Search results for: safety of construction projects

Authors: Krzysztof J. Czarnocki, F. Silveira, E. Czarnocka, K. Szaniawska

Abstract:

Research background: Problems related to the occupational health and decreasing level of safety occur commonly in the construction industry. Important factor in the occupational safety in construction industry is scaffold use. All scaffolds used in construction, renovation, and demolition shall be erected, dismantled and maintained in accordance with safety procedure. Increasing demand for new construction projects unfortunately still is linked to high level of occupational accidents. Therefore, it is crucial to implement concrete actions while dealing with scaffolds and risk assessment in construction industry, the way on doing assessment and liability of assessment is critical for both construction workers and regulatory framework. Unfortunately, professionals, who tend to rely heavily on their own experience and knowledge when taking decisions regarding risk assessment, may show lack of reliability in checking the results of decisions taken. Purpose of the article: The aim was to indicate crucial parameters that could be modeling with Risk Assessment Model (RAM) use for improving both building enterprise productivity and/or developing potential and safety climate. The developed RAM could be a benefit for predicting high-risk construction activities and thus preventing accidents occurred based on a set of historical accident data. Methodology/Methods: A RAM has been developed for assessing risk levels as various construction process stages with various work trades impacting different spheres of enterprise activity. This project includes research carried out by teams of researchers on over 60 construction sites in Poland and Portugal, under which over 450 individual research cycles were carried out. The conducted research trials included variable conditions of employee exposure to harmful physical and chemical factors, variable levels of stress of employees and differences in behaviors and habits of staff. Genetic modeling tool has been used for developing the RAM. Findings and value added: Common types of trades, accidents, and accident causes have been explored, in addition to suitable risk assessment methods and criteria. We have found that the initial worker stress level is more direct predictor for developing the unsafe chain leading to the accident rather than the workload, or concentration of harmful factors at the workplace or even training frequency and management involvement.

Keywords: safety climate, occupational health, civil engineering, productivity

Procedia PDF Downloads 289

Authors: Mamoon Mousa Atout

Abstract:

The industries of construction are in continuous growth not only in Middle East rejoin but almost all over the world. For the last fifteen years, big expansion and increase of different types of projects has been observed. Many infrastructural projects have been developed, high rise buildings, big shopping malls, power sub-stations, roads, bridges, schools, universities and developing many of new cities with full and complete facilities. The growth and enlargement of the mentioned developed projects has been accomplished through many international and local contracting organizations. Senior management of these organizations depend on their qualified and experienced team whom are aware of the implications of project management, construction management, engineering management and resource management during tendering till final completion of the project. This research aims to find out why reasons of principles of construction engineering and management are necessary for contracting firms and their managers. Principles of construction management help contracting organizations to accomplish and deliver projects without delay. This can be maintained by establishing guidelines’ details for updating the adopted system of construction management that they have through qualified and experienced project managers. The research focuses on benefits of other essential skills of projects planning, monitoring and control. Defining roles and responsibilities of contractor project managers during tendering and execution is a part of the investigated factors that will be analyzed. Other skills like optimizing and utilizing the obtainable project resources to deliver the project within time, cost and quality will be also investigated to find out how these factors are affecting the performance of contracting firms, projects managers and projects. The conclusion of the research will help senior management team and the contractors project managers about the benefits of implications and benefits construction management system and its effect upon the performance and knowledge of contract values that they have, and the optimal profit margin of the firm it.

Keywords: construction management, contracting firms, project managers, planning processes, roles and responsibilities

Procedia PDF Downloads 278

Authors: Mustapha Yakubu, Ahmed Usman, Hashim Ambursa

Abstract:

This paper presents the findings of a research which sought to investigate techniques used to improve cost and time control of construction projects management practice in Nigeria. However, there is limited research on issues surrounding the practical usage of these techniques. Data were collected through a questionnaire distributed to construction experts through a survey conducted on the 100 construction organisations and 50 construction consultancy firms in the Nigeria aimed at identifying common project cost and time control practices and factors inhibiting effective project control in practice. The study reveals that despite the vast application of control techniques a high proportion of respondents still experienced cost and time overruns on a significant proportion of their projects. Analysis of the survey results concluded that more effort should be geared at the management of the identified top project control inhibiting factors. This paper has outlined some measures for mitigating these inhibiting factors so that the outcome of project time and cost control can be improved in practice.

