Search results for: research and research-related projects

Authors: Afrah Saad Mohsen Al-Mahfadi

Abstract:

In rural areas of developing countries, participation of all stakeholders in water supply projects is an important step towards further development. As most of the beneficiaries are women, it is important that they should be involved to achieve successful and sustainable water supply projects. Women are responsible for the management of water both inside and outside home, and often spend more than six-hours a day fetching drinking water from distant water sources. The problem is that rural women play a role of little importance in the water supply projects’ phases in rural Yemen. Therefore, this research aimed at analyzing the different reasons of their lack of participation in projects and in what way a full participation -if achieved- could contribute to sustainable water supply projects in the rural mountainous areas in Yemen. Four water supply projects were selected as a case study in Al-Della'a Alaala sub-district in the Al-Mahweet governorate, two of them were implemented by the Social Fund and Development (SFD), while others were implemented by the General Authority for Rural Water Supply Projects (GARWSSP). Furthermore, the successful Al-Galba project, which is located in Badan district in Ibb governorate, was selected for comparison. The rural women's active participation in water projects have potential consequences including continuity and maintenance improvement, equipment security, and improvement in the overall health and education status of these areas. The majority of respondents taking part in GARWSSP projects estimated that there is no reason to involve women in the project activities. In the comparison project - in which a woman worked as a supervisor and implemented the project – all respondents indicated that the participation of women is vital for sustainability. Therefore, the results of this research are intended to stimulate rural women's participation in the mountainous areas of Yemen.

Keywords: assessment, rural woman, sustainability, water management

Procedia PDF Downloads 653

Authors: Kais Amir Kadhim

Abstract:

Context: The study focuses on the rhetorical structure of chapters in engineering final year projects, specifically the Introduction chapter, written by UMT (University of Marine Technology) engineering students. Existing research has explored the use of genre-based approaches to analyze the writing of final year projects in various disciplines. Research Aim: The aim of this study is to investigate the rhetorical structure of Introduction chapters in engineering final year projects by UMT students. The study aims to identify the frequency of communicative moves and their constituent steps within the Introduction chapters, as well as understand how students justify their research projects. Methodology: The research design will utilize a mixed method approach, combining both quantitative and qualitative methods. Forty Introduction chapters from two different fields in UMT engineering undergraduate programs will be selected for analysis. Findings: The study intends to identify the types of moves present in the Introduction chapters of engineering final year projects by UMT students. Additionally, it aims to determine if these moves and steps are obligatory, conventional, or optional. Theoretical Importance: The study draws upon Bunton's modified CARS (Creating a Research Space) model, which is a conceptual framework used for analyzing the introduction sections of theses. By applying this model, the study contributes to the understanding of the rhetorical structure of Introduction chapters in engineering final year projects. Data Collection: The study will collect data from forty Introduction chapters of engineering final year projects written by UMT engineering students. These chapters will be selected from two different fields within UMT's engineering undergraduate programs. Analysis Procedures: The analysis will involve identifying and categorizing the communicative moves and their constituent steps within the Introduction chapters. The study will utilize both quantitative and qualitative analysis methods to examine the frequency and nature of these moves. Question Addressed: The study aims to address the question of how UMT engineering students structure and justify their research projects within the Introduction chapters of their final year projects. Conclusion: The study aims to contribute to the knowledge of rhetorical structure in engineering final year projects by investigating the Introduction chapters written by UMT engineering students. By using a mixed method research design and applying the modified CARS model, the study intends to identify the types of moves and steps employed by students and explore their justifications for their research projects. The findings have the potential to enhance the understanding of effective academic writing in engineering disciplines.

Keywords: cohesive markers, learning, meaning, students

Procedia PDF Downloads 49

Authors: Mohammad Reza Abidi, Zahra Nourouz Pour, Mehdi Moudi

Abstract:

In this research, firstly critical success factors and deterrent factors in implementing projects and also the factors those cause information technology productivity (IT) paradox in Islamic Azad University, Zahedan branch examined. Research method of this paper is descriptive. In fact, the researcher by using survey, proposed useful solutions. In this research, subjects’ responders to questionnaires items were based on Likert scale. In the questionnaire, economic, technical, organizational and cultural factors in the university have been assessed in order to obtain the necessary validity. We used masters and technicians of IT department’s advices to realize reliability and consistency. For the reliability test we used Cronbach’s reliability test and validity has been obtained using SPSS software. Because of the research questions and objectives, t-student test is used for hypothesis testing. Finally we analyze the findings, we offer conclusions and suggestions.

