Search results for: public/private projects

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 485

Authors: Sujin Hwang, Hyerang Park, Hyunchul Kim

Abstract:

The purpose of this study is to find the effectiveness of the admission simplification policy. The number of online news articles about ‘high school record’ was collected and semantically analyzed to identify and analyze the social awareness during 2014 to 2015. The main results of the study are as follows: First, there was a difference in expectations that the burden of the examinees would decrease as announced by KCUE. Thus, there was still a strain on the university entrance exam after the enforcement of the policy. Second, private tutoring is expanding in different forms, rather than reducing the policy. It is different from the prediction that examinees can prepare for university admissions without the private tutoring. Thus, the college admission rules currently enforced needs to be improved. The reasonable college admission system changes are discussed.

Keywords: education policy, private tutoring, shadow education, education admission policy

Procedia PDF Downloads 204

Authors: Wanda Luen-Wun Siu, Xiaowen Zhang

Abstract:

This paper offered the primary methodical proof on how CSR reporting related to enterprise earnings in listed firms in China in light of most evidence focusing on cross-sectional data or data in a short span of time. Using full economic and business panel data on China’s publicly listed enterprise from 2006 to 2020 over two decades in the China Stock Market and Accounting Research database, we found initial evidence of significant direct relations between CSR reporting and firm corporate performance in both state-owned and privately owned firms over this period, supporting the stakeholder theory. Results also revealed that state-owned enterprises performed as well as private enterprises in the current period. But private enterprises performed better than state-owned enterprises in the subsequent years. Moreover, the release of social responsibility reports had a more significant impact on the financial performance of state-owned and private enterprises in the current period than in the subsequent periods. Specifically, CSR release was not significantly associated with the financial performance of state-owned enterprises on the lag of the first, second, and third periods. But it had an impact on the lag of the first, second, and third periods among private enterprises. Such findings suggested that CSR reporting helped improve the corporate financial performance of state-owned and private enterprises in the current period, but this kind of effect was more significant among private enterprises in the lag periods.

Keywords: China’s listed firms, CSR reporting, financial performance, panel analysis

Procedia PDF Downloads 145

Authors: K. Y. Chen, Y. N. Jia, H. Chua, C. W. Kan

Abstract:

As the largest developing country in the world, China is now facing the problem arising from the environment. Thus, China government increases the environmental investment yearly. In this study, we will analyse the effect of the public environmental investment on the sustainable development in China. Firstly, we will review the current situation of China's environmental issue. Secondly, we will collect the yearly environmental data as well as the information of public environmental investment. Finally, we will use the collected data to analyse and project the SWOT of public environmental investment in China. Therefore, the aim of this paper is to provide the relationship between public environmental investment and sustainable development in China. Based on the data collected, it was revealed that the public environmental investment had a positive impact on the sustainable development in China as well as the GDP growth. Acknowledgment: Authors would like to thank the financial support from the Hong Kong Polytechnic University for this work.

Keywords: China, public environmental investment, sustainable development, analysis

Procedia PDF Downloads 341

Authors: Bahram Siavashpor, Zeynab Haji Abdolhadi

Abstract:

The issue of the worn out textures is one of the urban community challenges in which, undoubtedly, the intervention is impossible without the social involvement. Some believe that in the worn out areas the most important intervention challenge is the social issues, and the most important social issue, in the intervention in the worn out areas, is how to attract public participation. Participation by itself has a widespread literature and despite relative acceptance, it should be said that planners, managers and designers are not always successful in attracting public participation. If participation means the intervention of all the residents in the neighborhood, women’s community forms half of these residents, but they are neglected in the participatory planning. It is important to know that to what extent the presence of women’s community in the related participation to the worn out textures affects the success of the projects. The present study hypotheses emphasize the effectiveness of women than men in involvement of the renovation and reforming projects. A case study was selected to investigate this hypothesis in order to test it through doing a questionnaire and visiting the place. Tehran Helal Ahmar region located in district 11 has 2740 households in which 51% are men and 49% women. The statistical population consists of 150 men and women of this area selected randomly. In the present study, interview technique with the executives was used as well as questionnaire along collecting the related research. The hypothesis analysis was carried out through SPSS and Excel software, in which two tests ‘Man-Whitney’ and ‘chi-square’ were used. The results indicate that women are empowered in the participation and renovation of the area, but it is necessary to rectify men’s attitude towards women’s ability in terms of women participation.