Keywords: construction project, cost control, Nigeria, time control

Procedia PDF Downloads 286

Authors: Saleh Alzahrani, Halim Boussabaine

Abstract:

The majority of Public Private Partnership (PPP) are developed based on the rationale that the design, construction, operation, and financing of a public project is to be awarded to a private party within a single contractual framework. PPP project risks normally include the development and construction of a new asset as well as its operation for decades. Undoubtedly the most serious consequences of risks during the construction period are price and time overruns. These events are amongst the most broadly used scenarios in value for money analysis risks. The sources of risk change over the life cycle of a PPP project. In traditional procurement, the public sector normally has to cover all price distress from these risks. At least there is plenty evidence to suggest that price distress is a norm in some of the projects that are delivered under traditional procurement. This paper will find the impact of construction risk factors into actual construction price into PPP projects. The paper will present a brief literature review on PPP risk pricing strategies, and then using system dynamics (SD) to analyses of the risks associated with the estimated project price. Based on the finding from these analyses a risk pricing association model is presented and discussed. The paper concludes with thoughts for future research.

Keywords: Public Private Partnership (PPP), Risk, Risk Pricing, System Dynamics (SD), construction price

Procedia PDF Downloads 541

Authors: J. Tamosaitiene

Abstract:

The article focuses on the identification and classification of key risk management criteria that represent the most important sustainability aspects of the construction industry. The construction sector is one of the most important sectors in Lithuania. Nowadays, the assessment of the risk level of a construction project is especially important for the quality of construction projects, the growth of enterprises and the sector. To establish the most important criteria for successful growth of the sector, a questionnaire for experts was developed. The analytic hierarchy process (AHP), the expert judgement method and other multicriteria decision making (MCDM) methods were used to develop the hybrid model. The results were used to develop an integrated knowledge system for the measurement of a risk level particular to construction projects. The article presents a practical case that details the developed system, sustainable aspects, and risk assessment.

Keywords: risk, system, model, construction

Procedia PDF Downloads 146

Authors: Khorief Ouissem, Sassi Boudmagh Souad, Mahimoud Aissa

Abstract:

The health and safety problem in the construction companies has been a major subject of research in Algeria for many years. The latest statistics of the Algerian National Social Security Fund (CNAS) shows that a third of accidents recorded at the national level are originated from construction activities. It is becoming increasingly essential and urgent to investigate and address its causes in order to find measures to overcome the deficiencies in this area. Thus, this paper takes in investigating this problem through a study conducted in the city of Skikda, Algeria. The study was carried out through questionnaire where twenty construction companies were taking into consideration. First, the study identifies the regulations and the laws related to the health and safety in the construction sector in Algeria. Then it goes on to assess and evaluate the implementation of the identified regulations in the companies selected. The result of the assessment indicates that the majority of the construction companies considered do not meet the health and safety standards and regulations. To extract the main causes of the failure of the system to control this industry, the observations and the evaluation were analyzed using the 5M or Ichikawa diagram method. This method is based on identifying the causes of the problem in terms of purpose, the list of potential causes for families. These families often correspond to 5M (Labor, Material, Methods, Middle, and Management). Finally, having identified the primary motives, the present authors propose a list of actions to move towards a more controlled and effective health and safety system for the construction industry.

Keywords: health and safety, construction industry, performance measurement, Algeria

Procedia PDF Downloads 315

Authors: Hailu Kebede Bekele

Abstract:

Construction delays are suitable where project events occur at a certain time expected due to causes related to the client, consultant, and contractor. Delay is the major cause of the cost overrun that leads to the poor efficiency of the project. The cost difference between completion and the originally estimated is known as cost overrun. The common ways of cost overruns are not simple issues that can be neglected, but more attention should be given to prevent the organization from being devastated to be failed, and financial expenses to be extended. The reasons that may raised in different studies show that the problem may arise in construction projects due to errors in budgeting, lack of favorable weather conditions, inefficient machinery, and the availability of extravagance. The study is focused on the pace of mega projects that can have a significant change in the cost overrun calculation.15 mega projects are identified to study the problem of the cost overrun in the site. The contractor, consultant, and client are the principal stakeholders in the mega projects. 20 people from each sector were selected to participate in the investigation of the current mega construction project. The main objective of the study on the construction cost overrun is to prioritize the major causes of the cost overrun problem. The methodology that was employed in the construction cost overrun is the qualitative methodology that mostly rates the causes of construction project cost overrun. Interviews, open-ended and closed-ended questions group discussions, and rating qualitative methods are the best methodologies to study construction projects overrun. The result shows that design mistakes, lack of labor, payment delay, old equipment and scheduling, weather conditions, lack of skilled labor, payment delays, transportation, inflation, and order variations, market price fluctuation, and people's thoughts and philosophies, the prior cause of the cost overrun that fail the project performance. The institute shall follow the scheduled activities to bring a positive forward in the project life.

