Search results for: project finance

Authors: Hassan Abdelgadir

Abstract:

Cost overruns have harmed the economies and reputations of several construction companies around the world. Many project management systems have been developed to keep track of a project's budget. However, due to several cost overrun difficulties in the construction industry, cost management is still deemed inadequate. As a result, the goal of this term paper is to identify and group prospective construction project cost overrun reasons based on their origin groups.Basically, all potential cost overrun elements were rigorously checked through 1iterature analysis before being divided into seven (7) groups of originating components, including project, contract, client, contractor, consultant, labor, and external. Each potential factor was completely defined with examples.

Keywords: construction projects, cost overruns, construction company, factors effect costoverruns

Procedia PDF Downloads 39

Authors: Masoud Ghahvechi Pour

Abstract:

Risk management is a systematic and regular process of identifying, analyzing and responding to risks throughout the project's life cycle in order to achieve the optimal level of elimination, reduction or control of risk. The purpose of project risk management is to increase the probability and effect of positive events and reduce the probability and effect of unpleasant events on the project. Risk management is one of the most fundamental parts of project management, so that unmanaged or untransmitted risks can be one of the primary factors of failure in a project. Effective risk management does not apply to risk regression, which is apparently the cheapest option of the activity. However, the main problem with this option is the economic sensitivity, because what is potentially profitable is by definition risky, and what does not pose a risk is economically interesting and does not bring tangible benefits. Therefore, in relation to the implemented project, effective risk management is finding a "middle ground" in its management, which includes, on the one hand, protection against risk from a negative direction by means of accurate identification and classification of risk, which leads to analysis And it becomes a comprehensive analysis. On the other hand, management using all mathematical and analytical tools should be based on checking the maximum benefits of these decisions. Detailed analysis, taking into account all aspects of the company, including stakeholder analysis, will allow us to add what will become tangible benefits for our project in the future to effective risk management. Identifying the risk of the project is based on the theory that which type of risk may affect the project, and also refers to specific parameters and estimating the probability of their occurrence in the project. These conditions can be divided into three groups: certainty, uncertainty, and risk, which in turn support three types of investment: risk preference, risk neutrality, specific risk deviation, and its measurement. The result of risk identification and project analysis is a list of events that indicate the cause and probability of an event, and a final assessment of its impact on the environment.

Keywords: risk, management, knowledge, risk management

Procedia PDF Downloads 29

Authors: Jagoda Bruni, Jan Müller-Lucanus, Gernot Stöger-Knes

Abstract:

The purpose of this article is to demonstrate modern project management approaches in the SAP S/R Hana surrounding a programming environment composed of multiple focus-diversified projects. We would like to propose innovative and goal-oriented management standards based on the specificity of the SAP transformations and customer-driven expectations. Due to the regular sprint-based controlling and management tools' application, it has been data-proven that extensive analysis of productive hours of the employees as much as a thorough review of the project progress (per GAP, per business process, and per Lot) within the whole program, can have a positive impact on customer satisfaction and improvement for projects' budget. This has been a collaborative study based on real-life experience and measurements in collaboration with our customers.

Keywords: project management, program management, SAP, controlling

Procedia PDF Downloads 52

Authors: Woosik Jang, Seung H. Han

Abstract:

The optimal partner selection is one of the most important factors to pursue the project’s success. However, in practice, there is a gaps in perception of success depending on the role of the enterprises for the projects. This frequently makes a relations between the partner evaluation results and the project’s final performances, insufficiently. To meet this challenges, this study proposes a strategic partner evaluation model considering the perception gaps between enterprises. A total 3 times of survey was performed; factor selection, perception gap analysis, and case application. After then total 8 factors are extracted from independent sample t-test and Borich model to set-up the evaluation model. Finally, through the case applications, only 16 enterprises are re-evaluated to “Good” grade among the 22 “Good” grade from existing model. On the contrary, 12 enterprises are re-evaluated to “Good” grade among the 19 “Bad” grade from existing model. Consequently, the perception gaps based evaluation model is expected to improve the decision making quality and also enhance the probability of project’s success.

