Search results for: SPE’s comparative solution projects

Authors: Mohammad Lemar Zalmai, Mustafa Nabi Kocakaya, Cemil Akcay, Ekrem Manisali

Abstract:

In recent years, the Building Information Modeling (BIM) approach has been developed expeditiously. As people see the benefits of this approach, it has begun to be used widely in construction projects and some countries made it mandatory to get more benefits from it. To promote the implementation of BIM in construction projects, it will be helpful to get some relevant information from surveys and interviews. The purpose of this study is to research the current adoption and implementation of BIM in public projects in Turkey. This study specified the challenges of BIM implementation in Turkey and proposed some solutions to overcome them. In this context, the challenges for BIM implementation and the factors that affect the BIM usage are determined based on previous academic researches and expert opinions by conducting interviews and questionnaire surveys. Several methods are used to process information in order to obtain weights of different factors to make BIM widespread in Turkey. This study concluded interviews' and questionnaire surveys' outcomes and proposed some suggestions to promote the implementation of BIM in Turkey. We believe research findings will be a good reference for boosting BIM implementation in Turkey.

Keywords: building information modelling, BIM implementations, Turkish construction industry, Turkish government sector projects

Procedia PDF Downloads 110

Authors: Ronaldo Seroa Da Motta, Gabriela Santiago

Abstract:

The main contribution of this study is the identification of the factors influencing the environmental licensing process of infrastructure projects in Brazil. These factors will be those that reflect the technical characteristics of the project, the corporate governance of the entrepreneur, and the institutional and regulatory governance of the environmental agency, including the number of interventions by non-licensing agencies. The model conditions these variables to the licensing processing time of 34 infrastructure projects. Our results indicated that the conditions would be more sensitive to the type of enterprise, complexity as in gas pipelines and hydroelectric plants in the most vulnerable biome with a greater value of the enterprise or the entrepreneur's assets, together with the number of employees of the licensing agency. The number of external interventions by other non-licensing institutions does not affect the licensing time. Such results challenge the current criticism that environmental licensing has been often pointed out as a barrier to speed up investments in infrastructure projects in Brazil due to the participation of civil society and other non-licensing institutions.

Keywords: environmental licensing, condionants, Brazil, timing process

Procedia PDF Downloads 106

Authors: Pablo Cardozo Herrera

Abstract:

In a dynamic market of Information Technology (IT) Service and with high quality demands and high performance requirements in decreasing costs, it is imperative that IT companies invest organizational effort in order to increase the effectiveness of their Information Technology Service Management (ITSM) processes through the improvement of ITSM project management and through solid support to the strategic decision-making process of IT directors. In this article, the author presents an analysis of common issues of IT companies around the world, with strategic needs of information unmet that provoke their ITSM processes and projects management that do not achieve the effectiveness and efficiency expected of their results. In response to the issues raised, the author proposes a framework consisting of an innovative theoretical framework model of ITSM management and a technological solution aligned to the Information Technology Infrastructure Library (ITIL) good practices guidance and ISO/IEC 20000-1 requirements. The article describes a research that proves the proposed framework is able to integrate, manage and coordinate in a holistic way, measurable and auditable, all ITSM processes and projects of IT organization and utilize the effectiveness assessment achieved for their strategic decision-making process increasing the process maturity level and improving the capacity of an efficient management.

Keywords: innovation in IT services, ITSM processes, ITIL and ISO/IEC 20000-1, IT service management, IT service excellence

Procedia PDF Downloads 369

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 476

Authors: Olivia Rybak-Karkosz

Abstract:

Art forgery is a serious problem present in the art market in every country despite its scale and experience. In the Polish art market, this problem has existed since its beginnings. The market expansion in recent years attracted new buyers, which led to growing prices of polish art. And that attracted deceitful sellers who supply the market with forgeries. Moreover, there are many new types of buyers, many of whom are art non-specialists. But even the most experienced collectors must be cautious when purchasing a piece of art. In this paper, the author would like to discuss legal acts in Polish law that criminalize the forgery of a piece of art and compare them with similar regulations from four European countries - the Italian Republic, Kingdom of the Netherlands, French Republic, and the Federal Republic of Germany. The author wants to verify if any solutions could inspire Polish legislators to implement them in domestic law to help reduce this crime and improve the criminal procedure of art forgery. The paper contains a concluding statement to implement a similar solution used in one of the presented countries.

