Search results for: real estate projects

Authors: Edoghogho Ogbeifun, Charles Mbohwa, J. H. C. Pretorius

Abstract:

Effective infrastructure development scheme planned and executed has positive influence on the quantity of available stock of infrastructure to meet the immediate and expansion needs of an organization, as well as contribute to the overall economic development of a nation, community or the local entity where the infrastructure is hosted. It is noteworthy, however, that infrastructure development scheme spans a long time frame, usually longer than the political life of the administration that initiates the scheme. In the majority of circumstances, execution may start and achieve different levels of completion; at best, only limited numbers are completed and put into functional use during the life of the administration that initiated the infrastructure scheme. When there is a change in leadership, many of the uncompleted projects are usually abandoned. The new administration repeats the circle of its predecessors and develops another set of infrastructure scheme which will suffer similar fate as the ones developed by their predecessors; thus doting the landscape with many uncompleted projects, which leads to infrastructure deficit. These circle will continue unless each succeeding leader sees governance as single continuum. Therefore, infrastructure projects not completed by one administration should be continued by succeeding administration, in order to increase the stock of relevant infrastructure available for the smooth operations organization and enhance the needed developments, as well as reduce the negative effects of infrastructure deficit. The single case study of qualitative research method was adopted to investigate the actions of the administration of three successive Vice-Chancellors, in a higher education institution in Nigeria, over a longitudinal period of twelve years. This is with a view to exploring the effects of each administration on the development and execution of infrastructure projects, with particular interest on abandoned projects. The findings revealed that although two of Vice-Chancellors were committed to infrastructure upgrade, they executed more new projects than completing abandoned ones, while the current leader has shown more pragmatism in completing abandoned projects alongside constructing new ones; thus demonstrating the importance of the continuity of governance. In this regard, there is a steady increase in the stock of infrastructure to accommodate the expansion of existing academic programmes, host new ones as well as reduce the negative effects of infrastructure deficit caused by abandoned projects.

Keywords: abandoned projects, continuity of governance, infrastructure development scheme, long time frame

Procedia PDF Downloads 153

Authors: Ahlam Inayatullah Badrul Munir, M. Husaini A. Rahman, Mohd Sukri Hassan

Abstract:

Real-time PCR is a molecular biology technique that is currently being widely used for halal services to differentiating between porcine and bovine DNA. The useful of technique become very important for student or workers (who works in the laboratory) to learn how the technique could be run smoothly without fail. Same concept with conventional PCR, real-time PCR also needed DNA template, primer, enzyme polymerase, dNTP, and buffer. The difference is in real-time PCR, have additional component namely fluorescent dye. The most common use of fluorescent dye in real-time PCR is SYBR green. The purpose of this study was to find out how sensitive, specific and efficient real-time PCR technique was combined with SYBR green method and specific primers of CYT b. The results showed that real-time PCR technique using SYBR Green, capable of detecting porcine and bovine DNA concentrations up to 0.0001 µl/ng. The level of efficiency for both types of DNA was 91% (90-110). Not only that in specific primer CYT b bovine primer could detect only bovine DNA, and porcine primer could detect only porcine primer. So, from the study could be concluded that real-time PCR technique that was combined with specific primer CYT b and SYBR green method, was sensitive, specific and efficient to detect porcine and bovine DNA.

Keywords: sensitivity, specificity, efficiency, real-time PCR, SYBR green, Cytochrome b, porcine DNA, bovine DNA

Procedia PDF Downloads 289

Authors: Heba Abdelmotaal, Magdy Abdel-Kader

Abstract:

Purpose: This study explores whether a firm’s effective political risk management is preventing real and accrual earnings management . Design/methodology/approach: Based on a sample of 130 firms operating in Egypt during the period 2008-2013, two hypotheses are tested using the panel data regression models. Findings: The empirical findings indicate a significant relation between real and accrual earnings management and political risk. Originality/value: This paper provides a statistically evidence on the effects of the political risk management failure on the mangers’ engagement in the real and accrual earnings management practices, and its impact on the firm’s performance.

Keywords: political risk, risk management failure, real activities manipulation, accrual earnings management

Procedia PDF Downloads 404

Authors: Jamuna Konda, Umamaheswara Reddy Karumuri, Sriramya Muthugi, Varun Pishati, Ravi Shakya,

Abstract:

This paper investigates the challenges involved in mathematical modeling of plant simulation models ensuring the performance of the plant models much closer to the real time physical model. The paper includes the analysis performed and investigation on different methods of modeling, design and development for plant model. Issues which impact the design time, model accuracy as real time model, tool dependence are analyzed. The real time hardware plant would be a combination of multiple physical models. It is more challenging to test the complete system with all possible test scenarios. There are possibilities of failure or damage of the system due to any unwanted test execution on real time.

