Search results for: islamic political parties

Authors: Omar Amoudi, Latifa Al Brashdi

Abstract:

Construction projects are always subject to risks and uncertainties due to its unique and dynamic nature, outdoor work environment, the wide range of skills employed, various parties involved in addition to situation of construction business environment at large. Altogether, these risks and uncertainties affect projects objectives and lead to cost overruns, delay, and poor quality. Construction projects in Oman often experience cost overruns and delay. Managing these risks and reducing their impacts on construction cost requires firstly identifying these risks, and then analyzing their severity on project cost to obtain deep understanding about these risks. This in turn will assist construction managers in managing and tacking these risks. This paper aims to investigate the main risk factors that affect construction projects cost in the Sultanate of Oman. In order to achieve the main aim, literature review was carried out to identify the main risk factors affecting construction cost. Thirty-three risk factors were identified from the literature. Then, a questionnaire survey was designed and distributed among construction professionals (i.e., client, contractor and consultant) to obtain their opinion toward the probability of occurrence for each risk factor and its possible impact on construction project cost. The collected data was analyzed based on qualitative aspects and in several ways. The severity of each risk factor was obtained by multiplying the probability occurrence of a risk factor with its impact. The findings of this study reveal that the most significant risk factors that have high severity impact on construction project cost are: Change of Oil Price, Delay of Materials and Equipment Delivery, Changes in Laws and Regulations, Improper Budgeting, and Contingencies, Lack of Skilled Workforce and Personnel, Delays Caused by Contractor, Delays of Owner Payments, Delays Caused by Client, and Funding Risk. The results can be used as a basis for construction managers to make informed decisions and produce risk response procedures and strategies to tackle these risks and reduce their negative impacts on construction project cost.

Keywords: construction cost, construction projects, Oman, risk factors, risk management

Procedia PDF Downloads 345

Authors: Beatriz Salamanca

Abstract:

In his public lecture ‘On the American Indians’ given at the University of Salamanca in 1538-39, Francisco de Vitoria presented an unsettling defense of freedom of movement, arguing that the Spanish had the right to travel and dwell in the New World, since it was considered part of the law of nations [ius gentium] that men enjoyed free mutual intercourse anywhere they went. The principle of freedom of movement brought hopeful expectations, promising to bring mankind together and strengthen the ties of fraternity. However, it led to polemical situations when those whose mobility was in question represented a harmful threat or was for some reason undesired. In this context, Vitoria’s argument has been seen on multiple occasions as a justification of the expansion of the Spanish empire. In order to examine the meaning of Vitoria’s defense of free mobility, a more detailed look at Vitoria’s text is required, together with the study of some of his earliest works, among them, his commentaries on Thomas Aquinas’s Summa Theologiae, where he presented relevant insights on the idea of the law of nations. In addition, it is necessary to place Vitoria’s work in the context of the intellectual tradition he belonged to and the responses he obtained from some of his contemporaries who were concerned with similar issues. The claim of this research is that the Spanish right to travel advocated by Vitoria was not intended to be interpreted in absolute terms, for it had to serve the purpose of bringing peace and unity among men, and could not contradict natural law. In addition, Vitoria explicitly observed that the right to travel was only valid if the Spaniards caused no harm, a condition that has been underestimated by his critics. Therefore, Vitoria’s legacy is of enormous value as it initiated a long lasting discussion regarding the question of the grounds under which human mobility could be restricted. Again, under Vitoria’s argument it was clear that this freedom was not absolute, but the controversial nature of his defense of Spanish mobility demonstrates how difficult it was and still is to address the issue of the circulation of peoples across frontiers, and shows the significance of this discussion in today’s globalized world, where the rights and wrongs of notions like immigration, international trade or foreign intervention still lack sufficient consensus. This inquiry about Vitoria’s defense of the principle of freedom of movement is being placed here against the background of the history of political thought, political theory, international law, and international relations, following the methodological framework of contextual history of the ‘Cambridge School’.

Keywords: Francisco de Vitoria, freedom of movement, law of nations, ius gentium, Spanish empire

Procedia PDF Downloads 366

Authors: Stanislaw Kosmynka

Abstract:

Although the genesis of the activity of fighting salafist radicalism in Spain dates back to the 80’s, the development of extremism of this kind manifested itself only in the next decade. Its first permanently functioning structures in this country in the second half of 90’s of 20th century came from Algieria and Syria. At the same time it should be emphasized that this distinction is in many dimensions conventional, the more so because they consisted also of immigrants from other coutries of Islam, particularly from Morocco. The paper seeks to understand the radical salafist challenge for Spain in the context of some terrorist networks consisted of immigrants from Morocco. On the eve of the new millennium Moroccan jihadists played an increasingly important role. Although the activity of these groups had for many years mainly logistical and propaganda character, the bomb attack carried out on 11 March 2004 in Madrid constituted an expression of open forms of terrorism, directed against the authorities and society of Spain and reflected the narration of representatives of the trend of the global jihad. The people involved in carrying out that act of violence were to a large extent Moroccan immigrants; also in the following years among the cells of radicals in Spain Moroccans stood out many times. That is why the forms and directions of activity of these extremists in Spain, also after 11th March 2004 and in the actual context of the impact of Islamic State, are worth presenting. The paper is focused on threats to the security of Spain and the region and remains connected with the issues of mutual relations of the society of a host country with immigrant communities which to a large degree come from this part of Maghreb.

Keywords: jihadi terrorism, Morocco, radical salafism, security, Spain, terrorist cells, threat

Procedia PDF Downloads 525

Authors: Habiba Ben Abdessalem

Abstract:

The emergence of giant set of textual data was the push that has encouraged researchers to invest in this field. The purpose of textual data analysis methods is to facilitate access to such type of data by providing various graphic visualizations. Applying these methods requires a corpus pretreatment step, whose standards are set according to the objective of the problem studied. This step determines the forms list contained in contingency table by keeping only those information carriers. This step may, however, lead to noisy contingency tables, so the use of wavelet denoising function. The validity of the proposed approach is tested on a text database that offers economic and political events in Tunisia for a well definite period.