Keywords: IT projects, Islamic Azad University, success factors, deterrent factors

Procedia PDF Downloads 280

Authors: Y. Gholipour, E. Rezazadeh

Abstract:

Delay is one of the most serious and common problems of construction project that can affect project delivery unfavorably. This research presents the most important causes of delay in large dam projects based on a survey on some executed dam construction in Iran. In this survey a randomly selected samples of owners, consultants and contractors have been involved. The outcome of this survey revealed that scheduled payments, site management, shop drawing review process, unforeseen ground conditions and contractor experience as the most important factors affecting on delay in dam construction projects.

Keywords: delay, dam construction, project management, Iran

Procedia PDF Downloads 414

Authors: Juha Kettunen

Abstract:

This study presents a project that tests and adjusts active European learning and teaching methods in Indonesian universities to increase their external impact on enterprises and other organizations; it also assesses the implementation of the Erasmus+ projects funded by the European Union. The project is based on the approach of innovation pedagogy that responds to regional development needs and integrates applied research and development projects into education to create capabilities for students to participate in development work after graduation. The assessment of the Erasmus+ project resulted in many improvements that can be made to achieve higher quality and innovativeness. The results of this study are useful for those who want to improve the applied research and development projects of higher education institutions.

Keywords: higher education, innovations, social network, project management

Procedia PDF Downloads 259

Authors: O. Badagadze, G. Sirbiladze, I. Khutsishvili

Abstract:

The work proposes a decision support methodology for the credit risk minimization in selection of investment projects. The methodology provides two stages of projects’ evaluation. Preliminary selection of projects with minor credit risks is made using the Expertons Method. The second stage makes ranking of chosen projects using the Possibilistic Discrimination Analysis Method. The latter is a new modification of a well-known Method of Fuzzy Discrimination Analysis.

Keywords: expert valuations, expertons, investment project risks, positive and negative discriminations, possibility distribution

Procedia PDF Downloads 637

Authors: A. Elbaz, K. Spang

Abstract:

Infrastructure projects are often subjected to delays and cost overruns and mistakenly described as unsuccessful projects. These projects have many peculiarities such as public attention, impact on the environment, subjected to special regulations, etc. They also deal with several stakeholders with different motivations and face unique risks. With this in mind we need to reconsider our approach to manage them, define their success factors and implement these success factors. Infrastructure projects are not only lacking a unified meaning of project success or a definition of success factors, but also a clear method to implement these factors. This paper investigates this gap and introduces a concept to implement success factors in an efficient way, taking into consideration the specific characteristics of infrastructure projects. This concept consists of six enablers such as project organization, project team, project management workflow, contract management, communication and knowledge transfer and project documentations. These enablers allow other success factors to be efficiently implemented in projects. In conclusion, this paper provides project managers as well as company managers with a tool to define and implement success factors efficiently in their projects, along with upgrading their assets for the coming projects. This tool consists of processes and validated checklists to ensure the best use of company resources and knowledge. Due to the special features of infrastructure projects this tool will be tested in the German infrastructure market. However, it is meant to be adaptable to other markets and industries.

Keywords: infrastructure projects, operative success factors, project success, success factors, transportation projects

Procedia PDF Downloads 88

Authors: Rossana Mancini

Abstract:

The charm of a ruin colonised by wild plants and flowers is part of Western culture. The relationship between ruins and vegetation involves a wide range of different fields of research. During the first phase of the research the most important writings and projects about this argument were investigated, to understand how the perception of the co-existence of ruins and vegetation has changed over time and to investigate the various different approaches that these different fields have adopted when tackling this issue. The paper presents some practical examples of projects carried out from the early 1900s on. The major result is that specifically regards conservation, the best attitude is the management of change, an inevitable process when it comes to the co-existence of ruins and nature and, particularly, ruins and vegetation. Limiting ourselves to adopting measures designed to stop, or rather slow down, the increasing level of entropy (and therefore disorder) may not be enough.

