Search results for: construction strategy
Commenced in January 2007
Frequency: Monthly
Edition: International
Paper Count: 7501

Search results for: construction strategy

7441 Time Overrun in Pre-Construction Planning Phase of Construction Projects

Authors: Hafiz Usama Imad, Muhammad Akram Akhund, Tauha Hussain Ali, Ali Raza Khoso, Fida Hussain Siddiqui

Abstract:

Construction industry plays a significant role in fulfilling the major requirements of the human being. It is one of the major constituents of every developed country. Although the construction industry of both the developing and developed countries encompasses a major part of the economy, and millions of rupees are utilized every year on various kinds of construction projects. But, this industry is facing numerous hurdles in terms of its budget and timely completion. Construction projects generally consist of several phases like planning, designing, execution, and finishing. This research study aims to determine the significant factors of time overrun in pre-construction planning (PCP) phase of construction projects in Pakistan. Questionnaires were distributed by various means and responses of respondents were compiled and collected data were then analyzed through a statistical technique using SPSS version 24. Major causes of time overrun in pre-construction planning phase; which is an extremely important phase of construction projects, were revealed. The research conclusion will provide a pathway for stakeholders to pay attention to the mentioned causes to overcome the major issue of time overrun.

Keywords: construction industry, Pakistan, pre-construction planning phase, time overrun

Procedia PDF Downloads 255
7440 A comparative Analysis of the Good Faith Principle in Construction Contracts

Authors: Nadine Rashed, A. Samer Ezeldin, Engy Serag

Abstract:

The principle of good faith plays a critical role in shaping contractual relationships, yet its application varies significantly across different types of construction contracts and legal systems. This paper presents a comparative analysis of how various construction contracts perceive the principle of good faith, a fundamental aspect that influences contractual relationships and project outcomes. The primary objective of this analysis is to examine the differences in the application and interpretation of good faith across key construction contracts, including JCT (Joint Contracts Tribunal), FIDIC (Fédération Internationale des Ingénieurs-Conseils), NEC (New Engineering Contract), and ICE (Institution of Civil Engineers) Contracts. To accomplish this, a mixed-methods approach will be employed, integrating a thorough literature review of current legal frameworks and academic publications with primary data gathered from a structured questionnaire aimed at industry professionals such as contract managers, legal advisors, and project stakeholders. This combined strategy will enable a holistic understanding of the theoretical foundations of good faith in construction contracts and its practical effects in real-world contexts. The findings of this analysis are expected to yield valuable insights into how varying interpretations of good faith can impact project performance, dispute resolution, and collaborative practices within the construction industry. This paper contributes to a deeper understanding of how the principle of good faith is evolving in the construction industry, providing insights for contract drafters, legal practitioners, and project managers seeking to navigate the complexities of contractual obligations across different legal systems.

Keywords: construction contracts, contractual obligations, ethical practices, good faith

Procedia PDF Downloads 25
7439 A Prediction of Electrical Cost for High-Rise Building Construction

Authors: Picha Sriprachan

Abstract:

The increase in electricity prices affects the cost of high-rise building construction. The objectives of this research are to study the electrical cost, trend of electrical cost and to forecast electrical cost of high-rise building construction. The methods of this research are: 1) to study electrical payment formats, cost data collection methods, and the factors affecting electrical cost of high-rise building construction, 2) to study the quantity and trend of cumulative percentage of the electrical cost, and 3) to forecast the electrical cost for different types of high-rise buildings. The results of this research show that the average proportion between electrical cost and the value of the construction project is 0.87 percent. The proportion of electrical cost for residential, office and commercial, and hotel buildings are closely proportional. If construction project value increases, the proportion of electrical cost and the value of the construction project will decrease. However, there is a relationship between the amount of electrical cost and the value of the construction project. During the structural construction phase, the amount of electrical cost will increase and during structural and architectural construction phase, electrical cost will be maximum. The cumulative percentage of the electrical cost is related to the cumulative percentage of the high-rise building construction cost in the same direction. The amount of service space of the building, number of floors and the duration of the construction affect the electrical cost of construction. The electrical cost of construction forecasted by using linear regression equation is close to the electrical cost forecasted by using the proportion of electrical cost and value of the project.

