Search results for: payment delays

Authors: Sunaitan Al Mutairi

Abstract:

A perfect start is a key factor for project completion on time. The study examined the effects of delayed mobilization of resources during the initial phases of the project. This paper mainly highlights the identification and categorization of all delays during the initial construction phase and their root cause analysis with corrective/control measures for the Kuwait Oil Company oil and gas projects. A relatively good percentage of the delays identified during the project execution (Contract award to end of defects liability period) attributed to mobilization/preliminary activity delays. Data analysis demonstrated significant increase in average project delay during the last five years compared to the previous period. Contractors had delays/issues during the initial phase, which resulted in slippages and progressively increased, resulting in time and cost overrun. Delays/issues not mitigated on time during the initial phase had very high impact on project completion. Data analysis of the delays for the past five years was carried out using trend chart, scatter plot, process map, box plot, relative importance index and Pareto chart. Construction of any project inside the Gathering Centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. Delay affects completion of projects and compromises quality, schedule and budget of project deliverables. Works executed as per plan during the initial phase and start-up duration of the project construction activities resulted in minor slippages/delays in project completion. In addition, there was a good working environment between client and contractor resulting in better project execution and management. Mainly, the contractor was on the front foot in the execution of projects, which had minimum/no delays during the initial and construction period. Hence, having a perfect start during the initial construction phase shall have a positive influence on the project success. Our research paper studies each type of delay with some real example supported by statistic results and suggests mitigation measures. Detailed analysis carried out with all stakeholders based on impact and occurrence of delays to have a practical and effective outcome to mitigate the delays. The key to improvement is to have proper control measures and periodic evaluation/audit to ensure implementation of the mitigation measures. The focus of this research is to reduce the delays encountered during the initial construction phase of the project life cycle.

Keywords: construction activities delays, delay analysis for construction projects, mobilization delays, oil & gas projects delays

Procedia PDF Downloads 316

Authors: Adji Achmad Rinaldo Fernandes

Abstract:

The research was conducted to apply semiparametric SEM modeling to the timeliness of paying credit. Semiparametric SEM is structural modeling in which two combined approaches of parametric and nonparametric approaches are used. The analysis method in this research is semiparametric SEM with a nonparametric approach using a truncated spline. The data in the study were obtained through questionnaires distributed to Bank X mortgage debtors and are confidential. The study used 3 variables consisting of one exogenous variable, one intervening endogenous variable, and one endogenous variable. The results showed that (1) the effect of capacity and willingness to pay variables on timeliness of payment is significant, (2) modeling the capacity variable on willingness to pay also produces a significant estimate, (3) the effect of the capacity variable on the timeliness of payment variable is not influenced by the willingness to pay variable as an intervening variable, (4) the R^2 value of 0.763 or 76.33% indicates that the model has good predictive relevance.

Keywords: structural equation modeling semiparametric, credit bank, accuracy of payment time, willingness to pay

Procedia PDF Downloads 43

Authors: Huong Nguyen Thi Thanh, Van Mai Thi Khanh

Abstract:

For around the world, payments for environmental services have been implemented since the late 1970s in Europe and North America; then, it was spread to Latin America, Asia, Africa, and finally Oceania in 2008. In Vietnam, payments for environmental services are an interesting issue recently with the forest as the main focus and therefore known as the program on payment for forest environmental services (PFES). PFES was piloted in Lam Dong and Son La in 2008 and has been widely applied in many provinces after 2010. PFES is in the orientation for the socialization of national forest protection in Vietnam and has made great strides in the last decade. By using the primary data and secondary data simultaneously, the paper clarifies two cases of implementing PFES in the Vietnam North Central area with the different mechanisms of payment. In the first case at Phu Loc district (Thua Thien Hue province), PFES is an indirect method by a water supply company via the Forest Protection and Development Fund. In the second one at Phong Nha – Ke Bang National Park (Quang Binh Province), tourism companies are the direct payers to forest owners. The paper describes the PFES implementation process at each site, clarifies the payment mechanism, and models the relationship between stakeholders in PFES implementation. Based on the current status of PFES sites, the paper compares and analyzes the advantages and disadvantages of the two payment methods. Finally, the paper proposes recommendations to improve the existing shortcomings in each payment mechanism.