Keywords: art forgery, comparative law, criminal law, criminal liability, protection of works of art

Procedia PDF Downloads 62

Authors: Tirthankar Chakraborty, Indranil Mukherjee

Abstract:

The environmental aspect had a major effect on industrial decisions after the deteriorating condition of our surroundings dsince the industrial activities became apparent. Green buildings have been seen as a possible solution to reduce the carbon emissions from construction projects and the housing industry in general. Though this has been established in several areas, with many commercial buildings being designed green, the scope for expansion is still significant and further information on the importance and advantages of green buildings is necessary. Several commercial green building projects have come up and the green buildings are mainly implemented in the residential sector when the residential projects are constructed to furnish amenities to a large population. But, residential buildings, even those of medium sizes, can be designed to incorporate elements of sustainable design. In this context, this paper attempts to give a theoretical appraisal of the use of renewable energy systems in residential buildings of different sizes considering the weather conditions (solar insolation and wind speed) of the metropolis, Kolkata, India. Three cases are taken; one with solar power, one with wind power and one with a combination of the two. All the cases are considered in conjunction with conventional energy, and the efficiency of each in fulfilling the total energy demand is verified. The optimum combination for reducing the carbon footprint of the residential building is thus established. In addition, an assessment of the amount of money saved due to green buildings in metered water supply and price of coal is also mentioned.

Keywords: renewable energy, green buildings, solar power, wind power, energy hybridization, residential sector

Procedia PDF Downloads 358

Authors: Nnadi Ezekiel Ejiofor

Abstract:

In Enugu, Nigeria, this study investigates the connection between strategic leadership and project management sustainability, with an emphasis on building projects in the State. The study set out to accomplish two specific goals: first, it sought to establish a link between creative project management and resource efficiency in construction projects in Enugu State, Nigeria; and second, it sought to establish a link between innovative thinking and waste minimization in those same projects. A structured questionnaire was used to collect primary data from 45 registered construction enterprises in the study area as part of the study's descriptive research approach. Due to the nonparametric nature of the data, Spearman Rank Order Correlation was used to evaluate the acquired data. The findings demonstrate that creative project management had a significant positive impact on resource efficiency in construction projects carried out by architecture firms in Enugu State, Nigeria (r =.849; p.001), and that innovative thinking had a significant impact on waste reduction in those same projects (r =.849; p.001). It was determined that strategic leadership had a significant impact on the sustainability of project management, and it was thus advised that project managers should foresee, prepare for, and effectively communicate present and future developments to project staff in order to ensure that the objective of sustainable initiatives, such as recycling and reuse, is implemented in construction projects.

Keywords: construction, project management, strategic leadership, sustainability, waste reduction

Procedia PDF Downloads 23

Authors: Sungik Kang, Ja-Hoon Koo

Abstract:

Globally, urban environments have become unequal, and cities have been segmented by income class. It is predicted that urban inequality has arisen by urban redevelopment and reconstruction projects that improve the urban environment and innovate cities. This study aims to analyze the occurrence and characteristics of urban inequality by using the housing price and sale price and demonstrating the correlation with the urban redevelopment project. This study measures 14 years of urban inequality index for 25 autonomous districts in Seoul and analyzes the correlation between urban inequality with urban redevelopment projects. As a conclusion of this study, first, the urban inequality index of Seoul has been continuously rising since 2015. Trends from 2006 to 2019 have been in U-curved shape in between 2015. In 2019, Seoul's urban inequality index was 0.420, a level similar to that of the 2007 financial crisis. Second, the correlation between urban redevelopment and urban inequality was not statistically significant. Therefore, we judged that urban redevelopment's scale or project structure has nothing with urban inequality. Third, while district designation of urban reconstruction temporarily alleviates urban inequality, the completion of the project increases urban inequality. When designating a district, urban inequality is likely to decrease due to decreased outdated housing transactions. However, the correlation with urban inequality increases as expensive houses has been placed after project completion.