Keywords: model based design (MBD), MATLAB, Simulink, stateflow, plant model, real time model, real-time workshop (RTW), target language compiler (TLC)

Procedia PDF Downloads 319

Authors: Taha Anjamrooz, Sareh Rajabi, Salwa Bheiry

Abstract:

Procurement is a key process in construction project management. The present construction procurement practices have been extensively analyzed for disregarding sustainability in the project life cycle. Currently, there is a gap of information on status-quo of sustainable procurement in construction field. Thus, the aim of this study is to review sustainable procurement practices in the construction field. Disregard of three sustainability pillars is one of the major drawbacks of present construction procurement practices. Sustainable procurement is a developing idea that can enhance procurement practices and improve the sustainability performance of the construction projects. At present, sustainable procurement is still not entirely used in the construction projects. A comprehensive literature review indicated that the construction industry is still not entirely informed about the benefits and challenges of using sustainable procurement, and about important indicators that play major impacts on those benefits and challenges. This study assesses the major indicator, benefits and challenges encountered in applying sustainable procurement in the construction industry. In addition, this study investigates understanding of construction professionals on the benefits and challenges of utilizing sustainable procurement for construction projects through selected indicators that are categorized according to society and community needs.

Keywords: sustainability, sustainable development, sustainable procurement, procurement, construction industry

Procedia PDF Downloads 152

Authors: Sevgi Özlem Bulu, Arif Furkan Mendi, Tolga Erol, İzzet Gökhan Özbilgin

Abstract:

The rapid progress of technology in today's competitive conditions has also accelerated companies' technology development activities. As a result, companies are paying more attention to R&D studies and are beginning to allocate a larger share to R&D projects. A more systematic, comprehensive, target-oriented implementation of R&D studies is crucial for the company to achieve successful results. As a consequence, Technology Roadmap (TRM) is gaining importance as a management tool. It has critical prospects for achieving medium and long term success as it contains decisions about past business, future plans, technological infrastructure. When studies on TRM are examined, projects to be placed on the roadmap are selected by many different methods. Generally preferred methods are based on multi-criteria decision making methods. Management of selected projects becomes an important point after the selection phase of the projects. At this stage, TRM are used. TRM can be created in many different ways so that each institution can prepare its own Technology Roadmap according to their strategic plan. Depending on the intended use, there can be TRM with different layers at different sizes. In the evaluation phase of the R&D projects and in the creation of the TRM, HAVELSAN, Turkey's largest defense company in the software field, carries out this process with great care and diligence. At the beginning, suggested R&D projects are evaluated by the Technology Management Board (TMB) of HAVELSAN in accordance with the company's resources, objectives, and targets. These projects are presented to the TMB periodically for evaluation within the framework of certain criteria by board members. After the necessary steps have been passed, the approved projects are added to the time-based TRM, which is composed of four layers as market, product, project and technology. The use of a four-layered roadmap provides a clearer understanding and visualization of company strategy and objectives. This study demonstrates the benefits of using TRM, four-layered Technology Roadmapping and the possibilities for the institutions in the defense industry.

Keywords: technology roadmap, research and development project, project selection, research development in defense industry

Procedia PDF Downloads 150

Authors: Monsuru Oyenola Popoola, Oladapo Samson Abiola, Wusamotu Alao Adeniji

Abstract:

The prevalent and incessant abandonment of road construction projects are alarming that it creates several negative effects to social, economic and environmental values of the project. The purpose of this paper is to investigate and determined the various causes and effects of abandoning road construction projects in Nigeria. Likert Scale questionnaire design was used to administered and analysed the data obtained for the stydy. 135 (Nr) questionnaires were completed and retrieved from the respondents, out of 200 (Nr) questionnaires sent out, representing a response rate of 67.5%. The analysis utilized the Relative Importance Index (R.I.I.) method and the results are presented in tabular form. The findings confirms that at least 20 factors were the causes of road projects abandonment in Nigeria with most including Leadership Instability, Improper Project Planning, Inconsistence in government policies and Design, Contractor Incompetence, Economy Instability and Inflation, Delay in remittance of money, Improper financial analysis, Poor risk management, Climatic Conditions, Improper Project Estimates etc. The findings also show that at least eight (8) effect were identified on the system, and these include; Waste of Financial Resources, Loss of economic value, Environmental degradation, Loss of economic value, Reduction in standard of living, Litigation and Arbitration, etc. The reflection is that allocating reasonable finance, developing appropriate and effective implementation plans and monitoring, evaluation and reporting on development project activities by key actors should enhance in resolving the problem of road projects abandonment.

Keywords: road construction, abandonment of road projects, climatic condition, project planning, contractor

Procedia PDF Downloads 270

Authors: Sahar Navabakhsh, Rokia Raslan, Yair Schwartz

Abstract:

Decision-making on regeneration of housing estates, whether to refurbish or re-build, has been mostly triggered by economic factors. To enable sustainable growth, it is vital that environmental and social impacts of different scenarios are also taken into account. The methodology used to include all the three sustainable development pillars is called Life Cycle Sustainability Assessment (LCSA), which comprises of Life Cycle Assessment (LCA) for the assessment of environmental impacts of buildings. Current practice of LCA is regularly conducted post design stage and by sustainability experts. Not only is undertaking an LCA at this stage less effective, but issues such as the limited scope for the definition and assessment of environmental impacts, the implication of changes in the system boundary and the alteration of each of the variable metrics, employment of different Life Cycle Impact Assessment Methods and use of various inventory data for Life Cycle Inventory Analysis can result in considerably contrasting results. Given the niche nature and scarce specialist domain of LCA of buildings, the majority of the stakeholders do not contribute to the generation or interpretation of the impact assessment, and the results can be generated and interpreted subjectively due to the mentioned uncertainties. For an effective and democratic assessment of environmental impacts, different stakeholders, and in particular the community and design team should collaborate in the process of data collection, assessment and analysis. This paper examines and evaluates a participatory approach to LCSA through the analysis of a case study of a housing estate in South West London. The study has been conducted throughout tier-based collaborative methods to collect and share data through surveys and co-design workshops with the community members and the design team as the main stakeholders. The assessment of lifecycle impacts is conducted throughout the process and has influenced the decision-making on the design of the Community Plan. The evaluation concludes better assessment transparency and outcome, alongside other socio-economic benefits of identifying and engaging the most contributive stakeholders in the process of conducting LCSA.