Keywords: cost overrun, delay, mega projects, design

Procedia PDF Downloads 41

Authors: Kenneth O. Otasowie, Matthew Ikuabe, Clinton Aigbavboa, Ayodeji Oke

Abstract:

Construction project cost are not only made up of production costs. This cost comprises of many other elements such as the preparation of a bidding document, cost estimations, drafting contractual agreements and monitoring that contractual obligations are met. Several studies have stressed the need for transaction costs (TC) to be defined in a way that covers all phases of a project and not only the pre-contract phase. Hence, this study aims to appraise transaction cost in South African (SA) construction projects by assessing what constitutes transaction cost, influencing factors and possible optimisation measures. A survey design was adopted. A total number of eighty (80) questionnaires were administered to quantity surveyors, procurement managers and project managers in Guateng Province, SA and seventy-two (72) were returned and found suitable for analysis. Collected data was analysed using percentage, mean item score, standard deviation, one-sample t-test. The findings show that external technical interaction, uncertainty, human factors are the most significant constituents of TC in SA, while technical competency, experience in similar project type and project characteristics are the leading influencing factors. Furthermore, understanding project characteristics, clear communication and technically competent project teams are most of the significant measures for optimising TC in SA construction projects. Therefore, this study recommends that a competent project team and a clear communication are fundamental to proper management of TC in SA construction projects.

Keywords: construction projects, project cost, South Africa, transaction cost

Procedia PDF Downloads 79

Authors: Adegbenga Ashiru, Adebimpe L. Ashiru

Abstract:

The construction industry is considered to work by diversifying personnel. Hence managing human resource is an issue considered to be a highly challenging task. Nonetheless, HR planning for the construction project is a very critical aspect of managing human resource within an expanding nature of construction industry, and there are rising concerns over the failure of construction planning to achieve its goals in spite of the substantial resources allocated to it and as a result of different planning strategies. To justify the above statement, this research was carried out to examine the sustainability of HR planning for construction project. Based on the researcher’s experience, a quantitative approach was adopted that provided a broader understanding of the research and was analysed using descriptive statistics and inferential statistics. The Statistical Package for the Social Sciences (SPSS) was used to obtain the descriptive and inferential statistical analysis. However, research findings showed that literature sources agreed with varying challenges of HR planning on construction projects which were justified by empirical findings. Also, the paper identified four major factors and the key consideration for Project HR Planning (Organisation’s structure with right individuals at right positions and evaluation current resources) will lead to the efficient utilisation implementation of new HR Planning technique and tools for a construction project. Essentially the main reoccurring theme identified was that management of the construction organisations needs to look into the essential factors needed to be considered at the strategic level. Furthermore, leaders leading a construction project team should consider those essential factors needed at the operational level to clarify the numerous functions of HRM in the construction organisations and avoid inconsistencies among several practices on construction projects. The Sustainability of HR planning for construction project policy was indicated and recommendations were made for further future research.

Keywords: construction industry, HRM planning in construction, SHRM in construction, HR planning in construction

Procedia PDF Downloads 325

Authors: Khawaja A. Wahaj Wani, Aykut Erkal

Abstract:

Pakistan's construction industry, a key player in economic development, has experienced remarkable growth. However, the surge in activities has been accompanied by dangerous working conditions, attributed to legislative gaps and flaws. Unhealthy construction practices, uncertain site conditions, and hazardous environments contribute to a concerning rate of injuries and fatalities. The principal aim of this research study is to undertake a thorough evaluation based on the assessment of the current situation of Health & Safety policies and the surveys performed by stakeholders of Pakistan with the aim of providing solution-centric methodologies for the enforcement of health and safety regulations within construction companies operating on project sites. Recognizing the pivotal role that the construction industry plays in bolstering a nation's economy, it is imperative to address the pressing need for heightened awareness among site engineers and laborers. The study adopts a robust approach, utilizing questionnaire surveys and interviews. As an exclusive investigative study, it encompasses all stakeholders: clients, consultants, contractors, and subcontractors. Targeting PEC-registered companies. Safety performance was assessed through the examination of sixty safety procedures using SPSS-18. A high Cronbach's alpha value of 0.958 ensures data reliability, and non-parametric tests were employed due to the non-normal distribution of data. The safety performance evaluation revealed significant insights. "Using Hoists and Cranes" and "Precautionary Measures (Shoring and Excavation)" exhibited commendable safety levels. Conversely, "Trainings on Safety" displayed a lower safety performance, alongside areas such as "Safety in Contract Documentation," "Meetings for Safety," and "Worker Participation," indicating room for improvement. These findings provide stakeholders with a detailed understanding of current safety measures within Pakistan's construction industry.