Keywords: high-rise building construction, electrical cost, construction phase, architectural phase

Procedia PDF Downloads 391
7438 Assessing the Influence of Using Traditional Methods of Construction on Cost and Quality of Building Construction

Authors: Musoke Ivan, Birungi Racheal

Abstract:

The construction trend is characterized by increased use of modern methods yet traditional methods are cheaper in terms of costs, in addition to the benefits it offers to the construction sector, like providing more jobs that could have been worked with the intensive machines. The purpose of this research was to assess the influence of using Traditional methods of construction (TMC) on the costs and quality of building structures and determine the different ways. Traditional methods of construction (TMC) can be applicable and integrated into the construction trend, and propose ways how this can be a success. The study adopted a quantitative method approach targeting various construction professionals like Architects, Quantity surveyors, Engineers, and Construction Managers. Questionnaires and analyses of literature were used to obtain research data and findings. Simple random sampling was used to select 40 construction professionals to which questionnaires were administered. The data was then analyzed using Microsoft Excel. The findings of the research indicate that Traditional methods of construction (TMCs) in Uganda are cheaper in terms of costs, but the quality is still low. This is attributed to a lack of skilled labour and efficient supervision while undertaking tasks leading to low quality. The study identifies strategies that would improve Traditional methods of construction (TMC), which include the employment of skilled manpower and effective supervision. It also identifies the need by stakeholders like the government, clients, and professionals to appreciate Traditional methods of construction (TMCs) and allow for a levelled ground for Traditional Methods of Construction and Modern methods of construction (MMCs).

Keywords: traditional methods of construction, integration, cost, quality

Procedia PDF Downloads 63
7437 Late Payment Issues Faced by Subcontractors in the Malaysian Construction Industry

Authors: Nur Emma Mustaffa, Hii Ping Ping

Abstract:

Late payment is a common issue in the construction industry and the subcontractors are not spared from it. This study has been carried out with the objectives to identify the implications of late payment issues toward the subcontractors and the strategies adopted by them to overcome the late payment issues. In terms of the strategies which can be adopted in overcoming the late payment, the subcontractors may suspend or slow down the construction process, making periodic follow up with the client, demand the rights to interest on late payment or the issuance of a promissory note by the client. The focus of the study is primarily on Grade 4 to Grade 7 contractors in Johor Bahru, Malaysia who carried out subcontracting works and registered under Construction Industry Development Board (CIDB). Employing survey as the main research method for data collection, the analysis would therefore mainly be adopting Likert Scale Analysis, Ranking Analysis and Frequency Distribution Analysis. This research showed the main implication of late payment issues towards subcontractors is created financial hardship to them. Besides, the most effective strategy adopted by the subcontractors to overcome the late payment issues is follow-up with client using formal procedure. From the findings, most of the subcontractors had low level of experiences and frequency in the adoption of Construction Industry Payment and Adjudication Act (CIPAA) 2012 to solve the payment disputes in the construction industry. In a nutshell, it is hoped that these findings will become guidance to the subcontractors to overcome the late payment issues in their future projects.

Keywords: subcontractors, implications, strategies, CIPAA 2012, payment

Procedia PDF Downloads 174
7436 Pure and Mixed Nash Equilibria Domain of a Discrete Game Model with Dichotomous Strategy Space

Authors: A. S. Mousa, F. Shoman

Abstract:

We present a discrete game theoretical model with homogeneous individuals who make simultaneous decisions. In this model the strategy space of all individuals is a discrete and dichotomous set which consists of two strategies. We fully characterize the coherent, split and mixed strategies that form Nash equilibria and we determine the corresponding Nash domains for all individuals. We find all strategic thresholds in which individuals can change their mind if small perturbations in the parameters of the model occurs.

Keywords: coherent strategy, split strategy, pure strategy, mixed strategy, Nash equilibrium, game theory

Procedia PDF Downloads 149
7435 Construction Project Planning Using Fuzzy Critical Path Approach

Authors: Omar M. Aldenali

Abstract:

Planning is one of the most important phases of the management science and network planning, which represents the project activities relationship. Critical path is one of the project management techniques used to plan and control the execution of a project activities. The objective of this paper is to implement a fuzzy logic approach to arrange network planning on construction projects. This method is used to finding out critical path in the fuzzy construction project network. The trapezoidal fuzzy numbers are used to represent the activity construction project times. A numerical example that represents a house construction project is introduced. The critical path method is implemented on the fuzzy construction network activities, and the results showed that this method significantly affects the completion time of the construction projects.

