Search results for: construction projects

Authors: A. L. Agarwal, D. A. Mahajan

Abstract:

Construction industry tumbled along with other industry/sectors during recent economic crash. Construction business could not regain thereafter and still pass through slowdown phase, resulted many real estate as well as infrastructure projects not completed on schedule and within budget. There are many theories, tools, techniques with software packages available in the market to analyze construction schedule. This study focuses on the construction project schedule and uncertainties associated with construction activities. The infrastructure construction project has been considered for the analysis of uncertainty on project activities affecting project duration and analysis is done using @RISK software. Different simulation results arising from three probability distribution functions are compiled to benefit construction project managers to plan more realistic schedule of various construction activities as well as project completion to document in the contract and avoid compensations or claims arising out of missing the planned schedule.

Keywords: construction project, distributions, project schedule, uncertainty

Procedia PDF Downloads 321

Authors: Li Ma, Meishuang Ma, Mengying Huang

Abstract:

The quality of construction projects reflects the credit and responsibilities of construction contractors for the owners and the whole society. Because the construction contractors master more relevant information about the entrusted engineering project under construction while the owners are in unfavorable position of gaining information, asymmetric information may lead the contractors act against the owners in order to pursue their own interests. Building a powerful motivation mechanism is the key to guarantee investor economic interests and the life and property of users in construction projects. Based on principal-agent theory and game theory, the authors develop relevant mathematical models to analyze and compare the contractor’s utility functions under different combinations of contracts’ explicit incentive mechanism and reputation’s implicit incentive mechanism aiming at finding out the conditions for incentive validity. The research concludes that the most rational motivation way is to combine the explicit and implicit incentive effects of both contracts and reputation mechanism, and puts forth some measures for problems on account of China’s current situation.

Keywords: construction contractors, contract, reputation, incentive mechanism

Procedia PDF Downloads 486

Authors: Abdulkadir Adamu Shehu

Abstract:

Company’s reputation is an elusive asset. The reputation gained by companies must be preserved for sustainability of the company. However, the construction project is still suffering from declination of character due to the factors that affect their reputation. The problem led to the loss of projects, abandoning of the projects and many more. This contributed to negative impact on the contractors in the construction industry. As for today, previous studies have not investigated in this regards yet. For that reason, this paper examines the factors which could promote contractor’s reputation in the construction industry in Nigeria. To achieve this aim, 140 questionnaires were distributed to the Nigerian contractors. Based on the 67% response rate, descriptive analysis and analysis of variance (ANOVA) were the tools applied for the data obtained to be analysed. The result shows that, good communication system and improve quality of output of products are the most significant variables that can promote contractor’s reputation. The homogenous analyses indicate that there are significant different perceptions of respondents in term of the significant effects. The research concluded that contractor’s reputation in construction industry must be maintained and further research was suggested to focus on the qualitative method to have in-depth knowledge on contractor’s reputation in the construction industry.

Keywords: construction industry, contractor’s reputation, effects of delay, Nigeria

Procedia PDF Downloads 408

Authors: Ringisai Abigail Mawondo-Dhliwayo, Kahilu Kajimo-Shakantu

Abstract:

Due to financial challenges which governments in general face, it is becoming more difficult for many to continually use their limited resources to undertake infrastructural development. Governments increasingly now need other delivery approaches, in particular, the Public-Private Partnerships which make it possible for the public sector to achieve infrastructural development without incurring any/minimum cost. The literature reviewed outlined that benefits of PPPs include timely delivery of quality projects with cost limits. The methodology utilized for the empirical study comprised six interviews and sixty questionnaires which were undertaken and administered by construction consultants and government officials involved in PPPs projects. The results obtained showed that PPPs are not widely used in Zimbabwe although the need for their use exists. The study also found some challenges which prevent or derail the rate at which PPPs are utilized, of which the primary one was a political influence. It is concluded that despite limitations, PPPs remain the most effective and viable option for the delivery of government projects. The study recommends that policy and framework for the implementation of PPPs be developed. More useful information could have been obtained if final users of PPPs projects were included in the sample for data collection.