Keywords: textual data, wavelet, denoising, contingency table

Procedia PDF Downloads 277

Authors: Amalia Triantafillidoy, Georgios Lappas, Prodromos Yannas, Alexandros Kleftodimos

Abstract:

In this paper an experiment was conducted to assess the impact of online deliberation on citizens’ attitudes. Specifically, this research compared pre and post deliberation opinions of participants who deliberated online via an asynchronous platform regarding the issue of political opinion polls. Results indicate that online deliberation had a positive effect on citizens’ attitudes since it was found that following deliberation participants changed their views regarding public opinion polls. Specifically, online deliberation improved discussants perceptions regarding the reliability of polls, while suppressing their negative views about the misuse of polls by media, polling organizations and politicians.

Keywords: attitudes change, e-democracy, online deliberation, opinion polls

Procedia PDF Downloads 320

Authors: Sabrina Howard

Abstract:

'Window Seat' uses public transportation as an entry point for understanding the relationship between public space, politics, and social identity construction. This project argues that by bringing people of different races, classes, and genders in 'contact' with one another, public transit operates as a site of exposure, as people consciously and unconsciously perform social identity within these spaces. These performances offer a form of freedom that we associate with being in urban spaces while simultaneously rendering certain racialized, gendered, and classed bodies vulnerable to violence. Furthermore, due to its exposing function, public transit operates as a site through which we, as urbanites and scholars, can read social injustice and reflect on the work that is necessary to become a truly democratic society. The major questions guiding this research are: How does using public transit as the entry point provide unique insights into the relationship between social identity, politics, and public space? What ideas do Americans hold about public space and how might these ideas reflect a liberal yearning for a more democratic society? To address these research questions, 'Window Seat' critically examines ethnographic data collected on public buses and trains in Los Angeles, California, and online news media. It analyzes these sources through literature in socio-cultural psychology, sociology, and political science. It investigates the 'everyday urban hero' narrative or popular news stories that feature an individual or group of people acting against discriminatory or 'Anti-American' behavior on public buses and trains. 'Window Seat' studies these narratives to assert that by circulating stories of civility in news media, United Statsians construct and maintain ideas of the 'liberal city,' which is characterized by ideals of freedom and democracy. Furthermore, for those involved, these moments create an opportunity to perform the role of the Good Samaritan, an identity that is wrapped up in liberal beliefs in diversity and inclusion. This research expands conversations in urban studies by making a case for the political significance of urban public space. It demonstrates how these sites serve as spaces through which liberal beliefs are circulated and upheld through identity performance.

Keywords: social identity, public space, public transportation, liberalism

Procedia PDF Downloads 204

Authors: Poonam A. Trambadia, Ashish V. Trambadia

Abstract:

The architecture of sultanate period of Ahmedabad had evolved just before the establishment of Mughal rule in North India. After shifting the capital of the kingdom from Patan to Ahmedabad, when the buildings and structures were being built, an interesting cultural blend happened in architecture. Many sultanate buildings in Ahmedabad historic city have resemblance with Patan including the names. Outer fortification walls and Gates were built during the rule of the third ruler in the late 15th century. All the gates had sandstone slabs supported by three arched entrance in sandstone with wooden shutter. A restoration project of Khanpur Gate was initiated in 2016. The paper identifies some evidences and some hidden layers of structures as important elements of cultural interchange while some were just forgotten in the process. The recycling of pre-existing elements of structures are examined and compared. There were layers uncovered that were hidden behind later repairs using traditional brick arch, which was taken out in the process. As the gate had partially collapsed, the restoration included piece by piece dismantling and restoring in the same sequence wherever required. The recycled materials found in the process were recorded and provided the basis for this study. The gate after this discovery sets a new example of fortification Gate built in Sultanate era. The comparison excludes Maratha and British Period Gates to avoid further confusion and focuses on 15th – 16th century sultanate architecture of Ahmedabad.

Keywords: Ahmedabad World Heritage, fortification, Indo-Islamic style, Sultanate architecture, cultural interchange

Procedia PDF Downloads 117

Authors: Sulaiman Al-Hinai, Setyawan Widyarto

Abstract:

The aim of this study is to identify the critically dominating factors on the delays of road constructions in the GCC countries and their effects on project delivery in Arab countries. Towards the achieved of the objectives the study used the empirical literature from the all relevant online sources and database as many as possible. The findings of this study have summarized and short listed of the success factors in the two categories such as internal and external factors have caused to be influenced to delay of road constructions in the Arab regions. However, in the category of internal factors, there are 63 factors short listed from seven group of factors which has revealed to effects on the delay of road constructions especially, the consultant related factors, the contractor related factors, designed related factors, client related factors, labor related factors, material related issues, equipment related issues respectively. Moreover, for external related factors are also considered to summarized especially natural disaster (flood, hurricanes and cyclone etc.), conflict, war, global financial crisis, compensation delay to affected property owner, price fluctuated, unexpected ground conditions (soil and high-water level), changing of government regulations and laws, delays in obtaining permission from municipality, loss of time by traffic control and restrictions at job site, problem with inhabitant of community, delays in providing service from utilities (water and electricity’s) and accident during constructions accordingly. The present study also concluded the effects of above factors which has delay road constructions through increasing of cost and overrun it, taken overtime, creating of disputes, going for lawsuits, finally happening of abandon of projects. Thus, the present study has given the following recommendations to overcome of above problems by increasing of detailed site investigations, ensure careful monitoring and regular meetings, effective site management, collaborative working and effective coordination’s, proper and comprehensive planning and scheduling and ensure full and intensive commitment from all parties accordingly.

Keywords: Arab GCC countries, critical success factors, road constructions delay, project management

Procedia PDF Downloads 127

Authors: Na Young Kim

Abstract:

This is a study on the relation between the introduction bill of the Whistle Blowing Act and the CPI (Corruption Perception Index) from 1998 to 2019. It shows that the degree of corruption can be relatively lowered when WBA is introduced, and the system is matured. And when WBA was introduced at the national level and matured, it was found that it could have a greater impact on corruption. Secondly, it shows that OECD countries may have relatively low levels of corruption. In addition to the two variables representing democracy, when additional control variables (GDP (economic power), population size, HDI (education level), etc.) are controlled under the same conditions, the degree of corruption in countries with high political rights can be low (it means clean), while those with high civil freedom can be serious (it means not clean).

