Search results for: bidirectional option contract

Authors: Ali Obaid Alyami

Abstract:

In Saudi Arabia, the pandemic of Coronavirus (COVID-19) has been affecting administrative contracts in many different ways. Lots of planned projects were stopped temporarily or implemented partially. Many contractors have suffered financial struggles and the absence of manpower. These administrative contracts are governed by Government Tenders and Procurement Law (GTPL) which was issued by a royal decree in 2019. This law addresses some challenges that could be stumbling blocks in the way of implementing a contract. One significant challenge is emergency circumstances that occur during the implementation of an administrative contract. The law provides some solutions for this disruption, but these solutions may not compensate for the whole damages that contractors suffer. This study will use the doctrinal methodology to analyze the rules of law and their application to the research problem. Most importantly, the issue that arises in this research is the possibility of governmental entities’ consideration, in administrative contracts, of the pandemic Coronavirus (COVID-19) as an emergency circumstance. This study points out the conditions for applying the theory of emergency circumstances on administrative contracts in addition to the definition of the theory and analyzing its elements. The other significant question is the limits on governmental entities to make a change in an administrative contract to achieve contractual rebalancing. GPTL and its implementing regulation set the conditions and limits of contractual rebalancing. However, this study finds that although GTPL provides rules for contractual rebalancing, there are some other mechanisms that contractors may take to fully compensate for the damages. For instance, when the loss cannot be minimized by GTPL, contractors might file lawsuits before the administrative judiciary. The study concludes that GTPL is a very comprehensive law system that stipulates specific rules for contractual rebalance and treats the emergency circumstances that obstruct the performance of administrative contracts.

Keywords: administrative contracts, emergency circumstances, balance of contract, administrative judiciary, government tenders, procurement law

Procedia PDF Downloads 76

Authors: Maryam Heidari, James H. Jones Jr.

Abstract:

Millions of online posts about different topics and products are shared on popular social media platforms. One use of this content is to provide crowd-sourced information about a specific topic, event or product. However, this use raises an important question: what percentage of information available through these services is trustworthy? In particular, might some of this information be generated by a machine, i.e., a bot, instead of a human? Bots can be, and often are, purposely designed to generate enough volume to skew an apparent trend or position on a topic, yet the consumer of such content cannot easily distinguish a bot post from a human post. In this paper, we introduce a model for social media bot detection which uses Bidirectional Encoder Representations from Transformers (Google Bert) for sentiment classification of tweets to identify topic-independent features. Our use of a Natural Language Processing approach to derive topic-independent features for our new bot detection model distinguishes this work from previous bot detection models. We achieve 94\% accuracy classifying the contents of data as generated by a bot or a human, where the most accurate prior work achieved accuracy of 92\%.

Keywords: bot detection, natural language processing, neural network, social media

Procedia PDF Downloads 116

Authors: Yin Yuanling

Abstract:

A Deep Feedback Recurrent Neural Network (DFRNN) and Bidirectional Long Short-Term Memory (BiLSTM) are designed to address the problem of low accuracy of traditional relationship extraction models. This method combines a deep feedback-based recurrent neural network (DFRNN) with a bi-directional long short-term memory (BiLSTM) approach. The method combines DFRNN, which extracts local features of text based on deep feedback recurrent mechanism, BiLSTM, which better extracts global features of text, and Self-Attention, which extracts semantic information. Experiments show that the method achieves an F1 value of 76.69% on the CEC dataset, which is 0.0652 better than the BiLSTM+Self-ATT model, thus optimizing the performance of the deep learning method in the event relationship extraction task.

Keywords: event relations, deep learning, DFRNN models, bi-directional long and short-term memory networks

Procedia PDF Downloads 144

Authors: Heng Yang, Tao Luo, Yakun Zhang, Kai Wang, Wei Qin, Liang Xie, Ye Yan, Erwei Yin

Abstract:

Recent years have seen that audio-visual recognition has shown great potential in a strong noise environment. The existing method of audio-visual recognition has explored methods with ResNet and feature fusion. However, on the one hand, ResNet always occupies a large amount of memory resources, restricting the application in engineering. On the other hand, the feature merging also brings some interferences in a high noise environment. In order to solve the problems, we proposed an effective framework with bidirectional distillation. At first, in consideration of the good performance in extracting of features, we chose the light model, Efficientnet as our extractor of spatial features. Secondly, self-distillation was applied to learn more information from raw data. Finally, we proposed a bidirectional distillation in decision-level fusion. In more detail, our experimental results are based on a multi-model dataset from 24 volunteers. Eventually, the lipreading accuracy of our framework was increased by 2.3% compared with existing systems, and our framework made progress in audio-visual fusion in a high noise environment compared with the system of audio recognition without visual.