Keywords: life cycle assessment, participatory LCA, life cycle sustainability assessment, participatory processes, decision-making, housing estate regeneration

Procedia PDF Downloads 118

Authors: Adel Mohamed El-Baghdady, Walid Sayed Abdulgalil, Ahmad Asran, Ibrahim Nosier

Abstract:

This paper studies the effectiveness of applying value engineering to actual concrete mixtures. The study was conducted in the State of Qatar on a number of strategic construction projects with international engineering specifications for the 2022 World Cup projects. The study examined the concrete mixtures of Doha Metro project and the development of KAHRAMAA’s (Qatar Electricity and Water Company) Abu Funtas Strategic Desalination Plant, in order to generally improve the quality and productivity of ready-mixed concrete used in construction and hydraulic projects. The application of value engineering to such concrete mixtures resulted in the following: i) improving the quality of concrete mixtures and increasing the durability of buildings in which they are used; ii) reducing the waste of excess materials of concrete mixture, optimizing the use of resources, and enhancing sustainability; iii) reducing the use of cement, thus reducing CO₂ emissions which ensures the protection of environment and public health; iv) reducing actual costs of concrete mixtures and, in turn, reducing the costs of construction projects; and v) increasing the market share and competitiveness of concrete producers. This research shows that applying the methodology of value engineering to ready-mixed concrete is an effective way to save around 5% of the total cost of concrete mixtures supplied to construction and hydraulic projects, improve the quality according to the technical requirements and as per the standards and specifications for ready-mixed concrete, improve the environmental impact, and promote sustainability.

Keywords: value management, cost of concrete, performance, optimization, sustainability, environmental impact

Procedia PDF Downloads 323

Authors: Hamed Zolfaghari, Mojtaba Kord

Abstract:

After feasibility study the design phase is started and the rest of other phases are highly dependent on this phase. forecasting the duration of design phase could do a miracle and would save a lot of time. This study provides a fast and accurate Machine learning (ML) and optimization framework, which allows a quick duration estimation of project design phase, hence improving operational efficiency and competitiveness of a design construction company. 3 data sets of three years composed of daily time spent for different design projects are used to train and validate the ML models to perform multiple projects. Our study concluded that Artificial Neural Network (ANN) performed an accuracy of 0.94.

Keywords: time estimation, machine learning, Artificial neural network, project design phase

Procedia PDF Downloads 53

Authors: Bhavana Gulaty, Arshia Chaudhri

Abstract:

Great civic projects contribute integrally to a city, and every city undergoes a recurring cycle of urban transformations and regeneration by their insertion. The M.I.C.E. (Meetings, Incentives, Convention and Exhibitions) industry is the forbearer of one category of such catalytic civic projects. Through a specific focus on M.I.C.E. destinations, this paper illustrates the multifarious dimensions that urban catalysts impact the city on S.P.U.R. (Seed. Profile. Urbane. Reflections), the theoretical framework of this paper aims to unearth these dimensions in the realm of the COEX (Convention & Exhibition) biosphere. The ‘COEX Biosphere’ is the filter of such catalysts being ecosystems unto themselves. Like a ripple in water, the impact of these strategic interventions focusing on art, culture, trade, and promotion expands right from the trigger; the immediate context to the region and subsequently impacts the global scale. These ripples are known to bring about significant economic, social, and political and network changes. The COEX inventory in the Asian context has one such prominent addition; the proposed India International Convention and Exhibition Centre (IICC) at New Delhi. It is envisioned to be the largest facility in Asia currently and would position India on the global M.I.C.E map. With the first phase of the project scheduled to open for use in the end of 2019, this flagship project of the Government of India is projected to cater to a peak daily footfall of 3,20,000 visitors and estimated to generate 5,00,000 jobs. While the economic benefits are yet to manifest in real time and ‘Good design is good business’ holds true, for the urban transformation to be meaningful, the benefits have to go beyond just a balance sheet for the city’s exchequer. This aspect has been found relatively unexplored in research on these developments. The methodology for investigation will comprise of two steps. The first will be establishing an inventory of the global success stories and associated benefits of COEX projects over the past decade. The rationale for capping the timeframe is the significant paradigm shift that has been observed in their recent conceptualization; for instance ‘Innovation Districts’ conceptualised in the city of Albuquerque that converges into the global economy. The second step would entail a comparative benchmarking of the projected transformations by IICC through a toolkit of parameters. This is posited to yield a matrix that can form the test bed for mapping the catalytic trajectory for projects in the pipeline globally. As a ready reckoner, it purports to be a catalyst to substantiate decision making in the planning stage itself for future projects in similar contexts.