Keywords: ruins, vegetation, conservation, archaeology, architecture

Procedia PDF Downloads 301

Authors: Mohammad Lemar Zalmai, Mustafa Nabi Kocakaya, Cemil Akcay, Ekrem Manisali

Abstract:

In recent years, the Building Information Modeling (BIM) approach has been developed expeditiously. As people see the benefits of this approach, it has begun to be used widely in construction projects and some countries made it mandatory to get more benefits from it. To promote the implementation of BIM in construction projects, it will be helpful to get some relevant information from surveys and interviews. The purpose of this study is to research the current adoption and implementation of BIM in public projects in Turkey. This study specified the challenges of BIM implementation in Turkey and proposed some solutions to overcome them. In this context, the challenges for BIM implementation and the factors that affect the BIM usage are determined based on previous academic researches and expert opinions by conducting interviews and questionnaire surveys. Several methods are used to process information in order to obtain weights of different factors to make BIM widespread in Turkey. This study concluded interviews' and questionnaire surveys' outcomes and proposed some suggestions to promote the implementation of BIM in Turkey. We believe research findings will be a good reference for boosting BIM implementation in Turkey.

Keywords: building information modelling, BIM implementations, Turkish construction industry, Turkish government sector projects

Procedia PDF Downloads 110

Authors: A. Samer Ezeldin, Sarah A. Fotouh

Abstract:

Optimization of resources is very important in all fields, as in construction management. Project managers have to face problems regarding management of cost, time and available resources of single projects and more problems arise when managing multiple projects. Most of the studies focused on optimization of resources for a single project, but, this paper will discuss the design and modeling of multiple resources optimization for multiple projects using Genetic Algorithm. Most of the companies in construction industry optimize the resources for single projects only, but with the presence of several mega projects in several developing countries running at the same time, there is a need for a model to enhance the efficiency of available resources and decreases the fluctuation as much as possible. The proposed model calculates the cost of each resource, tries to minimize the cost of extra resources as much as possible and generates the schedule of each project within a selected program.

Keywords: construction management, genetic algorithm, multiple projects, multiple resources, optimization

Procedia PDF Downloads 426

Authors: Saleh Komies, Mona Alharbi, Razan Alhayyani, Mozah Almulhim, Roseanne Khawaja, Ahmed Alradhi

Abstract:

One of the proposed solutions that faces some challenges is encouraging sustainable energy consumption across Saudi Arabia through crowdfunding platforms. To address these challenges, we need to determine the level of awareness of crowdfunding and green projects, as well as the preferences and willingness of Saudis to utilize crowdfunding as an alternative funding source for green projects in Saudi Arabia. In this study, we aim to determine the influence of environmental awareness and concern on the propensity to crowdfund green projects. The survey is being conducted as part of environmental initiatives to assess public perceptions and opinions on crowdfunding green projects in Saudi Arabia. A total of 450 responses to an online questionnaire distributed via convenience and snowball sampling were utilized for data analysis. The survey reveals that Saudis have a low understanding of crowdfunding concepts and a relatively high understanding of implementing green projects. The public is interested in crowdfunding green projects if there is a return on investment.

Keywords: crowdfunding, green projects, awareness, Saudi Arabia, energy, solar, wind

Procedia PDF Downloads 63

Authors: Chatelier Charlene, Oyegoke Adekunle, Ajayi Saheed, Jeffries Andrew

Abstract:

This study seeks to understand Schedule Risk Assessments as a priori for better performance whilst exploring the strategies employed to deliver complex projects like the New Polar research ship. This high-profile vessel was offered to Natural Environment Research Council and British Antarctic Survey (BAS) by Cammell Laird Shipbuilders. The Research Ship was designed to support science in extreme environments, with the expectancy to provide a wide range of specialist scientific facilities, instruments, and laboratories to conduct research over multiple disciplines. Aim: The focus is to understand the allocation and management of schedule risk on such a Major Project. Hypothesising that "effective management of schedule risk management" could be the most critical factor in determining whether the intended benefits mentioned are delivered within time and cost constraints. Objective 1: Firstly, the study seeks to understand the allocation and management of schedule risk in Major Projects. Objective 2: Secondly, it explores "effective management of schedule risk management" as the most critical factor determining the delivery of intended benefits. Methodology: This study takes a retrospective review of schedule risk management and how it influences project performance using a case study approach for the RRS (Royal Research Ship) Sir David Attenborough. Research Contribution: The outcomes of this study will contribute to a better understanding of project performance whilst building on its under-researched relationship to schedule risk management for complex projects. The outcomes of this paper will guide further research on project performance and enable the understanding of how risk-based estimates over time impact the overall risk management of the project.

Keywords: complexity, major projects, performance management, schedule risk management, uncertainty

Procedia PDF Downloads 69

Authors: Samira Boussema, Ben Hamed Salah

Abstract:

Entrepreneurship was always considered to be the most appropriate remedy for various economies’ symptoms. It is presented as a complex process that faces several barriers thereby inhibiting a project’s implementation phase. In fact, after a careful review of the literature, we noticed that empirical researches on reasons behind non-developing entrepreneurial projects are very rare, suggesting a lack in modeling the process in general and the pre-start phase in particular. Therefore, in this study we try to identify the main environmental barriers to developing business projects in Tunisia through the study of a representative sample of undeveloped projects. To this end, we used a quantitative approach which allowed us to examine the various barriers encountered by young entrepreneurs during their projects’ implementation. Indeed, by modeling the phenomenon we found that these managers face barriers of legal, financial, educational and government support dimensions.

Keywords: entrepreneurship, environmental barriers, non-implementation of projects, structural modeling

Procedia PDF Downloads 344

Authors: Seyed Ali Mohammadiborna, Mehdi Ravanshadnia

Abstract:

Project delays usually detrimentally affect perceptions of project success and can in some instances, result in increased costs and other time-related damages to project stakeholders. One of the realities in the national infrastructure projects is that since the primary stakeholders are state-affiliated, the delay factors of the projects have not been seriously taken into account despite the importance of on-time completion of projects. Project postponement has different economic and social consequences and leads to the technical and economic infeasibility of the infrastructure projects in the form of reduced productivity and exploitation capacity. The present study aimed at investigating delay factors of Iranian national infrastructure projects according to regulatory reports of the Plan and Budget Organization (BPO) of Iran. The present study scrutinized the influence of each of the factors that caused delays in national Iranian infrastructure projects according to the supervision reports of the planning and budget organization in 8 years. For this purpose, the study analyzed the information regarding the impact of 12 key delay factors causing delays in average 4867 projects per year in all provinces. The said factors were classified into the three groups of executive, credit, and financial and environmental-procurement factors.

Keywords: delays, infrastructure, projects, regulatory

Procedia PDF Downloads 112

Authors: Mengxia Jin, Yongqiang Chen, Wenqian Wang, Yu Wang

Abstract:

The complexity and specificity of construction projects have made common opportunism phenomenon, and contractual governance for opportunism has been a topic of considerable ongoing research. Based on TCE, the research distinguishes control and coordination as different functions of the contract to investigate their complexity separately. And in a nuanced way, the dimensionality of contractual control is examined. Through the analysis of motivation and capability of strong or weak form opportunism, the framework focuses on the relationship between the complexity of above contractual dimensions and different types of opportunistic behavior and attempts to verify the possible explanatory mechanism. The explanatory power of the research model is evaluated in the light of empirical evidence from questionnaires. We collect data from Chinese companies in the construction industry, and the data collection is still in progress. The findings will speak to the debate surrounding the effects of contract complexity on opportunistic behavior. This nuanced research will derive implications for research on the role of contractual mechanisms in dealing with inter-organizational opportunism and offer suggestions for curbing contract parties’ opportunistic behavior in construction projects.