Keywords: construction project, critical path, fuzzy network project, planning

Procedia PDF Downloads 144
7434 Using Wearable Technology to Monitor Workers’ Stress for Construction Safety: A Conceptual Framework

Authors: Namhun Lee, Seong Jin Kim

Abstract:

The construction industry represents one of the largest industries in the United States, yet it continues to face several occupational health and safety challenges. Many workers on construction sites are suffering from extended exposure to stressful situations such as poor and hazardous work environments and task complexity. Stress can be commonly defined as a feeling of emotional or physical tension, which can easily impact construction safety and result in a higher rate of job-related injuries in the construction industry. Physiological signals transmitted from wearable biosensors can be used to detect excessive stress. Therefore, workers’ stress should be detected and mitigated to prevent any type of serious incident or accident proactively. By doing this, construction productivity, as well as job satisfaction, would also be improved in the construction industry. To establish a foundation in this field of research, a conceptual framework for using wearable technology for construction safety has been developed for continuous and automatic monitoring of worker’s stress. The conceptual framework will serve as a foothold in future studies on the application of wearable technology for construction safety.

Keywords: construction safety, occupational stress, stress monitoring, wearable biosensors

Procedia PDF Downloads 161
7433 Uptake of Off-Site Construction: Benefit and Future Application

Authors: Faisal Alazzaz, Andrew Whyte

Abstract:

Off-site construction methods have played an important role in the construction sector in the past few decades. It is increasingly becoming a major alternative technique and strategic direction compared to traditional in-situ method. It produces a significant amount of value for the construction industry and the economy more generally. To date, an impressive number of studies have been lunched on the perceived perception of off-site construction. However, it seems that a quantifying benefit on the offsite construction area is lacking. Therefore, this paper examines the recent research literature on the benefits of off- site construction and provides future direction. In the beginning, this paper provides a brief history and current value of the off-site construction followed by a detailed discussion on the benefit of off-site construction. These benefits include but not limited to time saving, quality improvement, relieving skills shortages, cost reduction and productivity improvement. Toward this end, off-site construction should learn from other productive industry similar to services or manufacturing industry by applying operational management tools and techniques with extensive focus on employee empowerment will shed the light on future uptake of Off-site construction. This study is of value in providing scholars have a clear picture of perceived benefit of off-site construction research and give an opportunities for future uptake of off-site method.

Keywords: building projects, employer empowerment, off-site construction benefits, productivity

Procedia PDF Downloads 438
7432 Labour-saving Construction Using Buildability Framework through Strengthening Designers in Delivering More Buildable Designs

Authors: Muhammad Lawal A., Abdullateef Abdulkarim Jimoh

Abstract:

This study is to appraise the labour-saving construction methods achievable using a buildability framework through an improved design system. Adoption of labour-efficient technology and construction techniques will be necessary to supplement good buildable designs. Increased usage of prefabricated, modular, and standardized construction components, simplicity in the design, and the number of integrated elements all work to advance buildable design. The objectives of the study include `determining a more efficient buildability framework for designers to achieve labour-saving construction’. 20 completed building projects in Birnin Kebbi, Nigeria, is used as a case study to buttress the proposition that `a more buildable design using buildability frame result in labour-saving in construction adopting a Singapore study approach.

Keywords: buildability framework, buildable designs, construction, labour-saving construction

Procedia PDF Downloads 103
7431 Sustainable Framework Integration for Construction Project Management: A Multi-Dimensional Analysis

Authors: Tharaki S. Hettiarachchi

Abstract:

Sustainable construction has gained massive attention in the present world as the construction industry is highly responsible for carbon emissions and other types of unsustainable practices. Yet, the construction industry has not been able to completely attain sustainable goals. Therefore, the present study aims to identify the extent to which sustainability has been considered within the scope of construction project management and to analyze the challenges, gaps, and constraints associated. Accordingly, this study develops a sustainable framework to integrate in construction project management. In accomplishing the research aim, this research integrates a qualitative approach while relying on secondary data sources. The data shall be then analyzed with the use of a systematic literature review (SLR) method while following the PRISMA (2020) guideline and represented in a statistical form. The outcomes of this study may become highly significant in identifying the nature of the existing sustainable frameworks associated with construction project management scopes and to develop a new framework to integrate in order to enhance the effectiveness of sustainable applications in construction management. The outcomes of this research may benefit present and future construction professionals and academicians to organize sustainable construction-related knowledge in a useful way to apply in practical implementation for effective project management. Overall, this study directs present and future construction professionals toward an advanced construction project management mechanism.