Keywords: Whistle Blowing Act, anti-corruption, CPI, GDP

Procedia PDF Downloads 61

Authors: Mohamed Moheyeldin Mahmoud

Abstract:

Various Islamic, Coptic and Jewish archeological places are located in many Egyptian neighborhoods such as Alsayeda zainab, Aldarb Alahmar, Algammaleya and many other in which they are daily exposed to a great traffic intensity causing vibrations. Vibrations could be stated as one of the most important challenges that face the archeological buildings and threaten their survival. The impact of vibrations varies according to the nature of the soil, nature and building conditions, how far the source of vibration is and the period of exposure. Traffic vibrations could be also stated as one of the most common types of vibrations having the greatest impact on buildings and archaeological installations. These vibrations result from the way that the vehicles act with different types of roads which vary according to the shape, nature, and type of obstacles. Other elements concerning the vehicle itself such as speed, weight, and load have a direct impact on the vibrations resulting from the vehicle movement that couldn't be neglected. The research aims to determine some of the requirements that must be observed when designing the public means of transport operating in the archaeological areas, in order to preserve the archaeological nature of the place. The research concludes that light weight slow motion vehicles should be used (25-50 km/h at maximum) having a multi-leaf steel spring suspension system instead of having an air-bag one should be used in order to reduce generated vibrations that could destroy the archeological buildings. Isolation layers could be used in the engine chamber in order to reduce the resulting noise causing vibrations. Electrically operated engines that use solar photovoltaic cells as a source of electricity could be used instead of gas ones in order to reduce the resulting engine noise.

Keywords: archeological, design, isolation layers, suspension, vibrations

Procedia PDF Downloads 191

Authors: Agata Ferreira

Abstract:

Rapidly increasing debates and initiatives in the area of Corporate Social Responsibility (“CSR”) have reached the world of international investment law. CSR standards that focus on the operations of multinational companies are increasingly relevant in the context of international investment policy making. In the past, the connection between CSR standards and legal framework for foreign direct investment has been largely non-existent. Recently, however, there is a growing trend of a more balance approach to rights and obligations as between investors and states under investment treaties. CSR principles join other social and environmental measures slowly being included in the investment treaties to enhance their sustainable development dimension. Issues of CSR are present on negotiation tables of new mega regional investment treaties like TTIP for example. To date, only a very few bilateral investment treaties and a handful of other international treaties with investment provisions include CSR clauses. In addition, the existing provisions tend to be of a soft type, where parties merely acknowledge importance of good corporate governance and CSR for sustainable development or generally affirm their aim to encourage enterprises to observe internationally recognised guidelines and principles of CSR. The relevant provisions often leave it up to the states to encourage enterprises operating within their territories to voluntarily incorporate CSR principles. The interaction between general non-binding CSR standards, domestic laws and policies and provisions of international investment treaties have not been tested by investment tribunals yet. The role of investment treaties in raising awareness and promoting CSR is still in its infancy. The use of CSR standards in the international investment protection regime for promotion of CSR standards, and as a tool for disciplining investors into complying with such standards, pose a number of questions and is met with resistance from investors` lobbies. Integration of these two areas, CSR and international investment law, both consisting of multilayered, diverse and often overlapping instruments is by no means an easy task. Whether international investment world is ready to embrace CSR standards or shrug them off is a matter of uncertain future. The subject however has been raised, first introductions have been made and the time will show whether the relationship between legal framework of international investment and CSR will flourish or remain dormant.

Keywords: corporate social responsibility, foreign direct investment, investment treaties, sustainable development

Procedia PDF Downloads 270

Authors: Samart Homthong, Wutthipong Moungnoi

Abstract:

Critical success factors (CSFs) and the criteria to measure project success have received much attention over the decades and are among the most widely researched topics in the context of project management. However, although there have been extensive studies on the subject by different researchers, to date, there has been little agreement on the CSFs. The aim of this study is to identify the CSFs that influence the performance of construction projects, and determine their relative importance for different objectives across five stages in the project life cycle. A considerable literature review was conducted that resulted in the identification of 179 individual factors. These factors were then grouped into nine major categories. A questionnaire survey was used to collect data from three groups of respondents: client representatives, consultants, and contractors. Out of 164 questionnaires distributed, 93 were returned, yielding a response rate of 56.7%. Using the mean score, relative importance index, and weighted average method, the top 10 critical factors for each category were identified. The agreement of survey respondents on those categorised factors were analysed using Spearman’s rank correlation. A one-way analysis of variance was then performed to determine whether the mean scores among the various groups of respondents were statistically significant. The findings indicate the most CSFs in each category in procurement phase are: proper procurement programming of materials (time), stability in the price of materials (cost), and determining quality in the construction (quality). They are then followed by safety equipment acquisition and maintenance (health and safety), budgeting allowed in a contractual arrangement for implementing environmental management activities (environment), completeness of drawing documents (productivity), accurate measurement and pricing of bill of quantities (risk management), adequate communication among the project team (human resource), and adequate cost control measures (client satisfaction). An understanding of CSFs would help all interested parties in the construction industry to improve project performance. Furthermore, the results of this study would help construction professionals and practitioners take proactive measures for effective project management.

Keywords: critical success factors, procurement phase, project life cycle, project performance

Procedia PDF Downloads 183

Authors: Mausumi Chetia

Abstract:

One of the main causes of impoverishment of the rural areas of Assam has been the recurrent floods and riverbank erosion. One of the life-changing consequences is displacement. This results not only in a loss of livelihoods but also has wide-reaching socio-economic and cultural effects. Thus, due to such disasters, not only families but communities too are being displaced at large. This compels them to find temporary shelter and begin life from scratch. The role of the state has been highly negligible, with a displacement not being perceived as an ‘issue’ to be addressed. A more holistic approach is thus needed to take socio-economic, cultural, political as well as ecological considerations into account.