Keywords: renovation, social involvement, women’s participation, worn out texture

Procedia PDF Downloads 178

Authors: Sani AbdulRahman Bala

Abstract:

This empirical study delves into the realm of forensic accounting practices within the Nigerian Public Sector, seeking to quantitatively analyze their efficacy in addressing the persistent challenges of fraud and financial irregularities. With a focus on empirical data, this research employs a robust methodology to assess the current state of fraud in the Nigerian Public Sector and evaluate the performance of existing forensic accounting measures. Through quantitative analyses, including statistical models and data-driven insights, the study aims to identify patterns, trends, and correlations associated with fraudulent activities. The research objectives include scrutinizing documented fraud cases, examining the effectiveness of established forensic accounting practices, and proposing data-driven strategies for enhancing fraud detection and prevention. Leveraging quantitative methodologies, the study seeks to measure the impact of technological advancements on forensic accounting accuracy and efficiency. Additionally, the research explores collaborative mechanisms among government agencies, regulatory bodies, and the private sector by quantifying the effects of information sharing on fraud prevention. The empirical findings from this study are expected to provide a nuanced understanding of the challenges and opportunities in combating fraud within the Nigerian Public Sector. The quantitative insights derived from real-world data will contribute to the refinement of forensic accounting strategies, ensuring their effectiveness in addressing the unique complexities of financial irregularities in the public sector. The study's outcomes aim to inform policymakers, practitioners, and stakeholders, fostering evidence-based decision-making and proactive measures for a more resilient and fraud-resistant financial governance system in Nigeria.

Keywords: fraud, financial irregularities, nigerian public sector, quantitative investigation

Procedia PDF Downloads 33

Authors: Kanyapat U. Tapao

Abstract:

The purpose of this study is to analyze the operation strategy strategies and public relations trend for public relations strategies development in public television station in Thailand. This study is a qualitative approach by indent interview from the 6 key informants that are managers of Voice TV and Thairath TV Channel. The results showed that both TV stations have to do research before making a release on the operation strategy policy such as a slogan, segmentation, integrated marketing communication and PR activity and also in term of Public Relations trend are including online media, online content and online training before opening the station and start promoting. By the way, we found the PR strategy for both TV station should be including application on mobile, online content, CRM activity, online banner, special event, and brand ambassador in order to bring a very reliable way.

Keywords: online banner, operation strategy, public relations trend, public relations strategies development

Procedia PDF Downloads 297

Authors: Sumudu Sameera Perera Kimmantudawage, Chapal Khasnabis

Abstract:

Technology is changing at a rapid rate, with innovations in robotics being hailed and tested in countries such as Japan, the United States and Australia, however the conversation in a public health context is stagnant. While obvious barriers to robotics use in low and middle-income countries and regions exist, the avoidance of attempting to address these regions of the world may potentially lead to an ever-increasing divide between those of high income countries and those of less. A systematic review was undertaken to determine the number of projects involving research, development and testing of robotics considered low and middle-income regions. Major findings indicate that an overwhelmingly significant number of projects failed to consider low and middle-income countries or regions. These results are unsurprising however alarming, as bridging the divide is an important step forward in achieving the UN Sustainable Development Goals by 2030. It is hoped that this research would spawn future robotics research that focusses on lower and middle-income regions.

Keywords: assistive technology, health equality, robotics, socioeconomic

Procedia PDF Downloads 208

Authors: Armen Yezekyan

Abstract:

The main purpose of this research is to comprehensively explore and identify the problems of attestation of the public servants and to propose solutions for these issues through deeply analyzing laws and the legal theoretical literature. For the detailed analysis of the above-mentioned problems we will use some research methods, the implementation of which has a goal to ensure the objectivity and clarity of scientific research and its results.

Keywords: attestation, attestation commission, competition commission, public servant, public service, testing

Procedia PDF Downloads 396

Authors: Daniel Joseph Whittaker

Abstract:

This paper examines the broad array of historic sites from which Chicago common brick has emerged, and the methods this brick has been utilized within and around a new hybrid structure recently completed-and periodically opened to the public, as a private art, architecture, design, and social activism gallery space. Various technical aspects regarding the structural and aesthetic reuse methods of salvaged brick within the interior and exterior of this new Tadao Ando-designed building in Lincoln Park, Chicago, are explored. This paper expands specifically upon the multiple possible origins of Chicago common brick, as well as the extant brick currently composing the surrounding alley which is integral to demarcating the southern site boundary of the old apartment building now gallery. Themes encompassing Chicago’s archeological and architectural history, local resource extraction, and labor practices permeate this paper’s investigation into urban, social and architectural history and building construction technology advancements through time.

