation stages instead of transfer stage. This research identifies nine key issues in the transfer stage of BOT projects through a comprehensive study on three cases in China, and the expert interview and expert discussion meetings are held to validate the key issues and give detail analysis. A proposed framework of transfer management is prepared based on the experiences derived and lessons drawn from the case studies and expert interview and discussions, which is expected to improve the transfer management of BOT projects in practice.

Keywords: BOT project, key issues, transfer management, transfer stage

Procedia PDF Downloads 217

Authors: Tazeen Fatima

Abstract:

Use of project management in web & software development projects is very significant. It has been observed that even with the application of effective project management, projects usually do not complete their lifecycle and fail. To minimize these failures, key performance indicators have been introduced in previous studies to counter project failures. However, there are always gaps and problems in the KPIs identified. Despite of incessant efforts at technical and managerial levels, projects still fail. There is no substantial approach to identify and avoid these failures in the very beginning of the project lifecycle. In this study, we aim to answer these research problems by analyzing the concept of predictive analytics which is a specialized technology and is very easy to use in this era of computation. Project organizations can use data gathering, compute power, and modern tools to render efficient Predictions. The research aims to identify such a predictive analytics approach. The core objective of the study was to reduce failures and introduce effective implementation of project management principles. Existing predictive analytics methodologies, tools and solution providers were also analyzed. Relevant data was gathered from projects and was analyzed via predictive techniques to make predictions well advance in time to render effective project management in web & software development industry.

Keywords: project management, predictive analytics, predictive analytics methodology, project failures

Procedia PDF Downloads 306

Authors: Gheyzer Villegas, Edgardo Cedeño, Veruska Mata, Edmundo Chauran

Abstract:

One of the most significant changes that occurred in global commerce was the emergence of cryptocurrencies and blockchain technology. There is still much debate about the adoption of the economic model based on crypto assets, and myriad international projects and initiatives are being carried out to try and explore the potential that this new field offers. The Hive blockchain is a prime example of this, featuring two use cases: of how trade based on its native currencies can give successful results in the exchange of goods and services and in the financing of social impact projects. Its decentralized management model and visionary administration of its development fund have become a key part of its success.

Keywords: Hive, business, network, blockchain

Procedia PDF Downloads 38

Authors: Seini G. Kaufusi

Abstract:

Background. Physician-assisted death (PAD) has and continues to be a controversial issue in the U.S. Dying with dignity statutes exists in 9 U.S. jurisdictions that permit competent adults diagnosed with a terminal illness and given a prognosis of 6 month or less to live to request medication to hasten death. Robust advocacy for and against PAD influences policy, and opinions vary. Aim. This study aims to explore the association between race and the attitudes toward physician-assisted death in the U.S. Methods. Data for this study derives from the General Social Survey (GSS) dataset, a national survey conducted by the National Opinion Research Center (NORC) that focuses on the opinions and values of American’s. A cross-sectional design and probability sample from the 2018 data set was used to randomly select respondents. Results. The results indicated that race is significantly associated with attitudes towards physician-assisted death. The level of significance suggests a strong positive association, and the direction indicated that Black and Other racial groups have higher rates of positive decision about PAD. Conclusion. Although attitudes towards PAD varied, Black and other racial groups had favorable decisions for PAD. Further research is crucial in the continuous debate on PAD and understanding the influences of predictors for or against PAD.

Keywords: attitudes, euthanasia, physician-assisted death, race

Procedia PDF Downloads 136

Authors: M. Takhtravanchi, C. Pathirage

Abstract:

In the construction industry, project members are conveyor of project knowledge which is, often, not managed properly to be used in future projects. As construction projects are temporary and unique, project members are willing to be recruited once a project is completed. Therefore, poor management of knowledge across construction projects will lead to a considerable amount of knowledge loss; the ignoring of which would be detrimental to project performance. This issue is more prominent in projects undertaken through the traditional procurement system, as this system does not incentives project members for integration. Thus, disputes exist between the design and construction phases based on the poor management of knowledge between those two phases. This paper aims to highlight the challenges of the knowledge management that exists within the traditional procurement system. Expert interviews were conducted and challenges were identified and analysed by the Interpretive Structural Modelling (ISM) approach in order to summarise the relationships among them. Two identified key challenges are the Culture of an Organisation and Knowledge Management Policies. A knowledge of the challenges and their relationships will help project manager and stakeholders to have a better understanding of the importance of knowledge management.

Keywords: challenges, construction industry, knowledge management, traditional procurement system

Procedia PDF Downloads 400