Keywords: displacement, policy-framework, human-induced disasters, marginalised communities, India, Assam

Procedia PDF Downloads 275

Authors: Mark Davies, Carolyn Wallace, Christina Lloydwin, Tom Powell

Abstract:

Background: Frailty is increasingly recognized as a public health problem within an aging population. It is often characterized as an accumulation of clinical symptoms with progressive decline. We contend that dehydration is potentially the missing link driving the cycle of frailty; it contributes to malnutrition and cognitive decline and is a risk factor for other conditions. Frailty may also impact on fluid intake in cognitively intact older adults, indicating the cyclical nature of dehydration contributing to increasing frailty. Aim: To examine the relationships between fluid, hydration, and frailty in older adults in order to determine what works, for whom, how, why, and in what circumstances. Methods: A Realist Synthesis was first undertaken with n=50 studies, leading to the development of a Refined Programme Theory (RPT) articulating what hydration interventions work, for whom, to what degree, in what contexts, and how & why. Within the subsequent evaluation, the RPT was further confirmed/refuted/refined following semi-structured interviews with n=8 participants (healthcare professionals and patients). The RAMESES Quality Standards were followed throughout the study. Results: The Refined Programme Theory (RPT) highlighted three factors that result in optimized hydration for frail older people, i.e., Developing an Understanding Around Hydration, Empowering Participation, and System Reconfiguration. Our RPT indicates that hydration interventions work by developing an understanding of the importance of hydration, mitigating physical & cognitive barriers, increasing the agency of the patient, using a prompting process to reinforce drinking behavior, and routinizing hydration as a dimension of overall care. Conclusion: The study indicates that a greater understanding of the importance of hydration is required for all parties. Patients also require physical and psychological support if they are to be active agents in meeting their hydration needs. At a wider ‘system’ level, organizations must work in an integrated manner introducing processes that enable continuing professional development (CPD), encourage ongoing holistic assessment, and routinize hydration support.

Keywords: frailty, dehydration, older adults, realist review, realist evaluation

Procedia PDF Downloads 75

Authors: Ravan Samadov

Abstract:

Mentally disabled people are the most discriminated against among other disabled people and face much stronger negative attitudes across many cultures. The most complex and severe form of exclusion of these people is deprivation of liberty on the grounds of their disability. This problem was for many years overlooked to a great extent by the core human rights instruments. However, the United Nations (UN) Convention on the Rights of Persons with Disabilities (CRPD), adopted in 2006, is considered a potential tool to successfully fill the gap. It is especially vital for the developing countries with the vast majority of disabled people of the world and the CRPD is presumed to be able to trigger drastic positive changes. Article 14 of the mentioned human rights treaty has brought into the international forum a new notion, as prohibits deprivation of liberty on the grounds of disability. It is to be understood as an absolute prohibition of deprivation of liberty on the grounds of disability, including mental disability, which manifests in the form of non-consensual psychiatric hospitalisation. The interpretation by the CRPD Committee indicates that this prohibition well embraces all types of non-consensual psychiatric hospitalisation – whether it is based on illness, impairment or disability. This prohibition also extends to such justifications as ‘dangerousness’, ‘need for treatment’ and ‘diminished capacity’. Moreover, providing due substantive and/or procedural safeguards does not render any legitimacy to application of deprivation of liberty on the grounds of mental disability. Logically, this new prohibition form was to be duly considered by different UN human rights bodies, and was subsequently to bring changes to their practices. However, the analyses of post-CRPD work of those bodies allows for asserting the contrary, as they have continued displaying the position which recognises deprivation of liberty on the grounds of disability to be legitimate. While such a position could be justified in the pre-CRPD time as stemming from the silence of human rights documents about it, the continuation of this course after the CRPD entered into force may call the integrity and coherence of the UN human rights treaty system into question. The non-coherent approaches of different UN bodies to this novelty give grounds for misinterpretation thereof, and hinder its due implementation by the States Parties. The paper will discuss the nature of the mentioned new prohibition and the controversial approaches to that notion by different UN human rights bodies.

Keywords: CRPD, deprivation of liberty, mental disability, non-consensual psychiatric hospitalisation, UN bodies

Procedia PDF Downloads 337

Authors: Sonny Dewi Judiasih

Abstract:

Every person retains the right to marry and starts a family through a legitimized marriage. Indonesian Marriage Act has regulated the minimum age for boys to marry is 19 while the girls is 16, with an exception that the parents could ask for an exemption to the court or to the authorized official. Despite the age limit is set by the Marriage Act, however, with the influences from adat law and islamic law which allows younger persons to marry, the child marriage phenomenon is inevitable to happen in Indonesia. Child marriages in Indonesia have shown such alarming fact where 4.8 percentage of total marriage number come from persons with the age of 10 to 14 years old. The percentage was the result from a research conducted by the National Population and Family Planning Board (BKKBN). The result shows 41.9 percent of child marriages was contributed by girls who marry in the age of 15 to 19, which mostly comes from villagers. Other fact shows 50 percent of child marriages end in divorce with grounds varied from the mental health of the children, economic situation, and so on. With more children committed early marriages, more babies will be borned from indebted families. Subsequently, the government’s program to alleviate poverty will be short of expectations. Other risk for child marriages includes death of the mother and the child after giving birth. The people have challenged the legality of child marriages through judicial review filed to the Constitutional Court. The Court decided to reinforce the age limitation previously set by the Marriage Act by issuing judicial decision no: 30-74/PUU-Xii/2014. The Court stated that changes to the age limit must be in conform with cultural and traditional situation. Further, it stated child marriages are allowed to be arranged as an “emergency exit” if the parents filed such request to an exemption on the grounds of coercive situation and after the court or the authorized officials issued its approval.