Keywords: advantages and disadvantages, forest environmental services, forest protection, payment mechanism

Procedia PDF Downloads 126

Authors: Intissar Abbes, Yousra Hallem, Jean-michel Sahut

Abstract:

The purpose of this research is to explore the legitimacy of a proximity mobile payment (PMP) system by taking into account the social aspects related to its use (social acceptability). We have chosen to focus on the acceptability process of a PMP application (‘Flashplay’) from the first testing to the adoption in a service context. This PMP solution is a pilot program developed as part of a global strategy of disintermediation in various sectors (retail, catering, and entertainment). This case is particularly interesting for two reasons: the context and environment are suitable to the adoption of innovation in payment like other African countries and the possibility to study different stages of the social acceptability process of that PMP system. The neo-institutional theory is mobilized to identify the three pillars of legitimacy: cognitive, normative and regulatory. A longitudinal qualitative study was conducted with 27 customers using the PMP service. Results highlighted the importance of the consumption system and the service provider as institutions. Recommendations are thus proposed to PMP service providers in order to rethink the design and implementation strategies of their PMP system to ensure their adoption and promote the institutionalization of this type of consumption practice.

Keywords: legitimacy, payment, acceptability, mobility

Procedia PDF Downloads 181

Authors: Mikail Altan

Abstract:

International trust takes first place in the development of foreign trade in the country. They see an important role in ensuring that trust. Various payment methods that are developed in the banking system provide fast and reliable way to execution and promote foreign trade by financing the foreign trade. In this study, we investigate the influence of bank on foreign trade in Turkey. 26 years of data for 1990-2015 period have been used in this study. After correlation analysis, a simple regression model was established. Payment methods that are developed in the banking system make a positive contribution in Turkey’s foreign trade volume. In addition, the export of Turkey was affected positively more than import’s by these payment methods.

Keywords: banks, export, foreign trade, import

Procedia PDF Downloads 356

Authors: Joseph Marfo Boaheng, Daniel Ansong, Eugenia Amporfo

Abstract:

Health Insurance is proposed to provide financial protection against catastrophic health care cost arising from disease. Ghana has had a National Health Insurance Scheme (NHIS) since 2003 with the current enrolment/retention rate of 36%. The main goal of the scheme is to provide equity in the health sector as well as ensuring affordable health care for the poor. However, the current payment system is not flexible to attract significant proportion of the poor informal sector onto the scheme. Looking at the extensive use of mobiles in the Ghana where about 29,220,602.00 registered mobile phone lines are actively in used as of June 2014, paying health insurance premium through mobile phone could be feasible to attract larger proportion of the informal sector onto the scheme. Methodology: The quantitative cross-sectional survey was used to solicit the required information from 877 respondents living in Kumasi, the second capital city of Ghana. The magnitude of the effect of Pro-rata system (flexible payment terms) on NHIS enrollment rate was estimated with binary logistic regression model. Results: The odds for an individual to enroll onto NHIS with mobile phone increases about 2 times more when payment of insurance premium is on pro-rata basis ie. flexible payment terms (p=0.008, CI=1.212-3.565). Conclusion: The study advocates the National Health Insurance Authority consider this alternative payment system that has the potential of attracting a greater proportion of the informal sector to be enrolled or retained onto the scheme.

Keywords: enrollment, health insurance, mobile phone, pro-rata

Procedia PDF Downloads 392

Authors: Neliswa Dyosi

Abstract:

Purpose - Using an integrated Technology-Organization-Environment (TOE) framework and the model of technology appropriation (MTA) as a theoretical lens, this interpretive qualitative study seeks to understand and explain the factors that influence the appropriation, non-appropriation, and disappropriation of bitcoin as a payment method by South African retailers. Design/methodology/approach –The study adopts the interpretivist philosophical paradigm. Multiple case studies will be adopted as a research strategy. For data collection, the study follows a qualitative approach. Qualitative data will be collected from the six retailers in various industries. Semi-structured interviews and documents will be used as the data collection techniques. Purposive and snowballing sampling techniques will be used to identify participants within the organizations. Data will be analyzed using thematic analysis. Originality/value - Using the deduction approach, the study seeks to provide a descriptive and explanatory contribution to theory. The study contributes to theory development by integrating the MTA and TOE frameworks as a means to understand technology adoption behaviors of organizations, in this case, retailers. This is also the first study that looks at an integrated approach of the Technology-Organization-Environment (TOE) framework and the MTA framework to understand the adoption and use of a payment method. South Africa is ranked amongst the top ten countries in the world on cryptocurrency adoption. There is, however, still a dearth of literature on the current state of adoption and usage of bitcoin as a payment method in South Africa. The study will contribute to the existing literature as bitcoin cryptocurrency is gaining popularity as an alternative payment method across the globe.