Keywords: construction, framework development, project management, sustainability

Procedia PDF Downloads 62
7430 Factors Affecting Time Performance in Building Construction Projects

Authors: Ibraheem A. K. Mahameed

Abstract:

The aim of this study is to identify the risks affecting time performance of building construction projects in the West Bank in Palestine from contractors’ viewpoint. 38 risks that might affect time performance of building construction projects were defined through a detailed literature review. These risks have been classified into 6 groups: project, managerial, consultant, financial, external, and construction items. A questionnaire survey was performed to rank the considered risks in terms of severity and frequency. The analysis of the survey indicated that the top five risks affecting time performance of building construction projects in Palestine are: award project to the lowest price, political situation, poor communication and coordination between construction parties, change orders, and financial status of contractor.

Keywords: delay, time performance, construction, building

Procedia PDF Downloads 473
7429 Achieving Sustainable Rapid Construction Using Lean Principles

Authors: Muhamad Azani Yahya, Vikneswaran Munikanan, Mohammed Alias Yusof

Abstract:

There is the need to take the holistic approach in achieving sustainable construction for a contemporary practice. Sustainable construction is the practice that involved method of human preservation of the environment, whether economically or socially through responsibility, management of resources and maintenance utilizing support. This paper shows the correlation of achieving rapid construction with sustainable concepts using lean principles. Lean principles being used widely in the manufacturing industry, but this research will demonstrate the principles into building construction. Lean principle offers the benefits of stabilizing work flow and elimination of unnecessary work. Therefore, this principle contributes to time and waste reduction. The correlation shows that pulling factor provides the improvement of progress curve and stabilizing the time-quality relation. The finding shows the lean principles offer the elements of rapid construction synchronized with the elements of sustainability.

Keywords: sustainable construction, rapid construction, time reduction, lean construction

Procedia PDF Downloads 236
7428 Representing a Methodology for Refinement of Strategic Objectives in Strategy Map Establishment: Combining Quality Function Deployment and Fuzzy Screening

Authors: Bijan Nahavandi, Navid Jafarinejad, Somayeh Mehrafzad

Abstract:

Strategy maps represent the way of value creation in in each organization. Nowadays, implementation of strategy is the main concern for all organizations. Strategy map establishment is the start-up point of strategy implementation and this shows the critical importance of this concept. After some years past since emergence of strategy map, there are some shortcomings in its methodology that frequently quoted by many of researchers. One of these shortcomings is the shortage of a mechanism for refinement of objectives candidate for entrance to map. Organizations in practice have obsession and avidity to determine more number of objectives in strategy map. This study wants to represent a step by step approach to help obviate this problem using quality function deployment (QFD) as a helpful tool and fuzzy screening method. Finally, represented approach applies in a practical case and conclusions have been explained.

Keywords: balanced scorecard, fuzzy screening, house of strategic objectives (HoSO), quality function deployment, strategy map

Procedia PDF Downloads 353
7427 Causes and Effects of Delays in Construction Projects in Akure, Ondo State, South-West Nigeria

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 510
7426 Hybrid Concrete Construction (HCC) for Sustainable Infrastructure Development in Nigeria

Authors: Muhammad Bello Ibrahim, M. Auwal Zakari, Aliyu Usman

Abstract:

Hybrid concrete construction (HCC) combines all the benefits of pre-casting with the advantages of cast in-situ construction. Merging the two, as a hybrid structure, results in even greater construction speed, value, and the overall economy. Its variety of uses has gained popularity in the United States and in Europe due to its distinctive benefits. However, the increase of its application in some countries (including Nigeria) has been relatively slow. Several researches have shown that hybrid construction offers an ultra-high performance concrete that offers superior strength, durability and aesthetics with design flexibility and within sustainability credentials, based on the available and economically visible technologies. This paper examines and documents the criterion that will help inform the process of deciding whether or not to adopt hybrid concrete construction (HCC) technology rather than more traditional alternatives. It also the present situation of design, construction and research on hybrid structures.