Keywords: child, marriage, court, Indonesia

Procedia PDF Downloads 360

Authors: Charles A. Khamala

Abstract:

In 2003, constrained by an absent “rule of law culture” and negative economic growth, the new Kenyan government chose to pursue incremental judicial reforms rather than comprehensive constitutional reforms. President Mwai Kibaki’s first administration’s judicial reform strategy was two pronged. First, to implement unprecedented “radical surgery,” he appointed a new Chief Justice who instrumentally recommended that half the purportedly-corrupt judiciary should be removed by Presidential tribunals of inquiry. Second, the replacement High Court judges, initially, instrumentally-endorsed the “radical surgery’s” administrative decisions removing their corrupt predecessors. Meanwhile, retention of the welfare-reducing Constitution perpetuated declining public confidence in judicial institutions culminating in refusal by the dissatisfied opposition party to petition the disputed 2007 presidential election results, alleging biased and corrupt courts. Fatefully, widespread post-election violence ensued. Consequently, the international community prompted the second Kibaki administration to concede to a new Constitution. Suddenly, the High Court then adopted a non-instrumental interpretation to reject the 2003 “radical surgery.” This paper therefore critically analyzes whether the Kenyan court’s inconsistent interpretations–pertaining to the constitutionality of the 2003 “radical surgery” removing corruption from Kenya’s courts–was predicated on political expediency or human rights principles. If justice “must also seen to be done,” then pursuit of the CJ’s, Judicial Service Commission’s and president’s political or economic interests must be limited by respect for the suspected judges and magistrates’ due process rights. The separation of powers doctrine demands that the dismissed judges should have a right of appeal which entails impartial review by a special independent oversight mechanism. Instead, ignoring fundamental rights, Kenya’s new Supreme Court’s interpretation of another round of vetting under the new 2010 Constitution, ousts the High Court’s judicial review jurisdiction altogether, since removal of judicial corruption is “a constitutional imperative, akin to a national duty upon every judicial officer to pave way for judicial realignment and reformulation.”

Keywords: administrative decisions, corruption, fair hearing, judicial review, (non) instrumental

Procedia PDF Downloads 482

Authors: S. Murr, S. Phillips

Abstract:

One of the biggest challenges entering a market with a carsharing or any other shared mobility (SM) service is sound investment decision-making. To support this process, the authors think that a city index evaluating different criteria is necessary. The goal of such an index is to benchmark cities along a set of external measures to answer the main two challenges: financially viability and the understanding of its specific requirements. The authors have consulted several shared mobility projects and industry experts to create such a Shared Mobility City Index (SMCI). The current proposal of the SMCI consists of 11 individual index measures: general data (demographics, geography, climate and city culture), shared mobility landscape (current SM providers, public transit options, commuting patterns and driving culture) and political vision and goals (vision of the Mayor, sustainability plan, bylaws/tenders supporting SM). To evaluate the suitability of the index, 16 cities on the East Coast of North America were selected and secondary research was conducted. The main sources of this study were census data, organisational records, independent press releases and informational websites. Only non-academic sources where used because the relevant data for the chosen cities is not published in academia. Applying the index measures to the selected cities resulted in three major findings. Firstly, density (city area divided by number of inhabitants) is not an indicator for the number of SM services offered: the city with the lowest density has five bike and carsharing options. Secondly, there is a direct correlation between commuting patterns and how many shared mobility services are offered. New York, Toronto and Washington DC have the highest public transit ridership and the most shared mobility providers. Lastly, except one, all surveyed cities support shared mobility with their sustainability plan. The current version of the shared mobility index is proving a practical tool to evaluate cities, and to understand functional, political, social and environmental considerations. More cities will have to be evaluated to refine the criteria further. However, the current version of the index can be used to assess cities on their suitability for shared mobility services and will assist investors deciding which city is a financially viable market.

Keywords: carsharing, transportation, urban planning, shared mobility city index

Procedia PDF Downloads 303

Authors: João Boaventura Branco De Matos

Abstract:

Currently, in Brazil, there is a considerable collection of publications on the supplementary health sector, but the vast majority is limited to retrospective examination of the sector. The present contribution starts from the diagnosis of an overwhelming change in the role of the State and its institutions, as well as an accelerated and no less forceful change in the way of producing goods and services, resulting in a clash between these different waves (state and market). This shock produces unique energy, capable of imposing major changes in the most varied sectors. Based on this diagnosis, there was an opportunity to offer the perspective and propositional study of regulatory measures relevant to the best conduct and performance of this sector in the future.

Keywords: private health regulation, state and market, forecasts in Brazilian regulation, political economy

Procedia PDF Downloads 151

Authors: Masnur Marzuki

Abstract:

As in other democratic countries, the constitutional court of Indonesia has the role of interpreting and applying the Constitution in order to preserve its supremacy testing the constitutionality of statutes. With its strong power to enforce and guard the Constitution, the court is now challenged to provide people an opportunity to understand their constitutional rights close up. At the same time, the court has built up an enviable reputation among constitutional courts in new democracies for the technical quality of its legitimacy in the legal sense. Since its establishment in 2003, the Constitutional Court of Indonesia has decided more than 190 statutes in judicial review case. It has been remarkably successful to make a credible start on its work of guarding the Constitution. Unsurprisingly, many argue that the Court has elevated Indonesia’s democracy to a whole new level. In accomplishing its roles judicial review, the basic principle that can be identified is that the Constitutional Court must always be subordinated to the Constitution. It is not being allowed to invade the field of the legislator. In doing so, the court does not have any discretionary political basis in order to create legal norms or provisions that could not be deducted from the Constitution itself. When interpreting a statute “in accordance with the constitution”, the court recognizes and reasserts that it is strictly forbidden to extend the scope of a legal provision in such a way that would create a general norm not established by the law-maker. This paper aims to identify and assess the latest role of Indonesian Constitutional Court in interpreting and applying the Constitution. In particular, it questions 1) the role of the Constitutional Court in judicial review; and 2) the role of the court to assist the legislators in the accomplishment of their functions in order to preserve its supremacy testing the constitutionality of statutes. Concerning positive legislator, jurisprudential and judicial review theories will be approached. The empirical part will include qualitative and comparative research. Main questions to be addressed: Can the Constitutional Court be functionalized as positive legislator? What are the criteria for conducting role of Constitutional Courts as Positive Legislators and how can it be accepted? Concerning the subordination of Constitutional Courts to the Constitution and judicial review, both qualitative and quantitative methods will be used, and differences between Indonesia and German Constitutional Court will be observed. Other questions to be addressed: Can Constitutional Courts have any discretionary political basis in order to create legal norms or provisions that could not be deducted from the Constitution itself. Should the Constitutional Court always act as a negative legislator? However, the Constitutional Court in Indonesia has played role as positive legislators which create dynamic of Indonesian legal development. In performing the task of reviewing the constitutionality of statutes, the Constitutional Court has created legal norms or provisions that could be deducted from the Constitution itself.