Keywords: catalysts, COEX, M.I.C.E., urban transformations

Procedia PDF Downloads 127

Authors: Kristina Ancutiene

Abstract:

The goal of this research is to perform comparative analysis between the virtual fit of the woman's dress and the fit on a real person. The dress fitting was done using mechanical and structural parameters of the 100 % linen fabric and using Modaris_3D_Fit software (CAD Lectra). The dress was also sawn after which garment fit differences of real and virtual dress was researched. Four respondents whose figures were similar were used to evaluate the ease and strain deformations of the real and virtual dress. The scores that were given by the respondents wearing the real dress were compared to the ease and strain results that were given by the software. The main result was that respondents feel similar to the virtual stretch deformations but their ease feeling is not always matching the virtual ones. The results may be influenced by psychological factors and different understanding about purpose of garment.

Keywords: virtual garment, 3D CAD, garment fit, mechanical properties

Procedia PDF Downloads 298

Authors: Lokesh Harshe

Abstract:

The building construction sector is using 36% of global energy consumption with 39% of CO₂ emission. Professionals in the Built Environment Sector have long been aware of the industry’s contribution towards CO₂ emissions and are now moving towards more sustainable practices. As a result of this, many organizations have introduced rating systems to address the issue of global warming in the construction sector by ranking construction projects based on sustainability parameters. The pre-construction phase of any building project is the most essential time to make decisions for addressing the sustainability aspects. Traditionally, it is very difficult to collect data from different stakeholders and bring it together to form a decision based on factual data to perform sustainability analyses in the pre-construction phase. Building Information Modelling (BIM) is the solution where one single model is the result of the collaborative approach of BIM processes where all the information is shared, extracted, communicated, and stored on a single platform that everyone can access and make decisions based on real-time data. The focus of this research is on the Indian Green Rating System IGBC® with the objective of understanding IGBC® requirements and developing a framework to create the relationship between the rating processes and BIM. A Hypothetical (Architectural) model of a hostel building is developed using AutoCAD 2019 & Revit Arch. 2019, where the framework is applied to generate results on sustainability analysis using Green Building Studio (GBS) and Revit Add-ins. The results of any sustainability analysis are generated within a fraction of a minute, which is very quick in comparison with traditional sustainability analysis. This may save a considerable amount of time as well as cost. The future scope is to integrate Architectural, Structural, and MEP Models to perform accurate sustainability analyses with inputs from industry professionals working on real-life Green BIM projects.

Keywords: sustainability analyses, BIM, green rating systems, IGBC®, LEED

Procedia PDF Downloads 23

Authors: Radim Farana, Bogdan Walek, Michal Janosek, Jaroslav Zacek

Abstract:

This paper presents the advantages of fuzzy control use in technological processes control. The paper presents a real application of the Linguistic Fuzzy-Logic Control, developed at the University of Ostrava for the control of physical models in the Intelligent Systems Laboratory. The paper presents an example of a sensitive non-linear model, such as a magnetic levitation model and obtained results which show how modern information technologies can help to solve actual technical problems. A special method based on the LFLC controller with partial components is presented in this paper followed by the method of automatic context change, which is very helpful to achieve more accurate control results. The main advantage of the used system is its robustness in changing conditions demonstrated by comparing with conventional PID controller. This technology and real models are also used as a background for problem-oriented teaching, realized at the department for master students and their collaborative as well as individual final projects.

Keywords: control, fuzzy logic, sensitive system, technological proves

Procedia PDF Downloads 438

Authors: Saadia Khalid

Abstract:

This paper discusses the various leadership styles of project manager which lead to the success of a project since it is important for a project manager to understand and adopt the skills required to cope up with the modern challenges of any project. A project manager must be able to handle a project effectively and efficiently and be ready to assess the factors effecting success or failure of the project. A project manager must be capable of handling a project by managing, directing and leading the projects with requisite knowledge and skills. In this paper a project manager’s characteristics linkage to project success have been developed and analyzed for three different projects/industries. A web-based survey has also been carried out which revealed that specific leadership styles/traits can lead to better performance and success of organizations. Some basic factors like project complexity, the age, gender and nationality of the project manager and type of project also play a vital role in success of a project.

Keywords: leadership style, project success, project management, project manager

Procedia PDF Downloads 395

Authors: Wong Hock Tsen

Abstract:

This study aims to investigate the impact of exchange rate volatility on real export in Malaysia. The moving standard deviation with order three (MSD(3)) is used for the measurement of exchange rate volatility. The conventional and partially asymmetric autoregressive distributed lag (ARDL) models are used in the estimations. This study finds exchange rate volatility to have significant impact on real total export and some sub-categories of real total export. Moreover, this study finds that the positive or negative exchange rate volatility tends to have positive or negative impact on real export. Exchange rate volatility can be harmful to export of Malaysia.

