Search results for: Construction clients

Authors: Jong Hoon Kim, Hyun-Soo Lee, Moonseo Park, Min Jeong, Inbeom Lee

Abstract:

Pre-construction is essential in achieving the success of a construction project. Due to the early involvement of project participants in the construction phase, project managers are able to plan ahead and solve issues well in advance leading to the success of the project and the satisfaction of the client. This research utilizes quantitative data derived from construction management projects in order to identify the relationship between pre-construction, construction schedule, and client satisfaction. A total of 65 construction projects and 93 clients were investigated for this research in an attempt to identify (a) the relationship between pre-construction and schedule reduction, and (b) pre-construction and client loyalty. Based on the quantitative analysis, this research was able to establish a negative correlation based on 65 construction projects between pre-construction and project schedule existed. This finding represents that the more pre-construction is performed for a certain project, the overall construction schedule decreased. Then, to determine the relationship between pre-construction and client satisfaction, Net Promoter Score (NPS) of 93 clients from the 65 projects was utilized. Pre-construction and NPS was further analyzed and a positive correlation was found between the two. This infers that clients tend to be more satisfied with projects with higher ratio of pre-construction than those projects with less pre-construction.

Keywords: Client loyalty, NPS, pre-construction, schedule reduction.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 3158

Authors: Saif Ul Haq

Abstract:

The current study intends to examine the safety and quality considerations of clients of housing projects and their impact on the adoption of Quality Function Deployment (QFD) by the construction firm. Mixed method research technique has been used to collect and analyze the data wherein a survey was conducted to collect the data from 220 clients of housing projects in Saudi Arabia. Then, the telephonic and Skype interviews were conducted to collect data of 15 professionals working in the top ten real estate companies of Saudi Arabia. Data were analyzed by using partial least square (PLS) and thematic analysis techniques. Findings reveal that today’s customer prioritizes the safety and quality requirements of their houses and as a result, construction firms adopt QFD to address the needs of customers. The findings are of great importance for the clients of housing projects as well as for the construction firms as they could apply QFD in housing projects to address the safety and quality concerns of their clients.

Keywords: Construction industry, quality considerations, quality function deployment, safety considerations.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 850

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: Construction, delay factors, time delay, Australian construction industry.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1138

Authors: Charles Mothobiso

Abstract:

This study attempts to identify the client’s main priority when delivering green projects. The aim is to compare whether clients’ interests are similar when delivering conventional buildings as compared to green buildings. Private clients invest more in green buildings as compared to government and parastatal entities. Private clients prioritize on maximizing a return on investment and they mainly invest in energy-saving buildings that have low life cycle costs. Private clients are perceived to be more knowledgeable about the benefits of green building projects as compared to government and parastatal clients. A shortage of expertise and managerial skill leads to the low adaptation of green buildings in government and parastatal projects. Other factors that seem to prevent the adoption of green buildings are the preparedness of the supply chain within the industry and inappropriate procurement strategies adopted by clients.

Keywords: Construction clients, design team, green buildings procurement.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1167

Authors: R. Kozik, A. Leśniak A., E. Plebankiewicz

Abstract:

Contracting authorities in the public sector are obligated to apply the principles provided for in the Polish law for the evaluation and selection of contractors. In order to analyse the methods of contractors selecting applied in practice by public clients, the notices of contract award results for construction works were analysed. The analysis shows that the procedure selected more and more often is open competitive bidding, where the assessment of the competence of contractors is not very precise, as well as noncompetitive bidding, i.e. single source procurement. The share of procurement procedures, where the only criterion is price, is increasing. The solution to the problems existing here might be the introduction of one of the forms of pre-selection of contractors. The article also briefly discusses verification systems for companies applying for public contracts used in EU countries.