Keywords: partner evaluation model, project based enterprise, decision making, perception gap, project performance

Procedia PDF Downloads 127

Authors: Benjaporn Yaemjamuang

Abstract:

The purposes of this study were to investigate the success of project-based learning and to evaluate the performance and level of satisfaction of tourism students who participated in the study. This paper drew upon a data collection from a senior tourism students survey conducted in Rajamangala University during summer 2013. The purposive sampling was utilized to obtain the sample which included 45 tourism students. The pretest and posttest method was utilized. The findings revealed that the majority of respondents had gained higher knowledge after the posttest significantly. The respondents’ knowledge increased about 53.33 percent from pretest to posttest. Also, the findings revealed the top three highest level of satisfaction as follows: 1) the role of teacher and students, 2) the research activities of the project-based learning, 3) the learning methods of the project-based learning. Moreover, the mean score of all categories was 3.98 with a standard deviation of 0.88 which indicated that the average level of satisfaction was high.

Keywords: performance, project-based learning, satisfaction, tourism

Procedia PDF Downloads 265

Authors: Pradeep Singh, Shrish Verma

Abstract:

Software fault prediction models are created by using the source code, processed metrics from the same or previous version of code and related fault data. Some company do not store and keep track of all artifacts which are required for software fault prediction. To construct fault prediction model for such company, the training data from the other projects can be one potential solution. The earlier we predict the fault the less cost it requires to correct. The training data consists of metrics data and related fault data at function/module level. This paper investigates fault predictions at early stage using the cross-project data focusing on the design metrics. In this study, empirical analysis is carried out to validate design metrics for cross project fault prediction. The machine learning techniques used for evaluation is Naïve Bayes. The design phase metrics of other projects can be used as initial guideline for the projects where no previous fault data is available. We analyze seven data sets from NASA Metrics Data Program which offer design as well as code metrics. Overall, the results of cross project is comparable to the within company data learning.

Keywords: software metrics, fault prediction, cross project, within project.

Procedia PDF Downloads 310

Authors: Kunto Nurcahyoko

Abstract:

The fundamental perception used in this study is that teaching and learning activities in Indonesian classroom have potentially generated individual’s sensitivity on cross-cultural understanding. This study aims at investigating Indonesian university students’ perception on cross-cultural understanding after doing Cultural Snapshot Project. The data was critically analyzed through multicultural ideology and diversity theories. The subjects were 30 EFL college students in one of colleges in Indonesia. Each student was assigned to capture a photo which depicted the existence of any cultural manifestation in their surrounding such as discrimination, prejudice and stereotype. Students were then requested asked to reflect on the picture by writing a short description on the picture and make an exhibition using their pictures. In the end of the project, students were instructed to fill in questionnaires to show their perception before and after the project. The result reveals that Cultural Snapshot Project has given the opportunity for the students to better realize cross-cultural understanding in their environment. In conclusion, the study shows that Cultural Snapshot Project has specifically enhanced students’ perception of multiculturalism in three major areas: cultural sensitivity and empathy, social tolerance, and understanding of diversity.

Keywords: cultural snapshot, cross-cultural understanding, students’ perception, multiculturalism

Procedia PDF Downloads 285

Authors: Nnadi Ezekiel Ejiofor

Abstract:

In Enugu, Nigeria, this study investigates the connection between strategic leadership and project management sustainability, with an emphasis on building projects in the State. The study set out to accomplish two specific goals: first, it sought to establish a link between creative project management and resource efficiency in construction projects in Enugu State, Nigeria; and second, it sought to establish a link between innovative thinking and waste minimization in those same projects. A structured questionnaire was used to collect primary data from 45 registered construction enterprises in the study area as part of the study's descriptive research approach. Due to the nonparametric nature of the data, Spearman Rank Order Correlation was used to evaluate the acquired data. The findings demonstrate that creative project management had a significant positive impact on resource efficiency in construction projects carried out by architecture firms in Enugu State, Nigeria (r =.849; p.001), and that innovative thinking had a significant impact on waste reduction in those same projects (r =.849; p.001). It was determined that strategic leadership had a significant impact on the sustainability of project management, and it was thus advised that project managers should foresee, prepare for, and effectively communicate present and future developments to project staff in order to ensure that the objective of sustainable initiatives, such as recycling and reuse, is implemented in construction projects.

Keywords: construction, project management, strategic leadership, sustainability, waste reduction

Procedia PDF Downloads 24

Authors: Kasra HosseinMostofi, Mohamadamin Oyar Hossein, Reza Mehdizadeh Anvigh

Abstract:

BIM is an innovative concept for the majority of firms operating in industry. BIM offers a new paradigm to design, construct, operate, and maintain a facility. However, even with the most conscientious use, stakeholders can run into trouble during its implementation on a project or within an organization. At times, project stakeholders are unaware of the challenges that they can face with the implementation at the project level or an organizational level. Therefore, the study aimed to identify and compile barriers associated with the BIM implementation at the project and organizational level, as per the literature. Despite the fact that innumerable advantageous involved in exploiting BIM, there are some barriers to implement it properly. These barriers have been proved as impediments for academicians and members of construction team project to take the maximum advantage of its utilization. Although some research has been conducted to identify these barriers regarding BIM implementation in construction industry, more research is needed to be carried out among academicians to identify these barriers in institutions, and most importantly, to make suggestions for eliminating these obstacles.

