Search results for: project delays bill

Authors: Sunaitan Al Mutairi

Abstract:

A perfect start is a key factor for project completion on time. The study examined the effects of delayed mobilization of resources during the initial phases of the project. This paper mainly highlights the identification and categorization of all delays during the initial construction phase and their root cause analysis with corrective/control measures for the Kuwait Oil Company oil and gas projects. A relatively good percentage of the delays identified during the project execution (Contract award to end of defects liability period) attributed to mobilization/preliminary activity delays. Data analysis demonstrated significant increase in average project delay during the last five years compared to the previous period. Contractors had delays/issues during the initial phase, which resulted in slippages and progressively increased, resulting in time and cost overrun. Delays/issues not mitigated on time during the initial phase had very high impact on project completion. Data analysis of the delays for the past five years was carried out using trend chart, scatter plot, process map, box plot, relative importance index and Pareto chart. Construction of any project inside the Gathering Centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. Delay affects completion of projects and compromises quality, schedule and budget of project deliverables. Works executed as per plan during the initial phase and start-up duration of the project construction activities resulted in minor slippages/delays in project completion. In addition, there was a good working environment between client and contractor resulting in better project execution and management. Mainly, the contractor was on the front foot in the execution of projects, which had minimum/no delays during the initial and construction period. Hence, having a perfect start during the initial construction phase shall have a positive influence on the project success. Our research paper studies each type of delay with some real example supported by statistic results and suggests mitigation measures. Detailed analysis carried out with all stakeholders based on impact and occurrence of delays to have a practical and effective outcome to mitigate the delays. The key to improvement is to have proper control measures and periodic evaluation/audit to ensure implementation of the mitigation measures. The focus of this research is to reduce the delays encountered during the initial construction phase of the project life cycle.

Keywords: construction activities delays, delay analysis for construction projects, mobilization delays, oil & gas projects delays

Procedia PDF Downloads 285

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: construction, delay factors, time delay, australian construction industry

Procedia PDF Downloads 139

Authors: Seyed Ali Mohammadiborna, Mehdi Ravanshadnia

Abstract:

Project delays usually detrimentally affect perceptions of project success and can in some instances, result in increased costs and other time-related damages to project stakeholders. One of the realities in the national infrastructure projects is that since the primary stakeholders are state-affiliated, the delay factors of the projects have not been seriously taken into account despite the importance of on-time completion of projects. Project postponement has different economic and social consequences and leads to the technical and economic infeasibility of the infrastructure projects in the form of reduced productivity and exploitation capacity. The present study aimed at investigating delay factors of Iranian national infrastructure projects according to regulatory reports of the Plan and Budget Organization (BPO) of Iran. The present study scrutinized the influence of each of the factors that caused delays in national Iranian infrastructure projects according to the supervision reports of the planning and budget organization in 8 years. For this purpose, the study analyzed the information regarding the impact of 12 key delay factors causing delays in average 4867 projects per year in all provinces. The said factors were classified into the three groups of executive, credit, and financial and environmental-procurement factors.

Keywords: delays, infrastructure, projects, regulatory

Procedia PDF Downloads 110

Authors: Ayman Mohammed, Abdul Raffay Ilyas, Syeda Rohma Sadia, Zuha Durrani, Fareeha Kamal, Shaheryar Syed, Arshiya Shareef, Mukarram Zaidi

Abstract:

On June 16, 2019, Coalition Avenir de Québec (CAQ) passed Bill 21, a controversial bill impacting many Canadians. The Bill prohibits workers in the Quebec provincial sector from wearing any form of religious articles. While the Bill claims to treat all religious symbols equally, those with distinctive items of dress such as hijabs, kippahs, and turbans become targets of the discriminatory nature of the Bill. With the rise in xenophobic behaviour across Canada and the West, Think For Actions conducted a study of Bill 21. The study included responses from Indigenous, Muslims, Sikhs and Jewish people residing in Calgary. The focus was on the recent passing of Bill 21, their opinions on the perceived attitudes of intolerance, and the perceptions of common stereotypes. The data collection and analysis happened over 9 weeks. The method of data collection was semi-structured interviews held in focus groups in different religious institutions and cultural/community centres in Calgary. The focus groups generated unanimously negative responses to the Bill. Participants described the Bill as “hateful” and one which “targets minority religions”. The participants had hopes that the Bill would be defeated and Quebec residents would be protected by their basic rights to practice their religion.

Keywords: Bill 21, Islamophobia, Quebec, minorities, discrimination

Procedia PDF Downloads 116

Authors: Eunice Chiamaka Allen-Ngbale

Abstract:

Cargo claims are brought by cargo interests against carriers when the goods are not delivered or delivered short or mis-delivered or delivered damaged. The objective of the cargo claimant is to seek recovery for the loss suffered through the award of damages against the carrier by a court of competent jurisdiction. Moreover, whether the vessel on which the goods were carried is or is not under charter, the bill of lading plays a central role in the cargo claim. Since the bill of lading is an important international transport document, this paper examines, by chronicling the progress of a cargo claim as governed by the English law of contract. It finds that other than by contract, there are other modes of recovery available to a consignee or endorsee of a bill of lading to obtain a remedy under the sui generis contract of carriage contained in or evidenced by a bill of lading.