Keywords: lipreading, audio-visual, Efficientnet, distillation

Procedia PDF Downloads 134

Authors: Konstantinos Perifanos, Eirini Florou, Dionysis Goutsos

Abstract:

This paper presents and benchmarks a number of end-to-end Deep Learning based models for metaphor detection in Greek. We combine Convolutional Neural Networks and Recurrent Neural Networks with representation learning to bear on the metaphor detection problem for the Greek language. The models presented achieve exceptional accuracy scores, significantly improving the previous state-of-the-art results, which had already achieved accuracy 0.82. Furthermore, no special preprocessing, feature engineering or linguistic knowledge is used in this work. The methods presented achieve accuracy of 0.92 and F-score 0.92 with Convolutional Neural Networks (CNNs) and bidirectional Long Short Term Memory networks (LSTMs). Comparable results of 0.91 accuracy and 0.91 F-score are also achieved with bidirectional Gated Recurrent Units (GRUs) and Convolutional Recurrent Neural Nets (CRNNs). The models are trained and evaluated only on the basis of training tuples, the related sentences and their labels. The outcome is a state-of-the-art collection of metaphor detection models, trained on limited labelled resources, which can be extended to other languages and similar tasks.

Keywords: metaphor detection, deep learning, representation learning, embeddings

Procedia PDF Downloads 153

Authors: Laura Ramona Nae

Abstract:

The issue of risks faced by companies providing tourist and hotel services in the HoReCa field, related to the goods belonging to consumer tourists left in hotel storage, has acquired a new dimension in the context of the economic and geo-political influences that have recently intervened at the global level. Thus, hoteliers and not only had to create contractual mechanisms regarding the risks and to protect the businesses in this field of activity. This situation has led to a reassessment of the importance of insurance, in particular with regard to hotel liability insurance-premises liability, safety, and security of goods. Interpretation of clauses in contracts concluded between hoteliers and tourists consuming hotel services and products, all the more so in the current pandemic context of Covid 19, stressed the increase in the number of disputes generated by them. This article presents a general picture of the significance of the risks related to the activity carried out in the hospitality industry, tourism, respectively within the HoReCa field. The study mainly marks the specificities of the hotel deposit contract, as well as the related insurance specific to the field, as a way to cover these risks. The article also refers to alternative methods of out-of-court settlement of disputes (ADR) in the HoReCa domain, generally used in both Romania and the European Union.

Keywords: consumer tourist, disputes and ADR methods, deposit contract, hotel warehouse and hotelier insurance, hotel services and tourist products, HoReCa

Procedia PDF Downloads 57

Authors: Anthony Townley

Abstract:

Contract negotiation is fundamental to commercial law practice. For this study, genre and discourse analytical methodology was used to examine the legal negotiation of a Merger & Acquisition (M&A) deal undertaken by legal and business professionals in English across different jurisdictions in Europe. While some of the most delicate negotiations involved in this process were carried on face-to-face or over the telephone, these were generally progressed more systematically – and on the record – in the form of emails, email attachments, and as comments and amendments recorded in successive ‘marked-up’ versions of the contracts under negotiation. This large corpus of textual data was originally obtained by the author, in 2012, for the purpose of doctoral research. For this study, the analysis is particularly concerned with the use of emails and covering letters to exchange legal advice about the negotiations. These two genres help to stabilize and progress the negotiation process and account for negotiation activities. Swalesian analysis of functional Moves and Steps was able to identify structural similarities and differences between these text types and to identify certain salient discursive features within them. The analytical findings also indicate how particular linguistic strategies are more appropriately and more effectively associated with one legal genre rather than another. The concept of intertextuality is an important dimension of contract negotiation discourse and this study also examined how the discursive relationships between the different texts influence the way that texts are constructed. In terms of materials development, the research findings can contribute to more authentic English for Legal & Business Purposes pedagogies for students and novice lawyers and business professionals. The findings can first be used to design discursive maps that provide learners with a coherent account of the intertextual nature of the contract negotiation process. These discursive maps can then function as a framework in which to present detailed findings about the textual and structural features of the text types by applying the Swalesian genre analysis. Based on this acquired knowledge of the textual nature of contract negotiation, the authentic discourse materials can then be used to provide learners with practical opportunities to role-play negotiation activities and experience professional ways of thinking and using language in preparation for the written discourse challenges they will face in this important area of legal and business practice.

