Search results for: construction contract

Authors: Murat Gunduz, Mohanad H. A. AbuHassan

Abstract:

Construction industry mainly focuses on the superstructure, infrastructure, and oil and gas industry. The development of infrastructure projects in developing countries attracted a lot of foreign construction contractors, consultants, suppliers and diversified workforce to interfere and to be evolved in such huge investment. Reducing worksite delays in such projects require knowledge and attention. Therefore, it is important to identify the influencing delay attributes affecting construction projects. The significant project factors affecting construction delays were investigated. Data collection was carried out through an online web survey system to capture significant factors. Significant factors were determined with importance index and relevant recommendations are made. The output of the data analysis would lead the industry experts better assess the impact of construction delays on construction projects.

Keywords: Construction industry, delays, importance index.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2612

Authors: Temidayo. O. Osunsanmi, Clinton Aigbavboa, Ayodeji Oke

Abstract:

The construction industry is a renowned latecomer to the efficiency offered by the adoption of information technology. Whereas, the banking, manufacturing, retailing industries have keyed into the future by using digitization and information technology as a new approach for ensuring competitive gain and efficiency. The construction industry has yet to fully realize similar benefits because the adoption of ICT is still at the infancy stage with a major concentration on the use of software. Thus, this study evaluates the awareness and readiness of construction professionals towards embracing a full digitalization of the construction industry using construction 4.0. The term ‘construction 4.0’ was coined from the industry 4.0 concept which is regarded as the fourth industrial revolution that originated from Germany. A questionnaire was utilized for sourcing data distributed to practicing construction professionals through a convenience sampling method. Using SPSS v24, the hypotheses posed were tested with the Mann Whitney test. The result revealed that there are no differences between the consulting and contracting organizations on the readiness for adopting construction 4.0 concepts in the construction industry. Using factor analysis, the study discovers that adopting construction 4.0 will improve the performance of the construction industry regarding cost and time savings and also create sustainable buildings. In conclusion, the study determined that construction professionals have a low awareness towards construction 4.0 concepts. The study recommends an increase in awareness of construction 4.0 concepts through seminars, workshops and training, while construction professionals should take hold of the benefits of adopting construction 4.0 concepts. The study contributes to the roadmap for the implementation of construction industry 4.0 concepts in the South African construction industry.

Keywords: Building information technology, Construction 4.0, Industry 4.0, Smart Site.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 5653

Authors: Kettawa Boonprakarn, Jedsarid Sangkaphan, Bejapornd Deekhuntod, Nuntharat Suriyo

Abstract:

This study aimed to investigate the existence of field corn networks on the Thailand-Burma border under the patron-client contract farming system. The data of this qualitative study were collected through in-depth interviews with nine key informants.

The results of the study revealed that the existence of the field corn networks was associated with the relationship where farmers had to share their crops with protectors in the areas under the influence of the KNU (Karen National Union) and the DKBA (Democratic Karen Buddhist Army) or Burmese soldiers. A Mae Liang, the person who starts a network has a connection with a Thaokae, Luk Rai Hua Chai or the head of a group of farmers, and farmers. They are under the patron-client system with trust and loyalty that enable the head of the group and the farmers in the Burma border side to remain under the same Mae Liang even though the business has been passed down to later generations.

Keywords: Existence, field-corn networks, patron-client system, contract farming.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1687

Authors: Aussadavut Dumrongsiri

Abstract:

Westudy a dual-channel supply chain under decentralized setting in which manufacturer sells to retailer and to customers directly usingan online channel. A customer chooses the purchase-channel based on price and service quality. Also, to buy product from the retail store, the customer incurs a transportation cost influenced by the fluctuating gasoline cost. Both companies are under the revenue sharing contract. In this contract the retailer share a portion of the revenue to the manufacturer while the manufacturer will charge the lower wholesales price. The numerical result shows that the effects of gasoline costs, the revenue sharing ratio and the wholesale price play an important role in determining optimal prices. The result shows that when the gasoline price fluctuatesthe optimal on-line priceis relatively stable while the optimal retail price moves in the opposite direction of the gasoline prices.