Keywords: hybrid concrete construction, Nigeria, sustainable infrastructure development, design flexibility

Procedia PDF Downloads 561
7425 Major Causes of Delay in Construction Projects

Authors: Y. Gholipour, E. Rezazadeh

Abstract:

Delay is one of the most serious and common problems of construction project that can affect project delivery unfavorably. This research presents the most important causes of delay in large dam projects based on a survey on some executed dam construction in Iran. In this survey a randomly selected samples of owners, consultants and contractors have been involved. The outcome of this survey revealed that scheduled payments, site management, shop drawing review process, unforeseen ground conditions and contractor experience as the most important factors affecting on delay in dam construction projects.

Keywords: delay, dam construction, project management, Iran

Procedia PDF Downloads 447
7424 Development of Construction Cost Optimization System Using Genetic Algorithm Method

Authors: Hyeon-Seung Kim, Young-Hwan Kim, Sang-Mi Park, Min-Seo Kim, Jong-Myeung Shin, Leen-Seok Kang

Abstract:

The project budget at the planned stage might be changed by the insufficient government budget or the design change. There are many cases more especially in the case of a project performed for a long period of time. If the actual construction budget is insufficient comparing with the planned budget, the construction schedule should also be changed to match the changed budget. In that case, most project managers change the planned construction schedule by a heuristic approach without a reasonable consideration on the work priority. This study suggests an optimized methodology to modify the construction schedule according to the changed budget. The genetic algorithm was used to optimize the modified construction schedule within the changed budget. And a simulation system of construction cost histogram in accordance with the construction schedule was developed in the BIM (Building Information Modeling) environment.

Keywords: 5D, BIM, GA, cost optimization

Procedia PDF Downloads 588
7423 Design Standardization in Aramco: Strategic Analysis

Authors: Mujahid S. Alharbi

Abstract:

The construction of process plants in oil and gas-producing countries, such as Saudi Arabia, necessitates substantial investment in design and building. Each new plant, while unique, includes common building types, suggesting an opportunity for design standardization. This study investigates the adoption of standardized Issue For Construction (IFC) packages for non-process buildings in Saudi Aramco. A SWOT analysis presents the strengths, weaknesses, opportunities, and threats of this approach. The approach's benefits are illustrated using the Hawiyah Unayzah Gas Reservoir Storage Program (HUGRSP) as a case study. Standardization not only offers significant cost savings and operational efficiencies but also expedites project timelines, reduces the potential for change orders, and fosters local economic growth by allocating building tasks to local contractors. Standardization also improves project management by easing interface constraints between different contractors and promoting adaptability to future industry changes. This research underscores the standardization of non-process buildings as a powerful strategy for cost optimization, efficiency enhancement, and local economic development in process plant construction within the oil and gas sector.

Keywords: building, construction, management, project, standardization

Procedia PDF Downloads 64
7422 Constant Dimension Codes via Generalized Coset Construction

Authors: Kanchan Singh, Sheo Kumar Singh

Abstract:

The fundamental problem of subspace coding is to explore the maximum possible cardinality Aq(n, d, k) of a set of k-dimensional subspaces of an n-dimensional vector space over Fq such that the subspace distance satisfies ds(W1, W2) ≥ d for any two distinct subspaces W1, W2 in this set. In this paper, we construct a new class of constant dimension codes (CDCs) by generalizing the coset construction and combining it with CDCs derived from parallel linkage construction and coset construction with an aim to improve the new lower bounds of Aq(n, d, k). We found a remarkable improvement in some of the lower bounds of Aq(n, d, k).