Keywords: English for legal and business purposes, discourse analysis, genre analysis, intertextuality, pedagogical materials

Procedia PDF Downloads 149

Authors: Adelina Vrancianu

Abstract:

A public procurement procedure starts with the publication of the contract notice and the tender documentation. The documentation provides bidders with general guidelines and rules governing the tender process. At this stage, the interested economic operators start to prepare their bid. During this process, they may encounter unclear elements that, if are not clarified, may have a negative impact on the future bid with the ultimate sanction of exclusion. Until the opening of the bids, the potential bidders have the right to ask questions in order to clarify certain aspects of the tender documentation. In correlation, the contracting authorities have the obligation to answer these questions in a reasoned time and with clarity. In practice, the two conditions are not met due to a number of factors. This essay tries to outline the general principles regarding the clarifications during the phase of tender preparation. The provisions of the new directive on public procurement will be taken in consideration in this process in regard to the old directive.

Keywords: tender preparation, tender documentation, clarifications, contract notice

Procedia PDF Downloads 296

Authors: Juhan Kim, Jinsoo Kim

Abstract:

South Korea cannot import natural gas in any form other than LNG because of the division of South and North Korea. Further, the high proportion of natural gas in the national energy mix makes this resource crucial for energy security in Korea. Expansion of Panama Canal will allow for reducing the cost of shipping between the Far East and U.S East. Panama Canal expansion can have significant impacts on South Korea. Due to this situation, we review the natural gas optimal portfolio by considering the uniqueness of the Korean Natural gas market and expansion of Panama Canal. In order to assess Korea’s natural gas optimal portfolio, we developed natural gas portfolio model. The model comprises two steps. First, to obtain the optimal long-term spot contract ratio, the study examines the price level and the correlation between spot and long-term contracts by using the Markowitz, portfolio model. The optimal long-term spot contract ratio follows the efficient frontier of the cost/risk level related to this price level and degree of correlation. Second, by applying the obtained long-term contract purchase ratio as the constraint in the linear programming portfolio model, we determined the natural gas optimal import portfolio that minimizes total intangible and tangible costs. Using this model, we derived the optimal natural gas portfolio considering the expansion of Panama Canal. Based on these results, we assess the portfolio for natural gas import to Korea from the perspective of energy security and present some relevant policy proposals.

Keywords: natural gas, Panama Canal, portfolio analysis, South Korea

Procedia PDF Downloads 291

Authors: Seungmin Chee

Abstract:

This paper investigates which of the two arguments, conservatism or liquidation option, is a true underlying driver of the asymmetric slope coefficient result regarding the association between earnings and returns. The analysis of the relation between earnings and returns in four mutually exclusive settings segmented by ‘profits vs. losses’ and ‘positive returns vs. negative returns’ suggests that liquidation option rather than conservatism is likely to cause the asymmetric slope coefficient result. Furthermore, this paper documents the temporal changes between Basu period (1963-1990) and post-Basu period (1990-2005). Although no significant change in degree of conservatism or value relevance of losses is reported, stronger negative relation between losses and positive returns is observed in the post-Basu period. Separate regression analysis of each quintile based on the rankings of price to sales ratio and book to market ratio suggests that the strong negative relation is driven by growth firms.

Keywords: conservatism, earnings, liquidation option, returns

Procedia PDF Downloads 374

Authors: Ons Triki, Fathi Abid

Abstract:

Along with the increase in the use of leasing contracts in corporate finance, multiple studies aim to model the credit risk of the lease in order to cover the losses of the lessor of the asset if the lessee goes bankrupt. In the current research paper, a convertible lease contract is elaborated in a continuous time stochastic universe aiming to ensure the financial stability of the firm and quickly recover the losses of the counterparties to the lease in case of default. This work examines the term structure of the lease rates taking into account the credit default risk and the capital structure of the firm. The interaction between the lessee's capital structure and the equilibrium lease rate has been assessed by applying the competitive lease market argument developed by Grenadier (1996) and the endogenous structural default model set forward by Leland and Toft (1996). The cumulative probability of default was calculated by referring to Leland and Toft (1996) and Yildirim and Huan (2006). Additionally, the link between lessee credit risk and lease rate was addressed so as to explore the impact of convertible lease financing on the term structure of the lease rate, the optimal leverage ratio, the cumulative default probability, and the optimal firm value by applying an endogenous conversion threshold. The numerical analysis is suggestive that the duration structure of lease rates increases with the increase in the degree of the market price of risk. The maximal value of the firm decreases with the effect of the optimal leverage ratio. The results are indicative that the cumulative probability of default increases with the maturity of the lease contract if the volatility of the asset service flows is significant. Introducing the convertible lease contract will increase the optimal value of the firm as a function of asset volatility for a high initial service flow level and a conversion ratio close to 1.