Keywords: cryptocurrency, bitcoin, payment methods, blockchain, appropriation, online retailers, TOE framework, disappropriation, non-appropriation

Procedia PDF Downloads 133

Authors: Imtiaz Ali, Imam Mansoor

Abstract:

Investigations as a part of the academic study were undertaken to identify and evaluate the significant risks associated with the construction of K-span buildings in the region of UAE. Primary field data was collected through questionnaires obtaining specific open and close-ended questions from carefully selected construction firms, civil engineers and, construction manager regarding risks associated to K-span building construction. Historical data available for other regions of the same construction technique was available which was compared for identifying various non-critical and critical risk parameters by comparative evaluation techniques to come up with important risks and potential sources for their control and minimization in K-Span buildings that is increasing in the region. The associated risks have been determined with their Relative Importance Index (RII) values of which Risk involved in Change of Design required by Owners carries the highest value (RII=0.79) whereas, Delayed Payment by Owner to Contractor is one of the least (RII=0.42) value. The overall findings suggest that most relative risks as quantified originate or associated with the contractors. It may be concluded that project proponents undertaking K-span projects in planning and budgeting the cost and delays should take into account of risks on high account if changes in design are also required any delays in the material by the supplier would then be a major risk in K-span project delay. Since projects are, less costly, so owners have limited budgets, then they hire small contractors, which are not highly competent contractors. So study suggests that owner should be aware of these types of risks associated with the construction of K-span buildings in order to make it cost effective.

Keywords: k-span buildings, k-span construction, risk management, relative improvement index (RII)

Procedia PDF Downloads 373

Authors: Kreangkri Ratchagit

Abstract:

This paper is concerned with exponential stability of switched linear systems with interval time-varying delays. The time delay is any continuous function belonging to a given interval, in which the lower bound of delay is not restricted to zero. By constructing a suitable augmented Lyapunov-Krasovskii functional combined with Leibniz-Newton’s formula, a switching rule for the exponential stability of switched linear systems with interval time-varying delays and new delay-dependent sufficient conditions for the exponential stability of the systems are first established in terms of LMIs. Finally, some examples are exploited to illustrate the effectiveness of the proposed schemes.

Keywords: exponential stability, hybrid systems, timevarying delays, Lyapunov-Krasovskii functional, Leibniz-Newton’s formula

Procedia PDF Downloads 456

Authors: Seyed Ali Mohammadiborna, Mehdi Ravanshadnia

Abstract:

Project delays usually detrimentally affect perceptions of project success and can in some instances, result in increased costs and other time-related damages to project stakeholders. One of the realities in the national infrastructure projects is that since the primary stakeholders are state-affiliated, the delay factors of the projects have not been seriously taken into account despite the importance of on-time completion of projects. Project postponement has different economic and social consequences and leads to the technical and economic infeasibility of the infrastructure projects in the form of reduced productivity and exploitation capacity. The present study aimed at investigating delay factors of Iranian national infrastructure projects according to regulatory reports of the Plan and Budget Organization (BPO) of Iran. The present study scrutinized the influence of each of the factors that caused delays in national Iranian infrastructure projects according to the supervision reports of the planning and budget organization in 8 years. For this purpose, the study analyzed the information regarding the impact of 12 key delay factors causing delays in average 4867 projects per year in all provinces. The said factors were classified into the three groups of executive, credit, and financial and environmental-procurement factors.

Keywords: delays, infrastructure, projects, regulatory

Procedia PDF Downloads 135

Authors: Yen-An Tsai, Ching-Ling Lin, Jia-Woei Hou, Mei-Lien Chen

Abstract:

Endocrine-disrupting chemicals (EDCs) adversely affect the endocrine system. Phthalates, also called phthalic acid esters (PAEs), are manmade chemicals that are used as stabilizing agents in personal care products such as perfumes, lotions, and cosmetics. The aim was to explore whether PAEs exposure was associated with central precocious puberty (CPP) or constitutional delays in growth (CDGP). This case-control study included 48 female with CPP, 37 male with constitutional delays in growth, and 127 normal children and was conducted from December 2011 to August 2014. All participants completed a structured questionnaire regarding socio-demographic characteristics, lifestyle, and secondary sexual characteristics. The analytical method was based on ultra performance liquid chromatography-tandem mass spectrometry (UPLC-MS/MS) with isotope dilution for the quantitative detection of several phthalate metabolites in human urine. The risk of CPP with mep, mnbp, LMW >50th percentile were higher than those with 50th percentile were higher than those with <50 percentile in model 2. In model 1, we only found higher CDGP risk in mep, mnbp, and ΣPAEs. It shows that high phthalate exposure may associate with CDGP. In this case-control study, we found PAEs exposure was associated with central precocious puberty (CPP) or constitutional delays in growth.