Keywords: Certification, contractors selection, open tendering, public investors.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1902

Authors: E. Harrer, M. Mauerhofer, T. Werginz

Abstract:

As a result of intensive competition, the building sector is suffering from a high degree of rivalry. Furthermore, there can be observed an unbalanced distribution of project risks. Clients are aimed to shift their own risks into the sphere of the constructors or planners. The consequence of this is that the number of conflicts between the involved parties is inordinately high or even increasing; an alternative approach to counter on that developments are cooperative project forms in the construction sector. This research compares conventional contract models and models with partnering agreements to examine the influence on project risks by an early integration of the involved parties. The goal is to show up deviations in different project stages from the design phase to the project transfer phase. These deviations are evaluated by a survey of experts from the three spheres: clients, contractors and planners. By rating the influence of the participants on specific risk factors it is possible to identify factors which are relevant for a smooth project execution.

Keywords: Collaborative work, construction industry, contract-models, influence, partnering, project management, risk.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 823

Authors: Essa Alenazi, Zulfikar Adamu

Abstract:

The Kingdom of Saudi Arabia (KSA) is not an exception in relying on the growth of its construction industry to support rapid population growth. However, its need for infrastructure development is constrained by low productivity levels and cost overruns caused by factors such as delays to project completion. Delays in delivering a construction project are a global issue and while theories such as Optimism Bias have been used to explain such delays, in KSA, client-related causes of delays are also significant. The objective of this paper is to develop a framework-based approach to explore how the country’s construction industry can manage and reduce delays in construction projects through building information modelling (BIM) in order to mitigate the cost consequences of such delays.  It comprehensively and systematically reviewed the global literature on the subject and identified gaps, critical delay factors and the specific benefits that BIM can deliver for the delay management.  A case study comprising of nine hospital projects that have experienced delay and cost overruns was also carried out. Five critical delay factors related to the clients were identified as candidates that can be mitigated through BIM’s benefits. These factors are: Ineffective planning and scheduling of the project; changes during construction by the client; delay in progress payment; slowness in decision making by the client; and poor communication between clients and other stakeholders. In addition, data from the case study projects strongly suggest that optimism bias is present in many of the hospital projects. Further validation via key stakeholder interviews and documentations are planned.

Keywords: BIM, client perspective, delay management, optimism bias, public sector projects.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2412

Authors: A. Leśniak, E. Plebankiewicz, K. Zima

Abstract:

Construction projects can be implemented under various contractual and organizational systems. They can be divided into two groups: systems without the managing company where the Client manages the process, and systems with the managing company, where management is entrusted to an external company. In the public sector of the Polish market there are two ways of delivery of construction projects with the participation of the manager: one is to assign operations to another party, the so called Project Supervisor, whilst the other results from the application of FIDIC conditions of contract, which entail appointment of the Engineer. The decision is to be made by the Client and depends on various factors. On the public procurement market in Poland the selection of construction project manager boils down to awarding the contract for such a service. The selection can be done by one of eight public procurement procedures identified by the procurement law. The paper provides the analysis of 96 contracts for services awarded in 2011, which employed construction management. The study aimed to investigate the methods and criteria for selecting managers, applied in practice by the Polish public Clients.

Keywords: construction management, construction services, methods and criteria of tender selection, public procurement

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1738

Authors: Evisa Mitrou, Nicholas Tsitsianis, Supriya Shinde

Abstract:

In the age of digitisation and globalisation, businesses have shifted online and are investing in big data analytics (BDA) to respond to changing market conditions and sustain their performance. Our study shifts the focus from the adoption of BDA to the impact of BDA on financial performance. We explore the financial performance of both BDA-vendors (business-to-business) and BDA-clients (business-to-customer). We distinguish between the five BDA-technologies (big-data-as-a-service (BDaaS), descriptive, diagnostic, predictive, and prescriptive analytics) and discuss them individually. Further, we use four perspectives (internal business process, learning and growth, customer, and finance) and discuss the significance of how each of the five BDA-technologies affect the performance measures of these four perspectives. We also present the analysis of employee engagement, average turnover, average net income, and average net assets for BDA-clients and BDA-vendors. Our study also explores the effect of the COVID-19 pandemic on business continuity for both BDA-vendors and BDA-clients.

Keywords: BDA-clients, BDA-vendors, big data analytics, financial performance.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 496

Authors: J. Belás, E. Cipovová, M. Holec

Abstract:

The aim of this article was to analyze the relationship between the loyalty of banks´ employees and the acceptance of clients’ needs and to analyze the relationship between the loyalty of banks’ employees and the lack of their productivity in the Czech and Slovak banking sector. Our research has been realized through a questionnaire survey.