Keywords: building information modelling, construction, design and construction, designers

Procedia PDF Downloads 148

Authors: R. W. A. V. A. Wijenayake, P. M. R. N. Fernando, S. Nilesh, M. D. G. M. S. Diddeniya, M. Weligodapola, P. Shamila

Abstract:

The study is designed to examine the impact of a lifelong learning mindset on the career success of accounting and finance professionals in the western province of Sri Lanka. The learning mindset impacts the career success of accounting and finance professionals. The main objective of this study is to identify how the lifelong-learning mindset impacts on the career success of accounting and finance professionals. The lifelong learning mindset is the desire to learn new things and curiosity, resilience, and strategic thinking are the selected constructs to measure the lifelong learning mindset. Career success refers to certain objectives and emotional measures of improvement in one’s work life. The related variables of career success are measured through the number of promotions that have been granted in his/her work life. Positivism is the research paradigm, and the deductive approach is involved as this study relies on testing an existing theory. To conduct the study, the accounting and finance professionals in the western province in Sri Lanka were selected because most reputed international and local companies and specifically, headquarters of most of the companies are in western province. The responses cannot be collected from the whole population. Therefore, this study used a simple random sampling method, and the sample size was 120. Therefore, to identify the impact, 5-point Likert scale is used to perform this quantitative data. Required data gathered through an online questionnaire and the final outputs of the study will offer certain important recommendations to several parties such as universities, undergraduates, companies, and the policymakers to improve, help mentally and financially and motivate the students and the employees to continue their studies without ceasing after completion of their degree.

Keywords: career success, curiosity, lifelong learning mindset, resilience, strategic thinking

Procedia PDF Downloads 60

Authors: Adam Marks, Munir Majdalawieh, Maytha Al Ali

Abstract:

While research is rich with what criteria could be included in the academic program review processes, there is rarely any mention of how this significant and complex process should be managed. This paper proposes using project management methodology in alignment with the program review criteria of the Dickeson’s Prioritizing Academic Programs model. Project management and academic program review share two distinct characteristics; one is their life cycle, and the second is the core knowledge areas they use. This aligned and structured approach offers academic administrators a step-by-step guide that can help them manage this process and effectively assess academic programs.

Keywords: project management, academic program, program review, education, higher education institution, strategic management

Procedia PDF Downloads 340

Authors: Melvin Mothoa

Abstract:

Small Micro and Medium Enterprises are very significant for the development of their market economies. They are the main creators of the new working places, and they present a vital core of the market economy in countries across the globe. Access to finance is identified as crucial for small, micro, and medium-sized enterprises for their growth and innovation. This paper is conceived to propose a perception-based SMME framework to aid in access to financial support. Furthermore, the study will address issues that impede SMMEs in South Africa from obtaining finance from financial institutions. The framework will be tested against data collected from 200 Small Micro & Medium Enterprises in the Gauteng province of South Africa. The study adopts a quantitative method, and the delivery of self-administered questionnaires to SMMEs will be the primary data collection tool. Structural equation modeling will be used to further analyse the data collected.

Keywords: finance, small business, growth, development

Procedia PDF Downloads 70

Authors: Jingyu Hou

Abstract:

This paper proposes a new teaching and learning approach-project and Module Based Teaching and Learning (PMBTL). The PMBTL approach incorporates the merits of project/problem based and module based learning methods, and overcomes the limitations of these methods. The correlation between teaching, learning, practice, and assessment is emphasized in this approach, and new methods have been proposed accordingly. The distinct features of these new methods differentiate the PMBTL approach from conventional teaching approaches. Evaluation of this approach on practical teaching and learning activities demonstrates the effectiveness and stability of the approach in improving the performance and quality of teaching and learning. The approach proposed in this paper is also intuitive to the design of other teaching units.

