Search results for: main contractors

Authors: E. Kissi, V. K. Acheamfour, J. J. Gyimah, T. Adjei-Kumi

Abstract:

Factoring accounts receivable is widely accepted as an alternative financing source and utilized in almost every industry that sells business-to-business or business-to-government. However, its patronage in the construction industry is very limited as some barriers hinder its application in the construction industry. This study aims at assessing the barriers to the use of factoring accounts receivables in the Ghanaian construction industry. The study adopted the sequential exploratory research method where structured and unstructured questionnaires were conveniently distributed to D1K1 and D2K2 construction firms in Ghana. Using the one-sample t-test and Kendall’s Coefficient of concordance data was analyzed. The most severe challenge concluded is the high cost of factoring patronage. Other critical challenges identified were low knowledge on factoring processes, inadequate access to information on factoring, and high risks involved in factoring. Hence, it is recommended that contractors should be made aware of the prospects of factoring of accounts receivables in the construction industry. This study serves as basis for further rigorous research into factoring of accounts receivables in the industry.

Keywords: barriers, contractors, factoring accounts receivables, Ghanaian, perception

Procedia PDF Downloads 100

Authors: Gor Muradyan

Abstract:

The paper is about friction and wear, including mechanisms, modeling, characterization, measurement and testing case in Bangladesh. Bangladesh is a country under development, A lot of people live here, approximately 145 million. The territory of this country is very small. Therefore buildings are very close to each other. As the pipe lines are very old, and people get almost dirty water, there are a lot of ongoing projects under ADB. In those projects the contractors using HDD machines (Horizontal Directional Drilling ) and grundoburst. These machines are working underground. As ground in Bangladesh is very sludge, machine can't work relevant because of big friction in the soil. When drilling works are finished machine is pulling the pipe underground. Very often the pulling of the pipes becomes very complicated because of the friction. Therefore long section of the pipe laying can’t be done because of a big friction. In that case, additional problems rise, as well as additional work must be done. As we mentioned above it is not possible to do big section of the pipe laying because of big friction in the soil, Because of this it is coming out that contractors must do more joints, more pressure test. It is always connected with additional expenditure and losing time. This machine can pull in 75 mm to 500 mm pipes connected with the soil condition. Length is possible till 500m related how much friction it will had on the puller. As less as much it can pull. Another machine grundoburst is not working at this soil condition at all. The machine is working with air compressor. This machine are using for the smaller diameter pipes, 20 mm to 63 mm. Most of the cases these machines are being used for the installing of the house connection pipes, for making service connection. To make a friction less contractors using bigger pulling had then the pipe. It is taking down the friction, But the problem of this machine is that it can't work at sludge. Because of mentioned reasons the friction has a big mining during this kind of works. There are a lot of ways to reduce the friction. In this paper we'll introduce the ways that we have researched during our practice in Bangladesh.

Keywords: Bangladesh, friction and wear, HDD machines, reducing friction

Procedia PDF Downloads 277

Authors: Abdulkadir Adamu Shehu

Abstract:

Company’s reputation is an elusive asset. The reputation gained by companies must be preserved for sustainability of the company. However, the construction project is still suffering from declination of character due to the factors that affect their reputation. The problem led to the loss of projects, abandoning of the projects and many more. This contributed to negative impact on the contractors in the construction industry. As for today, previous studies have not investigated in this regards yet. For that reason, this paper examines the factors which could promote contractor’s reputation in the construction industry in Nigeria. To achieve this aim, 140 questionnaires were distributed to the Nigerian contractors. Based on the 67% response rate, descriptive analysis and analysis of variance (ANOVA) were the tools applied for the data obtained to be analysed. The result shows that, good communication system and improve quality of output of products are the most significant variables that can promote contractor’s reputation. The homogenous analyses indicate that there are significant different perceptions of respondents in term of the significant effects. The research concluded that contractor’s reputation in construction industry must be maintained and further research was suggested to focus on the qualitative method to have in-depth knowledge on contractor’s reputation in the construction industry.