Keywords: exchange rate volatility, autoregressive distributed lag, export, Malaysia

Procedia PDF Downloads 288

Authors: Aniket S. Joshi, Aditya R. Mane, Arjun Tukaram

Abstract:

In the 21st century, in the era of e-world, people are continuously getting updated by daily information such as weather conditions, news, stock exchange market updates, new projects, cricket updates, sports and other such applications. In the busy situation, they want this information on the little use of keyboard, time. Today in order to get such information user have to repeat same mouse and keyboard actions which includes time and inconvenience. In India due to rural background many people are not much familiar about the use of computer and internet also. Also in small clinics, small offices, and hotels and in the airport there should be a system which retrieves daily information with the minimum use of keyboard and mouse actions. We plan to design application based project that can easily retrieve information with minimum use of keyboard and mouse actions and make our task more convenient and easier. This can be possible with an image processing application which takes real time hand gestures which will get matched by system and retrieve information. Once selected the functions with hand gestures, the system will report action information to user. In this project we use real time hand gesture movements to select required option which is stored on the screen in the form of RSS Feeds. Gesture will select the required option and the information will be popped and we got the information. A real time hand gesture makes the application handier and easier to use.

Keywords: hand detection, hand tracking, hand gesture recognition, HSV color model, Blob detection

Procedia PDF Downloads 258

Authors: Riko Wahyudi, Rezky Lasekti Wicaksono, Ayu Satya Damayanti, Ridhasepta Multi Kenrosa

Abstract:

Implementing Forest Management Unit (FMU) is considered as the best solution for forest management in developing countries. However, when FMU has been formed, many parties then blame the FMU and assume it is not working on. Currently, there are two main issues that make FMU not be functional i.e. institutional and financial issues. This paper is addressing financial issues to make FMUs in Aceh Province can be functional. A mixed financing scheme is proposed here, both direct and indirect financing. The direct financing scheme derived from two components i.e. public funds and businesses. Non-tax instruments of intergovernmental fiscal transfer (IFT) system and FMU’s businesses are assessed. Meanwhile, indirect financing scheme is conducted by assessing public funds within villages around forest estate as about 50% of total villages in Aceh Province are located surrounding forest estate. Potential instruments under IFT system are forest and mining utilization royalties. In order to make these instruments become direct financing for FMU, interventions on allocation and distribution aspects of them are conducted. In the allocation aspect, alteration in proportion of allocation is required as the authority to manage forest has shifted from district to province. In the distribution aspect, Government of Aceh can earmark usage of the funds for FMUs. International funds for climate change also encouraged to be domesticated and then channeled through these instruments or new instrument under public finance system in Indonesia. Based on FMU’s businesses both from forest products and forest services, FMU can impose non-tax fees for each forest product and service utilization. However, for doing business, the FMU need to be a Public Service Agency (PSA). With this status, FMU can directly utilize the non-tax fees without transferring them to the state treasury. FMU only need to report the fees to Ministry of Finance. Meanwhile, indirect financing scheme is conducted by empowering villages around forest estate as villages in Aceh Province is receiving average village fund of IDR 800 million per village in 2017 and the funds will continue to increase in subsequent years. These schemes should be encouraged in parallel to establish a mixed financing scheme in order to ensure sustainable financing for FMU in Aceh Province, Indonesia.

Keywords: forest management, public funds, mixed financing, village

Procedia PDF Downloads 162

Authors: Aydemir Akyürek, Osman Nuri Ağdağ

Abstract:

Construction industry is in a rapid development for many years around the world and especially in Turkey. In the last three years sector has 10% growth and provides significant support on Turkey’s national economy. Many construction projects are on-going at urban and rural areas of Turkey which have substantial environmental impacts. Environmental impacts during construction phase are quite diversified and widespread. Environmental impacts of construction industry cannot be inspected properly in all cases and negative impacts may occur frequently in many projects in Turkey. In this study, implementation of ISO 14001 Environmental Management System (EMS) in construction plants is evaluated. In the beginning stage quality management systems generally reviewed and ISO 14001 EMS is selected for implementation. Standard requirements are examined first and implementation of every standard requirement is elaborated for the selected construction plant in the following stage. Key issues and common problems, gained benefits by execution of this type of international EMS standard are examined. As can be seen in sample projects, construction projects are being completed very fast and contractors are working in a highly competitive environment with low profit ratios in our country and mostly qualified work force cannot be accessible. Addition to this there are deficits on waste handling and environmental infrastructure. Besides construction companies which have substantial investments on EMSs can be faced with difficulties on competitiveness in domestic market, however professional Turkish contractors which implementing managements systems in larger scale at international projects are gaining successful results. Also the concept of ‘construction project management’ which is being implemented in successful projects worldwide cannot be implemented except larger projects in Turkey. In case of nonexistence of main management system (quality) implementation of EMSs cannot be managed. Despite all constraints, EMSs that will be implemented in this industry with commitment of top managements and demand of customers will be an enabling, facilitating tool to determine environmental aspects and impacts of construction sites, will provide higher compliance levels for environmental legislation, to establish best available methods for operational control on waste management, chemicals management etc. and to plan monitoring and measurement, to prioritize environmental aspects for investment schedules and waste management.