Keywords: construction projects, procurement, public private partnerships, public sector

Procedia PDF Downloads 233

Authors: Essa Alenazi, Zulfikar Adamu

Abstract:

The Kingdom of Saudi Arabia (KSA) is not an exception in relying on the growth of its construction industry to support rapid population growth. However, its need for infrastructure development is constrained by low productivity levels and cost overruns caused by factors such as delays to project completion. Delays in delivering a construction project are a global issue and while theories such as Optimism Bias have been used to explain such delays, in KSA, client-related causes of delays are also significant. The objective of this paper is to develop a framework-based approach to explore how the country’s construction industry can manage and reduce delays in construction projects through building information modelling (BIM) in order to mitigate the cost consequences of such delays.  It comprehensively and systematically reviewed the global literature on the subject and identified gaps, critical delay factors and the specific benefits that BIM can deliver for the delay management.  A case study comprising of nine hospital projects that have experienced delay and cost overruns was also carried out. Five critical delay factors related to the clients were identified as candidates that can be mitigated through BIM’s benefits. These factors are: Ineffective planning and scheduling of the project; changes during construction by the client; delay in progress payment; slowness in decision making by the client; and poor communication between clients and other stakeholders. In addition, data from the case study projects strongly suggest that optimism bias is present in many of the hospital projects. Further validation via key stakeholder interviews and documentations are planned.

Keywords: building information modelling (BIM), clients perspective, delay management, optimism bias, public sector projects

Procedia PDF Downloads 300

Authors: Mohammad Ashraf

Abstract:

This research links the use of Building Information Modeling technology in constructions and infrastructure projects, starting from the moment when considering the establishment of a project to demolishing or renovating it, going through the design work, planning, procurement and implementation. BIM Software's which used are Revit, Navisworks and Asta Project in the case study for the Atletico Madrid Stadium project (Wanda Stadium). Also, the project improves through various phases of construction (planning - implementation - management). Besides, the level of the details managed within this project advances gradually. In addition, the construction process problems become about 30 % less than before, resulting from high coordination between designing, implementation and follow through that is done by the project management office (PMO). The current disposition in the industry is to tightly manage the detail contained within the planning and coordination phases of construction, but we miss the opportunity to manage that data as it matures and grows into the execution and commissioning phases.

Keywords: construction management, BIM technology, planning, design, procurements, critical path method

Procedia PDF Downloads 257

Authors: Z. Hamed, K. Sa'deya, E. Abdelrasheed, I. Mahamid

Abstract:

The construction industry is one of the main sectors that play basic role in the urban and rural development of a society. It provides important ingredients for the development of an economy. However, many construction projects experience extensive cost overrun. This study was conducted to identify the causes of cost overrun in building construction contracts in Al Madinah, Saudi Arabia and test the importance of these causes from contractors' perspective. To achieve the study objectives, a questionnaire survey was conducted to identify and rank cost overrun causes from the perspective of contractors. The findings found that the top five cost overrun causes are: lack of experience in the line of work, lack of labor productivity, delay in payments, rework and material waste. It is hoped that the findings will guide efforts to improve the performance of construction industry in Saudi Arabia and other developing countries.

Keywords: building, contractor, cost increase, cost overrun

Procedia PDF Downloads 129

Authors: Rashmi Shahu

Abstract:

Flexibility is becoming a more widely accepted aspect of project management. Although contingency theory in project management states that the unknowns are controllable, complexity theory believes that the best way to handle the unknowns would be to have a flexible approach rather than rigidity. Designing a flexible system is a method of managing uncertainty. The present research work aims to evaluate flexibility in the initial design phase of projects taking examples of construction projects. Flexibility in the initial design phase is modeled in order to know the advantage in future. The comparison between the extra cost of flexibility in the initial design phase and the discount that can be achieved in future due to this premium will help the developers in making strategic decisions. This research uses a methodology for valuing flexibility by developing a mathematical formula for predicting future saving of cost. Two case studies were considered in this research to validate the mathematical formula. This research explains three case studies of an educational institution 28 years old for explaining the concept and giving benefits of flexible design for modification/renovation work of building.