Keywords: masonry construction, history brickmaking, private museums, Chicago Illinois, Tadao Ando

Procedia PDF Downloads 150

Authors: Nnadi Ezekiel Ejiofor

Abstract:

In Enugu, Nigeria, this study investigates the connection between strategic leadership and project management sustainability, with an emphasis on building projects in the State. The study set out to accomplish two specific goals: first, it sought to establish a link between creative project management and resource efficiency in construction projects in Enugu State, Nigeria; and second, it sought to establish a link between innovative thinking and waste minimization in those same projects. A structured questionnaire was used to collect primary data from 45 registered construction enterprises in the study area as part of the study's descriptive research approach. Due to the nonparametric nature of the data, Spearman Rank Order Correlation was used to evaluate the acquired data. The findings demonstrate that creative project management had a significant positive impact on resource efficiency in construction projects carried out by architecture firms in Enugu State, Nigeria (r =.849; p.001), and that innovative thinking had a significant impact on waste reduction in those same projects (r =.849; p.001). It was determined that strategic leadership had a significant impact on the sustainability of project management, and it was thus advised that project managers should foresee, prepare for, and effectively communicate present and future developments to project staff in order to ensure that the objective of sustainable initiatives, such as recycling and reuse, is implemented in construction projects.

Keywords: construction, project management, strategic leadership, sustainability, waste reduction

Procedia PDF Downloads 29

Authors: Sungik Kang, Ja-Hoon Koo

Abstract:

Globally, urban environments have become unequal, and cities have been segmented by income class. It is predicted that urban inequality has arisen by urban redevelopment and reconstruction projects that improve the urban environment and innovate cities. This study aims to analyze the occurrence and characteristics of urban inequality by using the housing price and sale price and demonstrating the correlation with the urban redevelopment project. This study measures 14 years of urban inequality index for 25 autonomous districts in Seoul and analyzes the correlation between urban inequality with urban redevelopment projects. As a conclusion of this study, first, the urban inequality index of Seoul has been continuously rising since 2015. Trends from 2006 to 2019 have been in U-curved shape in between 2015. In 2019, Seoul's urban inequality index was 0.420, a level similar to that of the 2007 financial crisis. Second, the correlation between urban redevelopment and urban inequality was not statistically significant. Therefore, we judged that urban redevelopment's scale or project structure has nothing with urban inequality. Third, while district designation of urban reconstruction temporarily alleviates urban inequality, the completion of the project increases urban inequality. When designating a district, urban inequality is likely to decrease due to decreased outdated housing transactions. However, the correlation with urban inequality increases as expensive houses has been placed after project completion.

Keywords: urban inequality, urban redevelopment projects, urban reconstruction projects, housing price inequality, panel analysis

Procedia PDF Downloads 186

Authors: Abdullah Almusharraf, Andrew Whyte

Abstract:

The sub-task pattern in terms of the deviations and defects should be identified and understand in order to improve the quality practices in construction projects. Therefore, the sub-task susceptibility to exposure to deviations and defects have been evaluated and classified via six classifications that have proposed in this study. 34 case studies on specific sub-task (from compression member in construction concrete structure) have been collected from seven construction projects in order to examined study’s classifications. The study revealed that the sub-task has high sensitive to deviation where (91%) of the cases recorded as deviations, however, only (19%) of cases recorded as defects. Another findings were that the actual work during the execution process has high source of deviation for this sub-task (74%) while only (26%) of the deviation source was due to both design documentations with the actual work. These findings significantly imply that it could be used the study’s classifications to determine the pattern of each sub-task and develop the proactive actions to overcome issues of the sub-task deviations and defects.

Keywords: sub-tasks, deviations, defects, quality, construction projects

Procedia PDF Downloads 417

Authors: Arsalan Salahi

Abstract:

Today, the number of changes in the construction industry and urban mass house building is increasing, which makes you need to pay more attention to targeted planning for human resource management and training. The human resources working in the construction industry have various problems and deficiencies, and in order to solve these problems, there is a need for basic management and training of these people in order to lower the construction costs and increase the quality of the projects, especially in mass house building projects. The success of any project in reaching short and long-term professional goals depends on the efficient combination of work tools, financial resources, raw materials, and most importantly, human resources. Today, due to the complexity and diversity of each project, specialized management fields have emerged to maximize the potential benefits of each component of that project. Human power is known as the most important resource in construction projects for its successful implementation, but unfortunately, due to the low cost of human power compared to other resources, such as materials and machinery, little attention is paid to it. With the correct management and training of human resources, which depends on its correct planning and development, it is possible to improve the performance of construction projects. In this article, the training and motivation of construction industry workers and their effects on the effectiveness of projects in this industry have been researched. In this regard, some barriers to the training and motivation of construction workers and personnel have been identified and solutions have been provided for construction companies. Also, the impact of workers and unskilled people on the efficiency of construction projects is investigated. The results of the above research show that by increasing the use of correct and basic training for human resources, we will see positive results and effects on the performance of construction projects.