Keywords: environmental management system, construction projects, ISO 14001, quality

Procedia PDF Downloads 332

Authors: Jingya You, Yongqiang Chen, Yuanyuan Hua, Wenqian Wang

Abstract:

Conflict is commonplace in construction projects, and construction projects always involve designing contracts between the owner and the contractor. However, how the contract affects the level of conflict between the owner and the contractor has not been elaborated. The purpose of this paper is to explain the effects of contractual complexity on the level of conflict, including task conflict and relationship conflict, and then to demonstrate the moderating role played by the interdependence between the owner and the contractor. Using data from owners and general contractors in the Chinese construction industry, this research reveals that contractual control will reduce relationship conflict. Contractual coordination will also reduce relationship conflict by the mediating effect of task conflict. Besides, under high joint interdependence, the positive relationship between task conflict and relationship conflict is strengthened, while high interdependence asymmetry has effects on weakening the relationship between task conflict and relationship conflict. The findings provide guidance for contract designers to draft suitable contracts in order to effectively deal with conflict. Additionally, this research implies that project managers should highlight the importance of contract in conflict management.

Keywords: construction projects, contract governance, interdependence, relationship conflict, task conflict

Procedia PDF Downloads 186

Authors: Rashmi Shahu

Abstract:

Flexibility is becoming a more widely accepted aspect of project management. Although contingency theory in project management states that the unknowns are controllable, complexity theory believes that the best way to handle the unknowns would be to have a flexible approach rather than rigidity. Designing a flexible system is a method of managing uncertainty. The present research work aims to evaluate flexibility in the initial design phase of projects taking examples of construction projects. Flexibility in the initial design phase is modeled in order to know the advantage in future. The comparison between the extra cost of flexibility in the initial design phase and the discount that can be achieved in future due to this premium will help the developers in making strategic decisions. This research uses a methodology for valuing flexibility by developing a mathematical formula for predicting future saving of cost. Two case studies were considered in this research to validate the mathematical formula. This research explains three case studies of an educational institution 28 years old for explaining the concept and giving benefits of flexible design for modification/renovation work of building.

Keywords: flexibility, future saving, flexibility cost, construction projects

Procedia PDF Downloads 330

Authors: Gurbir Singh Khaira, Anmoldeep Singh Kang

Abstract:

Exposures to environmental pollution remain a major source of health risk throughout the world, though risks are generally higher in developing countries, where poverty, lack of investment in modern technology and weak environmental legislation combine to cause high pollution levels. This paper will tell us about the environment is threatened severely by so many problems, some of which are caused by the activities of Construction Projects. The research reveals major environmental impacts of building construction projects to include environmental pollution, resource depletion and habitat destruction causing Destruction of ecosystem, Desertification, Soil Erosion and increasing Material Wastage. Construction is considered as one of the main sources of environmental pollution in the world, the level of knowledge and awareness of project participants, especially project managers, with regards to environmental impacts of construction processes needs to be enhanced. It was found that ‘Transportation Resource’, ‘Noise Pollution’, and ‘Dust Generation with Construction Machinery’ are the greatest environmental impacts in INDIA respectively. The results of this study are useful for construction managers and other participants in construction sites to become aware of construction processes impacts on the environment.

Keywords: construction projects, environmental impacts, material waste age, awareness

Procedia PDF Downloads 341

Authors: John Zanetich

Abstract:

Designing an educational activity that encourages inquiry and collaboration is key to engaging students in meaningful learning. Educational Information and Communications Technology (EICT) plays an important role in facilitating cooperative and collaborative learning in the classroom. The EICT also facilitates students’ learning and development of the critical thinking skills needed to solve real world problems. Projects and activities based on constructivism encourage students to embrace complexity as well as find relevance and joy in their learning. It also enhances the students’ capacity for creative and responsible real-world problem solving. Classroom activities based on constructivism offer students an opportunity to develop the higher–order-thinking skills of defining problems and identifying solutions. Participating in a classroom project is an activity for both acquiring experiential knowledge and applying new knowledge to practical situations. It also provides an opportunity for students to integrate new knowledge into a skill set using reflection. Classroom projects can be developed around a variety of learning objects including social media, knowledge management and learning communities. The construction of meaning through project-based learning is an approach that encourages interaction and problem-solving activities. Projects require active participation, collaboration and interaction to reach the agreed upon outcomes. Projects also serve to externalize the invisible cognitive and social processes taking place in the activity itself and in the student experience. This paper describes a classroom project designed to elicit interactions by helping students to unfreeze existing knowledge, to create new learning experiences, and then refreeze the new knowledge. Since constructivists believe that students construct their own meaning through active engagement and participation as well as interactions with others. knowledge management can be used to guide the exchange of both tacit and explicit knowledge in interpersonal interactions between students and guide the construction of meaning. This paper uses an action research approach to the development of a classroom project and describes the use of technology, social media and the active use of tacit knowledge in the college classroom. In this project, a closed group Facebook page becomes the virtual classroom where interaction is captured and measured using engagement analytics. In the virtual learning community, the principles of knowledge management are used to identify the process and components of the infrastructure of the learning process. The project identifies class member interests and measures student engagement in a learning community by analyzing regular posting on the Facebook page. These posts are used to foster and encourage interactions, reflect a student’s interest and serve as reaction points from which viewers of the post convert the explicit information in the post to implicit knowledge. The data was collected over an academic year and was provided, in part, by the Google analytic reports on Facebook and self-reports of posts by members. The results support the use of active tacit knowledge activities, knowledge management and social media to enhance the student learning experience and help create the knowledge that will be used by students to construct meaning.