Keywords: flexibility, future saving, flexibility cost, construction projects

Procedia PDF Downloads 336

Authors: Ahmed Stifi, Sascha Gentes, Fritz Gehbauer

Abstract:

The construction industry is perhaps one of the oldest industry of the world. The ancient monuments like the egyptian pyramids, the temples of Greeks and Romans like Parthenon and Pantheon, the robust bridges, old Roman theatres, the citadels and many more are the best testament to that. The industry also has a symbiotic relationship with other . Some of the heavy engineering industry provide construction machineries, chemical industry develop innovative construction materials, finance sector provides fund solutions for complex construction projects and many more. Construction Industry is not only mammoth but also very complex in nature. Because of the complexity, construction industry is prone to various tribulations which may have the propensity to hamper its growth. The comparitive study of this industry with other depicts that it is associated with a state of tardiness and delay especially when we focus on the managerial aspects and the study of triple constraint (time, cost and scope). While some institutes says the complexity associated with it as a major reason, others like lean construction, refers to the wastes produced across the construction process as the prime reason. This paper introduces corruption as one of the prime factors for such delays.To support this many international reports and studies are available depicting that construction industry is one of the most corrupt sectors worldwide, and the corruption can take place throught the project cycle comprising project selection, planning, design, funding, pre-qualification, tendering, execution, operation and maintenance, and even through the reconstrction phase. It also happens in many forms such as bribe, fraud, extortion, collusion, embezzlement and conflict of interest and the self-sufficient. As a solution to cope the corruption in construction industry, the paper introduces the integrity as a key factor and build a new integrity framework to develop and implement an integrity management system for construction companies and construction projects.

Keywords: corruption, construction industry, integrity, lean construction

Procedia PDF Downloads 354

Authors: Khaled Abu Awwad, Abdussalam Shibani, Michel Ghostin

Abstract:

In the last few years, building information modelling (BIM) has been acknowledged as a new technology capable of transforming the construction sector to a collaborated industry. The implementation of BIM in the United Kingdom (UK) construction sector has increased significantly in the last decade, particularly after the UK government mandated the use of BIM in all public projects by 2016. Despite this, there are many indicators that BIM implementation is the main concern for large companies, while small and medium-sized enterprises (SMEs) are lagging behind in adopting and implementing this new technology. This slow adoption of BIM leads to an uncompetitive disadvantage in public projects and possible private projects. On the other hand, there is limited research focusing on the implementation of BIM Level 2 within SMEs. Therefore, the aim of this study is to bridge this gap and provide a conceptual framework to aid SMEs in implementing BIM Level 2. This framework is a result of interpreting qualitative data obtained by conducting semi-structured interviews with BIM experts in the UK construction industry.

Keywords: building information modelling, critical success factors, small and medium-sized enterprises, United Kingdom

Procedia PDF Downloads 185

Authors: S. Abdulkadir, I. Y. Moh’d, S. U. Kunya, U. Nuruddeen

Abstract:

The basis of any contract formation between the client and contractor is the budgeted cost and the estimated duration of projects. These variables are paramount important to project's sponsor in a construction projects and in assessing the success or viability of construction projects. Despite the availability of various techniques of cost and time control, many projects failed to achieve their initial estimated cost and time. The paper evaluate the inhibiting factors of cost and time control in Nigerian construction practice and comparing the result with the United Kingdom practice as identified by one researcher. The populations of the study are construction professionals within Bauchi and Gombe state, Nigeria, a judgmental sampling employed in determining the size of respondents. Descriptive statistics used in analyzing the data in SPSS. Design change, project fraud and corruption, financing and payment of completed work found to be common among the top five inhibiting factors of cost and time control in the study area. Furthermore, the result had shown some comprising with slight contrast as in the case of United Kingdom practice. Study recommend the adaptation of mitigation measures developed in the UK prior to assessing its effectiveness and so also developing a mitigating measure for other top factors that are not within the one developed in United Kingdom practice. Also, it recommends a wider assessing comparison on the modify inhibiting factors of cost and time control as revealed by the study to cover almost all part of Nigeria.