Keywords: phthalates, puberty, delays, growth

Procedia PDF Downloads 180

Authors: Yash Goyal, Manish Korde, Juned Siddiqui

Abstract:

Today online education has gained more popularity so that people can easily complete their curriculum on their own time. Virtual learning has been widely used by many educators, especially in higher education institutions due to its benefits to students and faculty. A good knowledge of teaching theory and instructional design systems is required to experience meaningful learning. However, most educational websites are not designed to adapt to all screen sizes. Making the website accessible on all screen sizes is our main objective, so we have created a website that is readily accessible across all screen sizes and accepts all types of payment methods. And we see generally educational websites interface is simple and unexciting. So, we have made a user interface attractive and user friendly. It is not enough for a website to be user-friendly, but also to be familiar to admins and to reduce the workload of the admin as well. We visited so many popular websites under development that they all had issues like responsiveness, simple interface, security measures, payment methods, etc. To overcome this limitation, we have created a website which has taken care of security issues that is why we have created only one admin id and it can be control from that only. And if the user has successfully done the payment, then the admin can send him a username and password through mail individually so there will no fraud in the payment of the course.

Keywords: responsive, accessible, attractive, interface, objective, security.

Procedia PDF Downloads 101

Authors: Grienggrai Rajchakit

Abstract:

This paper is concerned with the exponential stability of switched linear systems with interval time-varying delays. The time delay is any continuous function belonging to a given interval, in which the lower bound of delay is not restricted to zero. By constructing a suitable augmented Lyapunov-Krasovskii functional combined with Leibniz-Newton's formula, a switching rule for the exponential stability of switched linear systems with interval time-varying delays and new delay-dependent sufficient conditions for the exponential stability of the systems are first established in terms of LMIs. Finally, some examples are exploited to illustrate the effectiveness of the proposed schemes.

Keywords: exponential stability, hybrid systems, time-varying delays, lyapunov-krasovskii functional, leibniz-newton's formula

Procedia PDF Downloads 542

Authors: Edoghogho Ogbeifun, Charles Mbohwa, J. H. C. Pretorius

Abstract:

Several research report on the factors responsible for the delays in the completion of construction projects has identified the issue of funding as a critical factor; insufficient funding, low cash-flow or lack of funds. Indeed, adequate funding plays pivotal role in the effective execution of construction projects. In the last twenty years (or so), there has been increase in the funds available for infrastructure development in tertiary institution in Nigeria, especially, through the Tertiary Education Trust Fund. This funding body ensures that there is enough fund for each approved project, which is released in three stages during the life of the construction project. However, a random tour of many of the institutions reveals striking evidence of projects not delivered on schedule, to quality and sometime out rightly abandoned. This suggests, therefore, that there are other latent factors, responsible for project delays, that should be investigated. Thus, this research, a pilot scheme, is aimed at unearthing the possible reasons for the delays being experienced in the execution of construction projects for infrastructure upgrade in public tertiary institutions in Nigeria, funded by Tertiary Education Trust Fund. The multiple site case study of qualitative research was adopted. The respondents were the Directors of Physical Planning and the Directors of Works of four Nigerian Public Universities. The findings reveal that delays can be situated within three entities, namely, the funding body, the institutions and others. Therefore, the emerging factors have been classified as external factors (haven to do with the funding body), internal factors (these concern the operations within the institutions) and general factors. The outcome of this pilot exercise provides useful information to guide the Directors as they interact with the funding body as well as challenges themselves to address the loopholes in their internal operations.

Keywords: delays, external factors, funding, general factors, Internal factors

Procedia PDF Downloads 143

Authors: Marcel Schneider, Nils Nießen

Abstract:

Microscopic simulation programs enable the description of the two processes of railway operation and the previous timetabling. Occupation conflicts are often solved based on defined train priorities on both process levels. These conflict resolutions produce knock-on delays for the involved trains. The sum of knock-on delays is commonly used to evaluate the quality of railway operations. It is either compared to an acceptable level-of-service or the delays are evaluated economically by linearly monetary functions. It is impossible to properly evaluate dispatching decisions without a well-founded objective function. This paper presents a new approach for evaluation of dispatching decisions. It uses models of choice of transport and considers the behaviour of the end-costumers. These models evaluate the knock-on delays in more detail than linearly monetary functions and consider other competing modes of transport. The new approach pursues the coupling of a microscopic model of railway operation with the macroscopic model of choice of transport. First it will be implemented for the railway operations process, but it can also be used for timetabling. The evaluation considers the possibility to change over to other transport modes by the end-costumers. The new approach first looks at the rail-mounted and road transport, but it can also be extended to air transport. The split of the end-costumers is described by the modal-split. The reactions by the end-costumers have an effect on the revenues of the railway undertakings. Various travel purposes has different pavement reserves and tolerances towards delays. Longer journey times affect besides revenue changes also additional costs. The costs depend either on time or track and arise from circulation of workers and vehicles. Only the variable values are summarised in the contribution margin, which is the base for the monetary evaluation of the delays. The contribution margin is calculated for different resolution decisions of the same conflict. The conflict resolution is improved until the monetary loss becomes minimised. The iterative process therefore determines an optimum conflict resolution by observing the change of the contribution margin. Furthermore, a monetary value of each dispatching decision can also be determined.