Keywords: computer science education, project and module based, software engineering, module based teaching and learning

Procedia PDF Downloads 461

Authors: Ouafa Sakka, Henri Barki, Louise Cote

Abstract:

Uncertainty and equivocality are defined in the information processing literature as two task characteristics that require different information processing responses from managers. As uncertainty often stems from a lack of information, addressing it is thought to require the collection of additional data. On the other hand, as equivocality stems from ambiguity and a lack of understanding of the task at hand, addressing it is thought to require rich communication between those involved. Past research has provided weak to moderate empirical support to these hypotheses. The present study contributes to this literature by defining uncertainty and equivocality at the project level and investigating their moderating effects on the association between several project information processing constructs and project performance. The information processing constructs considered are the amount of information collected by the project team, and the richness and frequency of formal communications among the team members to discuss the project’s follow-up reports. Data on 93 information system development (ISD) project managers was collected in a questionnaire survey and analyzed it via the Fisher Test for correlation differences. The results indicate that the highest project performance levels were observed in projects characterized by high uncertainty and low equivocality in which project managers were provided with detailed and updated information on project costs and schedules. In addition, our findings show that information about user needs and technical aspects of the project is less useful to managing projects where uncertainty and equivocality are high. Further, while the strongest positive effect of interactive use of follow-up reports on performance occurred in projects where both uncertainty and equivocality levels were high, its weakest effect occurred when both of these were low.

Keywords: uncertainty, equivocality, information processing model, management control systems, project control, interactive use, diagnostic use, information system development

Procedia PDF Downloads 262

Authors: Abdullah Mohammed Alshehri

Abstract:

The projects in the construction industry have significantly increased, given its contribution to the overall Gross Domestic Product (GDP) of the countries. Reflecting upon the complex nature and involvement of various agents, the study aims to analyze the conflicts cause within construction projects. Therefore, the study strived to come out with understanding the levels of conflict interaction across project phases. However, this conducted by investigating the association between antecedents and apparent conflicts inherent in. The study used a qualitative approach for collecting the data through a quantitative, semi-structured method. Formation of a questionnaire survey has been conducted for over 30 respondents. However, the survey came out with the identification of 25 conflict cause categories, which can take place in different construction project phases, including pre-design phase, pre-construction phase, construction phase, commissioning, and completion phase. For example, conflicts associated with inconsistencies or discrepancies within or between project documents, which took place at tendering time in the pre-construction phase were relatable with the selection of material specifications that should be supplied or used in the construction projects at the construction phase. Its analysis can provide comprehensive understanding, trace the root of the problem, which offers a roadmap to deepen the understanding of the conflict conditions and ‘course of action’ necessary for project management strategy actions toward avoiding or minimizing conflict causes at project life.

Keywords: construction, conflict causes, levels, interaction, phases

Procedia PDF Downloads 148

Authors: Mohd Iqbal Malik

Abstract:

Ethical philosophy of Quran pinnacled virtue and economics as the part and parcel of human life. Human beings are to be imagined by the sign of morals. Soul and morality are both among the essences of human personality. Islam lays the foundation of ethics by installation of making a momentous variance between virtue and vice. It suggests for the distribution of wealth in-order to terminate accumulation of economic resources. Quran claims for the ambiguous pavement to attain virtue by saying, ‘Never will you attain the good (reward) until you spend (in the way of Allah) from that which you love. And whatever you spend indeed, Allah knows of it.’ The essence of Quran is to eliminate all the deep-seated approaches through which the wealth of nations is being accumulated within few hands. The paper will study the Quranic Philosophy Of Islamic Economic System. In recent times, to get out of the human resource development mystery of Muslims, Ismail Al-Raji Faruqi led the way in the so-called ‘Islamization’ of knowledge. Rahman and Faruqi formed opposite opinions on this project. Al-Faruqi thought of the Islamization of knowledge in terms of introducing Western learning into received Islamic values and vice versa. This proved to be a mere peripheral treatment of Islamic values in relation to Western knowledge. It is true that out of the programme of Islamization of knowledge arose Islamic universities in many Muslim countries. Yet the academic programmes of these universities were not founded upon a substantive understanding and application of the tawhidi epistemology.