Keywords: comparison, cost, inhibiting factor, United Kingdom, time

Procedia PDF Downloads 418

Authors: Ali A. Karakhan

Abstract:

Stakeholders in the architecture, engineering, and construction (AEC) industry have been always searching for strategies to develop, design, and construct healthy and smart building projects. Healthy and smart building projects require that the building process including design and construction be altered and carefully implemented in order to bring about sustainable outcomes throughout the facility lifecycle. Healthy and smart building projects are expected to positively influence organizational success and facility performance across the project lifecycle leading to superior outcomes in terms of people, economy, and the environment. The present study aims to identify potential strategies that AEC organizations can implement to achieve healthy and smart building projects. Drivers and barriers for healthy and smart building features are also examined. The study findings indicate that there are three strategies to advance the development of healthy and smart building projects: (1) the incorporation of high-quality products and low chemical-emitting materials, (2) the integration of innovative designs, methods, and practices, and (3) the adoption of smart technology throughout the facility lifecycle. Satisfying external demands, achievement of a third-party certification, obtaining financial incentives, and a desire to fulfill professional duty are identified as the key drivers for developing healthy and smart building features; whereas, lack of knowledge and training, time/cost constrains, preference for/adherence to customary practices, and unclear business case for why healthy buildings are advantageous are recognized as the primary barriers toward a wider diffusion of healthy and smart building projects. The present study grounded in previous engineering, medical, and public health research provides valuable technical and practical recommendations for facility owners and industry professionals interested in pursuing sustainable, yet healthy and smart building projects.

Keywords: healthy buildings, smart construction, innovative designs, sustainable projects

Procedia PDF Downloads 136

Authors: Panagiotis Karadimos, Leonidas Anthopoulos

Abstract:

Predicting the actual cost and duration in construction projects concern a continuous and existing problem for the construction sector. This paper addresses this problem with modern methods and data available from past public construction projects. 39 bridge projects, constructed in Greece, with a similar type of available data were examined. Considering each project’s attributes with the actual cost and the actual duration, correlation analysis is performed and the most appropriate predictive project variables are defined. Additionally, the most efficient subgroup of variables is selected with the use of the WEKA application, through its attribute selection function. The selected variables are used as input neurons for neural network models through correlation analysis. For constructing neural network models, the application FANN Tool is used. The optimum neural network model, for predicting the actual cost, produced a mean squared error with a value of 3.84886e-05 and it was based on the budgeted cost and the quantity of deck concrete. The optimum neural network model, for predicting the actual duration, produced a mean squared error with a value of 5.89463e-05 and it also was based on the budgeted cost and the amount of deck concrete.

Keywords: actual cost and duration, attribute selection, bridge construction, neural networks, predicting models, FANN TOOL, WEKA

Procedia PDF Downloads 115

Authors: Mengxia Jin, Yongqiang Chen, Wenqian Wang, Yu Wang

Abstract:

The complexity and specificity of construction projects have made common opportunism phenomenon, and contractual governance for opportunism has been a topic of considerable ongoing research. Based on TCE, the research distinguishes control and coordination as different functions of the contract to investigate their complexity separately. And in a nuanced way, the dimensionality of contractual control is examined. Through the analysis of motivation and capability of strong or weak form opportunism, the framework focuses on the relationship between the complexity of above contractual dimensions and different types of opportunistic behavior and attempts to verify the possible explanatory mechanism. The explanatory power of the research model is evaluated in the light of empirical evidence from questionnaires. We collect data from Chinese companies in the construction industry, and the data collection is still in progress. The findings will speak to the debate surrounding the effects of contract complexity on opportunistic behavior. This nuanced research will derive implications for research on the role of contractual mechanisms in dealing with inter-organizational opportunism and offer suggestions for curbing contract parties’ opportunistic behavior in construction projects.

Keywords: contractual complexity, contractual control, contractual coordinatio, opportunistic behavior

Procedia PDF Downloads 363

Authors: M. Aladwani, Y. Alarfaj

Abstract:

The construction industry is currently experiencing a shift towards digitisation. This transformation is driven by adopting technologies like Building Information Modelling (BIM), drones, and augmented reality (AR). These advancements are revolutionizing the process of designing, constructing, and operating projects. BIM, for instance, is a new way of communicating and exploiting technology such as software and machinery. It enables the creation of a replica or virtual model of buildings or infrastructure projects. It facilitates simulating construction procedures, identifying issues beforehand, and optimizing designs accordingly. Drones are another tool in this revolution, as they can be utilized for site surveys, inspections, and even deliveries. Moreover, AR technology provides real-time information to workers involved in the project. Implementing these technologies in the construction industry has brought about improvements in efficiency, safety measures, and sustainable practices. BIM helps minimize rework and waste materials, while drones contribute to safety by reducing workers' exposure to areas. Additionally, AR plays a role in worker safety by delivering instructions and guidance during operations. Although the digital transformation within the construction industry is still in its early stages, it holds the potential to reshape project delivery methods entirely. By embracing these technologies, construction companies can boost their profitability while simultaneously reducing their environmental impact and ensuring safer practices.