The loyalty of banks’ employees was higher in the Czech Republic than in Slovak Republic which has been transformed into a higher acceptance rate of customers’ needs and lower lack of employees’ productivity. Within both countries, it has been found that the approach of loyal employees to the acceptance of clients’ needs is not statistically significantly different from the approach of other employees. It has been also discovered that loyal employees did not work more intensively and did not feel statistically significant lower lack of their own productivity.

Keywords: Acceptance of clients’ needs, loyalty of banks’ employees, productivity of employees.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2420

Authors: Adil K. Tamimi, Tarig Ali, Rawan Anoohi, Ahmed Rajput, Kaltham Alkamali

Abstract:

3D concrete printing is one of the most innovative and modern techniques in the field of construction that achieved several milestones in that field for the following advantages: saving project’s time, ability to execute complicated shapes, reduce waste and low cost. However, the concept of 3D printing in UAE is relatively new where construction teams, including clients, consultants, and contractors, do not have the required knowledge and experience in the field. This is the most significant obstacle for the construction parties, which make them refrained from using 3D concrete printing compared to conventional concreting methods. This study shows the historical development of the 3D concrete printing, its advantages, and the challenges facing this innovation. Concrete mixes and materials have been proposed and evaluated to select the best combination for successful 3D concrete printing. The main characteristics of the 3D concrete printing in the fresh and hardened states are considered, such as slump test, flow table, compressive strength, tensile, and flexural strengths. There is need to assess the structural stability of the 3D concrete by testing the bond between interlayers of the concrete.  

Keywords: 3D printing, concrete mixes, workability, compressive strength, slump test, tensile strength, flexural strength.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 624

Authors: N. Hamzah, M.A. Khoiry, I. Arshad, W.H.W. Badaruzzaman, N. M. Tawil

Abstract:

Construction delay is unavoidable in developing countries including Malaysia. It is defined as time overrun or extension of time for completion of a project. The purpose of the study is to determine the causes of delay in Malaysian construction industries based on previous worldwide research. The field survey conducted includes the experienced developers, consultants and contractors in Malaysia. 34 causes of the construction delay have been determined and 24 have been selected using the Rasch model analysis. The analysis result will be used as the baseline for the next research to find the causes of delay in the Malaysian construction industry taking place in Malaysian higher learning institutions.

Keywords: Causes of construction delay, construction projects, Malaysian construction industry, Rasch model analysis.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 7517

Authors: Kho Mei Ye, Hamzah Abdul Rahman

Abstract:

The purpose of this study is to identify the underlying causes of late payment from the contractors- perspective in the Malaysian construction industry and to recommend effective solutions to mitigate late payment problems. The target groups of respondents in this study were Grades G3, G5, G6 and G7 contractors with specialization in building works and civil engineering works registered with the Construction Industry Development Board (CIDB) in Malaysia. Results from this study were analyzed with Statistical Package for the Social Science (SPSS 15.0). From this study, it was found that respondents have highest ranked five significant variables out of a total of forty-one variables which can caused late payment problems: a) cash flow problems due to deficiencies in client-s management capacity (mean = 3.96); b) client-s ineffective utilization of funds (mean = 3.88); c) scarcity of capital to finance the project (mean = 3.81); d) clients failure to generate income from bank when sales of houses do not hit the targeted amount (mean=3.72); and e) poor cash flow because of lack of proper process implementation, delay in releasing of the retention monies to contractor and delay in the evaluation and certification of interim and final payment (mean = 3.66).

Keywords: Underlying causes, late payment, constructionindustry, Malaysia.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 7108

Authors: Yuri B. Cesarino, Vinícius R. Domingues, Darym J. F. Campos

Abstract:

Developing countries have some restrains towards the adoption of new technologies and construction methods. Some nations, such as Brazil, still use conventional construction methodologies, knowing its lesser cost-effectiveness. This research has been conducted to demonstrate how industrialized construction methods should be implemented in Brazil, especially in times of need. Using the common sense among different authors with different perspectives, it is clear that the second method is more suitable for construction development because of its great advantages. However, it is unlikely for this process to be adopted in the country as a result of several social-economic restraints. Nonetheless, Brazilian engineers have a major challenge ahead of them, and it will take more than creativity to solve such an issue.