Keywords: bill of lading, cargo interests, carriage contract, transfer of right of suit

Procedia PDF Downloads 115

Authors: Vahid Khadjeh Anvary, Hamideh Karimi Yazdi

Abstract:

Generally, the tool of comparison between performance of each stage in the life of a project, is the number of project progress during that period, which in most cases is only determined as one-dimensional with referring to one of three factors (physical, time, and financial). In many projects in developing countries there are controversies on accuracy and the way of analyzing progress report of projects that hinders getting definitive and engineering conclusions on the status of project.Identifying weakness points of this kind of one-dimensional look on project and determining a reliable and engineering approach for multi-dimensional decoding information receivable from project is of great importance in project management.This can be a tool to help identification of hidden diseases of project before appearing irreversible symptoms that are usually delays or increased costs of execution. The method used in this paper is defining and evaluating a hypothetical project as an example analyzing different scenarios and numerical comparison of them along with related graphs and tables. Finally, by analyzing different possible scenarios in the project, possibility or impossibility of predicting their occurrence is examine through the evidence.

Keywords: physical progress, time progress, financial progress, delays, critical path

Procedia PDF Downloads 345

Authors: Murat Gunduz, Mohanad H. A. AbuHassan

Abstract:

Construction industry mainly focuses on the superstructure, infrastructure, and oil and gas industry. The development of infrastructure projects in developing countries attracted a lot of foreign construction contractors, consultants, suppliers and diversified workforce to interfere and to be evolved in such huge investment. Reducing worksite delays in such projects require knowledge and attention. Therefore, it is important to identify the influencing delay attributes affecting construction projects. The significant project factors affecting construction delays were investigated. Data collection was carried out through an online web survey system to capture significant factors. Significant factors were determined with importance index and relevant recommendations are made. The output of the data analysis would lead the industry experts better assess the impact of construction delays on construction projects.

Keywords: construction industry, delays, importance index, frequency index

Procedia PDF Downloads 310

Authors: Nahed Al-Hajeri

Abstract:

Time and cost is an integral part of every construction plan and can affect each party’s contractual obligations. The performance of both time and cost are usually important to the client and contractor during the project. Almost all construction projects are experiencing time overrun. These time overruns always contributed as expensive to both client and contractor. Construction of any project inside the gathering centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. It also involves many agencies interdependent on each other like the vendors, structural and functional designers including various types of specialized engineers and it includes support of contractors and specialized contractors. This paper mainly highlights the types of construction delays due to which project suffer time and cost overrun. This paper also speaks about the delay causes and factors that contribute to the construction sequence delay for the oil and gas projects. Construction delay is supposed to be one of the repeated problems in the construction projects and it has an opposing effect on project success in terms of time, cost and quality. Some effective methods are identified to minimize delays in construction projects such as: 1. Site management and supervision, 2. Effective strategic planning, 3. Clear information and communication channel. Our research paper studies the types of delay with some real examples with statistic results and suggests solutions to overcome this problem.

Keywords: non-compensable delay, delays caused by force majeure, compensable delay, delays caused by the owner or the owner’s representative, non-excusable delay, delay caused by the contractor or the contractor’s representative, concurrent delay, delays resulting from two separate causes at the same time

Procedia PDF Downloads 221

Authors: Essa Alenazi, Zulfikar Adamu

Abstract:

The Kingdom of Saudi Arabia (KSA) is not an exception in relying on the growth of its construction industry to support rapid population growth. However, its need for infrastructure development is constrained by low productivity levels and cost overruns caused by factors such as delays to project completion. Delays in delivering a construction project are a global issue and while theories such as Optimism Bias have been used to explain such delays, in KSA, client-related causes of delays are also significant. The objective of this paper is to develop a framework-based approach to explore how the country’s construction industry can manage and reduce delays in construction projects through building information modelling (BIM) in order to mitigate the cost consequences of such delays.  It comprehensively and systematically reviewed the global literature on the subject and identified gaps, critical delay factors and the specific benefits that BIM can deliver for the delay management.  A case study comprising of nine hospital projects that have experienced delay and cost overruns was also carried out. Five critical delay factors related to the clients were identified as candidates that can be mitigated through BIM’s benefits. These factors are: Ineffective planning and scheduling of the project; changes during construction by the client; delay in progress payment; slowness in decision making by the client; and poor communication between clients and other stakeholders. In addition, data from the case study projects strongly suggest that optimism bias is present in many of the hospital projects. Further validation via key stakeholder interviews and documentations are planned.