Keywords: urban inequality, urban redevelopment projects, urban reconstruction projects, housing price inequality, panel analysis

Procedia PDF Downloads 179

Authors: Abdullah Almusharraf, Andrew Whyte

Abstract:

The sub-task pattern in terms of the deviations and defects should be identified and understand in order to improve the quality practices in construction projects. Therefore, the sub-task susceptibility to exposure to deviations and defects have been evaluated and classified via six classifications that have proposed in this study. 34 case studies on specific sub-task (from compression member in construction concrete structure) have been collected from seven construction projects in order to examined study’s classifications. The study revealed that the sub-task has high sensitive to deviation where (91%) of the cases recorded as deviations, however, only (19%) of cases recorded as defects. Another findings were that the actual work during the execution process has high source of deviation for this sub-task (74%) while only (26%) of the deviation source was due to both design documentations with the actual work. These findings significantly imply that it could be used the study’s classifications to determine the pattern of each sub-task and develop the proactive actions to overcome issues of the sub-task deviations and defects.

Keywords: sub-tasks, deviations, defects, quality, construction projects

Procedia PDF Downloads 407

Authors: Arsalan Salahi

Abstract:

Today, the number of changes in the construction industry and urban mass house building is increasing, which makes you need to pay more attention to targeted planning for human resource management and training. The human resources working in the construction industry have various problems and deficiencies, and in order to solve these problems, there is a need for basic management and training of these people in order to lower the construction costs and increase the quality of the projects, especially in mass house building projects. The success of any project in reaching short and long-term professional goals depends on the efficient combination of work tools, financial resources, raw materials, and most importantly, human resources. Today, due to the complexity and diversity of each project, specialized management fields have emerged to maximize the potential benefits of each component of that project. Human power is known as the most important resource in construction projects for its successful implementation, but unfortunately, due to the low cost of human power compared to other resources, such as materials and machinery, little attention is paid to it. With the correct management and training of human resources, which depends on its correct planning and development, it is possible to improve the performance of construction projects. In this article, the training and motivation of construction industry workers and their effects on the effectiveness of projects in this industry have been researched. In this regard, some barriers to the training and motivation of construction workers and personnel have been identified and solutions have been provided for construction companies. Also, the impact of workers and unskilled people on the efficiency of construction projects is investigated. The results of the above research show that by increasing the use of correct and basic training for human resources, we will see positive results and effects on the performance of construction projects.

Keywords: human resources, construction industry, principled training, skilled and unskilled workers

Procedia PDF Downloads 55

Authors: Natalia Rudeli, Elisabeth Viles, Adrian Santilli

Abstract:

Delays in the construction industry are a global phenomenon. Many construction projects experience extensive delays exceeding the initially estimated completion time. The main purpose of this study is to identify construction projects typical behaviors in order to develop a prognosis and management tool. Being able to know a construction projects schedule tendency will enable evidence-based decision-making to allow resolutions to be made before delays occur. This study presents an innovative approach that uses Cluster Analysis Method to support predictions during Earned Value Analyses. A clustering analysis was used to predict future scheduling, Earned Value Management (EVM), and Earned Schedule (ES) principal Indexes behaviors in construction projects. The analysis was made using a database with 90 different construction projects. It was validated with additional data extracted from literature and with another 15 contrasting projects. For all projects, planned and executed schedules were collected and the EVM and ES principal indexes were calculated. A complete linkage classification method was used. In this way, the cluster analysis made considers that the distance (or similarity) between two clusters must be measured by its most disparate elements, i.e. that the distance is given by the maximum span among its components. Finally, through the use of EVM and ES Indexes and Tukey and Fisher Pairwise Comparisons, the statistical dissimilarity was verified and four clusters were obtained. It can be said that construction projects show an average delay of 35% of its planned completion time. Furthermore, four typical behaviors were found and for each of the obtained clusters, the interim milestones and the necessary rhythms of construction were identified. In general, detected typical behaviors are: (1) Projects that perform a 5% of work advance in the first two tenths and maintain a constant rhythm until completion (greater than 10% for each remaining tenth), being able to finish on the initially estimated time. (2) Projects that start with an adequate construction rate but suffer minor delays culminating with a total delay of almost 27% of the planned time. (3) Projects which start with a performance below the planned rate and end up with an average delay of 64%, and (4) projects that begin with a poor performance, suffer great delays and end up with an average delay of a 120% of the planned completion time. The obtained clusters compose a tool to identify the behavior of new construction projects by comparing their current work performance to the validated database, thus allowing the correction of initial estimations towards more accurate completion schedules.