Keywords: convertible lease contract, lease rate, credit-risk, capital structure, default probability

Procedia PDF Downloads 98

Authors: Ghaleb Y. Abbasi, Sufyan Al-Mrayat

Abstract:

This study examined the contribution of thirty-six factors to building construction project’s cost overrun in Jordan. A questionnaire was distributed to a random sample of 350 stakeholders comprised of owners, consultants, and contractors, of which 285 responded. SPSS analysis was conducted to identify the top five causes of cost overrun, which were a large number of variation orders, inadequate quantities provided in the contract, misunderstanding of the project plan, incomplete bid documents, and choosing the lowest price in the contract bidding. There was an agreement among the study participants in ranking the factors contributing to cost overrun, which indicated that these factors were very commonly encountered in most construction projects in Jordan. Thus, it is crucial to enhance the collaboration among the different project stakeholders to understand the project’s objectives and set a realistic plan that takes into consideration all the factors that might influence the project cost, which might eventually prevent cost overrun.

Keywords: cost, overrun, building construction projects, Jordan

Procedia PDF Downloads 108

Authors: Puti F. Marzuki, Adrianto Oktavianus, Almerinda Regina

Abstract:

Interface problems among interacting parties in Indonesian construction projects have most often led to low productivity and completion delay. In the midst of this country’s needs to accelerate construction of public infrastructure providing connectivity among regions and supporting economic growth as well as better living quality, project delays have to be seriously addressed. This paper identifies potential causes factors of interface problems experienced by construction projects in Indonesia. Data are collected through a survey involving the main actors of six important public infrastructure construction projects including railway, LRT, sports stadiums, apartment, and education building construction projects. Five of these projects adopt the design-build project delivery method and one applies the design-bid-build scheme. Interface problems’ potential causes are categorized into contract, management, technical experience, coordination, financial, and environmental factors. Research results reveal that, especially in railway and LRT projects, potential causes of interface problems are mainly technical and managerial in nature. These relate to complex construction execution in highly congested areas. Meanwhile, coordination cause factors are mainly found in the education building construction project with loan from a foreign donor. All of the six projects have to resolve interface problems caused by incomplete or low-quality contract documents. This research also shows that the design-bid-build delivery method involving more parties in construction projects tends to induce more interface problem cause factors than the design-build scheme.

Keywords: cause factors, construction delays, project delivery method, contract documents

Procedia PDF Downloads 255

Authors: W. T. A. Mohammed, M. Eltaeb, R. Kashani

Abstract:

The first bending modes of tall asymmetric structures in the two lateral X and Y-directions have two different natural frequencies. To add tuned damping to these bending modes, one needs to either a) use two pendulum-tuned mass dampers (PTMDs) with one tuning frequency, each PTMD targeting one of the bending modes, or b) use one PTMD with two tuning frequencies (one in each lateral directions). Option (a), being more massive, requiring more space, and being more expensive, is less attractive than option (b). Considering that the tuning frequency of a pendulum depends mainly on the pendulum length, one way of realizing option (b) is by constraining the swinging length of the pendulum in one direction but not in the other; such PTMD is dubbed passive Bi-PTMD. Alternatively, option (b) can be realized by actively setting the tuning frequencies of the PTMD in the two directions. In this work, accurate physical models of passive Bi-PTMD and active PTMD are developed and incorporated into the numerical model of a tall asymmetric structure. The model of PTMDs plus structure is used for a)synthesizing such PTMDs for particular applications and b)evaluating their damping effectiveness in mitigating the dynamic lateral responses of their target asymmetric structures, perturbed by wind load in X and Y-directions. Depending on how elaborate the control scheme is, the active PTMD can either be made to yield the same damping effectiveness as the passive Bi-PTMD of the same size or the passive Bi-TMD twice as massive as the active PTMD.

Keywords: active tuned mass damper, high-rise building, multi-frequency tuning, vibration control

Procedia PDF Downloads 105

Authors: Abraham Castro-Alvarez, Luisaldo Sandate-Flores, Roberto Parra-Saldivar

Abstract:

The losing of crops during the whole production process is a problem that is affecting farmers in the whole world, as climate change affects the weather behavior. Stenocereus spp. is a tropical, exotic and endemic columnar cacti, it produces a colored and expensive fruit known how “pitaya”. The quality and value of the fruit, these species represent an attractive option for economical development in arid and semi-arid regions. This fruits are produced in Mexico, mainly in 4 regions, Mixteca Oaxaca-Puebla, Michoacan, Sinaloa-Sonora, Jalisco-Zacatecas. Pitaya can be an option to try mixed crop in this states due to the resistance to hard weather conditions. And also because of the marginalization problems that exist in these townships. As defined by the Population National Council it consists in the absence of development opportunities and the lack of capacity to get them. According to an analysis done in EsriPress ArcGis 10.1 the potential area in the country is almost the half of the territory being the total area of Mexico 1,965,249 km2 and the area with potential to produce pitaya 960,527 km2. This area covers part of the most affected townships that also have a few options of maize varieties making even harder the production of maize and exposing farmers to crop losing if conditions are good enough. Making pitaya a good option for these farmers to have an economic backup in their productions.