Keywords: construction industry, contractor’s reputation, effects of delay, Nigeria

Procedia PDF Downloads 399

Authors: S. U. Kunya, S. A. Mohammad

Abstract:

Construction projects in Nigeria are characterized with risks emanating from delays and accompanying cost-overruns. The aim of the study was to identify and assess factors constraining the utilization of risk management strategies in the execution of public construction project in North-East Nigeria. Data was collected with the aid of a well-structured questionnaire administered to three identified projects in the North-east. Data collected were analysed using the severity index. Findings revealed political involvement, selection of inexperienced contractors and lack of coordinated public sector strategy as the most severe factors constraining the utilization of risk management strategies. The study recommended that: formulation of laws to prevent negative political meddling in construction projects; selection of experienced, risk-informed contractors; and comprehensive risk assessment and planning on all public construction projects.

Keywords: factors, Nigeria, north-east, public projects, risk management, strategies, utilization

Procedia PDF Downloads 486

Authors: Yoke-Mui Lim, Yahaya Ahmad

Abstract:

Conservation works in Malaysia that is procured by public organisation usually follow the traditional approach where the works are tendered based on Bills of Quantities (BQ). One of the purposes of tendering is to enable the selection of a competent contractor that offers a competitive price. While competency of the contractors are assessed by their technical knowledge, experience and track records, the assessment of pricing will be dependent on the tender amount. However, the issue currently faced by the conservation works sector is the difficulty in assessing the competitiveness and reasonableness of the tender amount due to the high variance between the tenders amount. Thus, this paper discusses the factors that cause difficulty to the tenderers in pricing competitively in a bidding exercise for conservation tenders. Data on tendering is collected from interviews with conservation works contractors to gain in-depth understanding of the barriers faced in pricing tenders of conservation works. Findings from the study lent support to the contention that the variance of tender amount is very high amongst tenderers. The factors identified in the survey are the format of BQ, hidden works, experience and labour and material costs.

Keywords: building conservation, Malaysia, bill of quantities, tender

Procedia PDF Downloads 347

Authors: Mujahid S. Alturais

Abstract:

The construction of process plants in oil and gas-producing countries, such as Saudi Arabia, necessitates substantial investment in design and building. Each new plant, while unique, includes common building types, suggesting an opportunity for design standardization. This study investigates the adoption of standardized Issue For Construction (IFC) packages for non-process buildings in Saudi Aramco. A SWOT analysis presents the strengths, weaknesses, opportunities, and threats of this approach. The approach's benefits are illustrated using the Hawiyah Unayzah Gas Reservoir Storage Program (HUGRSP) as a case study. Standardization not only offers significant cost savings and operational efficiencies but also expedites project timelines, reduces the potential for change orders, and fosters local economic growth by allocating building tasks to local contractors. Standardization also improves project management by easing interface constraints between different contractors and promoting adaptability to future industry changes. This research underscores the standardization of non-process buildings as a powerful strategy for cost optimization, efficiency enhancement, and local economic development in process plant construction within the oil and gas sector.

Keywords: building, construction, management, project, standardization

Procedia PDF Downloads 33

Authors: Erica Cochran Hameen, Bobuchi Ken-Opurum, Mounica Guturu

Abstract:

The United Stated (U.S.) populous spends the majority of their time indoors in spaces where building codes and voluntary sustainability standards provide clear Indoor Environmental Quality (IEQ) metrics. The existing sustainable building standards and codes are aimed towards improving IEQ, health of occupants, and reducing the negative impacts of buildings on the environment. While they address the post-occupancy stage of buildings, there are fewer standards on the pre-occupancy stage thereby placing a large labor population in environments much less regulated. Construction personnel are often exposed to a variety of uncomfortable and unhealthy elements while on construction sites, primarily thermal, visual, acoustic, and air quality related. Construction site power generators, equipment, and machinery generate on average 9 decibels (dBA) above the U.S. OSHA regulations, creating uncomfortable noise levels. Research has shown that frequent exposure to high noise levels leads to chronic physiological issues and increases noise induced stress, yet beyond OSHA no other metric focuses directly on the impacts of noise on contractors’ well-being. Research has also associated natural light with higher productivity and attention span, and lower cases of fatigue in construction workers. However, daylight is not always available as construction workers often perform tasks in cramped spaces, dark areas, or at nighttime. In these instances, the use of artificial light is necessary, yet lighting standards for use during lengthy tasks and arduous activities is not specified. Additionally, ambient air, contaminants, and material off-gassing expelled at construction sites are one of the causes of serious health effects in construction workers. Coupled with extreme hot and cold temperatures for different climate zones, health and productivity can be seriously compromised. This research evaluates the impact of existing green building metrics on construction and risk management, by analyzing two codes and nine standards including LEED, WELL, and BREAM. These metrics were chosen based on the relevance to the U.S. construction industry. This research determined that less than 20% of the sustainability context within the standards and codes (texts) are related to the pre-occupancy building sector. The research also investigated the impact of construction personnel’s health and well-being on construction management through two surveys of project managers and on-site contractors’ perception of their work environment on productivity. To fully understand the risks of limited Environmental and Health Quality metrics for contractors (EHQ) this research evaluated the connection between EHQ factors such as inefficient lighting, on construction workers and investigated the correlation between various site coping strategies for comfort and productivity. Outcomes from this research are three-pronged. The first includes fostering a discussion about the existing conditions of EQH elements, i.e. thermal, lighting, ergonomic, acoustic, and air quality on the construction labor force. The second identifies gaps in sustainability standards and codes during the pre-occupancy stage of building construction from ground-breaking to substantial completion. The third identifies opportunities for improvements and mitigation strategies to improve EQH such as increased monitoring of effects on productivity and health of contractors and increased inclusion of the pre-occupancy stage in green building standards.

Keywords: construction contractors, health and well-being, environmental quality, risk management

Procedia PDF Downloads 106

Authors: Ezekiel Ejiofor Nnadi

Abstract:

Nigeria construction industry is known for its active construction activities. This has earmarked the industry to be the key to economic growth of the nation. It has largest employer of labour and gives sustenance to other industries like manufacturing industry. While this is a sign of growth and prosperity; the waste generated by the industry has always been a problem and a serious concern. It results in wastage of economic gain and has resultant health effect on the populace apart from injury being sustained on sites. This work provides a platform to learn more about construction waste, its management strategy and how to reduce waste production in Nigeria construction industry. Construction sites, waste management authority and public health institutions in Lagos as the centre of most construction activities in Nigeria were selected, and a set of questionnaire was administered to using the systematic sampling technique. Descriptive statistics and relative importance index (RII) technique were employed for the analysis of the data gathered. The findings of the analysis show that excessive wastes reduce contractors’ profit margin and also that some construction wastes contain hazardous and toxic elements such as lead, asbestos or radioactive materials which required proper handling and effective disposal. The conclusion was drawn that the check on waste on construction sites starts with the designers to the contractors who execute on site.

Keywords: construction cost, construction industry, economic growth, materials wastes

Procedia PDF Downloads 246

Authors: Aydemir Akyürek, Osman Nuri Ağdağ

Abstract:

Construction industry is in a rapid development for many years around the world and especially in Turkey. In the last three years sector has 10% growth and provides significant support on Turkey’s national economy. Many construction projects are on-going at urban and rural areas of Turkey which have substantial environmental impacts. Environmental impacts during construction phase are quite diversified and widespread. Environmental impacts of construction industry cannot be inspected properly in all cases and negative impacts may occur frequently in many projects in Turkey. In this study, implementation of ISO 14001 Environmental Management System (EMS) in construction plants is evaluated. In the beginning stage quality management systems generally reviewed and ISO 14001 EMS is selected for implementation. Standard requirements are examined first and implementation of every standard requirement is elaborated for the selected construction plant in the following stage. Key issues and common problems, gained benefits by execution of this type of international EMS standard are examined. As can be seen in sample projects, construction projects are being completed very fast and contractors are working in a highly competitive environment with low profit ratios in our country and mostly qualified work force cannot be accessible. Addition to this there are deficits on waste handling and environmental infrastructure. Besides construction companies which have substantial investments on EMSs can be faced with difficulties on competitiveness in domestic market, however professional Turkish contractors which implementing managements systems in larger scale at international projects are gaining successful results. Also the concept of ‘construction project management’ which is being implemented in successful projects worldwide cannot be implemented except larger projects in Turkey. In case of nonexistence of main management system (quality) implementation of EMSs cannot be managed. Despite all constraints, EMSs that will be implemented in this industry with commitment of top managements and demand of customers will be an enabling, facilitating tool to determine environmental aspects and impacts of construction sites, will provide higher compliance levels for environmental legislation, to establish best available methods for operational control on waste management, chemicals management etc. and to plan monitoring and measurement, to prioritize environmental aspects for investment schedules and waste management.