Keywords: human resources, construction industry, principled training, skilled and unskilled workers

Procedia PDF Downloads 60

Authors: Natalia Rudeli, Elisabeth Viles, Adrian Santilli

Abstract:

Delays in the construction industry are a global phenomenon. Many construction projects experience extensive delays exceeding the initially estimated completion time. The main purpose of this study is to identify construction projects typical behaviors in order to develop a prognosis and management tool. Being able to know a construction projects schedule tendency will enable evidence-based decision-making to allow resolutions to be made before delays occur. This study presents an innovative approach that uses Cluster Analysis Method to support predictions during Earned Value Analyses. A clustering analysis was used to predict future scheduling, Earned Value Management (EVM), and Earned Schedule (ES) principal Indexes behaviors in construction projects. The analysis was made using a database with 90 different construction projects. It was validated with additional data extracted from literature and with another 15 contrasting projects. For all projects, planned and executed schedules were collected and the EVM and ES principal indexes were calculated. A complete linkage classification method was used. In this way, the cluster analysis made considers that the distance (or similarity) between two clusters must be measured by its most disparate elements, i.e. that the distance is given by the maximum span among its components. Finally, through the use of EVM and ES Indexes and Tukey and Fisher Pairwise Comparisons, the statistical dissimilarity was verified and four clusters were obtained. It can be said that construction projects show an average delay of 35% of its planned completion time. Furthermore, four typical behaviors were found and for each of the obtained clusters, the interim milestones and the necessary rhythms of construction were identified. In general, detected typical behaviors are: (1) Projects that perform a 5% of work advance in the first two tenths and maintain a constant rhythm until completion (greater than 10% for each remaining tenth), being able to finish on the initially estimated time. (2) Projects that start with an adequate construction rate but suffer minor delays culminating with a total delay of almost 27% of the planned time. (3) Projects which start with a performance below the planned rate and end up with an average delay of 64%, and (4) projects that begin with a poor performance, suffer great delays and end up with an average delay of a 120% of the planned completion time. The obtained clusters compose a tool to identify the behavior of new construction projects by comparing their current work performance to the validated database, thus allowing the correction of initial estimations towards more accurate completion schedules.

Keywords: cluster analysis, construction management, earned value, schedule

Procedia PDF Downloads 240

Authors: Carlo Schick

Abstract:

Legitimacy can be regarded the very fabric of political orders. Up to this point, IR scholarship was particularly interested in the legitimacy of nation-states, international regimes and of non-governmental actors. The legitimacy of collaborative governance comprising public, private and civic actors, however, has not received much attention from an IR perspective. This is partly due to the fact that the concept of legitimacy is difficult to operationalise and measure in settings where there is no clear boundary between political authorities and those who are subject to collaborative governance. In this case, legitimacy cannot be empirically approached in its own terms, but can only be analysed in terms of dialectic legitimation processes. The author develops a three-fold analytical framework based on a dialogical understanding of legitimation. Legitimation first has to relate to public legitimacy demands and contestations of collaborative governance and second to legitimacy claims issued by collaborative governance networks themselves. Lastly, collaborative governance is dependent on constant self-legitimisation. The paper closes with suggesting a discourse analytic approach to further empirical research on the legitimacy of collaborative governance.

Keywords: legitimacy, collaborative governance, discourse analysis, dialectic legitimation

Procedia PDF Downloads 312

Authors: Tanvir Ahmed, Nahian Fyrose Fahim, Subrata Majumder, Sarker Kibria

Abstract:

English is unanimously recognized as the standard second language in the world, and no one can deny this fact. Many people believe that possessing English proficiency skills is the key to communicating effectively globally, especially for developing countries, which can bring further success to itself on many fronts, as well as to other countries, by ensuring its people worldwide access to education, business, and technology. Bangladesh is a developing country of about 160 million people. A notable number of students in Bangladesh are currently pursuing higher education, especially at the tertiary or collegiate level, in more than 150 public and private universities. English is the dominant linguistic medium through which college instruction and lectures are given to students in Bangladesh. However, many of our students who have only completed their primary and secondary levels of education in the Bangla medium or language are generally in an awkward position to suddenly take and complete many unfamiliar requirements by the time they enter the university as freshmen. As students, they struggle to complete at least 18 courses to acquire proficiency in English. After obtaining a tertiary education certificate, the students could then have the opportunity to acquire a sustainable position in the job market industry; however, many of them do fail, unfortunately, because of poor English proficiency skills. Our study focuses on students in both public and private universities (N=150) as well as education experts (N=30) in Bangladesh. We had prepared two sets of questionnaires that were based upon a literature review on this subject, as we had also collected data and identified the reasons, and arrived at probable solutions to overcoming these problems. After statistical analysis, the study suggested certain remedial measures that could be taken in order to increase student's proficiency in English as well as to ensure their employability potential.