Keywords: constitution, court, law, rights

Procedia PDF Downloads 425

Authors: Ciolomic Ioana Andreea, Farcas Teodora, Tiron-Tudor Adriana

Abstract:

Investments in research and innovation are widely acknowledged as being crucial drivers for economic growth, for job-creation and to secure social and economic welfare. The aim of this article is to disseminate the results of a Leonardo da Vinci Innovation Transfer project, AdapTykes Adaptation of trainings based up on the Finnish Workplace Development Programme. This project aims to analyses the adaptability of the Finnish model to the economic and political environment of the two emergent countries Romania and Hungary, in order to develop workplace innovation. The focus of this paper is to present the adaptability of the Finnish model to the Romanian context.

Keywords: innovation, human resources, education, tools

Procedia PDF Downloads 529

Authors: Wong Yat Cheung Maggie

Abstract:

Occupational Safety and Health Ordinance (OS&HO) (Chap 509) was enacted in 1997, OHS in HK should be growing and maturing, with a holistic approach to occupational health and safety in the workplace including physical, mental, social and spiritual well-being. The question is “How effective are OHSPs in meeting the current needs of HK health workers?” This study was designed to explore the issue for the first time, to empirically analyse the views of those who work in the system. The study employed a mixed method approach to collect various data from Occupational Health Service Providers (OHSPs), Occupational Health Service Consumers (OHSC): Registered nurses working in the hospital setting. This study was designed in two phases and two stages. Phase I Stage I was a paper survey to collect the data on OHSP. Then Phase I Stage II was a follow-up interview. Phase II Stage I was a paper survey to collect the data on OHSC. Then Phase II Stage II was a follow-up focus group study on OHSC for further clarification of the Phase II and Stage I result. The Phase I result reflects HK OHSPs point of view and their experience in the existing OHS practice in the local hospitals. It reflects various styles of reporting systems, staff profiles background and resource in providing OHS in HK hospitals. However, the basic OHS concern is similar between hospitals. In general, the OHS policies and procedures are available on site even though they may have different foci. The Phase II result is reflecting the HKs OHSCs echoes the OHSP feedback at providing of OHS, OHS concern and related policies and procedure are available on site. However, the most significant feedback from the OHSC at Phase II Stage II shows, nurses experienced various OHS concern most commonly work stress, workplace harassment and back strain without formal or official report to the related parties. The lack of reporting was due to the management handling attitude, stakeholders’ compliance and term of definition still have room to be improved even the related policies and procedures are available on site.

Keywords: occupational health service, registered nurse, Hong Kong hospital, mixed method

Procedia PDF Downloads 332

Authors: Tsegay Kahsay Gebrekidan, Gebremariam Gebrezgabher Gebremedhin, Abraha Kahsay Weldemariam, Meaza Kidane Teferi

Abstract:

Municipal solid waste management (MSWM) in Ethiopia is a complex issue with institutional, social, political, environmental, and economic dimensions, impacting sustainable development. Effective MSWM planning necessitates understanding the generation rate and composition of waste. This systematic review synthesizes qualitative and quantitative data from various sources to aggregate current knowledge, identify gaps, and provide a comprehensive understanding of municipal solid waste management in Ethiopia. The findings reveal that the generation rate of municipal solid waste in Ethiopia is 0.38 kg/ca/day, with the waste composition being predominantly food waste, followed by ash, dust, and sand, and yard waste. Over 85% of this MSW is either reusable or recyclable, with a significant portion being organic matter (73.13% biodegradable) and 11.78% recyclable materials. Physicochemical analyses reveal that Ethiopian MSW is suitable for composting and biogas production, offering opportunities to reduce environmental pollution, and GHGs, support urban agriculture, and create job opportunities. However; challenges persist, including a lack of political will, weak municipal planning, limited community awareness, and inadequate waste management infrastructure, and only 31.8% of MSW is collected legally, leading to inefficient and harmful disposal practices. To improve MSWM, Ethiopia should focus on public awareness; increased funding, infrastructure investment, private sector partnerships, and implementing the 4 R principles (reduce, reuse, and recycle). An integrated approach involving government, industry, and civil society is essential. Further research on the physicochemical properties and strategic uses of MSW is needed to enhance management practices. Implications: The comprehensive study of municipal solid waste management (MSWM) in Ethiopia reveals the intricate interplay of institutional, social, political, environmental, and economic factors that influence the nation’s sustainable development. The findings underscore the urgent need for tailored, integrated waste management strategies that are informed by a thorough understanding of MSW generation rates, composition, and current management practices. Ethiopia’s lower per capita MSW generation compared to developed countries and the predominantly organic composition of its waste present significant opportunities for sustainable waste management practices such as composting and recycling. These practices can not only minimize the environmental impact but also support urban greening, agriculture, and renewable energy production. The high organic content, suitable physicochemical properties of MSW for composting, and potential for biogas and briquette production highlight pathways for creating employment, reducing waste, and enhancing soil fertility. Despite these opportunities, Ethiopia faces substantial challenges due to inadequate political will, weak municipal planning, limited community awareness, insufficient waste management infrastructure, and poor policy implementation. The high rate of illegal waste disposal further exacerbates environmental and health issues, emphasizing the need for a more effective and integrated MSWM approach. To address these challenges and harness the potential of MSW, Ethiopia must prioritize increasing public awareness; investing in infrastructure, fostering private sector partnerships, and implementing the principles of reduce, reuse, and recycle (3 R). Developing strategies that involve all stakeholders and turning waste into valuable resources is crucial. Government, industry, and civil society must collaborate to implement integrated MSWM systems that focus on waste reduction at the source, alternative material use, and advanced recycling technologies. Further research at both federal and regional levels is essential to optimize the physicochemical analysis and strategic use of MSW. Prompt action is required to transform waste management into a pillar of sustainable urban development, ultimately improving environmental quality and human health in Ethiopia.