Keywords: BIM, digital construction, construction technologies, digital transformation

Procedia PDF Downloads 61

Authors: Mohammad Reza Zamanian

Abstract:

The construction industry has always been recognized as one of the most dangerous available industries, and the statistics of accidents and injuries resulting from it say that the safety category needs more attention and the arrival of up-to-date technologies in this field. Building information modeling (BIM) is one of the relatively new and applicable technologies in Iran, that the necessity of using it is increasingly evident. The main purposes of this research are to evaluate the feasibility of using this technology in the safety sector of construction projects and to evaluate the effectiveness and operationality of its various applications in this sector. These applications were collected and categorized after reviewing past studies and researches then a questionnaire based on Delphi method criteria was presented to 30 experts who were thoroughly familiar with modeling software and safety guidelines. After receiving and exporting the answers to SPSS software, the validity and reliability of the questionnaire were assessed to evaluate the measuring tools. Fuzzy logic is a good way to analyze data because of its flexibility in dealing with ambiguity and uncertainty issues, and the implementation of the Delphi method in the fuzzy environment overcomes the uncertainties in decision making. Therefore, this method was used for data analysis, and the results indicate the usefulness and effectiveness of BIM in projects and improvement of safety status at different stages of construction. Finally, the applications and the sections discussed were ranked in order of priority for efficiency and effectiveness. Safety planning is considered as the most influential part of the safety of BIM among the four sectors discussed, and planning for the installation of protective fences and barriers to prevent falls and site layout planning with a safety approach based on a 3D model are the most important applications of BIM among the 18 applications to improve the safety of construction projects.

Keywords: building information modeling, safety of construction projects, Delphi method, fuzzy logic

Procedia PDF Downloads 143

Authors: Ghaleb Y. Abbasi, Sufyan Al-Mrayat

Abstract:

This study examined the contribution of thirty-six factors to building construction project’s cost overrun in Jordan. A questionnaire was distributed to a random sample of 350 stakeholders comprised of owners, consultants, and contractors, of which 285 responded. SPSS analysis was conducted to identify the top five causes of cost overrun, which were a large number of variation orders, inadequate quantities provided in the contract, misunderstanding of the project plan, incomplete bid documents, and choosing the lowest price in the contract bidding. There was an agreement among the study participants in ranking the factors contributing to cost overrun, which indicated that these factors were very commonly encountered in most construction projects in Jordan. Thus, it is crucial to enhance the collaboration among the different project stakeholders to understand the project’s objectives and set a realistic plan that takes into consideration all the factors that might influence the project cost, which might eventually prevent cost overrun.

Keywords: cost, overrun, building construction projects, Jordan

Procedia PDF Downloads 78

Authors: Srikanth Nagarajan, P. Parthasarathy, Frits Lagers

Abstract:

Lower crude oil prices increased the pressure on oil and gas projects. Being competitive becomes very important and critical for the success in any industry. Increase in size of the project multiplies the magnitude of the issue. Timely completion of projects within the budget and schedule is very important for any project to succeed. A simple idea makes a larger impact on the total cost of the plant. In this robust world, the phases of engineering right from licensing technology, feed, different phases of detail engineering, procurement and construction has been so much compressed that they overlap with each other. Hence constructability techniques have become very important. Here in this paper, the focus will be on how these techniques can be implemented and reduce cost with the help of a case study. Constructability is a process driven by the need to impact project’s construction phase resulting in improved project delivery, costs and schedule. In construction phase of one of our fast-track mega project, it was noticed that there was an opportunity to reduce significant amount of cost and schedule by implementing Constructability study processes. In this case study, the actual methodology adopted during engineering and construction and the way for doing it better by implementing Constructability techniques with collaborative engineering efforts will be explained.