Keywords: Brazilian engineers, construction methods, industrialized construction, infrastructure.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1413

Authors: Dimitrios Ntardas, Alexandros Tzanetos, Georgios Dounias

Abstract:

High Voltage Substations (HVS) are the intermediate step between production of power and successfully transmitting it to clients, making them one of the most important checkpoints in power grids. Nowadays - renewable resources and consequently distributed generation are growing fast, the construction of HVS is of high importance both in terms of quality and time completion so that new energy producers can quickly and safely intergrade in power grids. The resources needed, such as machines and workers, should be carefully allocated so that the construction of a HVS is completed on time, with the lowest possible cost (e.g. not spending additional cost that were not taken into consideration, because of project delays), but in the highest quality. In addition, there are milestones and several checkpoints to be precisely achieved during construction to ensure the cost and timeline control and to ensure that the percentage of governmental funding will be granted. The management of such a demanding project is a NP-hard problem that consists of prerequisite constraints and resource limits for each task of the project. In this work, a hybrid meta-heuristic method is implemented to solve this problem. Meta-heuristics have been proven to be quite useful when dealing with high-dimensional constraint optimization problems. Hybridization of them results in boost of their performance.

Keywords: High voltage substations, nature-inspired algorithms, project management, meta-heuristics.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1169

Authors: Israngkura Na Ayudhya B, Kunishima M.

Abstract:

This paper analysis performance of disbursement procedure of public works project in Thailand. The results of research were summarised based on contracts, submitted invoice, inspection dated, copies of disbursement dated between client and their main contractor and interviewed with persons involved in central and local government projects during 1994-2008 in Thailand. The data collection was to investigate the disbursement procedure related to performance in disbursement during construction period (Planned duration of contract against Actual execution date in each month). A graphical presentation of a duration analysis of the projects illustrated significant disbursement formation in each project. It was established that the shortage of staff, the financial stability of clients, bureaucratic, method of disbursement and economics situation has play major role on performance of disbursement to their main contractors.

Keywords: Construction disbursement, Payment procedure, Public works

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1452

Authors: Murat Gunduz, Mohanad H. A. AbuHassan

Abstract:

Construction industry mainly focuses on the superstructure, infrastructure, and oil and gas industry. The development of infrastructure projects in developing countries attracted a lot of foreign construction contractors, consultants, suppliers and diversified workforce to interfere and to be evolved in such huge investment. Reducing worksite delays in such projects require knowledge and attention. Therefore, it is important to identify the influencing delay attributes affecting construction projects. The significant project factors affecting construction delays were investigated. Data collection was carried out through an online web survey system to capture significant factors. Significant factors were determined with importance index and relevant recommendations are made. The output of the data analysis would lead the industry experts better assess the impact of construction delays on construction projects.

Keywords: Construction industry, delays, importance index.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2618

Authors: Temidayo. O. Osunsanmi, Clinton Aigbavboa, Ayodeji Oke

Abstract:

The construction industry is a renowned latecomer to the efficiency offered by the adoption of information technology. Whereas, the banking, manufacturing, retailing industries have keyed into the future by using digitization and information technology as a new approach for ensuring competitive gain and efficiency. The construction industry has yet to fully realize similar benefits because the adoption of ICT is still at the infancy stage with a major concentration on the use of software. Thus, this study evaluates the awareness and readiness of construction professionals towards embracing a full digitalization of the construction industry using construction 4.0. The term ‘construction 4.0’ was coined from the industry 4.0 concept which is regarded as the fourth industrial revolution that originated from Germany. A questionnaire was utilized for sourcing data distributed to practicing construction professionals through a convenience sampling method. Using SPSS v24, the hypotheses posed were tested with the Mann Whitney test. The result revealed that there are no differences between the consulting and contracting organizations on the readiness for adopting construction 4.0 concepts in the construction industry. Using factor analysis, the study discovers that adopting construction 4.0 will improve the performance of the construction industry regarding cost and time savings and also create sustainable buildings. In conclusion, the study determined that construction professionals have a low awareness towards construction 4.0 concepts. The study recommends an increase in awareness of construction 4.0 concepts through seminars, workshops and training, while construction professionals should take hold of the benefits of adopting construction 4.0 concepts. The study contributes to the roadmap for the implementation of construction industry 4.0 concepts in the South African construction industry.