Keywords: contractual complexity, contractual control, contractual coordinatio, opportunistic behavior

Procedia PDF Downloads 357

Authors: Tazeen Fatima

Abstract:

Use of project management in web & software development projects is very significant. It has been observed that even with the application of effective project management, projects usually do not complete their lifecycle and fail. To minimize these failures, key performance indicators have been introduced in previous studies to counter project failures. However, there are always gaps and problems in the KPIs identified. Despite of incessant efforts at technical and managerial levels, projects still fail. There is no substantial approach to identify and avoid these failures in the very beginning of the project lifecycle. In this study, we aim to answer these research problems by analyzing the concept of predictive analytics which is a specialized technology and is very easy to use in this era of computation. Project organizations can use data gathering, compute power, and modern tools to render efficient Predictions. The research aims to identify such a predictive analytics approach. The core objective of the study was to reduce failures and introduce effective implementation of project management principles. Existing predictive analytics methodologies, tools and solution providers were also analyzed. Relevant data was gathered from projects and was analyzed via predictive techniques to make predictions well advance in time to render effective project management in web & software development industry.

Keywords: project management, predictive analytics, predictive analytics methodology, project failures

Procedia PDF Downloads 306

Authors: Mamoon Mousa Atout

Abstract:

The industries of construction are in continuous growth not only in Middle East rejoin but almost all over the world. For the last fifteen years, big expansion and increase of different types of projects has been observed. Many infrastructural projects have been developed, high rise buildings, big shopping malls, power sub-stations, roads, bridges, schools, universities and developing many of new cities with full and complete facilities. The growth and enlargement of the mentioned developed projects has been accomplished through many international and local contracting organizations. Senior management of these organizations depend on their qualified and experienced team whom are aware of the implications of project management, construction management, engineering management and resource management during tendering till final completion of the project. This research aims to find out why reasons of principles of construction engineering and management are necessary for contracting firms and their managers. Principles of construction management help contracting organizations to accomplish and deliver projects without delay. This can be maintained by establishing guidelines’ details for updating the adopted system of construction management that they have through qualified and experienced project managers. The research focuses on benefits of other essential skills of projects planning, monitoring and control. Defining roles and responsibilities of contractor project managers during tendering and execution is a part of the investigated factors that will be analyzed. Other skills like optimizing and utilizing the obtainable project resources to deliver the project within time, cost and quality will be also investigated to find out how these factors are affecting the performance of contracting firms, projects managers and projects. The conclusion of the research will help senior management team and the contractors project managers about the benefits of implications and benefits construction management system and its effect upon the performance and knowledge of contract values that they have, and the optimal profit margin of the firm it.

Keywords: construction management, contracting firms, project managers, planning processes, roles and responsibilities

Procedia PDF Downloads 264

Authors: Amir Reza Talaghat

Abstract:

Since 2015, a new approach and policy regarding energy resources protection and using renewable energies has been started in Iran which was developing new projects. Investigating about the feasibility study of these new projects helped to figure out five steps to prepare an executive feasibility study of the concerned projects, which are proper site selections, authorizations, design and simulation, economic study and programming, respectively. The results were interesting and essential for decision makers and investors to start implementing of these projects in reliable condition. The research is obtained through collection and study of the project's documents as well as recalculation to review conformity of the results with GIS data and the technical information of the bidders. In this paper, it is attempted to describe the result of the performed research by describing the five steps as an executive methodology, for preparing a feasible study of installing a 10 MW – solar farm project. The corresponding results of the research also help decision makers to start similar projects is explained in this paper as follows: selecting the best location for the concerned PV plant, reliable and safe conditions for investment and the required authorizations to start implementing the solar farm project in the concerned region, selecting suitable component to achieve the best possible performance for the plant, economic profit of the investment, proper programming to implement the project on time.