Keywords: being competitive, collaborative engineering, constructability, cost reduction

Procedia PDF Downloads 392

Authors: Saleh Alzahrani, Halim Boussabaine

Abstract:

Many of Public Private Partnership (PPP) are developed based on a public project is to be awarded to a private party within a one contractual framework. PPP project risks typically include the development and construction of a new asset as well as its operation. Certainly the most severe consequences of risks through the construction period are price and time overruns. These events are among the most generally used situation in value for money analysis risks. The sources of risk change during the time in PPP project. In traditional procurement, the public sector usually has to cover all prices suffering from these risks. At least there is plenty to suggest that price suffering is a norm in some of the projects that are delivered under traditional procurement. This paper will find the impact of exogenous risk factors into actual construction price into PPP projects. The paper will present a brief literature review on PPP risk pricing strategies and then using system dynamics (SD) to analyses of the risks associated with the estimated project price. Based on the finding from these analyses a risk pricing association model is presented and discussed. The paper concludes with thoughts for future research.

Keywords: public private partnership (PPP), risk, risk pricing, system dynamics (SD)

Procedia PDF Downloads 525

Authors: Saou Mohamed Amine

Abstract:

The construction industry has been identified as a user of substantial amount of materials and energy resources that has an enormous impact on environment. The energy efficient in refurbishment project is being considered as one of the approaches to achieve sustainability in construction industry. The increasing concern for environment has made building owners and designers to incorporate the energy efficiency features into their building projects. However, an overwhelming issue of existing non-energy efficient buildings which exceeds the number of new building could be ineffective if the buildings are not refurbished through the energy efficient measures. Thus, energy efficient in refurbishment project is being considered as one of the approaches to achieve sustainability that offers significant opportunities for reducing global energy consumption and greenhouse gas emissions. However, the quality of design team attributes and the characteristics of the refurbishment building projects have been argued to be the main factors that determine the energy efficiency performance of the building.

Keywords: construction industry, design team attributes, energy efficient performance, refurbishment projects characteristics

Procedia PDF Downloads 342

Authors: Alaa A. Al-Harthi, Abdulrahman S. Bageis, Bingunath Ingirige

Abstract:

Poor levels of performance and low productivity were highlighted by many previous studies as a major cause of failure in the Saudi construction industry. This paper provides recommendations to address key external indicators that led to poor levels of performance and low productivity in Engineering and Technical Departments (ETDs) within the Saudi governmental agencies. The ETDs are client’s representative on behalf of the Saudi Ministries. This paper represents a part of an investigation which contained external and internal challenges that led to occurrence of the research problem. The paper is focusing on the external challenges which contain 14 indicators. These 14 external indicators had been examined carefully through comprehensive review of the literature then have been tested through quantitative and qualitative methods. 400 questionnaires were distributed to dozens of different bodies. The actual response rate was 47% completed responses. Four semi-structured interviews were conducted with senior practitioners from the Public Construction Sector. The finding showed that the 14 external indicators directly and/or indirectly influence the Public Construction Sector. It was noticed significantly that these indicators have prevented the ETDs from performing properly. It was also found that the 14 external indicators were constant with all kinds of Government Construction Projects in the Saudi context. Addressing the 14 external indicators requires to be planned over the long run which is responsible by relevant Saudi governmental authorities under the umbrella of the Saudi Council of Ministers. The study recommends that Project Management Office (PMO) should be considered in order to improve the performance of the ETDs.

Keywords: construction projects' performance, low engineering productivity, public construction sector

Procedia PDF Downloads 573

Authors: Edoghogho Ogbeifun, Charles Mbohwa, J. H. C. Pretorius

Abstract:

Several research report on the factors responsible for the delays in the completion of construction projects has identified the issue of funding as a critical factor; insufficient funding, low cash-flow or lack of funds. Indeed, adequate funding plays pivotal role in the effective execution of construction projects. In the last twenty years (or so), there has been increase in the funds available for infrastructure development in tertiary institution in Nigeria, especially, through the Tertiary Education Trust Fund. This funding body ensures that there is enough fund for each approved project, which is released in three stages during the life of the construction project. However, a random tour of many of the institutions reveals striking evidence of projects not delivered on schedule, to quality and sometime out rightly abandoned. This suggests, therefore, that there are other latent factors, responsible for project delays, that should be investigated. Thus, this research, a pilot scheme, is aimed at unearthing the possible reasons for the delays being experienced in the execution of construction projects for infrastructure upgrade in public tertiary institutions in Nigeria, funded by Tertiary Education Trust Fund. The multiple site case study of qualitative research was adopted. The respondents were the Directors of Physical Planning and the Directors of Works of four Nigerian Public Universities. The findings reveal that delays can be situated within three entities, namely, the funding body, the institutions and others. Therefore, the emerging factors have been classified as external factors (haven to do with the funding body), internal factors (these concern the operations within the institutions) and general factors. The outcome of this pilot exercise provides useful information to guide the Directors as they interact with the funding body as well as challenges themselves to address the loopholes in their internal operations.