Keywords: building information modelling (BIM), clients perspective, delay management, optimism bias, public sector projects

Procedia PDF Downloads 291

Authors: Edoghogho Ogbeifun, Charles Mbohwa, J. H. C. Pretorius

Abstract:

Several research report on the factors responsible for the delays in the completion of construction projects has identified the issue of funding as a critical factor; insufficient funding, low cash-flow or lack of funds. Indeed, adequate funding plays pivotal role in the effective execution of construction projects. In the last twenty years (or so), there has been increase in the funds available for infrastructure development in tertiary institution in Nigeria, especially, through the Tertiary Education Trust Fund. This funding body ensures that there is enough fund for each approved project, which is released in three stages during the life of the construction project. However, a random tour of many of the institutions reveals striking evidence of projects not delivered on schedule, to quality and sometime out rightly abandoned. This suggests, therefore, that there are other latent factors, responsible for project delays, that should be investigated. Thus, this research, a pilot scheme, is aimed at unearthing the possible reasons for the delays being experienced in the execution of construction projects for infrastructure upgrade in public tertiary institutions in Nigeria, funded by Tertiary Education Trust Fund. The multiple site case study of qualitative research was adopted. The respondents were the Directors of Physical Planning and the Directors of Works of four Nigerian Public Universities. The findings reveal that delays can be situated within three entities, namely, the funding body, the institutions and others. Therefore, the emerging factors have been classified as external factors (haven to do with the funding body), internal factors (these concern the operations within the institutions) and general factors. The outcome of this pilot exercise provides useful information to guide the Directors as they interact with the funding body as well as challenges themselves to address the loopholes in their internal operations.

Keywords: delays, external factors, funding, general factors, Internal factors

Procedia PDF Downloads 114

Authors: Mamoon M. Atout

Abstract:

The Middle East Gulf region has witnessed rapid growth and development in many areas over the last two decades. The development of the real-estate sector, construction industry and infrastructure projects are a major share of the development that has participated in the civilization of the countries of the Gulf. Construction industry projects were planned and managed by different types of experts, who came from all over the world having different types of experiences in construction management and industry. Some of these projects were completed on time, while many were not, due to many accumulating factors. Many accumulated factors are considered as the principle reason for the problem experienced at the project construction stage, which reflected negatively on the project success. Specific causes of delay have been identified by construction managers to avoid any unexpected delays through proper analysis and considerations to some implications such as risk assessment and analysis for many potential problems to ensure that projects will be delivered on time. Construction management implications were adopted and considered by project managers who have experience and knowledge in applying the techniques of the system of engineering construction management. The aim of this research is to determine the benefits of the implications of construction management by the construction team and level of considerations of the techniques and processes during the project development and construction phases to avoid any delay in the projects. It also aims to determine the factors that participate to project completion delays in case project managers are not well committed to their roles and responsibilities. The results of the analysis will determine the necessity of the applications required by the project team to avoid the causes of delays that help them deliver projects on time, e.g. verifying tender documents, quantities and preparing the construction method of the project.

Keywords: construction management, control process, cost control, planning and scheduling

Procedia PDF Downloads 214

Authors: Mokhtar Nikgoo

Abstract:

Today's industrial world has undergone tremendous changes in certain periods. These changes are called environmental changes. And they have a direct impact on organizations and bodies. Therefore, the importance of knowing these changes is clear. This importance has caused the manufacturing organizations to move towards multiple products and constantly change and expand their system. This research tries to show how the organization moves in this category by defining the basic steps of implementing a project. One of the most important features of a hard-to-order production organization is the definition of different production projects from different customers. Therefore, the lack of sufficient understanding of the type of work causes the project to be defined for the organization in question, and the managers of the organization (in every organizational level) are constantly involved with different projects. In the implementation of the production project of the aforementioned organizations, directing the facilities and people of the organization towards the implementation of the project is of particular importance. Therefore, it is felt necessary to define the project manager and his basic duties. Considering the importance of this topic, the project chapter deals with project management and its importance and examines all the different issues in that category from the perspective of implementation. A project includes certain activities of the organization that require the use of different resources and all the activities of the organization in order to implement the project with defined facilities and at the designated times. Project management is planning, organizing and controlling the organization's resources for a short-term goal that has been created for short-term and medium-term goals and objectives. Project management has the important task of centering and integrating (coordinating) task and line managers. In other words, project management requires having a strong and appropriate relationship with the internal people of the system to carry out the assigned activities and must have a general and technical knowledge related to various activities in the project environment. It seems that everything with project management in It is communication. One of the characteristics of production organizations under the order is the relationship between the customer (customers) and the organization until the completion of the defined project. Due to the nature of the work, it is necessary for a person to establish this relationship between the client and the organization's people and to establish this relationship in such a way that it does not cause a lack of coordination in the organization's activities. Therefore, project management has a very important role at this stage, because the relationship between the client and his organization will be any problems and problems and points of view that the client has, he must inform the management so that he can implement the cases with its analysis and special processes. To be transferred to other departments and line managers.