Keywords: cluster analysis, construction management, earned value, schedule

Procedia PDF Downloads 234

Authors: S. B. Shahmarova, F. N. Iskandarli, J. T. Zeynalov, F. N. Mammadov, M. M. Mirzayev, F. Y. Bayramov

Abstract:

The physical, mechanical, and chemical properties of aggregates play an important role in the production of ready-mixed concrete. Furthermore, the alkali-silicate reaction of aggregates is one of the essential factors in construction projects for the durability and longer service life of buildings and construction structures to be built. It is necessary to use the aggregates from the liberated regions of Karabakh and East Zangazur in the preparation of concretes to be produced for reconstruction and renovation projects in those regions. In this regard, the study of the physical and mechanical properties of aggregates in the regions around the Araz River (Fuzuli, Jabrayil, and Zangilan) became a significant issue. So, gravel samples were taken from seven different sources located in the regions around Araz River, where the quarries are planned to be built. The chemical oxide composition of the samples was determined, water absorption and specific gravity tests, chloride, alkali-silicate reaction tests, aggregate crushing strength test, Los Angeles, and frost resistance (into the solution of MgSO₄ and Na₂SO₄) tests were performed, and the results were evaluated in accordance with the relevant standards. As a result, it was determined that the aggregates in the regions around the Araz River (Fuzuli, Jabrayil, and Zangilan) conform to the relative standards and can be used effectively in the production of various concretes to be used for the projects in Karabakh.

Keywords: aggregates of the regions around Araz River (Fuzuli, Jabrayil, and Zangilan), physical and mechanical properties, alkali-silicate reaction, Karabakh, Azerbaijan

Procedia PDF Downloads 65

Authors: Adalberto Gregorio Back

Abstract:

Historically, the Pinheiros River, which crosses the urban area of the largest South American metropolis, the city of São Paulo, has been the subject of several interventions involving different interests and multiple demands, including the implementation of road axes and industrial occupation in the city, following its floodplains. the dilution of sewers; generation of electricity, with the reversal of its waters to the Billings Dam; and urban drainage. These processes, together with the exclusionary and peripheral urban sprawl with high population density in the peripheries, result in difficulties for the collection and treatment of household sewage, which flow into the tributaries and the Pinheiros River itself. In the last 20 years, two separate projects have been undertaken to clean up its waters. The first one between 2001-2011 was the flotation system, aimed at cleaning the river in its own gutter with equipment installed near the Bilings Dam; and, more recently, from 2019 to 2022, the proposal to connect about 74 thousand dwellings to the sewage collection and treatment system, as well as to install treatment plants in the tributaries of Pinheiros where the connection to the system is impracticable, given the irregular occupations. The purpose of this paper is to make a comparative analysis on the dynamics of conflicts, interests and opportunities of coalitions between the actors involved in the two referred projects of pollution of the Pinheiros River. For this, we use the analysis of documents produced by the state government; as well as documents related to the legal disputes that occurred in the first attempt of decontamination involving the sanitation company; the Billings Dam management company interested in power generation; the city hall and regular and irregular dwellings not linked to the sanitation system.

Keywords: depollution of the Pinheiros River, interests groups, São Paulo, water energy nexus

Procedia PDF Downloads 81

Authors: Ringisai Abigail Mawondo-Dhliwayo, Kahilu Kajimo-Shakantu

Abstract:

Due to financial challenges which governments in general face, it is becoming more difficult for many to continually use their limited resources to undertake infrastructural development. Governments increasingly now need other delivery approaches, in particular, the Public-Private Partnerships which make it possible for the public sector to achieve infrastructural development without incurring any/minimum cost. The literature reviewed outlined that benefits of PPPs include timely delivery of quality projects with cost limits. The methodology utilized for the empirical study comprised six interviews and sixty questionnaires which were undertaken and administered by construction consultants and government officials involved in PPPs projects. The results obtained showed that PPPs are not widely used in Zimbabwe although the need for their use exists. The study also found some challenges which prevent or derail the rate at which PPPs are utilized, of which the primary one was a political influence. It is concluded that despite limitations, PPPs remain the most effective and viable option for the delivery of government projects. The study recommends that policy and framework for the implementation of PPPs be developed. More useful information could have been obtained if final users of PPPs projects were included in the sample for data collection.