Keywords: direct-channel, e-business, pricing model, dualchannel supply chain, gasoline cost, revenue sharing

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1293

Authors: Nikola Karanovic, Aleksandar Djuric

Abstract:

This paper introduces a method of calculating the quantities of construction materials and construction waste on site in city of Novi Sad. In buildings is about 40% of the total weight of materials that are in circulation in the world economic space. The best solution for this waste is to be stored at source, at the point of generation. There are several treatment options for this type of waste, reduction at source, reuse, recycling. Beside its negative effects on the environment, construction waste can be and resource. Novi Sad is divided in 16 single family resident zones and 10 multi family resident zones. For every zone of the city, quantities of used construction materials and construction waste were obtained. Rational use of natural resources is an essential factor in applying the principles of development with savings.

Keywords: Construction materials, Construction waste, Novi Sad, Recycling

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1604

Authors: Vladimira Vytlacilova

Abstract:

Recycling of construction and demolition waste (C&DW) and their new reuse in structures is one of the solutions of environmental problems. Construction and demolition waste creates a major portion of total solid waste production in the world and most of it is used in landfills all the time. The paper deals with the situation of the recycling of the building and demolition waste in the Czech Republic during the recent years. The paper is dealing with questions of C&D waste recycling, it also characterizes construction and demolition waste in general, furthermore it analyses production of construction waste and subsequent production of recycled materials.

Keywords: Recycling, Construction and demolition waste, Recycled rubble, Waste management.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 703

Authors: Hamed Homaei, Iraj Mahdavi, Ali Tajdin

Abstract:

One of the main concerns of miners is to increase the quality level of their products because the mining metals price depends on their quality level; however, increasing the quality level of these products has different costs at different levels of the supply chain. These costs usually increase after extractor level. This paper studies the coordination issue of a decentralized three-level supply chain with one supplier (extractor), one mineral processor and one manufacturer in which the increasing product quality level cost at the processor level is higher than the supplier and at the level of the manufacturer is more than the processor. We identify the optimal product quality level for each supply chain member by designing a revenue sharing contract. Finally, numerical examples show that the designed contract not only increases the final product quality level but also provides a win-win condition for all supply chain members and increases the whole supply chain profit.

Keywords: Three-stage supply chain, product quality improvement, channel coordination, revenue sharing.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1057

Authors: Shaikha AlSanad , Andrew Gale, Rodger Edwards

Abstract:

Buildings and associated construction methods have a significant impact on the environment. As construction activity increases in Kuwait, there is a need to create design and construction strategies which will minimize the environmental impact of new buildings. Green construction is a design philosophy intended to improve the sustainability of construction by the minimization of resource depletion and CO2 emissions throughout the life cycle of buildings. This paper presents and discusses the results of a survey that was conducted in Kuwait, with the objective of investigating the awareness of developers and other stakeholders regarding their understanding and use of green construction strategies. The results of the survey demonstrate that whilst there seems to be a reasonable level of awareness amongst the stakeholders, this awareness is not currently well reflected in the design and construction practices actually being applied. It is therefore concluded is there is a pressing need for intervention from Government in order that the use of sustainable green design and construction strategies becomes the norm in Kuwait.

Keywords: Sustainability, Sustainable construction, Green Building, Environmental assessment

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 3052

Authors: Thandokazi Nyangiwe, Christopher Amoah, Charles P. Mukumba

Abstract:

The South African construction sector is threatened by emerging black business forums called construction mafias. The emergence of the construction mafia has culminated in the disruptions and abandonment of construction sites resulting in the loss of jobs for construction workers. The paper examines the origin of construction mafias and their impact on the construction sector, including the potential ways to cope with their operations. A qualitative research approach was adopted for this study using open-ended interview questions to gather information from 30 key construction industry stakeholders, including contractors, subcontractors, consultants, and the construction project communities. Content and thematic analyses were used to analyses the data collected. The findings suggest that most participants do not fully understand the existence and operations of construction mafias in the construction industry. Construction mafias claim to be part of the local business forums. They disrupt construction projects and demand a certain amount, usually 30% of the construction value. Construction mafias frequently resort to intimidation and violence if their demands are unmet. Their operations have resulted in delayed completion of construction projects, abandonment of projects, and loss of income for the contractor and jobs for the construction workers. The interviews were limited to construction stakeholders. Because of the nature of the mafias’ operations, they could not be accessed for interviews for fear of being identified because of the connotation attached to their role as construction mafias. Construction project owners face disruptions of projects resulting in loss of equipment, materials, and income. Therefore, there is a need to sensitize the construction stakeholders in the construction industry regarding the existence and operations of the construction mafia and the implications on construction project performance and delivery. The findings will give insight into the operations of the construction mafias in the South African construction industry, which has caused disruptions in construction project sites. Stakeholders must find solutions to address the construction mafias’ disruptive actions on construction projects. The study presents an initial inquiry that will come up with how to manage and cope with the growing operations of construction mafias in the South African construction industry.

Keywords: Black business forums, construction mafia, South African construction industry.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 153

Authors: Jolanta Tamošaitienė

Abstract:

The article focuses on a developed comprehensive model to be used in an agile environment for the risk assessment and selection based on multi-attribute methods. The model is based on a multi-attribute evaluation of risk in construction, and the determination of their optimality criterion values are calculated using complex Multiple Criteria Decision-Making methods. The model may be further applied to risk assessment in an agile construction environment. The attributes of risk in a construction project are selected by applying the risk assessment condition to the construction sector, and the construction process efficiency in the construction industry accounts for the agile environment. The paper presents the comprehensive risk assessment model in an agile construction environment. It provides a background and a description of the proposed model and the developed analysis of the comprehensive risk assessment model in an agile construction environment with the criteria.

Keywords: Assessment, environment, agile, model, risk.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1029

Authors: V. K. Bansal

Abstract:

Geographic Information System (GIS) is a computerbased tool used extensively to solve various engineering problems related to spatial data. In spite of growing popularity of GIS, its complete potential to construction industry has not been realized. In this paper, the summary of up-to-date work on spatial applications of GIS technologies in construction industry is presented. GIS technologies have the potential to solve space related problems of construction industry involving complex visualization, integration of information, route planning, E-commerce, cost estimation, etc. GISbased methodology to handle time and space issues of construction projects scheduling is developed and discussed in this paper.

Keywords: Construction, GIS in construction, Scheduling, Project Management.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2617

Authors: S. R. Shamili, J. Karthikeyan

Abstract:

Fast development of the total populace and far and wide urbanization has surprisingly expanded the advancement of the construction industry. As a result of these activities, old structures are being demolished to make new buildings. Due to these large-scale demolitions, a huge amount of debris is generated all over the world, which results in a landfill. The use of construction and demolition waste as landfill causes groundwater contamination, which is hazardous. Using construction and demolition waste as aggregate can reduce the use of natural aggregates and the problem of mining. The objective of this study is to provide a detailed overview on how the construction and demolition waste material has been used as aggregate in structural concrete. In this study, the preparation, classification, and composition of construction and demolition wastes are also discussed.

Keywords: Aggregate, construction and demolition waste, landfill, large scale demolition.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 569

Authors: Zhankuliyeva S. A.

Abstract:

This article considers the main features of party construction in the course of political modernization of Kazakhstan. Along with consideration of party construction author analyzed how the transformation of the party system was fulfilled in Kazakhstan. Besides the basic stages in the course of party construction were explained by the author. The statistical data is cited.

Keywords: elections, multi-party system, party construction, political pluralism, political party, Republic of Kazakhstan (RK)

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1498

Authors: Hafiz Usama Imad, Muhammad Akram Akhund, Tauha Hussain Ali, Ali Raza Khoso, Fida Hussain Siddiqui

Abstract:

Construction industry plays a significant role in fulfilling the major requirements of the human being. It is one of the major constituents of every developed country. Although the construction industry of both the developing and developed countries encompasses a major part of the economy, and millions of rupees are utilized every year on various kinds of construction projects. But, this industry is facing numerous hurdles in terms of its budget and timely completion. Construction projects generally consist of several phases like planning, designing, execution, and finishing. This research study aims to determine the significant factors of time overrun in pre-construction planning (PCP) phase of construction projects in Pakistan. Questionnaires were distributed by various means and responses of respondents were compiled and collected data were then analyzed through a statistical technique using SPSS version 24. Major causes of time overrun in pre-construction planning phase; which is an extremely important phase of construction projects, were revealed. The research conclusion will provide a pathway for stakeholders to pay attention to the mentioned causes to overcome the major issue of time overrun.