Keywords: maize, pitaya, rain fed, Stenocereus

Procedia PDF Downloads 318

Authors: Aliana Leong, T. C. Huan

Abstract:

The purpose of Nostalgic themed tourism product is becoming popular in many countries. This study intends to investigate the role of nostalgia in destination image, experiential value and their effect on subsequent behavioral intention. The survey used stratified sampling method to include respondents from all the nearby Asian regions. The sampling is based on the data of inbound tourists provided by the Statistics and Census Service (DSEC) of government of Macau. The questionnaire consisted of five sections of 5 point Likert scale questions: (1) nostalgia, (2) destination image both before and after experience, (3) expected value, (4) experiential value, and (5) future visit intention. Data was analysed with structural equation modelling. The result indicates that nostalgia plays an important part in forming destination image and experiential value before individual had a chance to experience the destination. The destination image and experiential value share a bidirectional causal relationship that eventually contributes to future visit intention. The study also discovered that while experiential value is more effective in generating destination image, the later contribute more to future visit intention. The research design measures destination image and experiential value before and after respondents had experience the destination. The distinction between destination image and expected/experiential value can be examined because the longitudinal design of research method. It also allows this study to observe how nostalgia translates to future visit intention.

Keywords: nostalgia, destination image, experiential value, future visit intention

Procedia PDF Downloads 390

Authors: Olga C. Rodrigue

Abstract:

Long-term care and skilled nursing facilities experience ebbs and flows of nursing staffing, a problem compounded by the perception of the facilities as undesirable workplaces and competition for staff from other healthcare entities. Travel nurses are contracted to fill staffing needs due to increased admissions, increased and unexpected attrition of nurses, or facility expansion of services. Prior to beginning the contracted assignment, the travel nurse must meet industry, company, and regulatory requirements (The Joint Commission and CMS) for skills and knowledge. Travel nurses, however, inconsistently receive the pre-assignment orientation needed to work at the contracted facility, if any information is given at all. When performance expectations are not met, travel nurses may subsequently choose to leave the position without completing the terms of the contract, and some facilities may choose to terminate the contract prior to the expected end date. The overarching goal of the Doctor of Nursing Practice evidence-based practice improvement project is to provide travel nurses with the basic and necessary information to prepare them to begin a long-term and skilled nursing assignment. The project involves the identification of travel nurse learning needs through a survey and the development and provision of web-based learning modules to address those needs prior to arrival for a long-term and skilled nursing assignment.

Keywords: nurse staffing, travel nurse, travel staff, contract staff, contracted assignment, long-term care, skilled nursing, onboarding, orientation, staff development, supplemental staff

Procedia PDF Downloads 168

Authors: Christian Liebchen

Abstract:

Both from an environmental perspective and with respect to road traffic flow quality, planning so-called green waves along major road axes is a well-established target for traffic engineers. For one-way road axes (e.g. the Avenues in Manhattan), this is a trivial downstream task. For bidirectional arterials, the well-known necessary condition for establishing a green wave in both directions is that the driving times between two subsequent crossings must be an integer multiple of half of the cycle time of the signal programs at the nodes. In this paper, we propose an integer linear optimization model to establish fixed-time green waves in both directions that are as long and as wide as possible, even in the situation where the driving time condition is not fulfilled. In particular, we are considering an arterial along whose nodes separate left-turn signal groups are realized. In our computational results, we show that scheduling left-turn phases before or after the straight phases can reduce waiting times along the arterial. Moreover, we show that there is always a solution with green waves in both directions that are as long and as wide as possible, where absolute priority is put on just one direction. Compared to optimizing both directions together, establishing an ideal green wave into one direction can only provide suboptimal quality when considering prioritized parts of a green band (e.g., first few seconds).

Keywords: traffic light coordination, synchronization, phase sequencing, green waves, integer programming

Procedia PDF Downloads 117

Authors: Yue Meng, Lingyun Wei

Abstract:

In this paper, the coordination problem of a supply chain system composed of multiple retailers and manufacturers is studied under the background of the new retail supply chain. Taking a system composed of two retailers and one manufacturer as an example, this paper introduces an online store owned by the manufacturer to reflect the characteristics of the combination of online and offline new retail. Then, this paper gives the conditions that need to be satisfied to realize the coordination between retailers and manufacturers, such as the revenue sharing coefficient. The supply chain coordination model is compared with the newsboy model through a specific example. Finally, the conclusion is drawn that the profits of the coordinated supply chain and its members are better than the corresponding profits under the newsboy model; that is, the coordination of the supply chain is realized by using the revenue sharing contract and the transshipment fund mechanism.