Keywords: project management, crisis management, project delays bill, project duration

Procedia PDF Downloads 23

Authors: Khan Farhan Rafat, Riaz Ahmed

Abstract:

Renowned offshore organizations are drifting towards collaborative exertion to win and implement international projects for business gains. However, devoid of financial constraints, with the availability of skilled professionals, and despite improved project management practices through state-of-the-art tools and techniques, project delays have become a norm these days. This situation calls for exploring the factor(s) affecting the bonding between project management performance and project success. In the context of the well-known 3M’s of project management (that is, manpower, machinery, and materials), machinery and materials are dependent upon manpower. Because the body of knowledge inveterate on the influence of national culture on men, hence, the realization of the impact on the link between project management performance and project success need to be investigated in detail to arrive at the possible cause(s) of project delays. This research initiative was, therefore, undertaken to fill the research gap. The unit of analysis for the proposed research excretion was the individuals who had worked on skyscraper construction projects. In reverent studies, project management is best described using construction examples. It is due to this reason that the project oriented city of Dubai was chosen to reconnoiter on causes of project delays. A structured questionnaire survey was disseminated online with the courtesy of the Project Management Institute local chapter to carry out the cross-sectional study. The Construction Industry Institute, Austin, of the United States of America along with 23 high-rise builders in Dubai were also contacted by email requesting for their contribution to the study and providing them with the online link to the survey questionnaire. The reliability of the instrument was warranted using Cronbach’s alpha coefficient of 0.70. The appropriateness of sampling adequacy and homogeneity in variance was ensured by keeping Kaiser–Meyer–Olkin (KMO) and Bartlett’s test of sphericity in the range ≥ 0.60 and < 0.05, respectively. Factor analysis was used to verify construct validity. During exploratory factor analysis, all items were loaded using a threshold of 0.4. Four hundred and seventeen respondents, including members from top management, project managers, and project staff, contributed to the study. The link between project management performance and project success was significant at 0.01 level (2-tailed), and 0.05 level (2-tailed) for Pearson’s correlation. Before initiating the moderator analysis test for linearity, multicollinearity, outliers, leverage points and influential cases, test for homoscedasticity and normality were carried out which are prerequisites for conducting moderator review. The moderator analysis, using a macro named PROCESS, was performed to verify the hypothesis that national culture has an influence on the said link. The empirical findings, when compared with Hofstede's results, showed high power distance as the cause of construction project delays in Dubai. The research outcome calls for the project sponsors and top management to reshape their project management strategy and allow for low power distance between management and project personnel for timely completion of projects.

Keywords: causes of construction project delays, construction industry, construction management, power distance

Procedia PDF Downloads 183

Authors: Abdulaziz Alnajem, Amit Sharma

Abstract:

Business Case: Project delivery and enhancing activities' completion in the shortest possible time is critical during execution to proceed with the subsequent phases of Procurement, C & C phases of Contracts to have the required Production facilities/Infrastructure in place to achieve the Company strategic objective of 4.0 MBOPD oil production. SOR (Statement of requirement): Design and Engineering phase of Projects execution takes a long time. It is observed that, in most of the cases, company has crossed the Project Design Submittals review time as per the Contract/Company Standards, resulting into delays in projects completion, and cost impact to the company. Study Scope: Scope of the study covers the process from date of first submission of D & E documents by the contractor to final approval by the controlling team to proceed with the procurement of materials. This scope covers projects handled by the company’s project management teams and includes only the internal review process by the company.

Keywords: business management system, project management, oil and gas, analysis, improvement, design, delays

Procedia PDF Downloads 185

Authors: Michael Augustus Akagbor

Abstract:

Same-sex relationships have always existed in Ghana. In coastal towns such as James Town in the heart of the country’s capital, persons who were sexually different and attracted to members of their own sex were able to live their lives openly as queer persons without any fear for their lives. Since 2006, this idyllic existence has been under attack, with LGBTQ+ communities suffering violence and discrimination. This paper highlights the lived experiences of the LGBTIQ+ community in Ghana against the backdrop of the anti-gay bill - The Promotion of Proper Human Sexual Rights and Ghanaian Family Values Bill, 2021 (now renamed the Human Sexual Rights and Family Values Bill, 2021), currently before Parliament, introduced by eight members of Parliament as a Private Members’ Bill, and its implications for the LGBTQ+ community. The paper makes recommendations to key stakeholders on strategies to counter the cultural and religious arguments/strategies and activism of the anti-LGBTQ+ movement in Ghana. It relied on secondary data from a variety of sources, including the Bill before Parliament, media reports, and baseline surveys and studies conducted by LGBTQ organizations and other Civil Society Organizations (CSOs) in Ghana and elsewhere.

Keywords: sexual rights, promotion, family values, lgbtq+, ghana, discrimination

Procedia PDF Downloads 52

Authors: Adel A. Ghobbar, Ahmad Bakkar

Abstract:

Although special care is given to maintenance, aircraft systems fail, and these failures cause delays and cancellations. The occurrence of Delays and Cancellations affects operators and manufacturers negatively. To reduce technical delays and cancellations, one should be able to determine the important systems causing them. The goal of this research is to find a method to define the most expensive delays and cancellations systems for Airline operators. A predictive model was introduced to forecast the failure and their impact after carrying out research that identifies relevant information to tackle the problems faced while answering the questions of this paper. Data were obtained from the manufacturers’ services reliability team database. Subsequently, delays and cancellations evaluation methods were identified. No cost estimation methods were used due to their complexity. The model was developed, and it takes into account the frequency of delays and cancellations and uses weighting factors to give an indication of the severity of their duration. The weighting factors are based on customer experience. The data Analysis approach has shown that delays and cancellations events are not seasonal and do not follow any specific trends. The use of weighting factor does have an influence on the shortlist over short periods (Monthly) but not the analyzed period of three years. Landing gear and the navigation system are among the top 3 factors causing delays and cancellations for all three aircraft types. The results did confirm that the cooperation between certain operators and manufacture reduce the impact of delays and cancellations.