Keywords: delays, external factors, funding, general factors, Internal factors

Procedia PDF Downloads 124

Authors: Shahin Shabani, Pouya Pourmadadi

Abstract:

Tunnel boring machines (TBMs) have been used for the construction of various tunnels for mining projects for the purpose of access, conveyance of ore and waste, drainage, exploration, water supply and water diversion. Several mining projects have seen the successful and economic beneficial use of TBMs, and there is an increasing awareness of the benefits of TBMs for mining projects. Key technical considerations for the use of TBMs for the construction of tunnels for mining projects include geological issues (rock type, rock alteration, rock strength, rock abrasivity, durability, ground water inflows), depth of cover and the potential for overstressing/rockbursts, site access and terrain, portal locations, TBM constraints, minimum tunnel size, tunnel support requirements, contractor and labor experience, and project schedule demands. This study focuses on tunnelling mining, with the goal to develop methods and tools to be used to gain understanding of these processes, and to analyze metro of Tehran. The Metro Line 7 of Tehran is one of the Longest (26 Km) and deepest (27m) of projects that’s under implementation. Because of major differences like passing under all geotechnical layers of the town and encountering part of it with underground water table and also using mechanized excavation system, is one of special metro projects.

Keywords: TBM, tunnel boring machines economic, metro, line 7

Procedia PDF Downloads 366

Authors: Othoman Elsayah, Naren Gupta, Binsheng Zhang

Abstract:

The construction sector constitutes one of the most important sectors in the economy of any country. Contractor selection is a critical decision that is undertaken by client organizations and is central to the success of any construction project. Contractor selection (CS) is a process which involves investigating, screening and determining whether candidate contractors have the technical and financial capability to be accepted to formally tender for construction work. The process should be conducted prior to the award of contract, characterized by many factors such as: contactor’s skills, experience on similar projects, track- record in the industry, and financial stability. However, this paper evaluates the current state of knowledge in relation to contractor selection process and demonstrates the findings from the analysis of the data collected from the Delphi questionnaire survey. The survey was conducted with a group of 12 experts working in the Libyan construction industry (LCI). The paper starts by briefly explaining the general outline of the questionnaire including the survey participation rate, the different fields the experts came from, and the business titles of the participants. Then, the paper describes the tests used to determine when the experts had reached consensus. The paper is based on research which aims to develop rank contractor selection criteria with specific application to make construction projects in the Libyan context. The findings of this study will be utilized to establish the scope of work that will be used as part of a PhD research.

Keywords: contractor selection, Libyan construction industry, decision experts, Delphi technique

Procedia PDF Downloads 311

Authors: Alireza Ghaffari, Hassan Saghi

Abstract:

Project management is more complex than managing the day-to-day affairs of an organization. When the project dimensions are broad and multiple projects have to be monitored in different locations, the integrated management becomes even more complicated. One of the main concerns of project managers is the integrated project management, which is mainly rooted in the lack of accurate and accessible information from different projects in various locations. The collection of dispersed information from various parts of the network, their integration and finally the selective reporting of this information is among the goals of integrated information systems. It can help resolve the main problem, which is bridging the information gap between executives and senior managers in the organization. Therefore, the main objective of this study is to design and implement an important subset of a project management information system in order to successfully control the cost of construction projects so that its results can be used to design raw software forms and proposed relationships between different project units for the collection of necessary information.

Keywords: financial performance, cost subsystem, PMIS, project management

Procedia PDF Downloads 86

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: construction, delay factors, time delay, australian construction industry

Procedia PDF Downloads 153

Authors: Muhammad Lawal A., Abdullateef Abdulkarim Jimoh

Abstract:

This study is to appraise the labour-saving construction methods achievable using a buildability framework through an improved design system. Adoption of labour-efficient technology and construction techniques will be necessary to supplement good buildable designs. Increased usage of prefabricated, modular, and standardized construction components, simplicity in the design, and the number of integrated elements all work to advance buildable design. The objectives of the study include `determining a more efficient buildability framework for designers to achieve labour-saving construction’. 20 completed building projects in Birnin Kebbi, Nigeria, is used as a case study to buttress the proposition that `a more buildable design using buildability frame result in labour-saving in construction adopting a Singapore study approach.