Keywords: environmental management system, construction projects, ISO 14001, quality

Procedia PDF Downloads 332

Authors: Ndibarefinia Tobin

Abstract:

The UK construction industry has been under pressure for many years to produce economical buildings which offer value for money, not only during the construction phase, but more importantly, during the full life of the building. Whole life costing is considered as an economic analysis tool that takes into account the total investment cost in and ownership, operation and subsequent disposal of a product or system to which the whole life costing method is being applied. In spite of its importance, the practice is still crippled by the lack of tangible evidence, ‘know-how’ skills and knowledge of the practice i.e. the lack of professionals with the knowledge and training on the use of the practice in construction project, this situation is compounded by the absence of available data on whole life costing from relevant projects, lack of data collection mechanisms and so on. The aforementioned problems has forced many construction organisations to adopt project enhancement initiatives to boost their performance on the use of whole life costing techniques so as to produce economical buildings which offer value for money during the construction stage also the whole life of the building/asset. The management of knowledge in whole life costing is considered as one of the many project enhancement initiative and it is becoming imperative in the performance and sustainability of an organisation. Procuring building projects using whole life costing technique is heavily reliant on the knowledge, experience, ideas and skills of workers, which comes from many sources including other individuals, electronic media and documents. Due to the diversity of knowledge, capabilities and skills of employees that vary across an organisation, it is significant that they are directed and coordinated efficiently so as to capture, retrieve and share knowledge in order to improve the performance of the organisation. The implementation of knowledge management concept has different levels in each organisation. Measuring the maturity level of knowledge management in whole life costing practice will paint a comprehensible picture of how knowledge is managed in construction organisations. Purpose: The purpose of this study is to identify knowledge management maturity in UK construction organisations adopting whole life costing in construction project. Design/methodology/approach: This study adopted a survey method and conducted by distributing questionnaires to large construction companies that implement knowledge management activities in whole life costing practice in construction project. Four level of knowledge management maturity was proposed on this study. Findings: From the results obtained in the study shows that 34 contractors at the practiced level, 26 contractors at managed level and 12 contractors at continuously improved level.

Keywords: knowledge management, whole life costing, construction industry, knowledge

Procedia PDF Downloads 217

Authors: Nur Emma Mustaffa, Hii Ping Ping

Abstract:

Late payment is a common issue in the construction industry and the subcontractors are not spared from it. This study has been carried out with the objectives to identify the implications of late payment issues toward the subcontractors and the strategies adopted by them to overcome the late payment issues. In terms of the strategies which can be adopted in overcoming the late payment, the subcontractors may suspend or slow down the construction process, making periodic follow up with the client, demand the rights to interest on late payment or the issuance of a promissory note by the client. The focus of the study is primarily on Grade 4 to Grade 7 contractors in Johor Bahru, Malaysia who carried out subcontracting works and registered under Construction Industry Development Board (CIDB). Employing survey as the main research method for data collection, the analysis would therefore mainly be adopting Likert Scale Analysis, Ranking Analysis and Frequency Distribution Analysis. This research showed the main implication of late payment issues towards subcontractors is created financial hardship to them. Besides, the most effective strategy adopted by the subcontractors to overcome the late payment issues is follow-up with client using formal procedure. From the findings, most of the subcontractors had low level of experiences and frequency in the adoption of Construction Industry Payment and Adjudication Act (CIPAA) 2012 to solve the payment disputes in the construction industry. In a nutshell, it is hoped that these findings will become guidance to the subcontractors to overcome the late payment issues in their future projects.