Keywords: choice of transport, knock-on delays, monetary evaluation, railway operations

Procedia PDF Downloads 326

Authors: Nahed Al-Hajeri

Abstract:

Time and cost is an integral part of every construction plan and can affect each party’s contractual obligations. The performance of both time and cost are usually important to the client and contractor during the project. Almost all construction projects are experiencing time overrun. These time overruns always contributed as expensive to both client and contractor. Construction of any project inside the gathering centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. It also involves many agencies interdependent on each other like the vendors, structural and functional designers including various types of specialized engineers and it includes support of contractors and specialized contractors. This paper mainly highlights the types of construction delays due to which project suffer time and cost overrun. This paper also speaks about the delay causes and factors that contribute to the construction sequence delay for the oil and gas projects. Construction delay is supposed to be one of the repeated problems in the construction projects and it has an opposing effect on project success in terms of time, cost and quality. Some effective methods are identified to minimize delays in construction projects such as: 1. Site management and supervision, 2. Effective strategic planning, 3. Clear information and communication channel. Our research paper studies the types of delay with some real examples with statistic results and suggests solutions to overcome this problem.

Keywords: non-compensable delay, delays caused by force majeure, compensable delay, delays caused by the owner or the owner’s representative, non-excusable delay, delay caused by the contractor or the contractor’s representative, concurrent delay, delays resulting from two separate causes at the same time

Procedia PDF Downloads 239

Authors: Marko Niinimaki

Abstract:

Cryptocurrencies are getting increasingly popular, but very few of them can be conveniently used in daily mobile phone purchases. To solve this problem, we demonstrate how to build a functional prototype of a mobile cryptocurrency-based e-commerce application the communicates with Near-Field Communication (NFC) tags. Using the system, users are able to purchase physical items with an NFC tag that contains an e-commerce URL. The payment is done simply by touching the tag with a mobile device and accepting the payment. Our method is constructive: we describe the design and technologies used in the implementation and evaluate the security and performance of the solution. Our main finding is that the analysis and measurements show that our solution is feasible for e-commerce.

Keywords: cryptocurrency, e-commerce, NFC, mobile devices

Procedia PDF Downloads 181

Authors: Helen S. Ghali, Engy Serag, A. Samer Ezeldin

Abstract:

In many countries, the construction industry relies heavily on outsourcing models in executing their projects and expanding their businesses to fit in the diverse market. Such extensive integration of subcontractors is becoming an influential factor in contractor’s cash flow management. Accordingly, subcontractors’ financial terms are important phenomena and pivotal components for the well-being of the contractor’s cash flow. The aim of this research is to study the contractor’s cash flow with respect to the owner and subcontractor’s payment management plans, considering variable advance payment, payment frequency, and lag and retention policies. The model is developed to provide contractors with a decision support tool that can assist in selecting the optimum subcontracting plan to minimize the contractor’s financing limits and optimize the profit values. The model is built using Microsoft Excel VBA coding, and the genetic algorithm is utilized as the optimization tool. Three objective functions are investigated, which are minimizing the highest negative overdraft value, minimizing the net present worth of overdraft, and maximizing the project net profit. The model is validated on a full-scale project which includes both self-performed and subcontracted work packages. The results show potential outputs in optimizing the contractor’s negative cash flow values and, in the meantime, assisting contractors in selecting suitable subcontractors to achieve the objective function.