Keywords: solar farm, solar energy, execution of PV power plant PV power plant

Procedia PDF Downloads 140

Authors: Elena Bulmer

Abstract:

The research for this study has found that the formation of alliances for the successful revitalization of the global partnership for sustainable development, as defined by UN Sustainable Development Goal 17, entails considerable difficulty. This study uses for its empirical work marine environmental conservation projects and analyses the potential involvement of nonhuman actors as primordial stakeholders in these types of projects. The idea is to extend the scope of SDG 17 for it to also consider nonhuman subjects in order for it to better achieve its goal. The results of this study may be extrapolated to the business and management fields, which depend on natural resources for the development of their products. In the same way, in these areas, natural resources as nonhuman actors are not present in the stakeholder maps of these projects. Environmental Conservation projects are thus especially interesting to study with regards to their stakeholder context and have been used as the experimental setting for the empirical work of this study. The primordial stakeholders of these projects are not social objects and therefore go beyond the present limits of present stakeholder theory. The study that has been used to analyse this concept is a marine conservation project based in Spain, and to shed light in potential extending the role of the 17th Sustainable Development Goal to include nonhuman beings to be able to better achieve the rest of the SDGs, in this case, SDG 14 whose aim is to promote the conservation and sustainability of the world´s oceans.

Keywords: SDG 17, sustainability, stakeholder management, environmental conservation projects

Procedia PDF Downloads 180

Authors: Flavio Campos, Patricia Masmo, Fernanda Yamamoto

Abstract:

The report presents a research about teaching professional competencies through projects, considering the student as an active learner and curriculum development. Considering project based-learning, the report articulate the result of research about curriculum development for professional competencies and teaching-learning strategies to help the development of professional competencies in learning environments in the courses of National Learning Service in São Paulo, Brazil. There so, intend to demonstrate fundamentals to elaborate curriculum to learning environment, specific about teaching methodologies to enrich student-learning process, using projects. The practice that has been taking place since 2013 indicates the needs of rethinking knowledge and practice in courses that prepared students to labor.

Keywords: curriculum design, active learning, professional competencies, project based-learning

Procedia PDF Downloads 393

Authors: Nima Amani, Ali Salehi Dastjerdi, Fatemeh Ahmadi, Ardalan Sabamehr

Abstract:

The cost overrun of the construction projects has always been one of the main problems of the construction companies caused by the risky nature of the construction projects. Therefore, today, the application of risk management is inevitable. Although in theory, the issue of risk management is divided into the opportunities and threats management, in practice, most of the projects have been focused on the threats management. However, considering the opportunities management and applying the opportunities-response strategies can lead to the improved profitability of the construction projects of the companies. In this paper, a new technique is developed to identify the opportunities in the construction projects using an improved protocol and propose the appropriate opportunities-response strategies to the construction companies to provide them with higher profitability. To evaluate the effectiveness of the protocol for selecting the most appropriate strategies in ‎response to the opportunities and threats, two projects from a construction company in Iran were ‎studied. Both projects selected were in mid-range in terms of size and similar in terms of time, ‎run time and costs. Finally, the output indicates that using the proposed opportunities-response strategies show that the company's profitability in the future can be increased approximately for similar projects.

Keywords: opportunities management, risk-response strategy, opportunity-response strategy, productivity, risk management

Procedia PDF Downloads 200

Authors: Neslihan Karatas, Sibel Ecemis Kilic

Abstract:

This paper aims to examine macro-scale plans and projects/investments which have been prepared for İzmir since The Republican Period. Macro projects that were proposed by central government, local government, industry and urban actors such as the chamber of commerce will be discussed and these projects and its reflections to the city's macro scale planning decisions will be evaluated based on existing development. Effects of macro plans, the related private and public investments, the developments of unplanned/specific projects to the current city form will be discussed. The factors and plans which determine urban form and the problems caused by unanticipated/uncontrolled developments will be evaluated. The proposals will be developed about more efficient planning process.

Keywords: Izmir, macro projects, macro investments, planning

Procedia PDF Downloads 565

Authors: Roland Lachmayer, Mahtab Afsari

Abstract:

Research is the cornerstone for advancement of human communities. So that it is one of the indexes for evaluating advancement of countries. Research projects are usually cost and time-consuming and do not end in result in short term. Project scheduling is one of the integral parts of project management. The present article offers a new method by using C# and Matlab software to solve Fuzzy GERT networks for Exclusive-OR kind of nodes to schedule the network. In this article we concentrate on flowcharts that we used in Matlab to show how we apply Matlab to schedule Exclusive-OR nodes.