Keywords: subcontractors, implications, strategies, CIPAA 2012, payment

Procedia PDF Downloads 138

Authors: Helen S. Ghali, Engy Serag, A. Samer Ezeldin

Abstract:

In many countries, the construction industry relies heavily on outsourcing models in executing their projects and expanding their businesses to fit in the diverse market. Such extensive integration of subcontractors is becoming an influential factor in contractor’s cash flow management. Accordingly, subcontractors’ financial terms are important phenomena and pivotal components for the well-being of the contractor’s cash flow. The aim of this research is to study the contractor’s cash flow with respect to the owner and subcontractor’s payment management plans, considering variable advance payment, payment frequency, and lag and retention policies. The model is developed to provide contractors with a decision support tool that can assist in selecting the optimum subcontracting plan to minimize the contractor’s financing limits and optimize the profit values. The model is built using Microsoft Excel VBA coding, and the genetic algorithm is utilized as the optimization tool. Three objective functions are investigated, which are minimizing the highest negative overdraft value, minimizing the net present worth of overdraft, and maximizing the project net profit. The model is validated on a full-scale project which includes both self-performed and subcontracted work packages. The results show potential outputs in optimizing the contractor’s negative cash flow values and, in the meantime, assisting contractors in selecting suitable subcontractors to achieve the objective function.

Keywords: cash flow optimization, payment plan, procurement management, subcontracting plan

Procedia PDF Downloads 88

Authors: K. C. Iyer, T. Gupta, Y. M. Bindal

Abstract:

Head office overhead (HOOH) is an indirect cost and is recovered through individual project billings by the contractor. Delay in a project impacts the absorption of HOOH cost allocated to that particular project and thus diminishes the expected profit of the contractor. This unabsorbed HOOH cost is later claimed by contractors as damages. The subjective nature of the available formulae to compute unabsorbed HOOH is the difficulty that contractors and owners face and thus dispute it. The paper attempts to bring together the rationale of various HOOH formulae by gathering contractor’s HOOH cost data on all of its project, using case study approach and comparing variations in values of HOOH using scenario analysis. The case study approach uses project data collected from four construction projects of a contractor in India to calculate unabsorbed HOOH costs from various available formulae. Scenario analysis provides further variations in HOOH values after considering two independent situations mainly scope changes and new projects during the delay period. Interestingly, one of the findings in this study reveals that, in spite of HOOH getting absorbed by additional works available during the period of delay, a few formulae depict an increase in the value of unabsorbed HOOH, neglecting any absorption by the increase in scope. This indicates that these formulae are inappropriate for use in case of a change to the scope of work. Results of this study can help both parties in deciding on an appropriate formula more objectively, considering the events on a project causing the delay and contractor's position in respect of obtaining new projects.

Keywords: absorbed and unabsorbed overheads, head office overheads, scenario analysis, scope variation

Procedia PDF Downloads 138

Authors: Tas Yong Koh, Steve Rowlinson, Yuzhong Shen

Abstract:

In construction safety management, safety climate has long been linked to workers' safety behaviors and performance. For this reason, safety climate concept and tools have been used as heuristics to diagnose a range of safety-related issues by some progressive contractors in Hong Kong and elsewhere. However, as a diagnostic tool, safety climate tends to treat the different components of the climate construct in a linear fashion. Safety management in construction projects, in reality, is a multi-faceted and multilevel phenomenon that resembles a complex system. Hence, understanding safety management in construction projects requires not only the understanding of safety climate but also the organizational-systemic nature of the phenomenon. Our involvement, diagnoses, and interpretations of a range of safety climate-related issues which culminated in the project’s sub-optimum safety performance in an infrastructure construction project have brought about such revelation. In this study, a range of data types had been collected from various hierarchies of the project site organization. These include the frontline workers and supervisors from the main and sub-contractors, and the client supervisory personnel. Data collection was performed through the administration of safety climate questionnaire, interviews, observation, and document study. The findings collectively indicate that what had emerged in parallel of the seemingly linear climate-based exploration is the exposition of the organization-systemic nature of the phenomenon. The results indicate the negative impacts of climate perceptions mismatch, insufficient work planning, and risk management, mixed safety leadership, workforce negative attributes, lapsed safety enforcement and resources shortages collectively give rise to the project sub-optimum safety performance. From the dynamic causation and multilevel perspective, the analyses show that the individual, group, and organizational levels issues are interrelated and these interrelationships are linked to negative safety climate. Hence the adoption of both perspectives has enabled a fuller understanding of the phenomenon of safety management that point to the need for an organizational-systemic intervention strategy. The core message points to the fact that intervention at an individual level will only meet with limited success if the risks embedded in the higher levels in group and project organization are not addressed. The findings can be used to guide the effective development of safety infrastructure by linking different levels of systems in a construction project organization.

Keywords: construction safety management, dynamic causation, multilevel analysis, safety climate

Procedia PDF Downloads 150

Authors: Nahed Al-Hajeri

Abstract:

Time and cost is an integral part of every construction plan and can affect each party’s contractual obligations. The performance of both time and cost are usually important to the client and contractor during the project. Almost all construction projects are experiencing time overrun. These time overruns always contributed as expensive to both client and contractor. Construction of any project inside the gathering centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. It also involves many agencies interdependent on each other like the vendors, structural and functional designers including various types of specialized engineers and it includes support of contractors and specialized contractors. This paper mainly highlights the types of construction delays due to which project suffer time and cost overrun. This paper also speaks about the delay causes and factors that contribute to the construction sequence delay for the oil and gas projects. Construction delay is supposed to be one of the repeated problems in the construction projects and it has an opposing effect on project success in terms of time, cost and quality. Some effective methods are identified to minimize delays in construction projects such as: 1. Site management and supervision, 2. Effective strategic planning, 3. Clear information and communication channel. Our research paper studies the types of delay with some real examples with statistic results and suggests solutions to overcome this problem.

Keywords: non-compensable delay, delays caused by force majeure, compensable delay, delays caused by the owner or the owner’s representative, non-excusable delay, delay caused by the contractor or the contractor’s representative, concurrent delay, delays resulting from two separate causes at the same time

Procedia PDF Downloads 224

Authors: Soebowo Musa

Abstract:

Mining industries are known to be very volatile due to their sensitive nature toward changes in the environment, particularly coal mining. Heavy equipment distributors and coal mining contractors are among heavily affected by such volatility. They are facing more uncertainty on the sustainability of the coal mining industry. Strategic alliances and organizational capabilities such as innovation capability have long been seen as ways to stay competitive with a focus more on the strategic alliances partner-to-partner in serving their customers. In today’s rapid change in the environment, a shift in consumer behaviors, and the human-centric business approach, this study looks at the strategic alliance partner-to-customer relationship in both the industrial organization and resource-based theories. This study was conducted based on 250 respondents from the strategic alliances partner-to-customer between heavy equipment distributors and coal mining contractors in Indonesia. This study finds strategic alliances have the highest association toward cost reduction, a proxy of operational efficiency followed by its association toward innovation capability. Further, strategic alliances and innovation capability have a positive relationship with customer loyalty, while innovation capability and customer loyalty have no significant relationships toward the firm’s competitive advantage. This study also indicates that cost reduction is not a condition to develop customer loyalty in the strategic alliance partner-to-customer relationship. It confirms strategic alliances are a strategy that creates a firm’s operational efficiency, innovation capability that develops customer loyalty, and competitive advantage.