Keywords: cash flow optimization, payment plan, procurement management, subcontracting plan

Procedia PDF Downloads 129

Authors: Jing Jiang, Yuguang Gao, Yang Yu

Abstract:

Facing increasingly challenging insurance payment pressures, the Chinese healthcare system is undergoing significant transformations, akin to the implementation of DRG payment models by the United States' Medicare. Consequently, there is a pressing need for Chinese hospitals to establish optimizations in departmental operations tailored to the ongoing healthcare payment reforms. This abstract delineates the meticulous construction of a scientifically rigorous and comprehensive index system at the departmental level in China strategically aligned with the evolving landscape of healthcare payment reforms. Methodologically, it integrates key process areas and maturity assessment theories, synthesizing relevant literature and industry standards to construct a robust framework and indicator pool. Employing the Delphi method, consultations with 21 experts were conducted, revealing a collective demonstration of high enthusiasm, authority, and coordination in designing the index system. The resulting model comprises four primary indicators -technical capabilities, cost-effectiveness, operational efficiency, and disciplinary potential- supported by 14 secondary indicators and 23 tertiary indicators with varied coefficient adjustment for department types (platform or surgical). The application of this evaluation system in a Chinese hospital within the northeastern region yielded results aligning seamlessly with the actual operational scenario. In conclusion, the index system comprehensively considers the integrity and effectiveness of structural, process, and outcome indicators and stands as a comprehensive reflection of the collective expertise of the engaged experts, manifesting in a model designed to elevate the operational management of hospital departments. Its strategic alignment with healthcare payment reforms holds practical significance in guiding departmental development positioning, brand cultivation, and talent development.

Keywords: Chinese healthcare system, Delphi method, departmental management, evaluation indicators, hospital operations, weight coefficients

Procedia PDF Downloads 64

Authors: A. Šapkauskienė, A. Mačerinskienė, R. Andrulienė, R. Bruzgė, S. Masteika, K. Driaunys

Abstract:

The COVID-19 pandemic has affected not only world markets and economies but also the daily lives of customers and their payment habits. The pandemic has accelerated the digital transformation, so the role of technology will become even more important post-COVID. Although the popularity of cryptocurrencies has reached unprecedented heights, there are still obstacles, such as a lack of consumer experience and distrust of these technologies, so exploring the role of cryptocurrency and blockchain in the context of international travel becomes extremely important. Research on tourists’ intentions to use cryptocurrencies for payment purposes is limited due to the small number of research studies. To fill this research gap, an exploratory study based on the analysis of survey data was conducted. The purpose of the research is to explore how the behavior of tourists has changed making their financial transactions when paying for the tourism services in order to determine the intention to pay in cryptocurrencies. Behavioral intention can be examined as a dependent variable that is useful for the study of the acceptance of blockchain as cutting-edge technology. Therefore, this study examines the intention of travelers to use cryptocurrencies in electronic payments for tourism services. Several studies have shown that the intention to accept payments in a cryptocurrency is affected by the perceived usefulness of these payments and the perceived ease of use. The findings deepen our understanding of the readiness of service users to apply for blockchain-based payment in the tourism sector. The tourism industry has to focus not only on the technology but on consumers who can use cryptocurrencies, creating new possibilities and increasing business competitiveness. Based on research results, suggestions are made to guide future research on the use of cryptocurrencies by tourists in the tourism industry. Therefore, in line with the rapid expansion of virtual currency users, market capitalization, and payment in cryptographic currencies, it is necessary to explore the possibilities of implementing a blockchain-based system aiming to promote the use of services in the tourism sector as the most affected by the pandemic.

Keywords: behavioral intention, blockchain-based payment, cryptocurrency, tourism

Procedia PDF Downloads 104

Authors: Bengi Demirci

Abstract:

Out-of-pocket payments have become one of the common models adopted by health care reforms all over the world, and they have serious implications for not only the financial set-up of the health care systems in question but also for the people involved in terms of their access to the health care services provided. On the one hand, out-of-pocket payments are used in raising resources for the finance of the health care system and in decreasing non-essential health care expenses by having a deterrent role on the patients. On the other hand, out-of-pocket payment model causes regressive distribution effect by putting more burdens on the lower income groups and making them refrain from using health care services. Being a relatively incipient country having adopted the out-of-pocket payment model within the context of its Health Transformation Program which has been ongoing since the early 2000s, Turkey provides a good case for re-evaluating the pros and cons of this model in order not to sacrifice equality in access to health care for raising revenue for health care finance and vice versa. Therefore this study aims at analyzing the impact of out-of-pocket payments on the health finance system itself and on the patients’ access to healthcare services in Turkey where out-of-pocket payment model has been in use for a while. In so doing, data showing the revenue obtained from out-of-pocket payments and their share in health care finance are analyzed. In addition to this, data showing the change in the amount of expenditure made by patients on health care services after the adoption of out-of-pocket payments and the change in the use of various health care services in the meanwhile are examined. It is important for the incipient countries like Turkey to be careful in striking the right balance between the objective of cost efficiency and that of equality in accessing health care services while adopting the out-of-pocket payment model.