Keywords: research projects, fuzzy GERT, fuzzy CPM, CPM, α-cuts, scheduling

Procedia PDF Downloads 364

Authors: Omar Amoudi, Mariya Khalid

Abstract:

The limitation of the public funds for the infrastructure projects and with the deterioration of international oil prices and the negative consequences on the economies of oil producing and exporting countries, Oman has encouraged the partnership between the public and private sectors. As the private sector has a role in planning, financing, designing, operating and the maintenance of the public services. There is no doubt that, the adoption of Public Private Partnership (PPP) strategy faces many challenges which might affect the project seriously if it is not overcome in earlier time. These challenges depend on the level of understanding of the strategy, the roles and regulations and the availability of resources as well. This research aims at identifying the challenges facing the PPP infrastructure projects in Oman based on the similar previous studies supported by questionnaire survey and semi structured interviews. It also seeks to discuss the rationale for adoption in Oman and uncover the current status of PPP strategy. The identified challenges were ranked according to the importance index of each challenge. After analysis of data, it has observed that, the main challenges facing PPPs projects in Oman are high participation cost, high projects cost and regulation changes. The PPP strategy has to be adopted well and with a high level of experience in order to ensure a successful implementation of PPP projects in Oman.

Keywords: public private partnership (PPP), challenges, infrastructure, Oman

Procedia PDF Downloads 266

Authors: Ekaterina Posokhova, Boris Gavrilov

Abstract:

Priority national projects have become an essential phenomenon in the Russian Federation. Both regional and local government institutions and a significant part of the society have been involved in their implementation. The scale and multispectricity of the national projects give a reason to believe that their concept is beyond the scope of the individual state programs. The national project “environment” contains federal projects on waste management, water, and air quality, ecotourism development, and biodiversity conservation highlights the importance of the preservation and restoration of Volga River and Lake Baikal ecosystems. This study assesses the national projects according to their relativeness with the current SDGs (i.e., SGD 14 and 15), evaluates the methodology of the projects. The paper considers the peculiarities of the national projects as strategic management tools as well as the possibility of amending the project objective indicators. Conclusion on the effectiveness of NP in terms of achieving SDGs is provided.

Keywords: management, SDP, russia, conservation, law

Procedia PDF Downloads 115

Authors: Jingya You, Yongqiang Chen, Yuanyuan Hua, Wenqian Wang

Abstract:

Conflict is commonplace in construction projects, and construction projects always involve designing contracts between the owner and the contractor. However, how the contract affects the level of conflict between the owner and the contractor has not been elaborated. The purpose of this paper is to explain the effects of contractual complexity on the level of conflict, including task conflict and relationship conflict, and then to demonstrate the moderating role played by the interdependence between the owner and the contractor. Using data from owners and general contractors in the Chinese construction industry, this research reveals that contractual control will reduce relationship conflict. Contractual coordination will also reduce relationship conflict by the mediating effect of task conflict. Besides, under high joint interdependence, the positive relationship between task conflict and relationship conflict is strengthened, while high interdependence asymmetry has effects on weakening the relationship between task conflict and relationship conflict. The findings provide guidance for contract designers to draft suitable contracts in order to effectively deal with conflict. Additionally, this research implies that project managers should highlight the importance of contract in conflict management.

Keywords: construction projects, contract governance, interdependence, relationship conflict, task conflict

Procedia PDF Downloads 186

Authors: Kenneth O. Otasowie, Matthew Ikuabe, Clinton Aigbavboa, Ayodeji Oke

Abstract:

The practice of feasibility studies plays a huge role in the success of construction projects. Feasibility studies according to several research should be the reason for embarking on any project. However, it has been discovered that in South Africa (SA), feasibility studies are mainly done in the private sector construction but skipped in the construction of most public projects. Hence, this study aims to evaluate the barriers to feasibility studies practice in public projects and the implications. A survey design was adopted. A total number of One hundred and fifty (150) questionnaires were administered to Quantity Surveyors, Construction managers, Construction project managers, Project managers, Architects and Civil and Structural engineers in Guateng Province, SA and ninety (90) were returned and found suitable for analysis. Collected data was analysed using percentage, mean item score, standard deviation, one-sample t-test. The findings show that political interference and corruption are the most significant barriers to feasibility studies practice in the public construction projects in SA, while late project completion, poor quality infrastructure are among the implication of not conducting feasibility studies in SA public projects. Therefore, the study recommends the development of a framework for public projects execution that will reduce the interference of the political class in the country, that way the risk of late project completion and poor quality infrastructure will be mitigated.