Keywords: construction projects, procurement, public private partnerships, public sector

Procedia PDF Downloads 227

Authors: M. S. Annie Christi

Abstract:

Transportation Problem (TP) is based on supply and demand of commodities transported from one source to the different destinations. Usual methods for finding solution of TPs are North-West Corner Rule, Least Cost Method Vogel’s Approximation Method etc. The transportation costs tend to vary at each time. We can use fuzzy numbers which would give solution according to this situation. In this study the Best Candidate Method (BCM) is applied. For ranking Centroid Ranking Technique (CRT) and Robust Ranking Technique have been adopted to transform the fuzzy TP and the above methods are applied to EDWARDS Vacuum Company, Crawley, in West Sussex in the United Kingdom. A Comparative study is also given. We see that the transportation cost can be minimized by the application of CRT under BCM.

Keywords: best candidate method, centroid ranking technique, fuzzy transportation problem, robust ranking technique, transportation problem

Procedia PDF Downloads 258

Authors: Bhavana Gulaty, Arshia Chaudhri

Abstract:

Great civic projects contribute integrally to a city, and every city undergoes a recurring cycle of urban transformations and regeneration by their insertion. The M.I.C.E. (Meetings, Incentives, Convention and Exhibitions) industry is the forbearer of one category of such catalytic civic projects. Through a specific focus on M.I.C.E. destinations, this paper illustrates the multifarious dimensions that urban catalysts impact the city on S.P.U.R. (Seed. Profile. Urbane. Reflections), the theoretical framework of this paper aims to unearth these dimensions in the realm of the COEX (Convention & Exhibition) biosphere. The ‘COEX Biosphere’ is the filter of such catalysts being ecosystems unto themselves. Like a ripple in water, the impact of these strategic interventions focusing on art, culture, trade, and promotion expands right from the trigger; the immediate context to the region and subsequently impacts the global scale. These ripples are known to bring about significant economic, social, and political and network changes. The COEX inventory in the Asian context has one such prominent addition; the proposed India International Convention and Exhibition Centre (IICC) at New Delhi. It is envisioned to be the largest facility in Asia currently and would position India on the global M.I.C.E map. With the first phase of the project scheduled to open for use in the end of 2019, this flagship project of the Government of India is projected to cater to a peak daily footfall of 3,20,000 visitors and estimated to generate 5,00,000 jobs. While the economic benefits are yet to manifest in real time and ‘Good design is good business’ holds true, for the urban transformation to be meaningful, the benefits have to go beyond just a balance sheet for the city’s exchequer. This aspect has been found relatively unexplored in research on these developments. The methodology for investigation will comprise of two steps. The first will be establishing an inventory of the global success stories and associated benefits of COEX projects over the past decade. The rationale for capping the timeframe is the significant paradigm shift that has been observed in their recent conceptualization; for instance ‘Innovation Districts’ conceptualised in the city of Albuquerque that converges into the global economy. The second step would entail a comparative benchmarking of the projected transformations by IICC through a toolkit of parameters. This is posited to yield a matrix that can form the test bed for mapping the catalytic trajectory for projects in the pipeline globally. As a ready reckoner, it purports to be a catalyst to substantiate decision making in the planning stage itself for future projects in similar contexts.

Keywords: catalysts, COEX, M.I.C.E., urban transformations

Procedia PDF Downloads 127

Authors: EMMANUEL DWAMENA SASU

Abstract:

International climate policy actions require countries under Paris Agreement to design instruments, provide support (financial and technical), and strengthen institutional capacity with tendency to transcending policy formulation to implementation and sustainability. Changes associated with moisture depletion has been a growing phenomenon; especially in developing countries with projected global GDP drop from 7% to 2% between 2005 and 2050. These developments have potential to adversely affect food production in feeding the growing world population, with corresponding rise in global hunger. Incongruously, there is global absence of a harmonized policy direction; capable of providing the required indicators on climate policies for monitoring sustainability of international agricultural development projects. We conduct extensive review and synthesis on existing limitations on global climate policy governance, agricultural food security and sustainability of international agricultural development projects, and conjecture the role of non-state and sub-national climate stakeholder engagements, and monitoring and evaluation strategies for improved climate policy action for sustaining international agricultural development projects.