Keywords: transshipment, coordination, multi-retailer, revenue-sharing contract

Procedia PDF Downloads 143

Authors: Xiu Zhang

Abstract:

The Merchant of Venice focuses on identity anxiety through the contract of “a pound of flesh” and refers to the economic, legal and religious issues related to identity. The development of the emerging capitalist economy in Venetian society prompted Shylock to become a usurer. The social identity of Shylock’s lender enabled him to use the power of money to consolidate the interdependent relationship with Christians and strive for his position and living space in Venetian society. However, there have long been economical and religious conflicts between Jews and Christians. Therefore, in order to take vengeance on Antonio and take his life, so as to revenge the whole Christian society, Shylock insists on taking a pound of Antonio’s flesh in the name of abiding by the contract and the law. The choice of “a pound of flesh” is essentially the representation of human materialization and commercialization under the background of the rise of capitalism and economic transformation. At the same time, it also symbolizes Shylock’s efforts and attempts to reshape himself and his racial identity.

Keywords: merchant of Venice, ethical choices, Shylock, a pound of flesh, identity anxiety

Procedia PDF Downloads 141

Authors: Young Yoon, Jinsoo Kim

Abstract:

The adoption of information and communication technologies (ICT) in all industry is growing under industry 4.0. Many oil companies also are increasingly adopting ICT to improve the efficiency of existing operations, take more accurate and quicker decision making and reduce entire cost by optimization. It is true that ICT is playing an important role in the process of unconventional oil and gas development and companies must take advantage of ICT to gain competitive advantage. In this study, real option approach has been applied to Unconventional gas R&D project to evaluate ICT of them. Many unconventional gas reserves such as shale gas and coal-bed methane(CBM) has developed due to technological improvement and high energy price. There are many uncertainties in unconventional development on the three stage(Exploration, Development, Production). The traditional quantitative benefits-cost method, such as net present value(NPV) is not sufficient for capturing ICT value. We attempted to evaluate the ICT valuation by applying the compound option model; the model is applied to real CBM project case, showing how it consider uncertainties. Variables are treated as uncertain and a Monte Carlo simulation is performed to consider variables effect. Acknowledgement—This work was supported by the Energy Efficiency & Resources Core Technology Program of the Korea Institute of Energy Technology Evaluation and Planning (KETEP) granted financial resource from the Ministry of Trade, Industry & Energy, Republic of Korea (No. 20152510101880) and by the National Research Foundation of Korea Grant funded by the Korean Government (NRF-205S1A3A2046684).

Keywords: information and communication technologies, R&D, real option, unconventional gas

Procedia PDF Downloads 229

Authors: Salah Alrabeei, Mohammad Yousuf

Abstract:

The goal of option pricing theory is to help the investors to manage their money, enhance returns and control their financial future by theoretically valuing their options. However, most of the option pricing models have no analytical solution. Furthermore, not all the numerical methods are efficient to solve these models because they have nonsmoothing payoffs or discontinuous derivatives at the exercise price. In this paper, we solve the American option under jump diffusion models by using efficient time-dependent numerical methods. several techniques are integrated to reduced the overcome the computational complexity. Fast Fourier Transform (FFT) algorithm is used as a matrix-vector multiplication solver, which reduces the complexity from O(M2) into O(M logM). Partial fraction decomposition technique is applied to rational approximation schemes to overcome the complexity of inverting polynomial of matrices. The proposed method is easy to implement on serial or parallel versions. Numerical results are presented to prove the accuracy and efficiency of the proposed method.

Keywords: integral differential equations, jump–diffusion model, American options, rational approximation

Procedia PDF Downloads 120

Authors: Shahin Zanbaghi, Saeed Samet

Abstract:

The internet has transformed the way we shop. Previously, most of our purchases came in the form of shopping trips to a nearby store. Now, it’s as easy as clicking a mouse. But with great convenience comes great responsibility. We have to be constantly vigilant about our personal information. In this work, our proposed approach is to encrypt the information printed on the physical packages, which include personal information in plain text, using a symmetric encryption algorithm; then, we store that encrypted information into a Blockchain network rather than storing them in companies or corporations centralized databases. We present, implement and assess a blockchain-based system using Ethereum smart contracts. We present detailed algorithms that explain the details of our smart contract. We present the security, cost, and performance analysis of the proposed method. Our work indicates that the proposed solution is economically attainable and provides data integrity, security, transparency, and data traceability.