Keywords: biodegradable, healthy environment, integrated solid waste management, municipal

Procedia PDF Downloads 14

Authors: Mahalakshmi Vivekanandan S.

Abstract:

As per the recent changes happening in the global policies, climate-related changes and the impact it causes across every sector are viewed as green swan events – in essence, climate-related changes can often happen and lead to risk and a lot of uncertainty, but needs to be mitigated instead of considering them as black swan events. This brings about a question on how this risk can be computed so that the financial institutions can plan to mitigate it. Climate-related changes impact all risk types – credit risk, market risk, operational risk, liquidity risk, reputational risk and other risk types. And the models required to compute this has to consider the different industrial needs of the counterparty, as well as the factors that are contributing to this – be it in the form of different risk drivers, or the different transmission channels or the different approaches and the granular form of data availability. This brings out the suggestion that the climate-related changes, though it affects Pillar I risks, will be a Pillar II risk. This has to be modeled specifically based on the financial institution’s actual exposure to different industries instead of generalizing the risk charge. And this will have to be considered as the additional capital to be met by the financial institution in addition to their Pillar I risks, as well as the existing Pillar II risks. In this paper, the author presents a risk assessment framework to model and assess climate change risks - for both credit and market risks. This framework helps in assessing the different scenarios and how the different transition risks affect the risk associated with the different parties. This research paper delves into the topic of the increase in the concentration of greenhouse gases that in turn cause global warming. It then considers the various scenarios of having the different risk drivers impacting the Credit and market risk of an institution by understanding the transmission channels and also considering the transition risk. The paper then focuses on the industry that’s fast seeing a disruption: the automobile industry. The paper uses the framework to show how the climate changes and the change to the relevant policies have impacted the entire financial institution. Appropriate statistical models for forecasting, anomaly detection and scenario modeling are built to demonstrate how the framework can be used by the relevant agencies to understand their financial risks. The paper also focuses on the climate risk calculation for the Pillar II Capital calculations and how it will make sense for the bank to maintain this in addition to their regular Pillar I and Pillar II capital.

Keywords: capital calculation, climate risk, credit risk, pillar ii risk, scenario modeling

Procedia PDF Downloads 140

Authors: Justus Enninga

Abstract:

Enthusiasts and skeptics about economic growth have not much in common in their preference for institutional arrangements that solve ecological conflicts. This paper argues that agreement between both opposing schools can be found in the Bloomington Schools’ concept of polycentricity. Growth-enthusiasts who will be referred to as Simons after the economist Julian Simon and growth-skeptics named Ehrlichs after the ecologist Paul R. Ehrlich both profit from a governance structure where many officials and decision structures are assigned limited and relatively autonomous prerogatives to determine, enforce and alter legal relationships. The paper advances this argument in four steps. First, it will provide clarification of what Simons and Ehrlichs mean when they talk about growth and what the arguments for and against growth-enhancing or degrowth policies are for them and for the other site. Secondly, the paper advances the concept of polycentricity as first introduced by Michael Polanyi and later refined to the study of governance by the Bloomington School of institutional analysis around the Nobel Prize laureate Elinor Ostrom. The Bloomington School defines polycentricity as a non-hierarchical, institutional, and cultural framework that makes possible the coexistence of multiple centers of decision making with different objectives and values, that sets the stage for an evolutionary competition between the complementary ideas and methods of those different decision centers. In the third and fourth parts, it is shown how the concept of polycentricity is of crucial importance for growth-enthusiasts and growth-skeptics alike. The shorter third part demonstrates the literature on growth-enhancing policies and argues that large parts of the literature already accept that polycentric forms of governance like markets, the rule of law and federalism are an important part of economic growth. Part four delves into the more nuanced question of how a stagnant steady-state economy or even an economy that de-grows will still find polycentric governance desirable. While the majority of degrowth proposals follow a top-down approach by requiring direct governmental control, a contrasting bottom-up approach is advanced. A decentralized, polycentric approach is desirable because it allows for the utilization of tacit information dispersed in society and an institutionalized discovery process for new solutions to the problem of ecological collective action – no matter whether you belong to the Simons or Ehrlichs in a green political economy.

Keywords: degrowth, green political theory, polycentricity, institutional robustness

Procedia PDF Downloads 183

Authors: Renaud Gaucher

Abstract:

Research on happiness has developed significantly in the past fifty years and economics and the political science are starting to be influenced by advances in the field. Until recently, finance has stayed outside this movement. The goal of our research is to integrate finance into this movement conceptually. We explain the why, the what and the how of the finance of happiness. We then study the relationship between corporate finance and happiness. We discuss the optimization of the relationship between the financial performance of a firm and the happiness at work of its employees, and the reduction of financial risk by developing goods that foster the happiness of their users. Finally we look at the development of happiness investment funds, that is investment funds founded on happiness research, and the best ways to share risks and earnings to build a happier society.

Keywords: finance, happiness, investment fund, risk

Procedia PDF Downloads 188

Authors: Ali Heyder Alatas, D. Xin, L. Nai Ming

Abstract:

An oil spill emergency can vary in size and complexity, subject to factors such as volume and characteristics of spilled oil, incident location, impacted sensitivities and resources required. A major incident typically involves numerous stakeholders; these include the responsible party, response organisations, government authorities across multiple jurisdictions, local communities, and a spectrum of technical experts. An incident management team will encounter numerous challenges. Factors such as limited access to location, adverse weather, poor communication, and lack of pre-identified resources can impede a response; delays caused by an inefficient response can exacerbate impacts caused to the wider environment, socio-economic and cultural resources. It is essential that all parties work based on defined roles, responsibilities and authority, and ensure the availability of sufficient resources. To promote steadfast coordination and overcome the challenges highlighted, an Incident Management System (IMS) offers an essential tool for oil spill response. It provides clarity in command and control, improves communication and coordination, facilitates the cooperation between stakeholders, and integrates resources committed. Following the preceding discussion, a comprehensive review of existing literature serves to illustrate the application of IMS in oil spill response to overcome common challenges faced in a major-scaled incident. With a primary audience comprising practitioners in mind, this study will discuss key principles of incident management which enables an effective response, along with pitfalls and challenges, particularly, the tension between government and industry; case studies will be used to frame learning and issues consolidated from previous research, and provide the context to link practice with theory. It will also feature the industry approach to incident management which was further crystallized as part of a review by the Joint Industry Project (JIP) established in the wake of the Macondo well control incident. The authors posit that a common IMS which can be adopted across the industry not only enhances response capacity towards a major oil spill incident but is essential to the global preparedness effort.