Keywords: tertiary education, English language proficiency, employability, unemployment problems

Procedia PDF Downloads 68

Authors: Rodrigo Buaiz Boabaid

Abstract:

Tokenization of Blue Bonds is an emerging Green Finance tool that has the potential to scale Blue Carbon Projects to fight climate change. This innovative solution has a huge potential to democratize the green finance market and catalyze innovations in the climate change finance sector. Switzerland has emerged as a leader in the Green Finance space and is well-positioned to drive the adoption of Tokenization of Blue & Green Bonds. This unique approach has the potential to unlock new sources of capital and enable global investors to participate in the financing of sustainable blue carbon projects. By leveraging the power of blockchain technology, Tokenization of Blue Bonds can provide greater transparency, efficiency, and security in the investment process while also reducing transaction costs. Investments are in line with the highest regulations and designed according to the stringent legal framework and compliance standards set by Switzerland. The potential benefits of Tokenization of Blue Bonds are significant and could transform the way that sustainable projects are financed. By unlocking new sources of capital, this approach has the potential to accelerate the deployment of Blue Carbon projects and create new opportunities for investors to participate in the fight against climate change.

Keywords: blue bonds, blue carbon, tokenization, green finance

Procedia PDF Downloads 62

Authors: Mohammad Lemar Zalmai, Osman Hurol Turkakin, Cemil Akcay, Ekrem Manisali

Abstract:

In public construction projects, determining the contract period in the award phase is one of the most important factors. The contract period establishes the baseline for creating the cash flow curve and progress payment planning in the post-award phase. If overestimated, project duration causes losses for both the owner and the contractor. Therefore, it is essential to base construction project duration on reliable forecasting. In Turkey, schedules are usually built using the bar chart (Gantt) schedule, especially for governmental construction agencies. The usage of these schedules is limited for bidding purposes. Although the bar-chart schedule is useful in some cases, it lacks logical connections between activities; it would be harder to obtain the activities that have more effects than others on the project's total duration, especially in large complex projects. In this study, a construction schedule is prepared with Critical Path Method (CPM) that addresses the above-mentioned discrepancies. CPM is a simple and effective method that displays project time and critical paths, showing results of forward and backward calculations with considering the logic relationships between activities; it is a powerful tool for planning and managing all kinds of construction projects and is a very convenient method for the construction industry. CPM provides a much more useful and precise approach than traditional bar-chart diagrams that form the basis of construction planning and control. CPM has two main application utilities in the construction field; the first one is obtaining project duration, which is called an as-planned schedule that includes as-planned activity durations with relationships between subsequent activities. Another utility is during the project execution; each activity is tracked, and their durations are recorded in order to obtain as-built schedule, which is named as a black box of the project. The latter is more useful for delay analysis, and conflict resolutions. These features of CPM have been popular around the world. However, it has not been yet extensively used in Turkey. In this study, a real construction project is investigated as a case study; CPM-based scheduling is used for establishing both of as-built and as-planned schedules. Problems that emerged during the construction phase are identified and categorized. Subsequently, solutions are suggested. Two scenarios were considered. In the first scenario, project progress was monitored based as CPM was used to track and manage progress; this was carried out based on real-time data. In the second scenario, project progress was supposedly tracked based on the assumption that the Gantt chart was used. The S-curves of the two scenarios are plotted and interpreted. Comparing the results, possible faults of the latter scenario are highlighted, and solutions are suggested. The importance of CPM implementation has been emphasized and it has been proposed to make it mandatory for preparation of construction schedule based on CPM for public construction projects contracts.