Keywords: constant dimension codes, rank metric codes, coset construction, parallel linkage construction

Procedia PDF Downloads 24
7421 Reading Strategy Awareness of English Major Students

Authors: Hsin-Yi Lien

Abstract:

The study explored the role of metacognition in foreign language anxiety on a sample of 411 Taiwanese students of English as a Foreign Language. The reading strategy inventory was employed to evaluate the tertiary learners’ level of metacognitive awareness and a semi-structured background questionnaire was also used to examine the learners’ perceptions of their English proficiency and satisfaction of their current English learning. In addition, gender and academic level differences in employment of reading strategies were investigated. The results showed the frequency of reading strategy use increase slightly along with academic years and males and females actually employ different reading strategies. The EFL tertiary learners in the present study utilized cognitive strategies more frequently than metacognitive strategies or support strategies. Male students use metacognitive strategy more often while female students use cognitive and support strategy more frequently.

Keywords: cognitive strategy, gender differences, metacognitive strategy, support strategy

Procedia PDF Downloads 416
7420 Modelling Strategy Planning in Multi Business Companies

Authors: Gelareh Changizi, Mahsa Khajavi, Ladan Shahhosseini

Abstract:

Corporate-level strategy, or simply ‘parent strategy’, is a topic that has received much attention since the very early days of the strategic planning field. Since the multi level enterprises have different sub enterprises which deal with different business environments, we cannot define the same strategic perspective for all of them. Therefore, the determination of a perspective to manage and deal with affiliates of such enterprises is the main challenge. The parent strategy in mother enterprises' level has been analyzed in this research. A case study has been carried to comprehensively describe the proposed model.

Keywords: parent strategy, multi-business companies, performance evaluation, lifecycle

Procedia PDF Downloads 368
7419 The Eco-Efficient Construction: A Review of Embodied Energy in Building Materials

Authors: Francesca Scalisi, Cesare Sposito

Abstract:

The building construction industry consumes a large amount of resources and energy, both during construction (embodied energy) and during the operational phase (operating energy). This paper presents a review of the literature on low carbon and low embodied energy materials in buildings. The embodied energy comprises the energy consumed during the extraction, processing, transportation, construction, and demolition of building materials. While designing a nearly zero energy building, it is necessary to choose and use materials, components, and technologies that allow to reduce the consumption of energy and also to reduce the emissions in the atmosphere during all the Life Cycle Assessment phases. The appropriate choice of building materials can contribute decisively to reduce the energy consumption of the building sector. The increasing worries for the environmental impact of construction materials are witnessed by a lot of studies. The mentioned worries have brought again the attention towards natural materials. The use of more sustainable construction materials and construction techniques represent a major contribution to the eco-efficiency of the construction industry and thus to a more sustainable development.

Keywords: embodied energy, embodied carbon, life cycle assessment, architecture, sustainability, material construction

Procedia PDF Downloads 344
7418 Methodology of Construction Equipment Optimization for Earthwork

Authors: Jaehyun Choi, Hyunjung Kim, Namho Kim

Abstract:

Earthwork is one of the critical civil construction operations that require large-quantities of resources due to its intensive dependency upon construction equipment. Therefore, efficient construction equipment management can highly contribute to productivity improvements and cost savings. Earthwork operation utilizes various combinations of construction equipment in order to meet project requirements such as time and cost. Identification of site condition and construction methods should be performed in advance in order to develop a proper execution plan. The factors to be considered include capacity of equipment assigned, the method of construction, the size of the site, and the surrounding condition. In addition, optimal combination of various construction equipment should be selected. However, in real world practice, equipment utilization plan is performed based on experience and intuition of management. The researchers evaluated the efficiency of various alternatives of construction equipment combinations by utilizing the process simulation model, validated the model from a case study project, and presented a methodology to find optimized plan among alternatives.

Keywords: earthwork operation, construction equipment, process simulation, optimization

Procedia PDF Downloads 429
7417 Defense Strategy: Perang Semesta Strategy as a Reliable National Security System of Indonesia

Authors: Erdianta S, Chastiti M. Wulolo, IDK Kerta Widana

Abstract:

Perang Semesta strategy is a national security system used by Republic of Indonesia. It comes from local wisdom, cultural, and hereditary of Indonesia itself. This system involves all people and all nation resources, and it is early prepared by government and conducted totality, integratedly, directly, and continously to enforce a sovereignty of country, teritorial integrity and the safety of the whole nation from threats. This study uses a qualitative content analysis method by studying, recording, and analyzing government policy. The Perang Semesta strategy divided into main, backup, and supporting components. Every component has its function and responsibility in security perspective. So when an attack comes, all people of Indonesia will voluntary to defend the country. Perang Semesta strategy is a national security system which becomes the most reliable strategy toward geography and demography of Indonesia.