Keywords: command and control, incident management system, oil spill response, response organisation

Procedia PDF Downloads 156

Authors: Damanhur Munardi, Muhammad Hafiz, Dina Nurmalita Sari, Syarifah Ridani Alifa

Abstract:

Purpose: This research aims to analyze the Benefits, Opportunity, Cost, and Risk aspects of applying the Green Finance concept and to obtain the right Green Finance financing strategy to be implemented within a long-term and short-term strategic framework.Methodology: This research method uses a qualitative-descriptive analysis approach. The analysis technique uses Analytical Network Process (ANP) with a BOCR network structure approach.Findings: The research results show that the most priority long-term strategic alternative based on the long-term BOCR analysis is increasing awareness among the public and industry by 52% and the importance of coordination between related institutions by 50%. Meanwhile, the most priority short-term strategic alternatives are the importance of coordination between related institutions 29%, increasing awareness among the public and industry 28%, the banking industry proactively funding environmentally friendly companies and technology 23%, the existence of Green Finance POS (Standard Operating Procedures) 20%.Implications: This research can be used as a reference for regulators and policymakers in making strategic decisions that can increase green finance financing. The novelty of this research is identifying problems that occur in green finance financing in Aceh province by analyzing opinions from experts in related fields and financial regulators in Aceh to create a strategy that can be implemented to increase green finance financing in Aceh province through BPD in Aceh, namely Bank Aceh.

Keywords: green financing, banking, sharia, islamic

Procedia PDF Downloads 64

Authors: Giga Rahmah An-Nafisah, Lailatus Syifa Kamilah

Abstract:

Agriculture today, especially in Indonesia have globally improved. Since the election of the new president, who in the program of work priority the food self-sufficiency. Many ways and attempts have been planned carefully. All this is done to maximize agricultural production for the future. But if we look from another side, there is something missing. Yes! Improvement of life safety of the farmers, useless we fix all agricultural processing systems to maximize agricultural output, but the Hero of agriculture itself it does not change towards a better life. Yes, broker or middleman system agriculture results. Broker system or middleman this is the real problem facing farmers for their welfare. How come? As much as agriculture result, but if farmers were sell into middlemen with very low prices, then there will be no progress for their welfare. Broker system who do the actual middlemen should not happen in the current agricultural system, because the agriculture condition currently being concern, they would still be able to reap a profit as much as possible, no matter how miserable farmers manage the farm and currently face import competition this cannot be avoided anymore. This phenomenon is already visible plain sight all, who see it. Why? Because farmers those who fell victim cannot do anything to change this system. It is true, if only these middlemen who want to receive it for the sale of agricultural products, or arguably the only system that is the bridge realtor economic life of the farmers. The problem is that we should strive for the welfare of the heroes of our food. A golden bridge that could save them that, are the government. Why? Because the government can more easily with the powers to stop this broker system compared to other parties. The government supposed to be a bridge connecting the farmers with consumers or the people themselves. Yes, with improved broker system becomes: buy agricultural produce with highest prices to farmers and selling of agricultural products with lowest price to the consumer or the people themselves. And then the next question about the fate of middlemen? The system indirectly realtor is like system corruption. Why? Because the definition of corruption is an activity that is detrimental to the victim without being noticed by anyone continue to enrich himself and his victim's life miserable. Government may transfer performance of the middlemen into the idea of a new bridge that is done by the government itself. The government could lift them into this new bridge system employs them to remain a distributor of agricultural products themselves, but under the new policy made by the government to keep improving the welfare of farmers. This idea is made is not going to have much effect would improve the welfare of farmers, but most/least this idea will bring around many people for helping conscience farmers to the government, through the daily chatter, as well as celebrity gossip can quickly know too many people.

Keywords: broker system, farmers live, government, agricultural economics

Procedia PDF Downloads 294

Authors: George Leventakis, George Kokkinis, Nikos Moustakidis, George Papalexandratos, Ioanna Vasiliadou

Abstract:

Enhancing the feeling of public safety and crime prevention are tasks customarily assigned to the Police. Police departments have, however, recognized that traditional ways of policing methods are becoming obsolete; Community Policing (CP) philosophy; however, when applied appropriately, leads to seamless collaboration between various stakeholders like the Police, NGOs and the general public and provides the opportunity to identify risks, assist in solving problems of crime, disorder, safety and crucially contribute to improving the quality of life for everyone in a community. Social Media, on the other hand, due to its high level of infiltration in modern life, constitutes a powerful mechanism which offers additional and direct communication channels to reach individuals or communities. These channels can be utilized to improve the citizens’ perception of the Police and to capture individual and community needs, when their feedback is taken into account by Law Enforcement Agencies (LEAs) in a structured and coordinated manner. This paper presents research conducted under INSPEC²T (Inspiring CitizeNS Participation for Enhanced Community PoliCing AcTions), a project funded by the European Commission’s research agenda to bridge the gap between CP as a philosophy and as an organizational strategy, capitalizing on the use of Social Media. The project aims to increase transparency, trust, police accountability, and the role of civil society. It aspires to build strong, trusting relationships between LEAs and the public, supporting two-way, contemporary communication while at the same time respecting anonymity of all affected parties. Results presented herein summarize the outcomes of four online multilingual surveys, focus group interviews, desktop research and interviews with experts in the field of CP practices. The above research activities were conducted in various EU countries aiming to capture requirements of end users from diverse backgrounds (social, cultural, legal and ethical) and determine public expectations regarding CP, community safety and crime prevention.

Keywords: community partnerships, next generation community policing, social media, public safety

Procedia PDF Downloads 346