Keywords: as-built, case-study, critical path method, Turkish government sector projects

Procedia PDF Downloads 95

Authors: Petcharat Kerdonfag, Supunnee Thrakul

Abstract:

School health services through regular screening of school students’ health status have been the main responsibility for community or school health nurses. The purposes of these retrospective study were to assess and compare health problems between government and private primary school students in the central region of Thailand. The data were collected from the school health records in October at the end of the first semester in the academic year 2018. Two thousand and fifty primary school health records from government and private primary schools were gathered to assess health problems regarding anthropometric measurements, physical examination/personal hygiene, and clinical findings for this study. Descriptive statistics and Chi-square were used to be analyzed. The results revealed that health problems of all the school students remained high magnitude. The five top ranks for prevalence rate of health problems were dental caries (36.6%), visual acuity problem (27.7%), over-nutrition (16.8%), head lice (12.8%), and under-nutrition (6.8%), respectively. However, when compared between government and private schools among five health problems; dental caries (55.0% vs 19.9%), visual acuity problem (23.1% vs 31.9%), over-nutrition (20.2% vs 13.8%), head lice (26.5% vs 0.3%), and under-nutrition (10.6% vs 3.4%) with Chi-square analysis, there were significantly different (p < .001). The problem of visual acuity seems to be more serious in private schools while other health problems tend to be more critical in government schools. The findings have suggested that parents who have children in the private primary schools should pay more attention to visual health defects whereas parents with children in the government school should pay more vigilance regards to hygiene and health behavior problems.

Keywords: community health nursing, school health service, health status, primary school children

Procedia PDF Downloads 101

Authors: Ana Luiza Aranha

Abstract:

This paper contributes to the discussions that consider corruption as a challenge to the establishment of more democratically inclusive societies in Latin America. The paper advocates an intrinsic connection between democratic principles and corruption control – it is only possible to achieve just forms of democratic life if accountability institutions are able to control corruption, and therefore control the political exclusions that it brings. Departing from a non-trivial approach to corruption, and recognizing a gap in democratic theory when thinking about this phenomenon, corruption is understood as the breakdown of the democratic inclusive rule, whereby political decisions are made (and actions were taken) in spite of those potentially affected by them. Based on this idea, this paper proposes a new way of measuring corruption, moving away from usual aggregate measures – such as the Corruption Perception Index – and case studies of corruption scandals. The main argument sustains that corruption is intrinsically connected with the ability to be accountable and to provide public justification for the political conduct. The point advocated is that corruption involves a dimension of political exclusion. It generates a private benefit which is, from a democratic point of view, illegitimate, since it benefits some at the expense of the decisions made by the political community. Corruption is then a form of exclusion based on deception and opacity - for corruption, there is no plausible justification. Empirically, the paper uses the audit reports produced by the Brazilian anti-corruption agency (the CGU - Office of the Comptroller General) in its Inspections From Public Lotteries Program to exemplify how we can use this definition to separate corruption cases from mismanagement irregularities. On one side, there is poor management and inefficiencies, and, on the other, corruption, defined by the implausibility of public justifications – because the public officials would have to publicize illegitimate privileges and undue advantages. CGU reports provide the justifications given by the public officials for the irregularities found and also the acceptance or not by the control agency of these justifications. The analysis of this dialogue – between public officials and control agents – makes it possible to divide the irregularities on those that can be publicly justified versus those that cannot. In order to hold public officials accountable for their actions, making them responsible for the exclusions that they may cause (such as corruption), the accountability institutions fulfil an important role in reinforcing and empowering democracy and its basic inclusive condition.

Keywords: accountability, brazil, corruption, democracy

Procedia PDF Downloads 241

Authors: Prince Amartey

Abstract:

Water is critical to public health, quality of life, environmental preservation, economic activity, and long-term growth. In this environment, it is critical to ensure the ongoing improvement of all processes and practices that contribute to the quality and safety of water. Water safety plans (WSPs) developed by water companies are an essential public policy instrument for achieving these objectives. This manuscript examines international evidence of water safety planning adoption and implementation and reports on the current situation in Portugal as part of the necessary adaptation of the national legal framework to the publication of the Directive on water quality for human consumption. The goal is to take lessons from various successful WSP projects throughout the world while writing new legislation in Ghana and elsewhere. According to the findings, four crucial aspects and key factors of success in establishing and implementing WSPs exist commitment from leadership, technical proficiency, administration, and cooperation among agencies.

Keywords: safe drinking, risk, policy, implementation

Procedia PDF Downloads 63

Authors: EMMANUEL DWAMENA SASU

Abstract:

International climate policy actions require countries under Paris Agreement to design instruments, provide support (financial and technical), and strengthen institutional capacity with tendency to transcending policy formulation to implementation and sustainability. Changes associated with moisture depletion has been a growing phenomenon; especially in developing countries with projected global GDP drop from 7% to 2% between 2005 and 2050. These developments have potential to adversely affect food production in feeding the growing world population, with corresponding rise in global hunger. Incongruously, there is global absence of a harmonized policy direction; capable of providing the required indicators on climate policies for monitoring sustainability of international agricultural development projects. We conduct extensive review and synthesis on existing limitations on global climate policy governance, agricultural food security and sustainability of international agricultural development projects, and conjecture the role of non-state and sub-national climate stakeholder engagements, and monitoring and evaluation strategies for improved climate policy action for sustaining international agricultural development projects.