Keywords: arriers, feasibility studies, public construction, South Africa.

Procedia PDF Downloads 61

Authors: Julinda Keçi

Abstract:

In many countries, governments have been promoting the involvement of private sector entities to enter into long-term agreements for the development and delivery of large infrastructure projects, with a focus on overcoming the limitations upon public fund of the traditional approach. The involvement of private sector through public-private partnerships (PPP) brings in new capital investments, value for money and additional risks to handle. Worldwide research studies have shown that an objective, systematic, reliable and user-oriented risk assessment process and an optimal allocation mechanism among different stakeholders is crucial to the successful completion. In this framework this paper, which is the first stage of a research study, aims to identify the main risks for the delivery of PPP projects. A review of cross-countries research projects and case studies was performed to map the key risks affecting PPP infrastructure delivery. The matrix of mapping offers a summary of the frequency of factors, clustered in eleven categories: Construction, Design, Economic, Legal, Market, Natural, Operation, Political, Project finance, Project selection and Relationship. Results will highlight the most critical risk factors, and will hopefully assist the project managers in directing the managerial attention in the further stages of risk allocation.

Keywords: construction, infrastructure, public private partnerships, risks

Procedia PDF Downloads 404

Authors: Ghanim A. Bekr

Abstract:

Project success is what must be done for the project to be acceptable to the client, stakeholders and end-users who will be affected by the project. The study of project success and the critical success factors (CSFs) are the means adopted to improve the effectiveness of project. This research is conducted to make an attempt to identify which variables influence the success of project implementation. This study has selected, through an extensive literature review and interviews, (83) factors categorized in (7) groups that the questionnaire respondents were asked to score. The responses from 66 professionals with an average of 15 years of experience in different types of construction projects in Jordan were collected and analyzed using SPSS and most important factors for success for various success criteria are presented depending on the relative importance index to rank the categories. The research revealed the significant groups of factors are: Client related factors, Contractor’s related factors, Project Manager (PM) related factors, and Project management related factors. In addition the top ten sub factors are: Assertion of the client towards short time of the project, availability of skilled labor, Assertion of the client towards high level of the quality, capability of the client in taking risk, previous experience of the PM in similar projects, previous experience of the contractor in similar projects, decision making by the client/ the client’s representative at the right time, assertion of client towards low cost of project, experience in project management in previous projects, and flow of the information among parties. The results would be helpful to construction project professionals in taking proactive measures for successful completion of construction projects in Jordan.

Keywords: construction projects, critical success factors, Jordan, project success

Procedia PDF Downloads 129

Authors: Olubukola Olumuyiwa Tokede, Dominic D. Ahiaga-Dagbui, John Morrison

Abstract:

The project environment in construction has been widely criticised for its inability to learn from experience effectively. As each project is bespoke, learning is ephemeral, as it is often confined within its bounds and seldom assimilated with others that are being delivered in the project environment. To engender learning across construction projects, collaborative contractual arrangements, such as alliancing and partnering, have been embraced to aid the transferability of lessons across projects. These cooperative arrangements, however, tend to be costly, and hence construction organisations could revert to less expensive traditional procurement approaches after successful collaborative project delivery. This research, therefore, seeks to assess the lessons-learned in a post-alliance contractual framework. Using a case-study approach, we examine the experiences of a public sector authority who engaged a project facilitator to foster learning during the delivery of a significant piece of critical infrastructure. It was found that the facilitator enabled optimal learning outcomes in post-alliance contractual frameworks by attenuating the otherwise adversarial relationship between clients and contractors. Further research will seek to assess the effectiveness of different knowledge-brokering agencies in construction projects.

Keywords: facilitation, knowledge-brokering, learning, projects

Procedia PDF Downloads 110