Keywords: health care access, health care finance, health reform, out-of-pocket payments

Procedia PDF Downloads 371

Authors: Ossama Al-Maliki

Abstract:

Europay, MasterCard, and Visa (EMV) is one of the most popular payment protocol in the world. The EMV protocol supports Chip and PIN Transactions, Chip and Signature transactions, and Contactless transactions. This protocol suffers from tens of £ millions of lost per year due to many fraudulent payments. This is due to several reported vulnerable points in the protocols used for such payments that allow skimming, replay, cloning, Mole Point of Sale (POS), relay, and other attacks to be conducted. In this paper, we are focusing on the EMV contactless specification and we have proposed two proposal solutions to the addition of a localization factor to enhance the payment authentication of such transactions designed to prevent relay, cloning, and Mole-POS attacks. Our proposed solution is a back-end localization scheme to help the Issuer-Bank compare the location of the genuine cardholder in relation to the used POS. Our scheme uses 'something you have' which is the Cardholder Smartphone (CSP) to provide the location of the cardholder at the time of the transaction and without impacting the contactless payment time/protocol. The Issuer-bank obtain the CSP Location using tried and tested localization techniques, and independently of the cardholder. Both of our proposal solutions do not require infrastructure changes, and it uses existing EMV/SP protocol messages to communicate our scheme information.

Keywords: NFC, RFID, contactless card, authentication, location, EMV

Procedia PDF Downloads 241

Authors: Mohammad Saleh Vahdatpour, Yanqing Zhang

Abstract:

Understanding the neural mechanisms underlying motion detection in the human visual system has long been a fascinating challenge in neuroscience and artificial intelligence. This paper presents a spiking neural network model inspired by the processing of motion information in the primate visual system, particularly focusing on the Middle Temporal (MT) area. In our study, we propose a multi-layer spiking neural network model to perform motion detection tasks, leveraging the idea that synaptic delays in neuronal communication are pivotal in motion perception. Synaptic delay, determined by factors like axon length and myelin insulation, affects the temporal order of input spikes, thereby encoding motion direction and speed. Overall, our spiking neural network model demonstrates the feasibility of capturing motion detection principles observed in the primate visual system. The combination of synaptic delays, learning mechanisms, and shared weights and delays in SMD provides a promising framework for motion perception in artificial systems, with potential applications in computer vision and robotics.

Keywords: neural network, motion detection, signature detection, convolutional neural network

Procedia PDF Downloads 84

Authors: Chang-Ho Lee, Seung-Hoon Lee, Myeong-Jin Park, Oh-Min Kwon

Abstract:

This paper investigates improved stability criteria for sampled-data control of linear systems with disturbances and time-varying delays. Based on Lyapunov-Krasovskii stability theory, delay-dependent conditions sufficient to ensure H∞ stability for the system are derived in the form of linear matrix inequalities(LMI). The effectiveness of the proposed method will be shown in numerical examples.

Keywords: sampled-data control system, Lyapunov-Krasovskii functional, time delay-dependent, LMI, H∞ control

Procedia PDF Downloads 318

Authors: Shari S. C. Shang, Lynn S. L. Chiu

Abstract:

In the digital payment market, some consumers use only one payment wallet while many others play multi-homing with a variety of payment services. With the diffusion of new payment systems, we examined the determinants of the adoption of multi-homing behavior. This study aims to understand how a digital payment provider dynamically expands business touch points with cross-business strategies to enrich the digital ecosystem and avoid the trap of multi-homing in customers. By synthesizing platform ecosystem literature, we constructed a two-dimensional research framework with one determinant of user digital behavior from offline to online intentions and the other determinant of digital payment touch points from convenient accessibility to cross-business platforms. To explore on a broader scale, we selected 12 digital payments from 5 countries of UK, US, Japan, Korea, and Taiwan. With the interplays of user digital behaviors and payment touch points, we group the study cases into four types: (1) Channel Initiated: users originated from retailers with high access to in-store shopping with face-to-face guidance for payment adoption. Providers offer rewards for customer loyalty and secure the retailer’s efficient cash flow management. (2) Social Media Dependent: users usually are digital natives with high access to social media or the internet who shop and pay digitally. Providers might not own physical or online shops but are licensed to aggregate money flows through virtual ecosystems. (3) Early Life Engagement: digital banks race to capture the next generation from popularity to profitability. This type of payment aimed to give children a taste of financial freedom while letting parents track their spending. Providers are to capitalize on the digital payment and e-commerce boom and hold on to new customers into adulthood. (4) Traditional Banking: plastic credit cards are purposely designed as a control group to track the evolvement of business strategies in digital payments. Traditional credit card users may follow the bank’s digital strategy to land on different types of digital wallets or mostly keep using plastic credit cards. This research analyzed business growth models and inter-firms’ coopetition strategies of the selected cases. Results of the multiple case analysis reveal that channel initiated payments bundled rewards with retailer’s business discount for recurring purchases. They also extended other financial services, such as insurance, to fulfill customers’ new demands. Contrastively, social media dependent payments developed new usages and new value creation, such as P2P money transfer through network effects among the virtual social ties, while early life engagements offer virtual banking products to children who are digital natives but overlooked by incumbents. It has disrupted the banking business domains in preparation for the metaverse economy. Lastly, the control group of traditional plastic credit cards has gradually converted to a BaaS (banking as a service) model depending on customers’ preferences. The multi-homing behavior is not avoidable in digital payment competitions. Payment providers may encounter multiple waves of a multi-homing threat after a short period of success. A dynamic cross-business collaboration strategy should be explored to continuously evolve the digital ecosystems and allow users for a broader shopping experience and continual usage.