Keywords: climate policy, agriculture, development projects, sustainability

Procedia PDF Downloads 100

Authors: Sumit Rahangdale

Abstract:

This research paper is a comparative study of two BRTS cities of Madhya Pradesh (INDIA), Bhopal and Indore. Indore is the largest and most populous city of Madhya Pradesh, with heavy traffic, while Bhopal though being the capital of Madhya Pradesh is comparatively less developed and shows less traffic The cities show similarity in case of peri-urban nature, but variation is observed in transportation fare, where Indore has been able to reduce it but Bhopal couldn’t, one of the reason for it is the para-transit services. Indore can be considered as a successful model due to the low fares and can be implemented in other parts of the city. The research paper tries to identify relation of para-transit services with the peri-urban connectivity and provide a solution for the Bhopal case study.

Keywords: demand-supply-fare relationship, mobility and accessibility, paratransit, peri-urban connectivity

Procedia PDF Downloads 143

Authors: Abdolrasoul Ghasemi, Ali Arabmazar Yazdi, Yasaman Boroumand, Aliasghar Banouei

Abstract:

In regional studies, choosing an appropriate approach to analyze regional success or failure has always been a challenge. Hence, this study introduces an innovative approach to establish a link between regional success and failure in the past as well as the potential success of a region in the future. The former can be sought in the historical evaluation of comparative advantages, while the latter is portrayed as competitive advantage analysis with a forward-looking approach. Based on the interaction of comparative and competitive advantages, activities are classified into four groups, including activities with no advantage, hidden advantage, fragile advantage and synergistic advantage. In analyzing the comparative advantage of activities, the location quotient method is applied, and in analyzing their competitive advantage, Porter`s diamond model using the survey method is applied. According to the results, the share of no advantage, fragile advantage, hidden advantage and synergic advantage activities are respectively 10%, 42%, 16%, and 32%. Also, to achieve economic development in regional activities, our model provides various levels of priority. First, the activities with synergistic advantage should be prioritized, then the ones with hidden advantage, and finally the activities with fragile advantage.

Keywords: regional advantage, comparative advantage, competitive advantage, Porter's diamond model

Procedia PDF Downloads 327

Authors: Mamoon Mousa Atout

Abstract:

Projects managers in construction industry usually face a difficult organizational environment especially if the project is unique. The organization lacks the processes to practice construction management correctly, and the executive’s technical managers who have lack of experience in playing their role and responsibilities correctly. Project managers need to adopt best practices that allow them to do things effectively to make sure that the project can be delivered without any delay even though the executive’s technical managers should follow a certain process to avoid any factor might cause any delay during the project life cycle. The purpose of the paper is to examine the awareness level of projects managers about construction management processes, tools, techniques and implications to complete projects on time. The outcome and the results of the study are prepared based on the designed questionnaires and interviews conducted with many project managers. The method used in this paper is a quantitative study. A survey with a sample of 100 respondents was prepared and distributed in a construction company in Dubai, which includes nine questions to examine the level of their awareness. This research will also identify the necessary benefits of processes of construction management that has to be adopted by projects managers to mitigate the maximum potential problems which might cause any delay to the project life cycle.

Keywords: construction management, project objectives, resource planing and scheduling, project completion

Procedia PDF Downloads 367

Authors: Borja Bordel, Ramón Alcarria, Marina Pérez

Abstract:

In March 2020, in Spain, a sanitary and unexpected crisis caused by COVID-19 was declared. All of a sudden, all degrees, classes and evaluation tests and projects had to be transformed into online activities. However, the chaotic situation generated by a complex operation like that, executed without any well-established procedure, led to very different experiences and, finally, results. In this paper, we are describing three experiences in two different Universities in Madrid. On the one hand, the Technical University of Madrid, a public university with little experience in online education. On the other hand, Alfonso X el Sabio University, a private university with more than five years of experience in online teaching. All analyzed subjects were related to computer engineering. Professors and students answered a survey and personal interviews were also carried out. Besides, the professors’ workload and the students’ academic results were also compared. From the comparative analysis of all these experiences, we are extracting the most successful strategies, methodologies, and activities. The recommendations in this paper will be useful for courses during the next months when the sanitary situation is still affecting an educational organization. While, at the same time, they will be considered as input for the upcoming digitalization process of higher education.