Keywords: construction industry, health and safety regulations, Pakistan, risk management

Procedia PDF Downloads 33

Authors: Mohammed Aljoma, Eblal Zakzok

Abstract:

Safety is a science that seeks to protect and avoid humans from risks in any field and prevent losses in properties and lives as much as possible. On the other hand, occupational safety goals aim to protect workers from risks which can occur during work execution. The main purpose of occupational safety is to ultimately protect people, properties and the environment by reducing accidents and injuries that may cause losses and damages. To achieve this goal, we must remove the direct and indirect reasons which cause accidents and injuries; some of the reasons of accidents are the unsafe cases and inept behavior or both of them. This research focuses on the manner of providing instant protection from the very first beginning to people, properties and the environment by: -Inserting safety demands in the planning and designing works by identifying risk levels in every task of the project, -Using a new risk managing system or modifying or changing a previously-used one.

Keywords: planning, scheduling, risk management, project duration, site safety

Procedia PDF Downloads 278

Authors: Rameh Chauhan

Abstract:

Tunnel construction in Himalayan rock is a challenging task due to fragile nature of the strata. Tunnel excavation carried out from lower Himalayas to high Himalayas in different metamorphic rock. Therefore application of engineering geology plays a vital role during various stage of the tunneling projects. Engineering geology is defined as application of geology to construction of civil structures through engineering practice. It is applied to the design, construction and performance aspects of engineering structure on the surface or sub-surface like dam, underground and surface power house, cut slopes, tunnels and underground storage cavern for nuclear material. But this paper emphasized mostly on underground structures like big caverns of Power house, desilting chambers, and tunnels of various sizes. Construction of these structures in the fragile rock conditions of Himalayan geology from Western Himalayas to Eastern Himalayas necessitated the application of the engineering geology on the micro-scale base for the stability, performance, and longevity of the civil structures. Number of hydropower projects have been constructed, some of them are under construction and under investigation stage. These projects are located in various parts of Himalayas under various seismic-tectonic zones. Tunneling works are involved in these projects. This paper represents the various engineering geological practices adopted in investigation and construction stage of various projects based on experiences gained during past construction histories in Himalayan geology of young mountains in very fragile geological conditions. Highlighting and sharing of use of these techniques on various platforms will definitely enhance the knowledge for carrying out the construction of various projects for the development of society. Construction of the tunnels, surface, and sub-surface caverns, dams, highway, metro, highway tunnels are all based on engineering geological parameters in combinations with other engineering considerations.

Keywords: cavern-power house, desilting chambers and tunnels, seismic-tectonic-zones, earthquake-prone zones based on intensities

Procedia PDF Downloads 202

Authors: Nahed Al-Hajeri

Abstract:

Time and cost is an integral part of every construction plan and can affect each party’s contractual obligations. The performance of both time and cost are usually important to the client and contractor during the project. Almost all construction projects are experiencing time overrun. These time overruns always contributed as expensive to both client and contractor. Construction of any project inside the gathering centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. It also involves many agencies interdependent on each other like the vendors, structural and functional designers including various types of specialized engineers and it includes support of contractors and specialized contractors. This paper mainly highlights the types of construction delays due to which project suffer time and cost overrun. This paper also speaks about the delay causes and factors that contribute to the construction sequence delay for the oil and gas projects. Construction delay is supposed to be one of the repeated problems in the construction projects and it has an opposing effect on project success in terms of time, cost and quality. Some effective methods are identified to minimize delays in construction projects such as: 1. Site management and supervision, 2. Effective strategic planning, 3. Clear information and communication channel. Our research paper studies the types of delay with some real examples with statistic results and suggests solutions to overcome this problem.

Keywords: non-compensable delay, delays caused by force majeure, compensable delay, delays caused by the owner or the owner’s representative, non-excusable delay, delay caused by the contractor or the contractor’s representative, concurrent delay, delays resulting from two separate causes at the same time

Procedia PDF Downloads 228

Authors: Shariful Islam, Sharun Akter Khushbu, S. M. Shaqib, Shahriar Sultan Ramit

Abstract:

In the construction sector, ensuring worker safety is of the utmost significance. In this study, a deep learning-based technique is presented for identifying safety gear worn by construction workers, such as helmets, goggles, jackets, gloves, and footwear. The suggested method precisely locates these safety items by using the YOLO v7 (You Only Look Once) object detection algorithm. The dataset utilized in this work consists of labeled images split into training, testing and validation sets. Each image has bounding box labels that indicate where the safety equipment is located within the image. The model is trained to identify and categorize the safety equipment based on the labeled dataset through an iterative training approach. We used custom dataset to train this model. Our trained model performed admirably well, with good precision, recall, and F1-score for safety equipment recognition. Also, the model's evaluation produced encouraging results, with a [email protected] score of 87.7%. The model performs effectively, making it possible to quickly identify safety equipment violations on building sites. A thorough evaluation of the outcomes reveals the model's advantages and points up potential areas for development. By offering an automatic and trustworthy method for safety equipment detection, this research contributes to the fields of computer vision and workplace safety. The proposed deep learning-based approach will increase safety compliance and reduce the risk of accidents in the construction industry.