Keywords: reliability, availability, delays & cancellations, aircraft maintenance

Procedia PDF Downloads 101

Authors: Shobha Ramalingam

Abstract:

The majority of the infrastructure projects are affected by time overrun, resulting in project delays and subsequently cost overruns. Time overrun may vary from a few months to as high as five or more years, placing the project viability at risk. One of the probable reasons noted in the literature for this outcome in projects is due to poor productivity. Researchers contend that productivity in construction has only marginally increased over the years. While studies in the literature have extensively focused on time and cost parameters in projects, there are limited studies that integrate time and cost with productivity to assess project performance. To this end, a study was conducted to understand the project delay factors concerning cost, time and productivity. A case-study approach was adopted to collect rich data from a nuclear power plant project site for two months through observation, interviews and document review. The data were analyzed using three different approaches for a comprehensive understanding. Foremost, a root-cause analysis was performed on the data using Ishikawa’s fish-bone diagram technique to identify the various factors impacting the delay concerning time. Based on it, a questionnaire was designed and circulated to concerned executives, including project engineers and contractors to determine the frequency of occurrence of the delay, which was then compiled and presented to the management for a possible solution to mitigate. Second, a productivity analysis was performed on select activities, including rebar bending and concreting through a time-motion study to analyze product performance. Third, data on cost of construction for three years allowed analyzing the cost performance using earned value management technique. All three techniques allowed to systematically and comprehensively identify the key factors that deter project performance and productivity loss in the construction of the nuclear power plant project. The findings showed that improper planning and coordination between multiple trades, concurrent operations, improper workforce and material management, fatigue due to overtime were some of the key factors that led to delays and poor productivity. The findings are expected to act as a stepping stone for further research and have implications for practitioners.

Keywords: earned value analysis, time performance, project costs, project delays, construction productivity

Procedia PDF Downloads 68

Authors: Zarabizan Zakaria, Syuhaida Ismail, Aminah Md. Yusof

Abstract:

Project management process starts from the planning stage up to the stage of completion (handover of buildings, preparation of the final accounts and the closing balance). This process is not easy to implement efficiently and effectively. The issue of delays in construction is a major problem for construction projects. These delays have been blamed mainly on inefficient traditional construction practices that continue to dominate the current industry. This is due to several factors, such as environments of construction technology, sophisticated design and customer demands that are constantly changing and influencing, either directly or indirectly, the practice of management. Among the identified influences are physical environment, social environment, information environment, political and moral atmosphere. Therefore, this paper is emerged to determine the problem and issues in the final account closing in construction projects, and it establishes the need to embrace Supply Chain Management (SCM) and then elucidates the need and strategies for the development of a delay reduction framework. At the same time, this paper provides effective measures to avoid or at least reduce the delay to the optimum level. Allowing problems in the closure declaration to occur without proper monitoring and control can leave negative impact on the cost and time of delivery to the end user. Besides, it can also affect the reputation or image of the agency/department that manages the implementation of a contract and consequently may reduce customer's trust towards the agencies/departments. It is anticipated that the findings reported in this paper could address root delay contributors and apply SCM tools for their mitigation for the better development of construction project.

Keywords: final account closing, construction project, construction delay, supply chain management

Procedia PDF Downloads 329

Authors: Robert Pellerin, Michel Gamache, Remi Trudeau, Nathalie Perrier

Abstract:

The context of large engineering projects is particularly favorable to the appearance of engineering changes and contractual modifications. These elements are potential causes for claims. In this paper, we investigate one of the critical components of the claim management process: the calculation of the impacts of changes in terms of losses of productivity due to the need to accelerate some project activities. When project changes are initiated, delays can arise. Indeed, project activities are often executed in fast-tracking in an attempt to respect the completion date. But the acceleration of project execution and the resulting rework can entail important costs as well as induce productivity losses. In the past, numerous methods have been proposed to quantify the duration of delays, the gains achieved by project acceleration, and the loss of productivity. The calculation related to those changes can be divided into two categories: direct cost and indirect cost. The direct cost is easily quantifiable as opposed to indirect costs which are rarely taken into account during the calculation of the cost of an engineering change or contract modification despite several research projects have been made on this subject. However, proposed models have not been accepted by companies yet, nor they have been accepted in court. Those models require extensive data and are often seen as too specific to be used for all projects. These techniques are also ignoring the resource constraints and the interdependencies between the causes of delays and the delays themselves. To resolve this issue, this research proposes a simulation model that mimics how major engineering changes or contract modifications are handled in large construction projects. The model replicates the use of overtime in a reactive scheduling mode in order to simulate the loss of productivity present when a project change occurs. Multiple tests were conducted to compare the results of the proposed simulation model with statistical analysis conducted by other researchers. Different scenarios were also conducted in order to determine the impact the number of activities, the time of occurrence of the change, the availability of resources, and the type of project changes on productivity loss. Our results demonstrate that the number of activities in the project is a critical variable influencing the productivity of a project. When changes occur, the presence of a large number of activities leads to a much lower productivity loss than a small number of activities. The speed of reducing productivity for 30-job projects is about 25 percent faster than the reduction speed for 120-job projects. The moment of occurrence of a change also shows a significant impact on productivity. Indeed, the sooner the change occurs, the lower the productivity of the labor force. The availability of resources also impacts the productivity of a project when a change is implemented. There is a higher loss of productivity when the amount of resources is restricted.