Keywords: educational experience, online education, higher education digitalization, COVID, Spain

Procedia PDF Downloads 114

Authors: Alireza Ghaffari, Hassan Saghi

Abstract:

Project management is more complex than managing the day-to-day affairs of an organization. When the project dimensions are broad and multiple projects have to be monitored in different locations, the integrated management becomes even more complicated. One of the main concerns of project managers is the integrated project management, which is mainly rooted in the lack of accurate and accessible information from different projects in various locations. The collection of dispersed information from various parts of the network, their integration and finally the selective reporting of this information is among the goals of integrated information systems. It can help resolve the main problem, which is bridging the information gap between executives and senior managers in the organization. Therefore, the main objective of this study is to design and implement an important subset of a project management information system in order to successfully control the cost of construction projects so that its results can be used to design raw software forms and proposed relationships between different project units for the collection of necessary information.

Keywords: financial performance, cost subsystem, PMIS, project management

Procedia PDF Downloads 77

Authors: Wang Liguang, Zhang Xueqing

Abstract:

The build-operate-transfer (BOT) project delivery system has provided effective routes to mobilize private sector funds, innovative technologies, management skills and operational efficiencies for public infrastructure development and have been widely used in China during the last 20 years. Many BOT projects in China will be smoothly transferred to the government soon and the transfer stage, which is considered as the last stage, must be studied carefully and handled well to achieve the overall success of BOT projects. There will be many issues faced by both the public sector and private sector in the transfer stage of BOT projects, including project post-assessment, technology and documents transfer, personal training and staff transition, etc. and sometimes additional legislation is needed for future operation and management of facilities. However, most previous studies focused on the bidding, financing, and building and operation stages instead of transfer stage. This research identifies nine key issues in the transfer stage of BOT projects through a comprehensive study on three cases in China, and the expert interview and expert discussion meetings are held to validate the key issues and give detail analysis. A proposed framework of transfer management is prepared based on the experiences derived and lessons drawn from the case studies and expert interview and discussions, which is expected to improve the transfer management of BOT projects in practice.

Keywords: BOT project, key issues, transfer management, transfer stage

Procedia PDF Downloads 217

Authors: Hermanto J. M, Mirna Febriani

Abstract:

Resin acrylic, which is widely used, has the physical properties that can absorb liquids. This can lead to a change in the dimensions of the acrylic resin material. If repeated immersions were done, its strength would be affected. Disinfectant solutions have been widely used to reduce microorganisms both inside and outside the patient's mouth. One of the disinfecting materials that can be used is a clover solution. The purpose of this research is to find the ratio of water absorption of the acrylic resin material of self-cured type, soaked in clover solution for 10 minutes. The results showed that the average value obtained before soaked in clover solution was 0.0692 mg/cm3 and after soaked, in clover solution, the value was 0.090 mg/cm3. The conclusion of this research shows that the values of water sorption of acrylic resin before and after soaked in clover solution is still in ISO standard 1567/2001. Differences in water sorption value of self-cured acrylic resin before and after the immersion are caused by the process of liquid diffusion into the acrylic resin.

Keywords: absorption of fluid, self-cured acrylic resin, soaked, clover solution

Procedia PDF Downloads 139

Authors: Andrea Borroni

Abstract:

The evolution of technology, the global scale of economy, and the new short-term employment contracts make a very peculiar set of disposition of raising interest for the legal interpreter: the employee inventor compensation. Around the globe, this issue is differently regulated according to the legal systems; therefore, it is extremely fragmented. Of course, employers with transnational businesses should face this issue from a comparative perspective. Different legal regimes are available worldwide awarding, as a consequence, diverse compensation to the inventor and according to their own methodology. Given these premises, the recourse to comparative law methodology (legal formants, diachronic and synchronic methodology, common core approach) is the best equipped to face all these different national approaches in order to achieve a tidy systematic. This research, so, elaborates a map of the specific criteria to grant the compensation for the inventor and to show the criteria to calculate them. This finding has been the first step to find out a common core of the discipline given by the common features present in the different legal systems.

Keywords: comparative law, employee invention, intellectual property, legal transplant

Procedia PDF Downloads 312

Authors: Gheyzer Villegas, Edgardo Cedeño, Veruska Mata, Edmundo Chauran

Abstract:

One of the most significant changes that occurred in global commerce was the emergence of cryptocurrencies and blockchain technology. There is still much debate about the adoption of the economic model based on crypto assets, and myriad international projects and initiatives are being carried out to try and explore the potential that this new field offers. The Hive blockchain is a prime example of this, featuring two use cases: of how trade based on its native currencies can give successful results in the exchange of goods and services and in the financing of social impact projects. Its decentralized management model and visionary administration of its development fund have become a key part of its success.