Keywords: buildability framework, buildable designs, construction, labour-saving construction

Procedia PDF Downloads 74

Authors: Mohammed F. Haddad, Mohammad A. Albenayyan

Abstract:

Realistically, 3-D printing as a technology has not yet reached the required maturity level to handle construction housing projects for citizens on a country scale. However, potentially, it has all of the required elements for addressing this issue. There are two main high-level elements of this technology that need to be capitalized on in order for the technology to reach its full potential, technical and logistical. This paper aims to cover how 3-D printing can be a viable technical solution for housing projects and describe the impact of 3-D printing technical features on the logistical aspects of completing a housing project. Additionally, a perspective about 3-D printing in Saudi Arabia will be presented in order to give the reader an idea of where the kingdom stands in the deployment of this technology. Finally, a glimpse will be given regarding the potential utilization of this technology for space applications.

Keywords: large-scale 3-D printing, additive manufacturing, D- shape, contour crafting

Procedia PDF Downloads 107

Authors: Ayushi Mishra

Abstract:

Migrant construction workers or construction labors are one of the majority of the working population in our urban and rural areas. Even after being the majority, their involvement in the upbringing of the economy is hardly ever documented or recognized. Non-permanent or migrant workers face loads of exploitations and susceptibilities than other informal sector workers in India which in turn has affected the productivity of the labors. The relation of their employment and migration and the links of these dynamics to their housing and other basic needs in the city are mostly unstated. Even the urban planning and housing policies do not make thoughtful provision for them, they forcing them to live in extremely wretched conditions. And even if the policies are made, it frequently happens that they are not implemented. As the issue is very much prevalent in today’s time in India with so many large-scale and labor extensive projects going on, this study focuses on the assessment of the gap between the existing government policies and the current scenario of the construction workers in ongoing projects of Vijayawada, Andhra Pradesh. A few of the policies for construction workers conditions a lot of things, out of which only a few are functional which makes this study to assess the reason behind the unorganized living condition and poor physical, the social and mental health of construction workers of Vijayawada. In present, the dignity of construction labors is compromised every day on construction sites, in terms of work and basic rights which leads to many other problems in future. So to work for the betterment of this community, knowledge on the differences is very much required and hence this study is a little effort to replenish the difference and compare the policies with the existing conditions of construction labors in Vijayawada.

Keywords: construction, labours, policy, productivity

Procedia PDF Downloads 305

Authors: R. M. Rajapaksa

Abstract:

Construction industry is one of the key players in driving the economy of a country to achieve its prosperity. However, a dispute is one of the crucial factors which prevent the completion of construction contracts within the budgeted cost, scheduled time, and accepted quality. Disputes are inevitable in the construction contract. Accordingly, a study has been undertaken to identify the factors affecting contractual disputes in construction projects in Sri Lanka. The study was a mixed approach with major qualitative and minor quantitative. Qualitative study was set in the form of in-depth interviews with eighteen participants, and quantitative study was conducted using a questionnaire with twenty-four respondents from previously implemented projects by the National Water Supply & Drainage Board representing the employer, engineer and the Contractor to identify the factors affecting contractual disputes and to verify most critical factors respectively. Data analysis for qualitative and quantitative studies was carried out by means of transcribing, code & categorizeand average score methods, respectively. The study reveals that there are forty factors affecting the contractual disputes in construction contracts in Sri Lanka. The finding further illustrates that conflicting decisions by inexperience personnel in the higher position of the Employer, ambiguities resulting inadequate descriptions of the preliminary/general items in price schedule, unfair valuation and late confirmation of variations, unfair determination due to lack of experience of the Engineer/Consultant, under certification of progress payments, unfair grant of EOT & application of delay damages, unreasonable claims for variation of works, errors/discrepancies/ambiguities in the contract conditions and discrepancies & errors in designs & specifications are the most critical factors affecting contractual disputes. Finally, the study proposed remedial measures to most critical factors affecting contractual disputes.

Keywords: dispute, contractual, factors, employer, engineer, contractor, construction projects

Procedia PDF Downloads 190