Keywords: engineering changes, indirect costs overtime, productivity, scheduling, simulation

Procedia PDF Downloads 216

Authors: H. Y. Jung, Jing Wang, J. H. Park, Hao Shen

Abstract:

This brief addresses the passivity problem for neural networks with time-varying delays. The aim is focus on establishing the passivity condition of the considered neural networks.

Keywords: neural networks, passivity analysis, time-varying delays, linear matrix inequality

Procedia PDF Downloads 523

Authors: Eunice Chiamaka Allen-Ngbale

Abstract:

Prior to bill of lading (BOL), merchants travelled along with their goods; then recorded the goods in the ship’s mates’ register; and finally started selling the goods while in transit by way of BOL, indicative that BOL is negotiable. Common law doctrine of privity of contract did not allow the transfer of right to sue to a non-party to the contract. This created hardship to cargo owners, which made many jurisdictions enact laws in this regard. Bill of Lading Act 1855 (BLA) was enacted in the United Kingdom, which applied as statute of general application under section 375 Merchant Shipping Act 1990 (MSA) in Nigeria; and conferred contractual rights of the suit on consignees and endorsees, but on the passing of ownership upon or by reason of such consignment or endorsement on the shipment of the goods simultaneously. The repeal of section 375 MSA by section 439 MSA 2007 created a lacuna, and the doctrine of privity of contract is the extant law in Nigeria. The aim of this study is to evaluate laws governing the transfer of the contractual right of suit to a third party under the bill of lading in Nigeria. The specific objectives of this study are to ascertain: (i) whether the extant law of common law doctrine of privity of the contract covers the transfer of the right of suit to the third party under the bill of lading in Nigeria; (ii) impediment(s) of the common law to transfer such right in Nigeria in the absence of any legislation; (iii) the level of applicability of the doctrine of privity of contract as it relates to transfer of the contractual right of suit to third party under the bill of lading in Nigeria; and (iv) whether to proffer possible suggestion on how to fill the lacuna left by the repeal of Merchant Shipping Act 1990. This work adopted a doctrinal approach with reliance on primary and secondary source materials. It finds that the common law doctrine of privity of contract in Nigeria is retrogressive. This work recommends for amendment of the relevant statute to cure this defect/lacuna like other commonwealth nations for best international practices.

Keywords: contract of carriage by sea, doctrine of privity of contract, lawful holder of bill of lading, third party right of suit

Procedia PDF Downloads 129

Authors: Simplejit Kaur Dhanoa, Manmohan Singh

Abstract:

This study was done with the primary objective to evaluate the motor and mental developmental delays among children having neonatal Jaundice. A total sample of 300 neonates were collected; out of them, 150 were preterm neonates, and 150 were full term neonates from the hospital setting and follow up study was done with the help of the Developmental Assessment scale of the Indian Infant. The registered samples were assessed up to 2.6 years with a gap of 6 months. The outcomes of this study reveal that developmental delays were present among children who had preterm neonatal jaundice as compare to full term normal babies. Further, It was reported that both motor and mental development is affected due to neonatal hyperbilirubinemia in addition to preterm birth.

Keywords: hyperbinirubinemia, preterm neonates, developmental delays, preterm

Procedia PDF Downloads 132

Authors: S. Sunaina, Neha Saini

Abstract:

Children are considered as future of a country. In order to have a better future, better laws are required in the present, especially for the children. Their development primarily revolves around physical, mental, psychological, emotional and financial facets. Hence the holistic development of a child in the contemporary society is a must in order to secure a better future. The present paper is an endeavour to analyse the development of children in India vis-a-vis The Child Development Bill 2016 and Child Labour (Abolition) Bill 2016 pending before the Indian Parliament. The findings of the study will attempt to highlight the flaws of the Bills and their probable repercussions, supporting the same with Constitutional provisions, judicial precedents, and the international perspective. Finally, the paper will conclude with concrete suggestions to overcome the flaws of the Bills so that the Bills, when passed, can be sincerely implemented.