Keywords: deep learning, safety equipment detection, YOLOv7, computer vision, workplace safety

Procedia PDF Downloads 49

Authors: Shalini Priyadarshini

Abstract:

The notion of performance measurement has held great appeal for the industry and research communities alike. This idea is also true for the construction sector, and some propose that performance measurement and productivity analysis are two separate management functions, where productivity is a subset of performance, the latter requiring comprehensive analysis of comparable factors. Labor productivity is considered one of the best indicators of production efficiency. The construction industry continues to account for a disproportionate share of injuries and illnesses despite adopting several technological and organizational interventions that promote worker safety. Specialty trades contractors typically complete a large fraction of work on any construction project, but insufficient body of work exists that address subcontractor safety and productivity issues. Literature review has revealed the possibility of a relation between productivity, safety and other factors and their links to project, organizational, task and industry performance. This research posits that there is an association between productivity and performance at project as well as organizational levels in the construction industry. Moreover, prior exploration of the importance of safety within the performance-productivity framework has been anecdotal at best. Using structured questionnaire survey and organization- and project level data, this study, which is a combination of cross-sectional and longitudinal research designs, addresses the identified research gap and models the relationship between productivity, safety, and performance with a focus on specialty trades in the construction sector. Statistical analysis is used to establish a correlation between the variables of interest. This research identifies the need for developing and maintaining productivity and safety logs for smaller businesses. Future studies can design and develop research to establish causal relationships between these variables.

Keywords: construction, safety, productivity, performance, specialty trades

Procedia PDF Downloads 253

Authors: Uttam Neupane, Narendra Budha, Subash Kumar Bhattarai

Abstract:

Material management is an essential part in construction project management. There are a number of material management problems in the Nepalese construction industry, which contribute to an inefficient material management system. Ineffective material management can cause waste of time and money thus increasing the problem of time and cost overrun. An assessment of material management system with gap and solution was carried out on 20 construction projects implemented by the Federal Level Project Implementation Unit (FPIU); Kaski district of Nepal. To improve the material management process, the respondents have provided possible solutions to overcome the gaps seen in the current material management process. The possible solutions are preparation of material schedule in line with the construction schedule for material requirement planning, verifications of material and locating of source, purchasing of the required material in advance before commencement of work, classifying the materials, and managing the inventory based on their usage value and eliminating and reduction in wastages during the overall material management process.

Keywords: material management, construction site, inventory, construction project

Procedia PDF Downloads 41

Authors: Ghanim A. Bekr

Abstract:

Project success is what must be done for the project to be acceptable to the client, stakeholders and end-users who will be affected by the project. The study of project success and the critical success factors (CSFs) are the means adopted to improve the effectiveness of project. This research is conducted to make an attempt to identify which variables influence the success of project implementation. This study has selected, through an extensive literature review and interviews, (83) factors categorized in (7) groups that the questionnaire respondents were asked to score. The responses from 66 professionals with an average of 15 years of experience in different types of construction projects in Jordan were collected and analyzed using SPSS and most important factors for success for various success criteria are presented depending on the relative importance index to rank the categories. The research revealed the significant groups of factors are: Client related factors, Contractor’s related factors, Project Manager (PM) related factors, and Project management related factors. In addition the top ten sub factors are: Assertion of the client towards short time of the project, availability of skilled labor, Assertion of the client towards high level of the quality, capability of the client in taking risk, previous experience of the PM in similar projects, previous experience of the contractor in similar projects, decision making by the client/ the client’s representative at the right time, assertion of client towards low cost of project, experience in project management in previous projects, and flow of the information among parties. The results would be helpful to construction project professionals in taking proactive measures for successful completion of construction projects in Jordan.

Keywords: construction projects, critical success factors, Jordan, project success

Procedia PDF Downloads 134

Authors: Jawad Taheri

Abstract:

This paper investigates the impact of foreign aid-funded development projects on corruption perception in Afghanistan, utilizing instrumental variable (IV) approaches in regression analysis setting. Seven sub-categories of development projects are examined in order to have a glance over comparative usefulness of each project. The study incorporates natural disaster indicators as exogenous variables to mitigate endogeneity concerns and control variables. The findings reveal significant associations between certain types of projects and corruption perception. Road and bridge construction, irrigation, and agriculture projects are found to decrease corruption perception, fostering optimism and trust within affected communities. Mosque construction and healthcare initiatives aligned with religious beliefs also contribute to reduced corruption perception. However, drinking water projects are associated with increased corruption perception, highlighting potential challenges in their implementation. The study emphasizes the importance of well-implemented projects, cultural contexts, and effective governance in mitigating corruption and fostering trust within communities. These findings contribute to a refined understanding of the relationship between development projects and corruption perception in Afghanistan.