Keywords: Building information technology, Construction 4.0, Industry 4.0, Smart Site.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 5664

Authors: Michael Gerges, Ograbe Ahiakwo, Martin Jaeger, Ahmad Asaad

Abstract:

Recent advances of Building Information Modeling (BIM) especially in the Middle East have increased remarkably. Dubai has been taking a lead on this by making it mandatory for BIM to be adopted for all projects that involve complex architecture designs. This is because BIM is a dynamic process that assists all stakeholders in monitoring the project status throughout different project phases with great transparency. It focuses on utilizing information technology to improve collaboration among project participants during the entire life cycle of the project from the initial design, to the supply chain, resource allocation, construction and all productivity requirements. In view of this trend, the paper examines the extent of applying BIM in the State of Kuwait, by exploring practitioners’ perspectives on BIM, especially their perspectives on main barriers and main advantages. To this end structured interviews were carried out based on questionnaires and with a range of different construction professionals. The results revealed that practitioners perceive improved communication and mitigated project risks by encouraged collaboration between project participants. However, it was also observed that the full implementation of BIM in the State of Kuwait requires concerted efforts to make clients demanding BIM, counteract resistance to change among construction professionals and offer more training for design team members. This paper forms part of an on-going research effort on BIM and its application in the State of Kuwait and it is on this basis that further research on the topic is proposed.

Keywords: Building Information Modeling, BIM, construction industry, Kuwait.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2895

Authors: Nikola Karanovic, Aleksandar Djuric

Abstract:

This paper introduces a method of calculating the quantities of construction materials and construction waste on site in city of Novi Sad. In buildings is about 40% of the total weight of materials that are in circulation in the world economic space. The best solution for this waste is to be stored at source, at the point of generation. There are several treatment options for this type of waste, reduction at source, reuse, recycling. Beside its negative effects on the environment, construction waste can be and resource. Novi Sad is divided in 16 single family resident zones and 10 multi family resident zones. For every zone of the city, quantities of used construction materials and construction waste were obtained. Rational use of natural resources is an essential factor in applying the principles of development with savings.

Keywords: Construction materials, Construction waste, Novi Sad, Recycling

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1607

Authors: Vladimira Vytlacilova

Abstract:

Recycling of construction and demolition waste (C&DW) and their new reuse in structures is one of the solutions of environmental problems. Construction and demolition waste creates a major portion of total solid waste production in the world and most of it is used in landfills all the time. The paper deals with the situation of the recycling of the building and demolition waste in the Czech Republic during the recent years. The paper is dealing with questions of C&D waste recycling, it also characterizes construction and demolition waste in general, furthermore it analyses production of construction waste and subsequent production of recycled materials.

Keywords: Recycling, Construction and demolition waste, Recycled rubble, Waste management.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 704

Authors: Andrea Palazzo, Daniel Macek, Veronika Malinova

Abstract:

Contour processing is the new technology challenge for architects and construction companies. The many advantages it promises make it one of the most interesting solutions for construction in terms of automation of building processes. The technology for 3D printing houses offers many application possibilities, from low-cost construction, to being considered by NASA for visionary projects as a good solution for building settlements on other planets. Another very important point is that clients, as architects, will no longer have many limits in design concerning ideas and creativity. The prices for real estate are constantly increasing and the lack of availability of construction materials as well as the speculation that has been created around it in 2021 is bringing prices to such a level that in the future it will be difficult for developers to find customers for these ultra-expensive homes. Hence, this paper starts with the introduction of 3D printing, which now has the potential to gain an important position in the market, becoming a valid alternative to the classic construction process. This technology is not only beneficial from an economic point of view but it is also a great opportunity to have an impact on the environment by reducing CO2 emissions. Further on in the article we will also understand if, after the COP 26 (2021 United Nations Climate Change Conference), world governments could also push towards building technologies that reduce the waste materials that are needed to be disposed of and at the same time reduce emissions with the contribution of governmental funds. This paper will give us insight on the multiple benefits of 3D printing and emphasize the importance of finding new solutions for materials that can be used by the printer. Therefore, based on the type of material, it will be possible to understand the compatibility with current regulations and how the authorities will be inclined to support this technology. This will help to enable the rise and development of this technology in Europe and in the rest of the world on actual housing projects and not only on prototypes.