Keywords: Construction industry, Pakistan, pre-construction planning phase, time overrun.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 907

Authors: Rawan A. Abdelrazeq, Ahmed M. Khalafallah, Nabil A. Kartam

Abstract:

Selection of competent contractors for construction projects is usually accomplished through competitive bidding or negotiated contracting in which the contract bid price is the basic criterion for selection. The evaluation of contractor’s safety performance is still not a typical criterion in the selection process, despite the existence of various safety prequalification procedures. There is a critical need for practical and automated systems that enable owners and decision makers to evaluate contractor safety performance, among other important contractor selection criteria. These systems should ultimately favor safety-conscious contractors to be selected by the virtue of their past good safety records and current safety programs. This paper presents an exploratory sequential mixed-methods approach to develop a framework for an automated decision support system that evaluates contractor safety performance based on a multitude of indicators and metrics that have been identified through a comprehensive review of construction safety research, and a survey distributed to domain experts. The framework is developed in three phases: (1) determining the indicators that depict contractor current and past safety performance; (2) soliciting input from construction safety experts regarding the identified indicators, their metrics, and relative significance; and (3) designing a decision support system using relational database models to integrate the identified indicators and metrics into a system that assesses and rates the safety performance of contractors. The proposed automated system is expected to hold several advantages including: (1) reducing the likelihood of selecting contractors with poor safety records; (2) enhancing the odds of completing the project safely; and (3) encouraging contractors to exert more efforts to improve their safety performance and practices in order to increase their bid winning opportunities which can lead to significant safety improvements in the construction industry. This should prove useful to decision makers and researchers, alike, and should help improve the safety record of the construction industry.

Keywords: Construction safety, contractor selection, decision support system, relational database.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1549

Authors: Sunaitan Al Mutairi

Abstract:

A perfect start is a key factor for project completion on time. The study examined the effects of delayed mobilization of resources during the initial phases of the project. This paper mainly highlights the identification and categorization of all delays during the initial construction phase and their root cause analysis with corrective/control measures for the Kuwait Oil Company oil and gas projects. A relatively good percentage of the delays identified during the project execution (Contract award to end of defects liability period) attributed to mobilization/preliminary activity delays. Data analysis demonstrated significant increase in average project delay during the last five years compared to the previous period. Contractors had delays/issues during the initial phase, which resulted in slippages and progressively increased, resulting in time and cost overrun. Delays/issues not mitigated on time during the initial phase had very high impact on project completion. Data analysis of the delays for the past five years was carried out using trend chart, scatter plot, process map, box plot, relative importance index and Pareto chart. Construction of any project inside the Gathering Centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. Delay affects completion of projects and compromises quality, schedule and budget of project deliverables. Works executed as per plan during the initial phase and start-up duration of the project construction activities resulted in minor slippages/delays in project completion. In addition, there was a good working environment between client and contractor resulting in better project execution and management. Mainly, the contractor was on the front foot in the execution of projects, which had minimum/no delays during the initial and construction period. Hence, having a perfect start during the initial construction phase shall have a positive influence on the project success. Our research paper studies each type of delay with some real example supported by statistic results and suggests mitigation measures. Detailed analysis carried out with all stakeholders based on impact and occurrence of delays to have a practical and effective outcome to mitigate the delays. The key to improvement is to have proper control measures and periodic evaluation/audit to ensure implementation of the mitigation measures. The focus of this research is to reduce the delays encountered during the initial construction phase of the project life cycle.