Keywords: blockchain, Ethereum, smart contract, commit-reveal scheme

Procedia PDF Downloads 150

Authors: Fatin Fadhilah Hasib, Puji Sucia Sukmaningrum, Imron Mawardi, Achsania Hendratmi

Abstract:

Murabaha is the most popular contract by the Islamic banks in Indonesia, since there is opinion stating that the risk level of mudharaba and musyaraka are higher and the return is uncertain. This research aims to analyze the difference of return, risk, and variation coefficient between profit sharing-based and trading-based financing in Islamic bank. This research uses quantitative approach using Wilcoxon signed rank test with data sampled from 13 Indonesian Islamic banks, collected from their quarterly financial reports from 2011 to 2015. The result shows the significant difference in return, while risk and variation coefficient are almost same. From the analysis, it can be concluded that profit sharing-based financing is less desirable not because of its risk. Trading-based financing is more desirable than the profit sharing because of its return.

Keywords: financing, Islamic bank, return, risk

Procedia PDF Downloads 378

Authors: Aaron Huber, Manoj Karwa

Abstract:

Floods, heat waves, drought, wildfires, tornadoes and other environmental disasters are a snapshot of looming national problems that can create increasing demands on the national grid. With nearly 500,000 school buses on the road and the environmental protection agency (EPA) providing nearly $1B for electric school buses, there is a solution for this national issue. Bidirectional batteries in electric school buses enable a future proof solution to sustain the power grid during adverse environmental conditions and other periods of high demand. School buses have larger batteries than standard electric vehicles. When they are not transporting students, these buses can spend peak solar hours parked and plugged into bi-directional direct current fast chargers (DCFC). A partnership with Highland Electric, Proterra and Rhombus enabled over 7 MWh of energy servicing Massachusetts and Vermont grids. The buses were part of a vehicle to grid (V2G) program with National Grid and Green Mountain Power that can charge an average American home for one month with a single bus. V2G infrastructure enables school systems to future proof their charging strategies, strengthen their local grids and can create additional revenue streams with their EV fleets. A bidirectional ecosystem with Highland, Proterra and Rhombus can enable grid resiliency or the ability to withstand power outages caused by excessive demands, natural disasters or rogue nation's attacks with no loss of service. A fleet of school buses is a standalone resilient asset that can be accessed across a city to keep its citizens safe without having any toxic fumes. Nearly 95% of all school buses across USA are powered by diesel internal combustion engines. Diesel exhaust has been classified as a human carcinogen, and it can lead to and exacerbate respiratory conditions. Bidirectional school buses and chargers enable energy justice by providing backup power in case of emergencies or high demand for marginalized communities and aim to make energy more accessible, affordable, clean, and democratically managed.

Keywords: V2G, vehicle to grid, electric buses, eBuses, DC fast chargers, DCFC

Procedia PDF Downloads 77

Authors: Hongbin Yang, Mingxue Liao, Changwen Zheng, Mengyao Kong, Chaohui Liu

Abstract:

Microfacet-based reflection models are widely used to model light reflections for rough surfaces. Microfacet models have become the standard surface material building block for describing specular components with varying roughness; and yet, while they possess many desirable properties as well as produce convincing results, their design ignores important sources of scattering, which can cause a significant loss of energy. Specifically, they only simulate the single scattering on the microfacets and ignore the subsequent interactions. As the roughness increases, the interaction will become more and more important. So a multiple-scattering microfacet model based on specular V-cavity is presented for this important open problem. However, it spends much unnecessary rendering time because of setting the same number of scatterings for different roughness surfaces. In this paper, we design a geometric attenuation term G to compute the BRDF (Bidirectional reflection distribution function) of multiple scattering of rough surfaces. Moreover, we consider determining the number of scattering by deterministic heuristics for different roughness surfaces. As a result, our model produces a similar appearance of the objects with the state of the art model with significantly improved rendering efficiency. Finally, we derive a multiple scattering BRDF based on the original microfacet framework.

Keywords: bidirectional reflection distribution function, BRDF, geometric attenuation term, multiple scattering, V-cavity model

Procedia PDF Downloads 116

Authors: Nadine Rashed, A. Samer Ezeldin, Engy Serag

Abstract:

The principle of good faith plays a critical role in shaping contractual relationships, yet its application varies significantly across different types of construction contracts and legal systems. This paper presents a comparative analysis of how various construction contracts perceive the principle of good faith, a fundamental aspect that influences contractual relationships and project outcomes. The primary objective of this analysis is to examine the differences in the application and interpretation of good faith across key construction contracts, including JCT (Joint Contracts Tribunal), FIDIC (Fédération Internationale des Ingénieurs-Conseils), NEC (New Engineering Contract), and ICE (Institution of Civil Engineers) Contracts. To accomplish this, a mixed-methods approach will be employed, integrating a thorough literature review of current legal frameworks and academic publications with primary data gathered from a structured questionnaire aimed at industry professionals such as contract managers, legal advisors, and project stakeholders. This combined strategy will enable a holistic understanding of the theoretical foundations of good faith in construction contracts and its practical effects in real-world contexts. The findings of this analysis are expected to yield valuable insights into how varying interpretations of good faith can impact project performance, dispute resolution, and collaborative practices within the construction industry. This paper contributes to a deeper understanding of how the principle of good faith is evolving in the construction industry, providing insights for contract drafters, legal practitioners, and project managers seeking to navigate the complexities of contractual obligations across different legal systems.

Keywords: construction contracts, contractual obligations, ethical practices, good faith

Procedia PDF Downloads 22

Authors: Mhd. Zakiul Fikri, M. Agus Maulidi

Abstract:

Indonesia is a constitutional state. As the constitutional state, Indonesia is not only using a single legal system, but also adopting three legal systems consist of: The European continental legal system or positive law of Indonesia, adat law system, and legal system of religion. This study will discuss Marosok tradition in the process of buying and selling cattle in Payakumbuh: a comparative study between adat law and positive law of Indonesia. The objectives of this research are: First, to find the meaning of the philosophical of Marosok tradition in Payakumbuh. Second, to find the legal implications of the Marosok tradition reviewed aspects of adat law and positive law of Indonesia. Third, to find legal procedure in arbitrating the dispute wich is potentially appear in the post-process of buying and selling cattle based on positive law and adat law adopted in Indonesia. This research is empirical legal research that using two model approaches which are statute approach and conceptual approach. Data was obtained through interviews, observations, and documents or books. Then a method of data analysis used is inductive analysis. Finally, this study found that: First, tradition of Marosok contains the meaning of harmonization of social life that keep people from negative debate, envy, and arrogant. Second, Marosok tradition is one of the adat law in Indonesia; it is one of contract law in the process of buying and selling. If the comparison between the practice Marosok tradition as adat law with the provisions of Article 1320 book of civil code about the terms of the validity of a contract, the elements contained in the provisions of these regulations are met in practice Marosok. Thus, the practice of Marosok in buying and selling cattle process in Payakumbuh justified in view of the positive law of Indonesia. Last of all, all kinds of disputes arising due to contracts made by Marosok tradition can be resolved by positive law and adat law of Indonesia.

Keywords: Adat law, contract, Indonesia, Marosok

Procedia PDF Downloads 323

Authors: Antonio Abatemarco, Francesca Stroffolini

Abstract:

In the economic literature, Rawls’ Theory of Justice is usually interpreted in a two-stage setting, where a priority to the worst off individual is imposed as a distributive value judgment. In this paper, instead, we model Rawls’ Theory in a three-stage setting, that is, a separating line is drawn between the original position, the educational stage, and the working life. Hence, in this paper, we challenge the common interpretation of Rawls’ Theory of Justice as Fairness by showing that this Theory goes well beyond the definition of a distributive value judgment, in such a way as to embrace efficiency issues as well. In our model, inequalities are shown to be permitted as far as they stimulate a greater effort in education in the population, and so economic growth. To our knowledge, this is the only possibility for the inequality to be ‘bought’ by both the most-, and above all, the least-advantaged individual as suggested by the Difference Principle. Finally, by recalling the old tradition of ‘universal ex-post efficiency’, we show that a unique optimal social contract does not exist behind the veil of ignorance; more precisely, the sole set of potentially Rawls-optimal social contracts can be identified a priori, and partial justice orderings derived accordingly.

Keywords: justice, Rawls, inequality, social contract

Procedia PDF Downloads 222

Authors: Meshari Aljohani, Stephan Olariu, Ravi Mukkamala

Abstract:

Data is essential for enhancing the quality of life. Its value creates chances for users to profit from data sales and purchases. Users in data marketplaces, however, must share and trade data in a secure and trusted environment while maintaining their privacy. The first main contribution of this paper is to identify enabling technologies and challenges facing the development of decentralized data marketplaces. The second main contribution is to propose a decentralized data marketplace framework based on blockchain technology. The proposed framework enables sellers and buyers to transact with more confidence. Using a security deposit, the system implements a unique approach for enforcing honesty in data exchange among anonymous individuals. Before the transaction is considered complete, the system has a time frame. As a result, users can submit disputes to the arbitrators which will review them and respond with their decision. Use cases are presented to demonstrate how these technologies help data marketplaces handle issues and challenges.

Keywords: blockchain, data, data marketplace, smart contract, reputation system

Procedia PDF Downloads 158