Keywords: constructivism, knowledge management, tacit knowledge, social media

Procedia PDF Downloads 193

Authors: Kais Amir Kadhim

Abstract:

Context: The study focuses on the rhetorical structure of chapters in engineering final year projects, specifically the Introduction chapter, written by UMT (University of Marine Technology) engineering students. Existing research has explored the use of genre-based approaches to analyze the writing of final year projects in various disciplines. Research Aim: The aim of this study is to investigate the rhetorical structure of Introduction chapters in engineering final year projects by UMT students. The study aims to identify the frequency of communicative moves and their constituent steps within the Introduction chapters, as well as understand how students justify their research projects. Methodology: The research design will utilize a mixed method approach, combining both quantitative and qualitative methods. Forty Introduction chapters from two different fields in UMT engineering undergraduate programs will be selected for analysis. Findings: The study intends to identify the types of moves present in the Introduction chapters of engineering final year projects by UMT students. Additionally, it aims to determine if these moves and steps are obligatory, conventional, or optional. Theoretical Importance: The study draws upon Bunton's modified CARS (Creating a Research Space) model, which is a conceptual framework used for analyzing the introduction sections of theses. By applying this model, the study contributes to the understanding of the rhetorical structure of Introduction chapters in engineering final year projects. Data Collection: The study will collect data from forty Introduction chapters of engineering final year projects written by UMT engineering students. These chapters will be selected from two different fields within UMT's engineering undergraduate programs. Analysis Procedures: The analysis will involve identifying and categorizing the communicative moves and their constituent steps within the Introduction chapters. The study will utilize both quantitative and qualitative analysis methods to examine the frequency and nature of these moves. Question Addressed: The study aims to address the question of how UMT engineering students structure and justify their research projects within the Introduction chapters of their final year projects. Conclusion: The study aims to contribute to the knowledge of rhetorical structure in engineering final year projects by investigating the Introduction chapters written by UMT engineering students. By using a mixed method research design and applying the modified CARS model, the study intends to identify the types of moves and steps employed by students and explore their justifications for their research projects. The findings have the potential to enhance the understanding of effective academic writing in engineering disciplines.

Keywords: cohesive markers, learning, meaning, students

Procedia PDF Downloads 49

Authors: Mehrdad Abkenari, Mehmet Kunt, Mahdi Nourollahi

Abstract:

Evaluating the environmental risk factors is a combination of analysis of transportation effects. Various definitions for risk can be found in different scientific sources. Each definition depends on a specific and particular perspective or dimension. The effects of potential risks present along the new proposed routes and existing infrastructures of large transportation projects like railways should be studied under comprehensive engineering frameworks. Despite various definitions provided for ‘risk’, all include a uniform concept. Two obvious aspects, loss and unreliability, have always been pointed in all definitions of this term. But, selection as the third aspect is usually implied and means how one notices it. Currently, conducting engineering studies on the environmental effects of railway projects have become obligatory according to the Environmental Assessment Act in developing countries. Considering the longitudinal nature of these projects and probable passage of railways through various ecosystems, scientific research on the environmental risk of these projects have become of great interest. Although many areas of expertise such as road construction in developing countries have not seriously committed to these studies yet, attention to these subjects in establishment or implementation of different systems have become an inseparable part of this wave of research. The present study used environmental risks identified and existing in previous studies and stations to use in next step. The second step proposes a new hybrid approach of analytical network process (ANP) and DEMATEL in fuzzy conditions for assessment of determined risks. Since evaluation of identified risks was not an easy touch, mesh structure was an appropriate approach for analyzing complex systems which were accordingly employed for problem description and modeling. Researchers faced the shortage of real space data and also due to the ambiguity of experts’ opinions and judgments, they were declared in language variables instead of numerical ones. Since fuzzy logic is appropriate for ambiguity and uncertainty, formulation of experts’ opinions in the form of fuzzy numbers seemed an appropriate approach. Fuzzy DEMATEL method was used to extract the relations between major and minor risk factors. Considering the internal relations of risk major factors and its sub-factors in the analysis of fuzzy network, the weight of risk’s main factors and sub-factors were determined. In general, findings of the present study, in which effective railway environmental risk indicators were theoretically identified and rated through the first usage of combined model of DEMATEL and fuzzy network analysis, indicate that environmental risks can be evaluated more accurately and also employed in railway projects.

Keywords: DEMATEL, ANP, fuzzy, risk

Procedia PDF Downloads 385

Authors: Hailu Kebede Bekele

Abstract:

Construction delays are suitable where project events occur at a certain time expected due to causes related to the client, consultant, and contractor. Delay is the major cause of the cost overrun that leads to the poor efficiency of the project. The cost difference between completion and the originally estimated is known as cost overrun. The common ways of cost overruns are not simple issues that can be neglected, but more attention should be given to prevent the organization from being devastated to be failed, and financial expenses to be extended. The reasons that may raised in different studies show that the problem may arise in construction projects due to errors in budgeting, lack of favorable weather conditions, inefficient machinery, and the availability of extravagance. The study is focused on the pace of mega projects that can have a significant change in the cost overrun calculation.15 mega projects are identified to study the problem of the cost overrun in the site. The contractor, consultant, and client are the principal stakeholders in the mega projects. 20 people from each sector were selected to participate in the investigation of the current mega construction project. The main objective of the study on the construction cost overrun is to prioritize the major causes of the cost overrun problem. The methodology that was employed in the construction cost overrun is the qualitative methodology that mostly rates the causes of construction project cost overrun. Interviews, open-ended and closed-ended questions group discussions, and rating qualitative methods are the best methodologies to study construction projects overrun. The result shows that design mistakes, lack of labor, payment delay, old equipment and scheduling, weather conditions, lack of skilled labor, payment delays, transportation, inflation, and order variations, market price fluctuation, and people's thoughts and philosophies, the prior cause of the cost overrun that fail the project performance. The institute shall follow the scheduled activities to bring a positive forward in the project life.