Keywords: Construction activities delays, delay analysis for construction projects, mobilization delays, oil and gas projects delays.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1798

Authors: Faisal Alazzaz, Andrew Whyte

Abstract:

Off-site construction methods have played an important role in the construction sector in the past few decades. It is increasingly becoming a major alternative technique and strategic direction compared to traditional in-situ method. It produces a significant amount of value for the construction industry and the economy more generally. To date, an impressive number of studies have been lunched on the perceived perception of off-site construction. However, it seems that a quantifying benefit on the offsite construction area is lacking. Therefore, this paper examines the recent research literature on the benefits of off- site construction and provides future direction. In the beginning, this paper provides a brief history and current value of the off-site construction followed by a detailed discussion on the benefit of off-site construction. These benefits include but not limited to time saving, quality improvement, relieving skills shortages, cost reduction and productivity improvement. Toward this end, off-site construction should learn from other productive industry similar to services or manufacturing industry by applying operational management tools and techniques with extensive focus on employee empowerment will shed the light on future uptake of Off-site construction. This study is of value in providing scholars have a clear picture of perceived benefit of off-site construction research and give an opportunities for future uptake of off-site method.

Keywords: Building projects, Employer empowerment, Off-site construction benefits, Productivity.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 5353

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: Construction, delay factors, time delay, Australian construction industry.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1131

Authors: A.Marisa, Nor'Aini Yusof

Abstract:

Managers as the key employees have a very important role in maintaining the workforce performance which is critical to the construction companies- success in the future. If motivated employees start with motivated managers probably it would seem plausible if the de-motivated ones start with de-motivated managers. This study aims to analyze the importance of motivated managers to their successes and construction companies- successes. In this study, a quantitative method was used and the study area was in Medan, North Sumatera. Questionnaire survey was distributed directly to construction companies in Medan which are listed in the Construction Services Development Board. A total of 60 managers responded and the completed questionnaires were analyzed using the descriptive analysis. The results indicated that the respondents acknowledge the importance of motivation among themselves to the projects and construction companies- success, implying that it is vital to maintain the motivation and good performance of the workforce.

Keywords: construction companies, managers, motivation

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2324

Authors: Preeda Sansakorn, Min An

Abstract:

In order to be capable of dealing with uncertainties, subjectivities, including vagueness arising in building construction projects, the application of fuzzy reasoning technique based on fuzzy set theory is proposed. This study contributes significantly to the development of a fuzzy reasoning safety risk assessment model for building construction projects that could be employed to assess the risk magnitude of each hazardous event identified during construction, and a third parameter of probability of consequence is incorporated in the model. By using the proposed safety risk analysis methodology, more reliable and less ambiguities, which provide the safety risk management project team for decision-making purposes.

Keywords: Safety risks assessment, building construction safety, fuzzy reasoning, construction risk assessment model, building construction projects.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2283

Authors: Matthew O. Ikuabe, Ayodeji E. Oke, Clinton O. Aigbavboa, Douglas O. Aghimien, Tshepo P. Mokori

Abstract:

The use of technological innovations has been touted to be beneficial in the delivery of construction projects. Particularly, Radio Frequency Identification (RFID) technology is widely regarded to be of immense advantage for the management of construction projects. This study focused on evaluating the barriers to the use of RFID technology for the delivery of construction projects. Using Gauteng Province in South Africa as the study area, questionnaire was used in eliciting responses from construction professionals which made up the population of the study. Retrieved data were analyzed using Mean Item Score and One-Sample t-test. Findings from the study showed that the most significant barriers to the deployment of RFID for construction project delivery are high cost and lack of awareness. Conclusively, the study made recommendations that would aid in the abatement of the barriers to the use of RFID technology for construction project delivery.

Keywords: Barriers, construction, project delivery, RFID.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 400

Authors: Rami Darwish

Abstract:

The transport industry is transitioning to sustainable industrial systems to meet its environmental targets. At the heart of this transition lies the electrification of bus systems, which involves the introduction and testing of sustainable technologies in protected environments for customer evaluation. While the transition necessitates business-model innovation, practical implementation has proven to be complex. This article delves into efforts to present the business model of a bus operator engaged in public procurement with the goal of facilitating the industry's shift towards electrification. Through an in-depth case study, the influence of public contracts’ design on the evolution of a technology and the operator's business model for electrification is explored. While the extant literature suggests that public procurement can facilitate business-model innovation and sustainable development, the findings reveal that public-contract design can limit value creation and value capture in potential business models, locking organizations into existing business models and hindering the socio-technical transition to sustainability. Interestingly, public-procurement contract design can play a pivotal role in preventing sustainable innovations from breaking through. This highlights the importance of contract design as a vehicle for dialogue between businesses and authorities that can enable systemic change. The case study also illuminates a paradoxical scenario in which the transport authority was required to reconcile the efficiency and stability required for bus transport with the potential benefits of electrification technologies promising sustainability. Finally, recommendations for navigating and addressing this tension are provided. The implications of these findings extend to the literature on discontinuous innovation and business-model innovation.

Keywords: Sustainable transition, public procurement, business-model innovation, discontinuous innovation, lock-in.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 76

Authors: Johnson Adafin, James O. B. Rotimi, Suzanne Wilkinson, Abimbola O. Windapo

Abstract:

An aspect of client expenditure management that requires attention is the level of accuracy achievable in design-stage elemental cost planning. This has been a major concern for construction clients and practitioners in New Zealand (NZ). Pre-tender estimating inaccuracies are significantly influenced by the level of risk information available to estimators. Proper cost planning activities should ensure the production of a project’s likely construction costs (initial and final), and subsequent cost control activities should prevent unpleasant consequences of cost overruns, disputes and project abandonment. If risks were properly identified and priced at the design stage, observed variance between design-stage elemental cost plans (ECPs) and final tender sums (FTS) (initial contract sums) could be reduced. This study investigates the variations between design-stage ECPs and FTS of construction projects, with a view to identifying risk factors that are responsible for the observed variance. Data were sourced through interviews, and risk factors were identified by using thematic analysis. Access was obtained to project files from the records of study participants (consultant quantity surveyors), and document analysis was employed in complementing the responses from the interviews. Study findings revealed the discrepancies between ECPs and FTS in the region of -14% and +16%. It is opined in this study that the identified risk factors were responsible for the variability observed. The values obtained from the analysis would enable greater accuracy in the forecast of FTS by Quantity Surveyors. Further, whilst inherent risks in construction project developments are observed globally, these findings have important ramifications for construction projects by expanding existing knowledge on what is needed for reasonable budgetary performance and successful delivery of construction projects. The findings contribute significantly to the study by providing quantitative confirmation to justify the theoretical conclusions generated in the literature from around the world. This therefore adds to and consolidates existing knowledge.

Keywords: Accuracy, design-stage, elemental cost plan, final tender sum, New Zealand.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1744

Authors: Soo-yeon Seo, Seol-ki Kim, Su-jin Jung

Abstract:

In the construction of a building, it is necessary to minimize construction period and secure enough work space for stacking of materials during the construction especially in city area. In this manner, various top-down construction methods have been developed and widely used in Korea. This paper investigates the stress variation of underground structure of a building constructed by using SPS (Strut as Permanent System) known as a top-down method in Korea through an analytical approach. Various types of earth pressure distribution related to ground condition were considered in the structural analysis of an example structure at each step of the excavation. From the analysis, the most high member force acting on beams was found when the ground type was medium sandy soil and a stress concentration was found in corner area.

Keywords: Construction of building, top-down construction method, earth pressure distribution, member force, stress concentration.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1673

Authors: Stephen C. W. Kong

Abstract:

The use of 3D computer-aided design (CAD) models to support construction project planning has been increasing in the previous year. 3D CAD models reveal more planning ideas by visually showing the construction site environment in different stages of the construction process. Using 3D CAD models together with scheduling software to prepare construction plan can identify errors in process sequence and spatial arrangement, which is vital to the success of a construction project. A number of 4D (3D plus time) CAD tools has been developed and utilized in different construction projects due to the awareness of their importance. Virtual prototyping extends the idea of 4D CAD by integrating more features for simulating real construction process. Virtual prototyping originates from the manufacturing industry where production of products such as cars and airplanes are virtually simulated in computer before they are built in the factory. Virtual prototyping integrates 3D CAD, simulation engine, analysis tools (like structural analysis and collision detection), and knowledgebase to streamline the whole product design and production process. In this paper, we present the application of a virtual prototyping software which has been used in a few construction projects in Hong Kong to support construction project planning. Specifically, the paper presents an implementation of virtual prototyping in a residential building project in Hong Kong. The applicability, difficulties and benefits of construction virtual prototyping are examined based on this project.