Keywords: digital payment, digital ecosystems, multihoming users, cross business strategy, user digital behavior intentions

Procedia PDF Downloads 158

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: construction, delay factors, time delay, australian construction industry

Procedia PDF Downloads 173

Authors: Elizabeth Spink

Abstract:

Providing safe and affordable drinking water to low-income households in developing countries remains a challenge. Policy goals of increasing household piped-water access and cost recovery for utility providers are often at odds. Nonpayment of utility bills is frequently cited as a constraint to improving the quality of utility service. However, nonpayment is widely tolerated, and households often accumulate significant debt to the utility provider. This study examines the effect of enforcement of water bill payment through supply disconnections in Livingstone, Zambia. This research uses a dynamic model of household monthly payments and accumulation of arrears, which determine the probability of disconnection, and simulates the effect of exogenous changes in enforcement levels. This model is empirically tested using an event-study framework of exogenous increases in enforcement capacity that occur during administrative rezoning events, which reduce the number of households that one enforcement agent is responsible for. The results show that households are five percentage points more likely to make a payment in the months following a rezoning event, but disconnections for low-income households increase as well, resulting in little change in revenue collected by the water utility. The results suggest that high enforcement of water bill payments toward credit-constrained households may be ineffective and lead to reduced piped-water access.

Keywords: enforcement, nonpayment, piped-water access, water utilities

Procedia PDF Downloads 243

Authors: Iyai Davies, Olivier L. C. Haas

Abstract:

In this paper, the problem of stability and stabilization for neutral delay-differential systems with infinite delay is investigated. Using Lyapunov method, new delay-independent sufficient condition for the stability of neutral systems with infinite delay is obtained in terms of linear matrix inequality (LMI). Memory-less state feedback controllers are then designed for the stabilization of the system using the feasible solution of the resulting LMI, which are easily solved using any optimization algorithms. Numerical examples are given to illustrate the results of the proposed methods.

Keywords: infinite delays, Lyapunov method, linear matrix inequality, neutral systems, stability

Procedia PDF Downloads 429

Authors: Ankit Kumar, Balram Dubey

Abstract:

This study proposes a three dimensional prey-predator model with additional food, provided to predator individuals, including gestation delay in predators and delay in supplying the additional food to predators. It is assumed that the interaction between prey and predator is followed by Holling type-II functional response. We discussed the steady states and their local and global asymptotic behavior for the non-delayed system. Hopf-bifurcation phenomenon with respect to different parameters has also been studied. We obtained a range of predator’s tendency factor on provided additional food, in which the periodic solutions occur in the system. We have shown that oscillations can be controlled from the system by increasing the tendency factor. Moreover, the existence of periodic solutions via Hopf-bifurcation is shown with respect to both the delays. Our analysis shows that both delays play an important role in governing the dynamics of the system. It changes the stability behavior into instability behavior. The direction and stability of Hopf-bifurcation are also investigated through the normal form theory and the center manifold theorem. Lastly, some numerical simulations and graphical illustrations have been carried out to validate our analytical findings.

Keywords: additional food, gestation delay, Hopf-bifurcation, prey-predator

Procedia PDF Downloads 128

Authors: H. N. Agiza, M. A. Sohaly, M. A. Elfouly

Abstract:

Parkinson's disease (PD) is a heterogeneous disorder with common age of onset, symptoms, and progression levels. In this paper we will solve analytically the PD model as a non-linear delay differential equation using the steps method. The step method transforms a system of delay differential equations (DDEs) into systems of ordinary differential equations (ODEs). On some numerical examples, the analytical solution will be difficult. So we will approximate the analytical solution using Picard method and Taylor method to ODEs.

Keywords: Parkinson's disease, step method, delay differential equation, two delays

Procedia PDF Downloads 202