Keywords: ethical philosophy, modern Islamic finance, knowledge of finance, Islamic banking

Procedia PDF Downloads 278

Authors: Akhmad F. K. Khitam, Yi Tai, Hsin-Yun Lee

Abstract:

In the modern research of construction management, the goals of scheduling are not only to finish the project within the limited duration, but also to improve the impact of people and environment. Especially for the impact to the pedestrian and vehicles, the considerable social cost should be estimated in the total performance of a construction project. However, the site environment has many differences between projects. These interactions affect the requirement and goal of scheduling. It is difficult for schedule planners to quantify these interactions. Therefore, this study use 3D dynamic simulation technology to plan the schedule of the construction engineering projects that affect the current space users (i.e., the pedestrians and vehicles). The proposed model can help the project manager find out the optimal schedule to minimize the inconvenience brought to the space users. Besides, a roadwork project and a building renovation project were analyzed for the practical situation of engineering and operations. Then this study integrates the proper optimization algorithms and computer technology to establish a decision support model. The proposed model can generate a near-optimal schedule solution for project planners.

Keywords: scheduling, simulation, optimization, pedestrian and vehicle behavior

Procedia PDF Downloads 108

Authors: Woosik Jang, Seung Heon Han, Seung Won Baek

Abstract:

Natural gas (NG) is an energy resource in a few countries, and most NG producers do business in politically unstable countries. In addition, as 90% of the LNG market is controlled by a small number of international oil companies (IOCs) and national oil companies (NOCs), entry of latecomers into the market is extremely limited. To meet these challenges, project viability needs to be assessed based on limited information from a project screening perspective. However, the early stages of the project have the following difficulties: (1) What are the factors to consider? (2) How many professionals do you need to decide? (3) How to make the best decision with limited information? To address this problem, this study proposes a model for evaluating LNG project viability based on the Dempster-Shafer theory (DST). A total of 11 indicators for analyzing the gas field, reflecting the characteristics of the LNG industry, and 23 indicators for analyzing the market environment, were identified. The proposed model also evaluates the LNG project based on the survey and provides uncertainty of the results based on DST as well as quantified results. Thus, the proposed model is expected to be able to support the decision-making process of the gas field project using quantitative results as a systematic framework, and it was developed as a stand-alone system to improve its usefulness in practice. Consequently, the amount of information and the mathematical approach are expected to improve the quality and opportunity of decision making for LNG projects for enterprises.

Keywords: project screen, energy enterprise, decision support system, Dempster-Shafer theory

Procedia PDF Downloads 310

Authors: Reza Heidari, Maryam Amiri

Abstract:

In a technological world, many countries have a tendency to fortifying their companies and technological infrastructures. Also, one of the most important requirements for developing technology is innovation, and then, all companies are struggling to consider innovation as a basic principle. Since, the expansion of a product need to combine different technologies, therefore, different innovative projects would be run in the firms as a base of technology development. In such an environment, enterprise resource planning (ERP) has special significance in order to develop and strengthen of innovations. In this article, an economic-probabilistic analysis was provided to perform an implementation project of ERP in the technological innovation (TI) based firms. The used model in this article assesses simultaneously both risk and economic analysis in view of the probability of each event that is jointly between economical approach and risk investigation approach. To provide an economic-probabilistic analysis of risk of the project, activities and milestones in the cash flow were extracted. Also, probability of occurrence of each of them was assessed. Since, Resources planning in an innovative firm is the object of this project. Therefore, we extracted various risks that are in relation with innovative project and then they were evaluated in the form of cash flow. This model, by considering risks affecting the project and the probability of each of them and assign them to the project's cash flow categories, presents an adjusted cash flow based on Net Present Value (NPV) and with probabilistic simulation approach. Indeed, this model presented economic analysis of the project based on risks-adjusted. Then, it measures NPV of the project, by concerning that these risks which have the most effect on technological innovation projects, and in the following measures probability associated with the NPV for each category. As a result of application of presented model in the information and communication technology (ICT) industry, provided an appropriate analysis of feasibility of the project from the point of view of cash flow based on risk impact on the project. Obtained results can be given to decision makers until they can practically have a systematically analysis of the possibility of the project with an economic approach and as moderated.

Keywords: cash flow categorization, economic evaluation, probabilistic, risk assessment, technological innovation

Procedia PDF Downloads 382

Authors: Aurora Cerri, Niko Pollojani

Abstract:

The Tirana – Elbasan Road project is the most important highway project in Albania, constructed in the period May 2011 - ongoing. This project included construction of 38 km highway category road including 2.6 km of tunnel. It serves as a corridor connecting the Tirana, Capital of Albania and South-East area, and in the near future it is expected to continue in the direction of Macedonian border. Environmental Impact Assesment procedure for this project is provided by the Albanian Environmental Law No. 10431. This law establishes the regulation of procedures for identifying, assessment and reporting on the effects of certain projects on the environment, and the associated administrative procedures, during the decision-making process by the Ministry of Environment and Tourism for issuing environmental permit, and ensures that all relevant information concerning the environment are provided and considered. Due to the nature and size of the project, during the environmental impact assessment process, the European Union legislation, namely the EIA Directive 85/337 / EEC is considered. Moreover, in some cases, due to the lack of national standards and practical guidelines, when necessary those of EU member countries are considered. This paper presents an analysis of the EIA procedure followed on ‘Tirana – Elbasan’ Road project, with a focus on the application of the main stages of the procedure such as: screening, scoping, review, the EIA report; and consideration of alternatives, measures for impact prevention and reduction, and the public hearing T/discussion.

Keywords: highway, environmental impact assesment, Tirana, prevention

Procedia PDF Downloads 287

Authors: Nyong Princely Awazi, Gadinga Walter Forje, Barnabas Neba Nfornkah, Ndzifon Jude Kimengsi

Abstract:

Ecotourism is documented as a sustainable measure of bridging conservation goals and livelihood sustenance around protected areas, due to its ability of not just providing alternative livelihood, but also in providing the necessary resources that can help finance conservation initiatives. In Cameroon, all ecotourism activities around national parks are aimed at generating revenue through the conservation service while providing sustainable livelihood options to the local population. There exists an information lacuna regarding the contribution of ecotourism finances to conservation efforts in the country. This study was aimed at establishing the contribution of ecotourism finances to conservation initiatives in and around the Campo Ma’an National Park (CMNP). Data were collected through the administering of 120 structured questionnaires to ecotourism actors and 15 key/expert interviews with tourism and conservation actors in the Campo Ma’an landscape. Chi-square test, Spearman’s rank correlation and regressions were used for data analysis. The study revealed that the main sources of ecotourism financing to the park service are through entrance fees, cameras and vehicle fees paid by tourists as well as ecotourism project financing through NGOs. Calculations from the tourism register of the park showed that the park was able to raise as much as 1,576,000 FCFA (US$ 3,152) annually. It was further established that ecotourism revenue has not greatly supported conservation, with 54% of respondents perceiving ecotourism not contributing to biodiversity conservation. Chi Square test results highlighted poor ecotourism governance, low level of ecotourism development, corruption from park management staff, obsolete nature of the current finance law on the management of protected area revenue as key factors hindering ecotourism financing in conservation. For ecotourism financing to contribute to biodiversity conservation in the CMNP and in Cameroon’s protected areas, the government needs to revise the finance law on the management of revenue generated from protected areas, improve park governance to fight corruption and enhance transparency, invest in the development and marketing of the Campo Ma’an national park as a tourism destination in the country.

Keywords: Cameroon, Campo Ma’an National Park, conservation, ecotourism, ecotourism financing

Procedia PDF Downloads 84

Authors: Ho Wen Hui, Azwina Wati Abdull Manaf, Asfarina Kartika Mohd Shakri

Abstract:

The global trend of Fintech had taken the Malaysian shore by storm in recent years, thus making the studies and observations of its impacts more critical than ever. Additionally, Fintech has grown to become an unavoidable subject in the Islamic Banking and Finance (IBF) industry. In relation to that, this paper seeks to analyze the development of Fintech parallel with the IBF industry and its connection to Islamic economics. While the scarcity of studies on this area is apparent, it is found that there is a need to regulate the development of the Fintech Industry and its effects while analyzing the ramifications and positive effects of Fintech towards parties involved in IBF industry. This paper objectively studies the phenomenon of Islamic Fintech around the world as a whole as well as more specifically in Malaysia. The paper will then explore on the existing regulatory instruments in Malaysia, study their boundaries as well as limitations and contribute on possible reform to regulate Islamic Fintech in this jurisdiction. It is aimed that this paper will prompt and encourage more thorough studies to be conducted on the topic of Fintech which would subsequently contribute to a positive growth of the IBF industry worldwide.