Keywords: foreign aid, development projects, corruption perception, Afghanistan, instrumental variable analysis, survey of Afghan people (SAP), natural disasters, exogenous variation

Procedia PDF Downloads 49

Authors: Samuel Opeyemi Williams, Razali Adul Hamid, Mohd Saidin Misman, Dominic Ileyemi Ajayi, Taki Eddine Seghier

Abstract:

Construction industry is famous with hazardous and high-risk environment with operatives facing a greater risk of work-related fatality or injury than operatives in other industries. It is characterised with different types of accident, ranging from electrocution, trip and slip, fall from height, struck-by, explosion, trench collapse, to scaffolding accidents, with each type being caused by different factors. However, accidents are unplanned, unforeseeable and unexpected events, but regardless of the high-risk nature of the industry, accidents are preventable. The aim of the paper is to determine the extent of the utilization of the safety measures, as well as identifying the factors underlining the non-usage. A research methodology consisting of a literature review was used to identify the types and causes of site accidents, while a well-structured questionnaire was used to determine the level of the usage of safety measures on site. The data were analysed with the results revealing the use of protective clothing, safety helmet, first aid, protective shoe, safety belt, and face shield to aid safety of workers, as well as ascribing non-usage of safety measures to cost, ignorance, lack of experts and non-inclusion in contract document. Recommendations are included in the paper suggesting the enforcement of the utilization of safety measures in reducing the spate of accident occurrence on construction sites.

Keywords: construction industry, safety measures, accident, prevention

Procedia PDF Downloads 295

Authors: Melissa Teo

Abstract:

It is increasingly important that project managers develop greater capabilities to better manage the social, cultural, political, environmental and economic impacts on proposed construction projects. These challenges are best resolved in consultation with communities rather than in conflict with them. This is particularly important on controversial projects which are projects that have obtained government sanctioned ‘development approval’ but not ‘community approval’. While a rich body of research and intellectual frameworks exist in the fields of urban geography and planning to understand and manage community concerns during the pre-development approval stages of new projects, current theoretical frameworks guiding community engagement in project management are inadequate. A new and innovative research agenda is needed to guide thinking about the role of local communities in the construction process and is an important research gap that needs to be filled. Within this context, this research aims to assess the effectiveness of strategies adopted by project teams to engage with local communities so as to capture lessons learnt to apply to future projects. This paper reports a research methodology which uses Arnstein’s model of participation to better understand how power differentials between the project team and local communities can influence the adoption of community engagement strategies. A case study approach is utilizing interviews and documentary analysis of a large-scale controversial construction project in Queensland, Australia is presented. The findings will result in a number of recommendations to guide community engagement practices on future projects.

Keywords: community engagement, construction, case study, project management

Procedia PDF Downloads 237

Authors: Lingzhi Li, Jiankun Zhang, Tiantian Gu

Abstract:

Hazard management that can prevent fatal accidents and property losses is a fundamental process during the buildings’ construction stage. However, due to lack of safety supervision resources and operational pressures, the conduction of hazard management is poor and ineffective in China. In order to improve the quality of construction safety management, it is critical to explore the use of information technologies to ensure that the process of hazard management is efficient and effective. After exploring the existing problems of construction hazard management in China, this paper develops the griddization management model for construction hazard management. First, following the knowledge grid infrastructure, the griddization computing infrastructure for construction hazards management is designed which includes five layers: resource entity layer, information management layer, task management layer, knowledge transformation layer and application layer. This infrastructure will be as the technical support for realizing grid management. Second, this study divides the construction hazards into grids through city level, district level and construction site level according to grid principles. Last, a griddization management process including hazard identification, assessment and control is developed. Meanwhile, all stakeholders of construction safety management, such as owners, contractors, supervision organizations and government departments, should take the corresponding responsibilities in this process. Finally, a case study based on actual construction hazard identification, assessment and control is used to validate the effectiveness and efficiency of the proposed griddization management model. The advantage of this designed model is to realize information sharing and cooperative management between various safety management departments.