Keywords: bill, children, development, repercussion

Procedia PDF Downloads 241

Authors: Rika van Zyl

Abstract:

South Africa’s racial discrimination past has led to the drafting of the Constitution with the Bill of Rights for the people of South Africa. The Bill of Rights prohibits the state from unfairly discriminating directly or indirectly on certain grounds, one of which is race and another is gender. This has forced changes to the law of succession. The customary law rule of male primogeniture was abolished to ensure that women were not excluded from the intestate succession of the male head of the family in 2005. It was said that this rule cannot be reconciled with the notions of equality and human dignity contained in the Bill of Rights. The freedom of testation has further come under fire in South Africa, where it was found to be unfair discrimination and against public policy to exclude a specific gender (women) from inheriting in a private will. Although no one has the right to inherit in South Africa, any person with an interest can approach the court alleging that a right in the Bill of Rights has been infringed. A will that is found inconsistent with the South African Bill of Rights then cannot be enforced. Recent case law found that to leave out a specific gender (women) from a will, based entirely on the fact that they are of said specific gender, is in contravention of the Constitution and should, therefore, be declared invalid. It was said that the courts should take a transformative constitutional approach when equality rights are affected. Otherwise, the historical and insidious unequal distribution of wealth in South Africa will continue along the fault lines such as gender. This decision has opened the debate on the extent to which the state can interfere with the private autonomy of an individual who is deceased. Some of these arguments will be discussed, including the ambit of public policy in this regard.

Keywords: equality, discrimination, succession, public policy

Procedia PDF Downloads 14

Authors: Omar Amoudi, Latifa Al Brashdi

Abstract:

Construction projects are always subject to risks and uncertainties due to its unique and dynamic nature, outdoor work environment, the wide range of skills employed, various parties involved in addition to situation of construction business environment at large. Altogether, these risks and uncertainties affect projects objectives and lead to cost overruns, delay, and poor quality. Construction projects in Oman often experience cost overruns and delay. Managing these risks and reducing their impacts on construction cost requires firstly identifying these risks, and then analyzing their severity on project cost to obtain deep understanding about these risks. This in turn will assist construction managers in managing and tacking these risks. This paper aims to investigate the main risk factors that affect construction projects cost in the Sultanate of Oman. In order to achieve the main aim, literature review was carried out to identify the main risk factors affecting construction cost. Thirty-three risk factors were identified from the literature. Then, a questionnaire survey was designed and distributed among construction professionals (i.e., client, contractor and consultant) to obtain their opinion toward the probability of occurrence for each risk factor and its possible impact on construction project cost. The collected data was analyzed based on qualitative aspects and in several ways. The severity of each risk factor was obtained by multiplying the probability occurrence of a risk factor with its impact. The findings of this study reveal that the most significant risk factors that have high severity impact on construction project cost are: Change of Oil Price, Delay of Materials and Equipment Delivery, Changes in Laws and Regulations, Improper Budgeting, and Contingencies, Lack of Skilled Workforce and Personnel, Delays Caused by Contractor, Delays of Owner Payments, Delays Caused by Client, and Funding Risk. The results can be used as a basis for construction managers to make informed decisions and produce risk response procedures and strategies to tackle these risks and reduce their negative impacts on construction project cost.

Keywords: construction cost, construction projects, Oman, risk factors, risk management

Procedia PDF Downloads 302

Authors: Goutom K. Pall

Abstract:

At the very heart of the power system, power transmission (PT) acts as an essential link between power generation and distribution. Timely completion of PT infrastructures is therefore crucial to support the development of power system as a whole. Yet despite the importance, studies on PT infrastructure development projects are embryonic and, hence, PT projects undergoing widespread delays worldwide. These delay factors are idiosyncratic and identifying the critical delay factors is essential if the PT industry professionals are to complete their projects efficiently and within the expected timeframes. This study identifies and categorizes 46 causes of PT project delay under ten major groups using six sector expert’s recommendations studied by a preliminary questionnaire survey. Based on the experts’ strong recommendations, two new groups are introduced in the final questionnaire survey: sector specific factors (SSF) and general factors (GF). SSF pertain to delay factors applicable only to the PT projects, while GF represents less biased samples with shared responsibilities of all project parties involved in a project. The study then uses 112 data samples from the contractors to rank the delay factors using relative importance index (RII). The results reveal that SSF, GF and external factors are the most critical groups, while the highest ranked delay factors include the right of way (RoW) problems of transmission lines (TL), delay in payments, frequent changes in TL routes, poor communication and coordination among the project parties and accessibility to TL tower locations. Finally, recommendations are made to minimize the identified delay. The findings are expected to be of substantial benefit to professionals in minimizing time overrun in PT projects implementation, as well as power generation, power distribution, and non-power linear construction projects worldwide.