Keywords: climate policy, agriculture, development projects, sustainability

Procedia PDF Downloads 107

Authors: Yi Wang, Xun Liang

Abstract:

This paper introduces a model of internet public opinion waves, which describes the message propagation and measures the influence of a detected event. We collect data on public opinion propagation from different platforms on the internet, including micro-blogs and news. Then, we compare the spread of public opinion to the seismic waves and correspondently define the P-wave and S-wave and other essential attributes and characteristics in the process. Further, a model is established to evaluate the magnitude scale of the events. In the end, a practical example is used to analyze the influence of network public opinion and test the reasonability and effectiveness of the proposed model.

Keywords: internet public opinion waves (IPOW), magnitude scale, cross-platform, information propagation

Procedia PDF Downloads 262

Authors: Golyasamin Khanehzaei, Mohd. Bakri Ishak, Ahmad Makmom Hj Abdullah, Latifah Abd Manaf

Abstract:

Abstract—Management of clinical waste is a critical problem worldwide. Immediate attention is required to manage the clinical waste in an appropriate way in newly developing economy country such as Malaysia. The increasing amount of clinical waste generated is resulted from rapid urbanization and growing number of private health care facilities in developing countries such as Malaysia. In order to develop a sensible clinical waste management system and improvement of the management, information on factors affecting clinical waste generation has the crucial role. This paper is the study of management characteristics of clinical waste and the level of efficiency of clinical waste management systems operating in private clinics located in Selangor, Malaysia. Are they following the proper international standards? By taking all of this in consideration the aim of this paper is to identify and discuss the current trend, current challenges and also the present opportunities among the challenges of clinical waste management in private clinics of Selangor, Malaysia. The SWOT analysis was characterized for the evaluation of strengths, weaknesses, opportunities and threats. The methodology for this study was constituted of direct observation, Informal interviews, Conducting SWOT analysis, conduction of one sustainability dimensions analysis and application. The results show that clinical waste management in private clinics is far from an ideal model.

Keywords: clinical waste, SWOT analysis, Selangor, Malaysia

Procedia PDF Downloads 330

Authors: Myles Frederick McLellan

Abstract:

When errors in the criminal justice process lead to wrongful convictions and miscarriages of justice, it falls upon the State to make reparation for the egregious harms brought to innocent individuals. Of all the remedies available to seek compensation, private and public law litigation against the police and prosecution services is the most widely used. Unfortunately, all levels of court including the Supreme Court of Canada have explicitly endorsed the prospect of striking out or dismissing these claims at the outset on an expedited basis. The burden on agents of the State as defendants to succeed on motions for such relief is so low that very few actions will survive to give an innocent accused his or her day in court. This paper will be a quantitative and qualitative analysis on the occurrence and success of motions to strike and dismiss to forestall financial recovery for the damage caused when a criminal investigation and prosecution goes wrong. This paper will also include a comparative component on the private law systems at common law (e.g. USA, UK, Australia and New Zealand) with respect to the availability of a similar process to pre-emptively terminate litigation for the recovery of compensation to an innocent individual.

Keywords: compensation, innocence, miscarriages of justice, wrongful convictions

Procedia PDF Downloads 119

Authors: Ruth Estrada Javier - Reyes

Abstract:

The study assessed the status of HTM program of selected private higher education institutions for internationalization across the eleven regions of the country. The descriptive survey method of research was used in this study. A devised survey questionnaire was utilized to gather information about the status of Philippine Higher Education Institutions’ internationalization of hospitality and tourism management education programs. The respondents were 12 administrators, 17 deans and program heads, 104 faculty members and 860 HTM students. Frequency, percentage, mean, standard deviation, t-test and F-test were used to treat the data. The results of the study are as follows: HEIs’ HTM education had complied with the policies/standards of CHED as per CMO No. 30 S. 2006. The respondents of the HTM education program were qualified for internationalization as assessed both by administrators and faculty. The private HEIs are ready to apply for international certification of their HTM education programs. The curriculum of HTM education programs in private HEIs are enriched by internationalization requirements. The administrators and faculty of HTM education programs are qualified educators but have limited participation in collaborative international research and linkages. The HEIs are qualified to apply for the internationalization of the Hospitality and Tourism Management education program in preparation to the ASEAN 2015.