Keywords: Indonesia, Perang Semesta strategy, national security, local wisdom

Procedia PDF Downloads 455
7416 Research on the Strategy of Old City Reconstruction under Market Orientation: Taking Mutoulong Community in Shenzhen as an Example

Authors: Ziwei Huang

Abstract:

In order to promote Inventory development in Shenzhen, the market-oriented real estate development mode has occupied a dominant position in the urban renewal activities of Shenzhen. This research is based on the theory of role relationship and urban regime, taking the Mutoulong community as the research object. Carries on the case depth analysis found that: Under the situation of absence and dislocation of the government's role, land property rights disputes and lack of communication platforms is the main reason for the problems of nail households and market failures, and the long-term delay in the progress of old city reconstruction. Through the analysis of the cause of the transformation problem and the upper planning and interest coordination mechanism, the optimization strategy of the old city transformation is finally proposed as follows: the establishment of interest coordination platform, the risk assessment of the government's intervention in the preliminary construction of the land, the adaptive construction of laws and regulations, and the re-examination of the interest relationship between the government and the market.

Keywords: Shenzhen city, Mutoulong community, urban regeneration, urban regime theory, role relationship theory

Procedia PDF Downloads 97
7415 Identifying Project Delay Factors in the Australian Construction Industry

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: construction, delay factors, time delay, australian construction industry

Procedia PDF Downloads 176
7414 Abating the Barriers to the Deployment of RFID for Construction Project Delivery in South Africa

Authors: Matthew O. Ikuabe, Ayodeji E. Oke, Clinton O. Aigbavboa, Douglas O. Aghimien

Abstract:

The use of technological innovations have been touted to be beneficial in the delivery of construction projects. Particularly, Radio Frequency Identification (RFID) technology is widely regarded to be of immense advantage for the management of construction projects. This study focused on evaluating the barriers to the use of Radio Frequency Identification (RFID) technology for the delivery of construction projects. Using Gauteng Provincein South Africa as the study area, questionnaire was used in eliciting responses from construction professionals, which made up the population of the study. Retrieved data was analysed using Mean Item Score and One-Sample t-test. Findings from the study showed that the most significant barriers to the deployment of RFID for construction project delivery are high cost and lack of awareness. Conclusively, the study made recommendations that would aid in the abatement of the barriers to the use of RFID technology for construction project delivery.

Keywords: barriers, construction, project delivery, RFID

Procedia PDF Downloads 206
7413 Development of Risk Assessment and Occupational Safety Management Model for Building Construction Projects

Authors: Preeda Sansakorn, Min An

Abstract:

In order to be capable of dealing with uncertainties, subjectivities, including vagueness arising in building construction projects, the application of fuzzy reasoning technique based on fuzzy set theory is proposed. This study contributes significantly to the development of a fuzzy reasoning safety risk assessment model for building construction projects that could be employed to assess the risk magnitude of each hazardous event identified during construction, and a third parameter of probability of consequence is incorporated in the model. By using the proposed safety risk analysis methodology, more reliable and less ambiguities, which provide the safety risk management project team for decision-making purposes.

Keywords: safety risk assessment, building construction safety, fuzzy reasoning, construction risk assessment model, building construction projects

Procedia PDF Downloads 493
7412 An Assessment of the Factors Affecting Green Building Technology (GBT) Adoption

Authors: Nuruddeen Usman, Usman Mohammed Gidado

Abstract:

A construction and post construction activity in buildings contributes to environmental degradation, because of the generation of solid waste during construction to the production of carbon dioxide by the occupants during utilization. These problems were caused as a result of lack of adopting green building technology during and after construction. However, this study aims at conceptualizing the factors that are affecting the adoption of green building technology with a view to suggest better ways for its successful adoption in the construction industry through developing a green building technology model. Thus, the research findings show that: Economic, social, cultural, and technological progresses are the factors affecting Green Building Technology Adoption. Therefore, identifying these factors and developing the model might help in the successful adoption of green building technology.

Keywords: green building technology, construction, post construction, degradation

Procedia PDF Downloads 663