Keywords: Additive manufacturing, building development building regulation, contour crafting, printing material.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 256

Authors: Shaikha AlSanad , Andrew Gale, Rodger Edwards

Abstract:

Buildings and associated construction methods have a significant impact on the environment. As construction activity increases in Kuwait, there is a need to create design and construction strategies which will minimize the environmental impact of new buildings. Green construction is a design philosophy intended to improve the sustainability of construction by the minimization of resource depletion and CO2 emissions throughout the life cycle of buildings. This paper presents and discusses the results of a survey that was conducted in Kuwait, with the objective of investigating the awareness of developers and other stakeholders regarding their understanding and use of green construction strategies. The results of the survey demonstrate that whilst there seems to be a reasonable level of awareness amongst the stakeholders, this awareness is not currently well reflected in the design and construction practices actually being applied. It is therefore concluded is there is a pressing need for intervention from Government in order that the use of sustainable green design and construction strategies becomes the norm in Kuwait.

Keywords: Sustainability, Sustainable construction, Green Building, Environmental assessment

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 3055

Authors: Thandokazi Nyangiwe, Christopher Amoah, Charles P. Mukumba

Abstract:

The South African construction sector is threatened by emerging black business forums called construction mafias. The emergence of the construction mafia has culminated in the disruptions and abandonment of construction sites resulting in the loss of jobs for construction workers. The paper examines the origin of construction mafias and their impact on the construction sector, including the potential ways to cope with their operations. A qualitative research approach was adopted for this study using open-ended interview questions to gather information from 30 key construction industry stakeholders, including contractors, subcontractors, consultants, and the construction project communities. Content and thematic analyses were used to analyses the data collected. The findings suggest that most participants do not fully understand the existence and operations of construction mafias in the construction industry. Construction mafias claim to be part of the local business forums. They disrupt construction projects and demand a certain amount, usually 30% of the construction value. Construction mafias frequently resort to intimidation and violence if their demands are unmet. Their operations have resulted in delayed completion of construction projects, abandonment of projects, and loss of income for the contractor and jobs for the construction workers. The interviews were limited to construction stakeholders. Because of the nature of the mafias’ operations, they could not be accessed for interviews for fear of being identified because of the connotation attached to their role as construction mafias. Construction project owners face disruptions of projects resulting in loss of equipment, materials, and income. Therefore, there is a need to sensitize the construction stakeholders in the construction industry regarding the existence and operations of the construction mafia and the implications on construction project performance and delivery. The findings will give insight into the operations of the construction mafias in the South African construction industry, which has caused disruptions in construction project sites. Stakeholders must find solutions to address the construction mafias’ disruptive actions on construction projects. The study presents an initial inquiry that will come up with how to manage and cope with the growing operations of construction mafias in the South African construction industry.

Keywords: Black business forums, construction mafia, South African construction industry.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 163

Authors: Jolanta Tamošaitienė

Abstract:

The article focuses on a developed comprehensive model to be used in an agile environment for the risk assessment and selection based on multi-attribute methods. The model is based on a multi-attribute evaluation of risk in construction, and the determination of their optimality criterion values are calculated using complex Multiple Criteria Decision-Making methods. The model may be further applied to risk assessment in an agile construction environment. The attributes of risk in a construction project are selected by applying the risk assessment condition to the construction sector, and the construction process efficiency in the construction industry accounts for the agile environment. The paper presents the comprehensive risk assessment model in an agile construction environment. It provides a background and a description of the proposed model and the developed analysis of the comprehensive risk assessment model in an agile construction environment with the criteria.