Keywords: delay, project delay, power transmission projects, time-overruns

Procedia PDF Downloads 144

Authors: C. W. F. Che Wan Putra, M. Alshawi, M. S. Al Ahbabi, M. Jabakhanji

Abstract:

Much of the waste that is generated throughout the life-cycle of a building is mainly related to project stakeholders not having access to information that others have created. This results in waste and high costs. Over the past decade, however, the industry reacted to these challenges by adopting effective procurement approaches, such as partnering and design and build, to improve collaboration and communication among projects’ stakeholders. Most recently, there is a focus on creating and reusing digital project information of stakeholders throughout the life-cycle to facilitate the exchange of information among partners. This shift is based around BIM (Building Information Modelling) and collaborative environment (IPD). The power of collaborative BIM goes beyond improving efficiency. Sustainability, perhaps the most important challenge for the design and construction community, is at the intersection of BIM and collaborative project delivery, drawing strength from both. Due to these benefits, a research study has been carried out to investigate the need of BIM and IPD, on a large scale construction project which is procured on a traditional approach, i.e. design-bid-build. A qualitative research work including a semi-structured interview with project partners was conducted on a typical project in the UAE, whereby the selected project suffered from severe delays and cost overrun. This paper aims to bring about clear evidence to what most likely to happen to a typical construction project in spite of employing very good consultants, project manager and contractors and how these problems could have been avoided if BIM and IPD were deployed.

Keywords: building information modelling (BIM), integrated project delivery (IPD), collaborative environment, case study

Procedia PDF Downloads 373

Authors: Puti F. Marzuki, Adrianto Oktavianus, Almerinda Regina

Abstract:

Interface problems among interacting parties in Indonesian construction projects have most often led to low productivity and completion delay. In the midst of this country’s needs to accelerate construction of public infrastructure providing connectivity among regions and supporting economic growth as well as better living quality, project delays have to be seriously addressed. This paper identifies potential causes factors of interface problems experienced by construction projects in Indonesia. Data are collected through a survey involving the main actors of six important public infrastructure construction projects including railway, LRT, sports stadiums, apartment, and education building construction projects. Five of these projects adopt the design-build project delivery method and one applies the design-bid-build scheme. Interface problems’ potential causes are categorized into contract, management, technical experience, coordination, financial, and environmental factors. Research results reveal that, especially in railway and LRT projects, potential causes of interface problems are mainly technical and managerial in nature. These relate to complex construction execution in highly congested areas. Meanwhile, coordination cause factors are mainly found in the education building construction project with loan from a foreign donor. All of the six projects have to resolve interface problems caused by incomplete or low-quality contract documents. This research also shows that the design-bid-build delivery method involving more parties in construction projects tends to induce more interface problem cause factors than the design-build scheme.

Keywords: cause factors, construction delays, project delivery method, contract documents

Procedia PDF Downloads 224

Authors: Hailu Kebede Bekele

Abstract:

Construction delays are suitable where project events occur at a certain time expected due to causes related to the client, consultant, and contractor. Delay is the major cause of the cost overrun that leads to the poor efficiency of the project. The cost difference between completion and the originally estimated is known as cost overrun. The common ways of cost overruns are not simple issues that can be neglected, but more attention should be given to prevent the organization from being devastated to be failed, and financial expenses to be extended. The reasons that may raised in different studies show that the problem may arise in construction projects due to errors in budgeting, lack of favorable weather conditions, inefficient machinery, and the availability of extravagance. The study is focused on the pace of mega projects that can have a significant change in the cost overrun calculation.15 mega projects are identified to study the problem of the cost overrun in the site. The contractor, consultant, and client are the principal stakeholders in the mega projects. 20 people from each sector were selected to participate in the investigation of the current mega construction project. The main objective of the study on the construction cost overrun is to prioritize the major causes of the cost overrun problem. The methodology that was employed in the construction cost overrun is the qualitative methodology that mostly rates the causes of construction project cost overrun. Interviews, open-ended and closed-ended questions group discussions, and rating qualitative methods are the best methodologies to study construction projects overrun. The result shows that design mistakes, lack of labor, payment delay, old equipment and scheduling, weather conditions, lack of skilled labor, payment delays, transportation, inflation, and order variations, market price fluctuation, and people's thoughts and philosophies, the prior cause of the cost overrun that fail the project performance. The institute shall follow the scheduled activities to bring a positive forward in the project life.

Keywords: cost overrun, delay, mega projects, design

Procedia PDF Downloads 26

Authors: Emmy Kipsoi

Abstract:

Kenya legalized the Sexual offence bill (2001), after vigorous campaigning and lobbying by feminist both in and out of parliament to ensure that the bill passed with minimal amendments. The sexual offense act provides for a good description on what constitutes sexual offences and the penalties that follow. It is from this context that the paper explores and interrogated the lived experiences of women living and working in Kenyan urban towns, who had experienced some form of sexual harassment. The study employed phenomenology to interpret the experiences of twenty (20) women in an urban town between the ages of 20 to 65 years women who had received at least some formal education and where engaged in some formal form of employment. The findings indicated that various forms of sexual harassment were experienced in the Kenyan town. Secondly, the knowledge about the contents of the bill wanting most of the women interviews were not aware of the protection accorded by law. The number of reported cases of sexual harassment shed light on the isolation, frustration and fear that women live despite a progressive law in print

Keywords: Kenya, phenomenology, sexual harassment, women

Procedia PDF Downloads 275