Keywords: status, Hospitality and Tourism Management Program, internationalization, Private Higher Education Institutions

Procedia PDF Downloads 393

Authors: B. Gültekin, T. Gültekin

Abstract:

Peace diplomacy is the most important international tool to maintain peace all over the World. This study consists of three parts. In the first part, the leadership of Devlet Bahçeli, leader of the Nationalist Movement Party, will be introduced as a tool of peace communication and peace management. Also, in this part, peace communication will be explained by the peace leadership traits of Devlet Bahçeli, who is one of the efficient political leaders representing the concepts of compromise and agreement on different sides of politics. In the second part of study, it is aimed to analyze Devlet Bahçeli’s leadership within the frame of peace communication and the final part of this study is about creating an original public communication model for public diplomacy based on Devlet Bahçeli as an example. As a result, the main purpose of this study is to develop an original peace communication model including peace modules, peace management projects, original dialogue procedures and protocols exhibited in the policies of Devlet Bahçeli. The political leadership represented by Devlet Bahçeli inspires political leaders to provide peace communication. In this study, principles and policies of peace leadership of Devlet Bahçeli will be explained as an original model on a peace communication platform.

Keywords: public diplomacy, dialogue management, peace leadership, peace diplomacy

Procedia PDF Downloads 136

Authors: Faiza Marrium, Masood Rabbani, Ali Ahmad Sheikh, Muhammad Yasin Tipu Javed Muhammad, Sohail Raza

Abstract:

More than 75% diseases spreading in the past 10 years in human population globally are linked to veterinary sector. Veterinary diagnostic labs are the powerful ally for diagnosis, prevention and monitoring of animal diseases in any country. In order to avoid detrimental effects of errors in disease diagnostic and biorisk management, there is a dire need to establish quality control system. In current study, 3 private and 6 public sectors veterinary diagnostic labs were selected for survey. A questionnaire survey in biorisk management guidelines of CWA 15793 was designed to find quality control breaches in lab design, personal, equipment and consumable, quality control measures adopted in lab, waste management, environmental monitoring and customer care. The data was analyzed through frequency distribution statistically by using (SPSS) version 18.0. A non-significant difference was found in all parameters of lab design, personal, equipment and consumable, quality control measures adopted in lab, waste management, environmental monitoring and customer care with an average percentage of 46.6, 57.77, 52.7, 55.5, 54.44, 48.88 and 60, respectively. A non-significant difference among all nine labs were found, with highest average compliance percentage of all parameters are lab 2 (78.13), Lab 3 (70.56), Lab 5 (57.51), Lab 6 (56.37), Lab 4 (55.02), Lab 9 (49.58), Lab 7 (47.76), Lab 1 (41.01) and Lab 8 (36.09). This study shows that in Lahore district veterinary diagnostic labs are not giving proper attention to quality of their system and there is no significant difference between setups of private and public sector laboratories. These results show that most of parameters are between 50 and 80 percent, which needs some work and improvement as per WHO criteria.

Keywords: veterinary lab, quality management system, accreditation, regulatory body, disease identification

Procedia PDF Downloads 127

Authors: Safa Moussoud

Abstract:

Contrary to modern misconceptions, women in the Muslim Middle Ages enjoyed a generous degree of liberty both in the public and private sphere. Poetry was a significant component of public life throughout the Muslim Civilization as its vitality and multi-generic nature acted as a way for medieval Muslims to communicate with each other. As such, a continuity of poetic literary heritage was preserved through multiple centuries and dynasties. This paper will argue that Muslim women were active participants in medieval Muslim society’s social and public sphere and therefore, can be seen as vital contributors to the intellectual and literary creation of the Muslim Civilization. This paper will examine poetry written by Safiyya al-Baghddadiya and Salma bint al-Qaratisi from the Abbasid period, as well as Wallada bint al-Mustakfi from the Andalusian period and focus particularly at the poetesses’ modes of self-expression regarding beauty and sexuality to argue that Medieval Muslim women enjoyed creative and literary liberty thus allowing them to proclaim their subjectivity publicly through poetry. By emphasizing women’s involvement in the social aspects of Medieval Muslim societies, this paper will ultimately urge for a more thorough investigation of Muslim women’s role and function in the making of the Muslim Civilization.

Keywords: Arabo-Islamic society, medieval Muslims, Muslim poetesses, self-expression

Procedia PDF Downloads 113