Keywords: Assessment, environment, agile, model, risk.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1035

Authors: V. K. Bansal

Abstract:

Geographic Information System (GIS) is a computerbased tool used extensively to solve various engineering problems related to spatial data. In spite of growing popularity of GIS, its complete potential to construction industry has not been realized. In this paper, the summary of up-to-date work on spatial applications of GIS technologies in construction industry is presented. GIS technologies have the potential to solve space related problems of construction industry involving complex visualization, integration of information, route planning, E-commerce, cost estimation, etc. GISbased methodology to handle time and space issues of construction projects scheduling is developed and discussed in this paper.

Keywords: Construction, GIS in construction, Scheduling, Project Management.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2619

Authors: Eugen Pop, Mihai Barbos, Razvan Lupu

Abstract:

The client server systems using mobile communications networks for data transmission became very attractive for many economic agents, in the purpose of promoting and offering electronic services to their clients. E-services are suitable for business developing and financial benefits increasing. The products or services can be efficiently delivered to a large number of clients, using mobile Internet access technologies. The clients can have access to e-services, anywhere and anytime, with the support of 3G, GPRS, WLAN, etc., channels bandwidth, data services and protocols. Based on the mobile communications networks evolution and development, a convergence of technological and financial interests of mobile operators, software developers, mobile terminals producers and e-content providers is established. These will lead to a high level of integration of IT&C resources and will facilitate the value added services delivery through the mobile communications networks. In this paper it is presented a client server system, for e-services access, with Smartphones and PDA-s mobile software applications, installed on Symbian and Windows Mobile operating systems.

Keywords: Client server system, e-services access, mobile communications, PDA, Smartphone.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2625

Authors: S. R. Shamili, J. Karthikeyan

Abstract:

Fast development of the total populace and far and wide urbanization has surprisingly expanded the advancement of the construction industry. As a result of these activities, old structures are being demolished to make new buildings. Due to these large-scale demolitions, a huge amount of debris is generated all over the world, which results in a landfill. The use of construction and demolition waste as landfill causes groundwater contamination, which is hazardous. Using construction and demolition waste as aggregate can reduce the use of natural aggregates and the problem of mining. The objective of this study is to provide a detailed overview on how the construction and demolition waste material has been used as aggregate in structural concrete. In this study, the preparation, classification, and composition of construction and demolition wastes are also discussed.

Keywords: Aggregate, construction and demolition waste, landfill, large scale demolition.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 571

Authors: Zhankuliyeva S. A.

Abstract:

This article considers the main features of party construction in the course of political modernization of Kazakhstan. Along with consideration of party construction author analyzed how the transformation of the party system was fulfilled in Kazakhstan. Besides the basic stages in the course of party construction were explained by the author. The statistical data is cited.

Keywords: elections, multi-party system, party construction, political pluralism, political party, Republic of Kazakhstan (RK)

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1499

Authors: Hafiz Usama Imad, Muhammad Akram Akhund, Tauha Hussain Ali, Ali Raza Khoso, Fida Hussain Siddiqui

Abstract:

Construction industry plays a significant role in fulfilling the major requirements of the human being. It is one of the major constituents of every developed country. Although the construction industry of both the developing and developed countries encompasses a major part of the economy, and millions of rupees are utilized every year on various kinds of construction projects. But, this industry is facing numerous hurdles in terms of its budget and timely completion. Construction projects generally consist of several phases like planning, designing, execution, and finishing. This research study aims to determine the significant factors of time overrun in pre-construction planning (PCP) phase of construction projects in Pakistan. Questionnaires were distributed by various means and responses of respondents were compiled and collected data were then analyzed through a statistical technique using SPSS version 24. Major causes of time overrun in pre-construction planning phase; which is an extremely important phase of construction projects, were revealed. The research conclusion will provide a pathway for stakeholders to pay attention to the mentioned causes to overcome the major issue of time overrun.

Keywords: Construction industry, Pakistan, pre-construction planning phase, time overrun.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 915