Keywords: construction hazard, griddization computing, grid management, process

Procedia PDF Downloads 246

Authors: Omar Amoudi, Latifa Al Brashdi

Abstract:

Construction projects are always subject to risks and uncertainties due to its unique and dynamic nature, outdoor work environment, the wide range of skills employed, various parties involved in addition to situation of construction business environment at large. Altogether, these risks and uncertainties affect projects objectives and lead to cost overruns, delay, and poor quality. Construction projects in Oman often experience cost overruns and delay. Managing these risks and reducing their impacts on construction cost requires firstly identifying these risks, and then analyzing their severity on project cost to obtain deep understanding about these risks. This in turn will assist construction managers in managing and tacking these risks. This paper aims to investigate the main risk factors that affect construction projects cost in the Sultanate of Oman. In order to achieve the main aim, literature review was carried out to identify the main risk factors affecting construction cost. Thirty-three risk factors were identified from the literature. Then, a questionnaire survey was designed and distributed among construction professionals (i.e., client, contractor and consultant) to obtain their opinion toward the probability of occurrence for each risk factor and its possible impact on construction project cost. The collected data was analyzed based on qualitative aspects and in several ways. The severity of each risk factor was obtained by multiplying the probability occurrence of a risk factor with its impact. The findings of this study reveal that the most significant risk factors that have high severity impact on construction project cost are: Change of Oil Price, Delay of Materials and Equipment Delivery, Changes in Laws and Regulations, Improper Budgeting, and Contingencies, Lack of Skilled Workforce and Personnel, Delays Caused by Contractor, Delays of Owner Payments, Delays Caused by Client, and Funding Risk. The results can be used as a basis for construction managers to make informed decisions and produce risk response procedures and strategies to tackle these risks and reduce their negative impacts on construction project cost.

Keywords: construction cost, construction projects, Oman, risk factors, risk management

Procedia PDF Downloads 314

Authors: Riki Panchal, Debasis Sarkar

Abstract:

This paper describes the work done for the GIS-based project management for different infrastructure projects. It is a review paper which gives the idea of the trends in the construction project management and various models adopted for the betterment of the project planning and execution. Traditional scheduling and progress control techniques such as bar charts and the critical path method fail to provide information pertaining to the spatial aspects of a construction project. An integrated system was developed to represent construction progress not only in terms of a CPM schedule but also in terms of a graphical representation of the construction that is synchronized with the work schedule. Hence, it is suggested to work on the common platform from where all the data can be shared and analyzed.

Keywords: GIS, project management, integrated model, infrastructure project

Procedia PDF Downloads 493

Authors: Naci Büyükkaraciğan, Yildirim Akyol

Abstract:

Large plants that covering the back and accumulate water of a river valley for energy production, drinking, irrigation water supply, economic benefits that serve many purposes, such as regulation of flood protection, are called dams. Place, in which unites in order to achieve an optimum balance between manpower for Lowest cost and economic as belonging to that structure to create machines, materials and construction of the project, is called as the site. Dam construction sites are combined sites in together in many businesses. Therefore, there can be found in the many workers and machines are many accidents in this type of construction sites. The necessity of systematic and scientific studies due to various reasons arises in order to be protected from conditions that could damage the health, During the execution of the work on construction sites. Occupational health and safety of the study, called the case, also in the European Union has begun to be addressed by weight since the 1980s. In particular, issued in 1989 89/391/EEC on occupational health and safety directive, occupational health and adopted the Directive within the framework of the security field, and then exposed to a large number of individual directive within this framework on the basis of the directive. Turkey's Law No. 6331 entered into force in June 2012 on the subject. In this study, measures related to the construction site of the dam should be taken with occupational safety and health have been examined and tried to put forward recommendations on the subject.

Keywords: civil engineering, dam, occupational safety and health, site organizations

Procedia PDF Downloads 313

Authors: Abdullah Alhomidan

Abstract:

This study is conducted to identify the main factors affecting accuracy of pretender cost estimate in building construction projects in Saudi Arabia from owners’ perspective. 44 factors affecting pretender cost estimate were identified through literature review and discussion with some construction experts. The results show that the top important factors affecting pretender cost estimate accuracy are: level of competitors in the tendering, material price changes, communications with suppliers, communications with client, and estimating method used.

Keywords: cost estimate, accuracy, pretender, estimating, bid estimate

Procedia PDF Downloads 539

Authors: Olubukola Olumuyiwa Tokede, Dominic D. Ahiaga-Dagbui, John Morrison

Abstract:

The project environment in construction has been widely criticised for its inability to learn from experience effectively. As each project is bespoke, learning is ephemeral, as it is often confined within its bounds and seldom assimilated with others that are being delivered in the project environment. To engender learning across construction projects, collaborative contractual arrangements, such as alliancing and partnering, have been embraced to aid the transferability of lessons across projects. These cooperative arrangements, however, tend to be costly, and hence construction organisations could revert to less expensive traditional procurement approaches after successful collaborative project delivery. This research, therefore, seeks to assess the lessons-learned in a post-alliance contractual framework. Using a case-study approach, we examine the experiences of a public sector authority who engaged a project facilitator to foster learning during the delivery of a significant piece of critical infrastructure. It was found that the facilitator enabled optimal learning outcomes in post-alliance contractual frameworks by attenuating the otherwise adversarial relationship between clients and contractors. Further research will seek to assess the effectiveness of different knowledge-brokering agencies in construction projects.