Keywords: construction project planning, prefabrication, simulation, virtual prototyping.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2773

Authors: G. Robles, A. Stifi, José L. Ponz-Tienda, S. Gentes

Abstract:

This research paper aims to identify, analyze and rank factors affecting labor productivity in Spain with respect to their relative importance. Using a selected set of 35 factors, a structured questionnaire survey was utilized as the method to collect data from companies. Target population is comprised by a random representative sample of practitioners related with the Spanish construction industry. Findings reveal the top five ranked factors are as follows: (1) shortage or late supply of materials; (2) clarity of the drawings and project documents; (3) clear and daily task assignment; (4) tools or equipment shortages; (5) level of skill and experience of laborers. Additionally, this research also pretends to provide simple and comprehensive recommendations so that they could be implemented by construction managers for an effective management of construction labor forces.

Keywords: Construction management, Factors, Improvement, Labor productivity, Lean construction.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 6907

Authors: A.Marisa, Nor'Aini Yusof

Abstract:

Managers as the key employees have a very important role in maintaining the workforce performance which is critical to the construction companies- success in the future. If motivated employees start with motivated managers probably it would seem plausible if the de-motivated ones start with de-motivated managers. This study aims to analyze the importance of motivated managers to their successes and construction companies- successes. In this study, a quantitative method was used and the study area was in Medan, North Sumatera. Questionnaire survey was distributed directly to construction companies in Medan which are listed in the Construction Services Development Board. A total of 60 managers responded and the completed questionnaires were analyzed using the descriptive analysis. The results indicated that the respondents acknowledge the importance of motivation among themselves to the projects and construction companies- success, implying that it is vital o maintain the motivation and good performance of the workforce.

Keywords: construction companies, managers, motivation

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1663

Authors: Jin Si, Yanzhong Wang

Abstract:

The essence of the 21st century is knowledge economy. Knowledge has become the key resource of economic growth and social development. Construction industry is no exception. Because of the characteristic of complexity, project manager can't depend only on information management. The only way to improve the level of construction project management is to set up a kind of effective knowledge accumulation mechanism. This paper first introduced the IFC standard and the concept of ontology. Then put forward the construction method of the architectural engineering domain ontology based on IFC. And finally build up the concepts, properties and the relationship between the concepts of the ontology. The deficiency of this paper is also pointed out.

Keywords: Construction Engineering, IFC, Ontology

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2064

Authors: Hasan S. Mahmoud, Salwa M. Beheiry, Vian Ahmed

Abstract:

In light of the repercussions of the 2008 global economic crisis, the response of the United Arab Emirates economy and growth, and the vast construction activities that are undergoing, there is a need to investigate the relationship between construction activities and the Gross Domestic Product (GDP). This study aims to investigate the causality relationship between the construction industry in the United Arab Emirates and the GDP of the country in the last decade. For that, this study will investigate the relationship between the growth of the GDP and the growth of construction activities and their value addition to the economy. To ascertain this relationship, Granger Causality method is used to identify the causality between the time-dependent series.

Keywords: Construction value addition, Granger causality, Growth of GDP, UAE.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1217

Authors: Md. Aftabuzzaman, Md. Kamruzzaman

Abstract:

Road-related expenditure and building construction activity are two significant drivers of the Victorian economy. This paper investigates the relationship between building construction activity and road-related expenditure. Data for construction activities were collected from Victorian Building Authority, and road-related expenditure data were explored by the Bureau of Infrastructure and Transport Research Economics. The trend between these two sectors was compared. The analysis found a strong relationship between road-related expenditure and the volume of construction activity, i.e., the more construction activities, the greater the requirement of road-related expenditure, or vice-versa. The road-related expenditure has a two-year lag period, suggesting that the road sector requires two years to respond to the growth in the building sector.

Keywords: Building construction activity, infrastructure, road expenditure, Victorian building authority.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 323