Keywords: cost overrun, delay, mega projects, design

Procedia PDF Downloads 31

Authors: Abdullah Mohammed Alshehri

Abstract:

The projects in the construction industry have significantly increased, given its contribution to the overall Gross Domestic Product (GDP) of the countries. Reflecting upon the complex nature and involvement of various agents, the study aims to analyze the conflicts cause within construction projects. Therefore, the study strived to come out with understanding the levels of conflict interaction across project phases. However, this conducted by investigating the association between antecedents and apparent conflicts inherent in. The study used a qualitative approach for collecting the data through a quantitative, semi-structured method. Formation of a questionnaire survey has been conducted for over 30 respondents. However, the survey came out with the identification of 25 conflict cause categories, which can take place in different construction project phases, including pre-design phase, pre-construction phase, construction phase, commissioning, and completion phase. For example, conflicts associated with inconsistencies or discrepancies within or between project documents, which took place at tendering time in the pre-construction phase were relatable with the selection of material specifications that should be supplied or used in the construction projects at the construction phase. Its analysis can provide comprehensive understanding, trace the root of the problem, which offers a roadmap to deepen the understanding of the conflict conditions and ‘course of action’ necessary for project management strategy actions toward avoiding or minimizing conflict causes at project life.

Keywords: construction, conflict causes, levels, interaction, phases

Procedia PDF Downloads 149

Authors: Mohammed F. Haddad, Mohammad A. Albenayyan

Abstract:

Realistically, 3-D printing as a technology has not yet reached the required maturity level to handle construction housing projects for citizens on a country scale. However, potentially, it has all of the required elements for addressing this issue. There are two main high-level elements of this technology that need to be capitalized on in order for the technology to reach its full potential, technical and logistical. This paper aims to cover how 3-D printing can be a viable technical solution for housing projects and describe the impact of 3-D printing technical features on the logistical aspects of completing a housing project. Additionally, a perspective about 3-D printing in Saudi Arabia will be presented in order to give the reader an idea of where the kingdom stands in the deployment of this technology. Finally, a glimpse will be given regarding the potential utilization of this technology for space applications.

Keywords: large-scale 3-D printing, additive manufacturing, D- shape, contour crafting

Procedia PDF Downloads 98

Authors: M. Aladwani, Y. Alarfaj

Abstract:

The construction industry is currently experiencing a shift towards digitisation. This transformation is driven by adopting technologies like Building Information Modelling (BIM), drones, and augmented reality (AR). These advancements are revolutionizing the process of designing, constructing, and operating projects. BIM, for instance, is a new way of communicating and exploiting technology such as software and machinery. It enables the creation of a replica or virtual model of buildings or infrastructure projects. It facilitates simulating construction procedures, identifying issues beforehand, and optimizing designs accordingly. Drones are another tool in this revolution, as they can be utilized for site surveys, inspections, and even deliveries. Moreover, AR technology provides real-time information to workers involved in the project. Implementing these technologies in the construction industry has brought about improvements in efficiency, safety measures, and sustainable practices. BIM helps minimize rework and waste materials, while drones contribute to safety by reducing workers' exposure to areas. Additionally, AR plays a role in worker safety by delivering instructions and guidance during operations. Although the digital transformation within the construction industry is still in its early stages, it holds the potential to reshape project delivery methods entirely. By embracing these technologies, construction companies can boost their profitability while simultaneously reducing their environmental impact and ensuring safer practices.

Keywords: BIM, digital construction, construction technologies, digital transformation

Procedia PDF Downloads 53

Authors: Abdulrahman M. Qahtani, Gary. B. Wills, Andy. M. Gravell

Abstract:

Communicating and managing customers’ requirements in software development projects play a vital role in the software development process. While it is difficult to do so locally, it is even more difficult to communicate these requirements over distributed boundaries and to convey them to multiple distribution customers. This paper discusses the communication of multiple distribution customers’ requirements in the context of customised software products. The main purpose is to understand the challenges of communicating and managing customisation requirements across distributed boundaries. We propose a model for Communicating Customisation Requirements of Multi-Clients in a Distributed Domain (CCRD). Thereafter, we evaluate that model by presenting the findings of a case study conducted with a company with customisation projects for 18 distributed customers. Then, we compare the outputs of the real case process and the outputs of the CCRD model using simulation methods. Our conjecture is that the CCRD model can reduce the challenge of communication requirements over distributed organisational boundaries, and the delay in decision making and in the entire customisation process time.

Keywords: customisation software products, global software engineering, local decision making, requirement engineering, simulation model

Procedia PDF Downloads 399