Keywords: facilitation, knowledge-brokering, learning, projects

Procedia PDF Downloads 115

Authors: Muhammad Yousaf Sadiq

Abstract:

The complexity arises in defining the construction quality due to its perception, based on inherent market conditions and their requirements, the diversified stakeholders itself and their desired output. An quantitative survey based approach was adopted in this constructive study. A questionnaire-based survey was conducted for the assessment of construction Quality perception and expectations in the context of quality improvement technique. The survey feedback of professionals of the leading construction organizations/companies of Pakistan construction industry were analyzed. The financial capacity, organizational structure, and construction experience of the construction firms formed basis for their selection. The quality perception was found to be project-scope-oriented and considered as an excess cost for a construction project. Any quality improvement technique was expected to maximize the profit for the employer, by improving the productivity in a construction project. The study is beneficial for the construction professionals to assess the prevailing construction quality perception and the expectations from implementation of any quality improvement technique in construction projects.

Keywords: construction quality, expectation, improvement, perception

Procedia PDF Downloads 447

Authors: Ali Youniss Aidbaiss, G. Unnikrishnan, Anoob Hakim

Abstract:

Scope changes, scope creeps, cost and time overruns have become common in projects in the oil and gas sector. Even in repetitive projects, failure to implement lessons learnt and correct past mistakes have resulted in various setbacks. This paper describes the concept of reusing successfully implemented design packages as templates for repetitive projects, and thereby lowering the instances of project failures. Units or systems successfully installed in projects can be identified and taken up for preparing template design packages. Standardization of units and systems helps to develop templates from successful designs which can be repeatedly used with confidence. These packages can be used with minimum modifications for developing FEED packages faster, saving cost and other valuable resources. Lessons learnt from the completed project incorporated in the templates avoid repeating past mistakes during detailed design, procurement and execution. With template packages, consistent quality can be maintained for similar projects, avoiding scope creep and scope changes which will ultimately result in cost and time savings.

Keywords: engineering work package, repetitive construction, template design package, time saving in projects

Procedia PDF Downloads 290

Authors: Adel Mohamed El-Baghdady, Walid Sayed Abdulgalil, Ahmad Asran, Ibrahim Nosier

Abstract:

This paper studies the effectiveness of applying value engineering to actual concrete mixtures. The study was conducted in the State of Qatar on a number of strategic construction projects with international engineering specifications for the 2022 World Cup projects. The study examined the concrete mixtures of Doha Metro project and the development of KAHRAMAA’s (Qatar Electricity and Water Company) Abu Funtas Strategic Desalination Plant, in order to generally improve the quality and productivity of ready-mixed concrete used in construction and hydraulic projects. The application of value engineering to such concrete mixtures resulted in the following: i) improving the quality of concrete mixtures and increasing the durability of buildings in which they are used; ii) reducing the waste of excess materials of concrete mixture, optimizing the use of resources, and enhancing sustainability; iii) reducing the use of cement, thus reducing CO₂ emissions which ensures the protection of environment and public health; iv) reducing actual costs of concrete mixtures and, in turn, reducing the costs of construction projects; and v) increasing the market share and competitiveness of concrete producers. This research shows that applying the methodology of value engineering to ready-mixed concrete is an effective way to save around 5% of the total cost of concrete mixtures supplied to construction and hydraulic projects, improve the quality according to the technical requirements and as per the standards and specifications for ready-mixed concrete, improve the environmental impact, and promote sustainability.

Keywords: value management, cost of concrete, performance, optimization, sustainability, environmental impact

Procedia PDF Downloads 328

Authors: Nuruddeen Usman, Mohammad Sani

Abstract:

The performance of project delivery methods has been an issue of concern to various stakeholders in the construction industry. The contracting system of project delivery is the traditional system used in the delivery of most public projects in Nigeria. The direct labor system is used most times as an alternative to the traditional system. There were so many complain about the performance of contracting system and the suitability of direct labor as an alternative to the delivery of public projects. Therefore, this paper is aimed at investigating the effect of project size on the project delivery methods in the completed public buildings. Questionnaires were self-administered to managerial staff in the study area and analyzed using descriptive statistics. The findings reveals that contracting system was choosing for large size building construction project delivery with higher frequency (F) of 40 (76.9%) against direct labor with 12 (23.1%). While the small size project, the result revealed a frequency (F) of 26 (50%) for contracting system and direct labor system respectively. Base on the research findings, the contracting system, was recommended for all sizes of building construction project delivery while direct labor system can only use as an alternative for small size building construction projects delivery.

Keywords: construction size, contracting system, direct labour, effect

Procedia PDF Downloads 436