Keywords: financial technology, FinTech, Islamic banking & finance, regulation

Procedia PDF Downloads 197

Authors: Vita Kalnberzina, Lauren Miller Anderson

Abstract:

The aim of the paper is to report on the results of the telecollaboration project results carried out between the students of the University of Latvia, National Louis University in the US, and Austral University in Chili during the Intercultural Communication course. The objectives of the study are 1) to compare different forms of student telecollaboration and virtual exchange, 2) to collect and analyse the student feedback on the telecollaboration project, 3) to evaluate the products (films) produced during the telecollaboration project. The methods of research used are as follows: Survey of the student feedback after the project, video text analysis of the films produced by the students, and interview of the students participating in the project. We would like to compare the results of a three-year collaboration project, where we tried out synchronous telecollaboration and asynchronous collaboration. The different variables that were observed were the impact of the different time zones, different language proficiency levels of students, and different curricula developed for collaboration. The main findings suggest that the effort spent by students to organize meetings in different time zones and to get to know each other diminishes the quality of the product developed and thus reduces the students' feeling of accomplishment. Therefore, we would like to propose that asynchronous collaboration where the national teams work on a film project specifically developed by the students of one university for the students of another university ends up with a better quality film, which in its turn appeals more to the students of the other university and creates a deeper intercultural bond between the collaborating students.

Keywords: telecollaboration, intercultural communication, synchronous collaboration, asynchronous collaboration

Procedia PDF Downloads 68

Authors: Kian Jon Chua, Islam Md Raisul

Abstract:

Findings on a research study conducted for a group of year-2 engineering students participating in a flipped classroom (FC) experience that is judiciously incorporated into project-based learning (PBL) module are presented. The chief purpose of the research is to identify whether if the incorporation of flipped classroom approach to project-based learning indeed yields a positive learning experience for engineering students. Results are presented and compared from the two classes of students – one is subjected to a traditional PBL learning mode while the other undergoes a hybrid PBL-FC learning format. Some themes related to active learning, problem-solving ability, teacher as facilitator, and degree of self-efficacy are also discussed. This paper hopes to provide new knowledge and insights relating to the introduction of flipped classroom learning to a project-based engineering module. Some potential study limitations and future directions to address them are also presented.

Keywords: hybrid project-based learning, flipped classroom, problem-solving, active learning

Procedia PDF Downloads 112

Authors: Shehu Usman Rano Aliyu

Abstract:

Despite the significance of finance as a major trade lubricant, evidence in the literature alludes to its scarcity and increasing cost, especially in developing countries where small and medium-scale enterprises are worst affected. The creation of the African Continental Free Trade Area (AFCFTA) in 2018, an organ of the African Union (AU), was meant to serve as a beacon for deepening economic integration through the removal of trade barriers inhibiting intra-African trade and movement of persons, among others. Hence, this research explores the role Islamic trade finance (ITF) could play in spurring intra- and inter-African trade. The study involves six countries; Egypt, Kenya, Malaysia, Morocco, Nigeria, and Saudi Arabia, and employs survey research, a total of 430 sample data, and SmartPLS Structural Equation Modelling (SEM) techniques in its analyses. We find strong evidence that Shari’ah, legal and regulatory compliance issues of the ITF institutions rhythm with the internal, national, and international compliance requirements equally as the unique instruments applied in ITF. In addition, ITF was found to be largely driven by global economic and political stability, socially responsible finance, ethical and moral considerations, risk-sharing, and resilience of the global Islamic finance industry. Further, SMEs, Governments, and Importers are the major beneficiary sectors. By and large, AfCFTA’s protocols align with the principles of ITF and are therefore suited for the proliferation of Islamic finance in the continent. And, while AML/KYC and BASEL requirements, compliance to AAOIFI and IFSB standards, paucity of Shari'ah experts, threats to global security, and increasing global economic uncertainty pose as major impediments, the future of ITF would be shaped by a greater need for institutional and policy support, global economic cum political stability, robust regulatory framework, and digital technology/fintech. The study calls for the licensing of more ITF institutions in the continent, participation of multilateral institutions in ITF, and harmonization of Shariah standards.

Keywords: AfCFTA, islamic trade finance, murabaha, letter of credit, forwarding

Procedia PDF Downloads 28

Authors: Eny Suastuti

Abstract:

This paper is about state’s capital equity in establishing State-owned Company (PT Merpati Persero). Under private law regime, PT Merpati Persero equity is a state asset allocated separately from the State Budget. Consequently, it is no longer a state asset; rather, it becomes a part of company assets. The adoption of Act No. 17 of 2003 on State Finance, Act No. 31 of 1999, which is amended by Act No. 20 of 2001 on Eradication of Corrupt Practices, Act No. 15 of 2004 on Auditing, Management, and Accountability of State Finance, and Act No. 15 of 2006 Audit Board raises legal issues of whether State-owned Company’s (PT Merpati Persero) loss may be deemed as loss on state finance made by the Directors of PT Merpati Persero, which implication leads to corrupt practices conducted by the Directors. The principle of civil law states that state assets are separated from the state budget is not a government asset. Therefore the case of a lease agreement 2 (two) units of Boeing 737-400 and Boeing 737-500 between PT Merpati Nusantara Airlines with companies Third Stone Aircraft Leasing Group (TALG) the United States cannot be prosecuted under Articles 2 and 3 of Act No. 31 of 1999 Jo Act No. 20 of 2001 on Eradication of Corrupt Practices (Law PTPK). From this paper, three things are found. First, state’s capital equity, which has been allocated separately from state assets in establishing the PT Merpati Perserois not state asset; rather, it is company’s asset. Second, in the case of mismanagement leading to company loss, the Directors of PT Merpati Persero may not be charged with committing corrupt practice as prescribed in Articles 2 and 3 of Corrupt Practices Eradication Law. Third, misperception has been made by judicial practices since the courts consider loss in certain transaction made by Directors of PT Merpati Persero to be loss of state finance whose implication is applicability of Articles 2 and 3 of Corrupt Practices Eradication Law.

Keywords: corrupt practice, loss, state's capital equity, state finance (PT Merpati Persero)

Procedia PDF Downloads 236

Authors: Y. Gholipour, E. Rezazadeh

Abstract:

Delay is one of the most serious and common problems of construction project that can affect project delivery unfavorably. This research presents the most important causes of delay in large dam projects based on a survey on some executed dam construction in Iran. In this survey a randomly selected samples of owners, consultants and contractors have been involved. The outcome of this survey revealed that scheduled payments, site management, shop drawing review process, unforeseen ground conditions and contractor experience as the most important factors affecting on delay in dam construction projects.

Keywords: delay, dam construction, project management, Iran

Procedia PDF Downloads 414

Authors: Ali Fazeli Moslehabadi

Abstract:

One of the topics discussed in civil projects, during the execution of the project, which the continuous change of work volumes is usually the characteristics of these types of projects, is how to calculate the volume of done work. The difference in volumes announced by the execution unit with the estimated volume by the technical office unit, has direct effect on the announced progress of the project. This issue can show the progress of the project more or less than actual value and as a result making mistakes for stakeholders and project managers and misleading them. This article intends to introduce some practical methods for calculating the volume of done work in civil projects. It then reviews the strengths and weaknesses of each of them, in order to resolve these contradictions and conflicts.

Keywords: technical skills, systemic skills, communication skills, done work volume calculation techniques

Procedia PDF Downloads 132

Authors: Y. Rathiranee, D. M. Semasinghe

Abstract:

This study attempts to identify the factors influencing on women empowerment of rural area in Sri Lanka through micro finance services. Data were collected from one hundred (100) rural women involving self employment activities through a questionnaire using direct personal interviews. Judgment and Convenience Random sampling technique was used to select the sample size from three Divisional Secretariat divisions of Kandawalai, Poonakari and Karachchi in Kilinochchi District. The factor analysis was performed on fourteen (14) variables for screening and reducing the variables to identify the influencing factors on empowerment. Multiple regression analysis was used to identify the relationship between the three empowerment factors and the impact of micro-finance on overall empowerment of rural women. The result of this study summarized the variables into three factors namely decision making, freedom to mobility and family support and which are positively associated with empowerment. In addition to this the value of adjusted R2 is 0.248 indicates that all the variables extracted can be explained 24.8% of the variation in the women empowerment through microfinance. Independent variables of these three factors have a positive correlation with women empowerment as well as significant values at 5 percent level.

Keywords: influencing factors, micro finance, rural women, women empowerment

Procedia PDF Downloads 432

Authors: Deepa Vijay, Chellammal Surianarayanan, Gopinath Ganapathy

Abstract:

Requirements of a software project serve as a guideline for the entire project team which enable the team towards producing the right outcome. As requirements are the key in deciding the success of the project, it should be specified in an unambiguous manner. Also, the requirements should be complete and consistent. It should be interpreted in the same way by the entire software project team as the customer interprets. Specifying requirements in textual manner is common in software development. This leads to poor understanding of the requirements which results in more errors and degraded quality. There are some literatures which focus on semantic way of specifying functional requirement which ensure the consistency and completeness of requirements. Alternately in the work, a method is proposed to map the syntactic requirements with corresponding semantics in the form of ontologies. This improves the understanding of requirements, prevents errors and improves quality.

Keywords: functional requirement, ontology, requirements management, semantics

Procedia PDF Downloads 338