Keywords: Hive, business, network, blockchain

Procedia PDF Downloads 38

Authors: M. Takhtravanchi, C. Pathirage

Abstract:

In the construction industry, project members are conveyor of project knowledge which is, often, not managed properly to be used in future projects. As construction projects are temporary and unique, project members are willing to be recruited once a project is completed. Therefore, poor management of knowledge across construction projects will lead to a considerable amount of knowledge loss; the ignoring of which would be detrimental to project performance. This issue is more prominent in projects undertaken through the traditional procurement system, as this system does not incentives project members for integration. Thus, disputes exist between the design and construction phases based on the poor management of knowledge between those two phases. This paper aims to highlight the challenges of the knowledge management that exists within the traditional procurement system. Expert interviews were conducted and challenges were identified and analysed by the Interpretive Structural Modelling (ISM) approach in order to summarise the relationships among them. Two identified key challenges are the Culture of an Organisation and Knowledge Management Policies. A knowledge of the challenges and their relationships will help project manager and stakeholders to have a better understanding of the importance of knowledge management.

Keywords: challenges, construction industry, knowledge management, traditional procurement system

Procedia PDF Downloads 400

Authors: Adrian Morris, Rodney Phillips, Mattia Tabacchi

Abstract:

Minimizing construction noise and vibration impacts is a key challenge for major infrastructure projects in urban environments. Before commencing construction works, Construction Noise and Vibration Management Plan (CNVMP) and Construction Noise and Vibration Impact Statements (CNVIS) are required to be prepared and submitted to the relevant government authorities for review and approval. However, the assessment of potential impacts from work activities at pre-approval stage may be inaccurate as works methodology and scheduling are yet to be determined. In response, noise and vibration management tools have been developed to refine and supplement the CNVIS as works progress. These tools have been successfully implemented in major infrastructure projects allowing contractors to plan and assess construction works in a cost effective and timely manner. As a result, noise and vibration management tools have been incorporated into management plans and are increasingly required by regulators.

Keywords: noise management, environmental noise, infrastructure projects, construction, vibration, cost effective

Procedia PDF Downloads 96

Authors: Amna Batool

Abstract:

Agile methodology is the current most popular technique in software development projects. Agile methods in software development bring optimistic impact on software performances, quality and customer satisfaction. There are some organizations and small-medium enterprises adopting agile into their local software development projects as well as in distributed software development projects. Adopting agile methods in local software development projects is valuable. However, agile global software deployment needs an attention. There are different key challenges in agile global software development that need to resolve and enhance the global software development cycles. The proposed systematic literature review investigates all key challenges of agile in global software development. Moreover, a quantitative methodology (an actual survey) targeted to present a real case scenario of these particular key challenges faced by one of the software houses that is BestWeb Malaysia. The outcomes of systematic literature and the results of quantitative methodology are compared with each other to evaluate if the key challenges pointed out in systematic review still exist. The proposed research and its exploratory results can assist small medium enterprises to avoid these challenges by adopting the best practices in their global software development projects. Moreover, it is helpful for novice researchers to get valuable information altogether.

Keywords: agile software development, ASD challenges, agile global software development, challenges in agile global software development

Procedia PDF Downloads 126

Authors: Wafa' Alsharafat, Suhila Farhan Abu-Owida

Abstract:

Genetic algorithm (GA) is a powerful evolutionary searching technique that is used successfully to solve and optimize problems in different research areas. Genetic Algorithm (GA) considered as one of optimization methods used to solve Travel salesman Problem (TSP). The feasibility of GA in finding a TSP solution is dependent on GA operators; encoding method, population size, termination criteria, in general. In specific, crossover and its probability play a significant role in finding possible solutions for Symmetric TSP (STSP). In addition, the crossover should be determined and enhanced in term reaching optimal or at least near optimal. In this paper, we spot the light on using a modified crossover method called modified sequential constructive crossover and its impact on reaching optimal solution. To justify the relevance of a parameter value in solving the TSP, a set comparative analysis conducted on different crossover methods values.

Keywords: genetic algorithm, crossover, mutation, TSP

Procedia PDF Downloads 187