Keywords: strategic alliance, innovation capability, cost reduction, customer loyalty, competitive advantage

Procedia PDF Downloads 88

Authors: Adil K. Tamimi, Tarig Ali, Rawan Anoohi, Ahmed Rajput, Kaltham Alkamali

Abstract:

3D concrete printing is one of the most innovative and modern techniques in the field of construction that achieved several milestones in that field for the following advantages: saving project’s time, ability to execute complicated shapes, reduce waste and low cost. However, the concept of 3D printing in UAE is relatively new where construction teams, including clients, consultants, and contractors, do not have the required knowledge and experience in the field. This is the most significant obstacle for the construction parties, which make them refrained from using 3D concrete printing compared to conventional concreting methods. This study shows the historical development of the 3D concrete printing, its advantages, and the challenges facing this innovation. Concrete mixes and materials have been proposed and evaluated to select the best combination for successful 3D concrete printing. The main characteristics of the 3D concrete printing in the fresh and hardened states are considered, such as slump test, flow table, compressive strength, tensile, and flexural strengths. There is need to assess the structural stability of the 3D concrete by testing the bond between interlayers of the concrete.  

Keywords: 3D printing, workability, compressive strength, robots, dimensions

Procedia PDF Downloads 123

Authors: Yassir AbdelRazig, Amine Ghanem

Abstract:

Construction projects are information intensive in nature and involve many activities that are related to each other. Wireless technologies can be used to improve the accuracy and timeliness of data collected from construction sites and shares it with appropriate parties. Nonetheless, the construction industry tends to be conservative and shows hesitation to adopt new technologies. A main concern for owners, contractors or any person in charge on a job site is the cost of the technology in question. Wireless technologies are not cheap. There are a lot of expenses to be taken into consideration, and a study should be completed to make sure that the importance and savings resulting from the usage of this technology is worth the expenses. This research attempts to assess the effectiveness of using the appropriate wireless technologies based on criteria such as performance, reliability, and risk. The assessment is based on a utility function model that breaks down the selection issue into alternatives attribute. Then the attributes are assigned weights and single attributes are measured. Finally, single attribute are combined to develop one single aggregate utility index for each alternative.

Keywords: analytic hierarchy process, decision theory, utility function, wireless technologies

Procedia PDF Downloads 313

Authors: Siziwe Monica Zuma

Abstract:

The Expanded Public Works Program (EPWP) is an instrument that the South African Government uses to reduce unemployment and poverty and also stimulate economic growth. However, due to the limited budget and programs in the EPWP, the program has had challenges in reducing unemployment, poverty and stimulating economic growth. The EPWP Vuk’uphile program had positive outcomes in developing Black emerging contractors, in order for them to participate in the main stream economy far better than when the EPWP program was not introduced. The Skills component of the program particularly the EPWP Infrastructure, which is the most funded program under EPWP has had limited success in transferring appropriate skills to ensure labour participants can penetrate the labour market after participating in the EPWP. Education and skills are important attributes that can contribute to labour absorption, however, the EPWP particularly the infrastructure program needs to strengthen skills development over a longer period of time suggested a year with multi skills relevant to the labour market. Longer and more sustained employment provides a safety net and reduces poverty better that short term employment. The EPWP program can be expanded in the infrastructure sector, focusing on rural infrastructure, agricultural infrastructure, infrastructure related components like property, ownership, management, and other services. These can stimulate the Economic sector Infrastructure of EPWP, offer longer term and more sustained employment and rural enterprise development and further employment. The Expanded Public Works Program (EPWP) is an instrument that the South African Government uses to reduce unemployment and poverty and also stimulate economic growth. However, due to the limited budget and programs in the EPWP, the program has had challenges in reducing unemployment, poverty and stimulating economic growth. The EPWP Vuk’uphile program has had positive outcomes in developing Black emerging contractors, in order for them to participate in the main stream economy far better than when the EPWP program was not introduced. The Skills component of the program particularly the EPWP Infrastructure, which is the most funded program under EPWP has had limited success in transferring appropriate skills to ensure labour participants are able to penetrate the labour market after participating in the EPWP. Education and skills are important attributes that can contribute to labour absorption, however, the EPWP particularly the infrastructure program needs to strengthen skills development over a longer period of time suggested a year with multi skills relevant to the labour market. Longer and more sustained employment provides a safety net and reduces poverty better that short term employment. The EPWP program can be expanded in the infrastructure sector, focusing on rural infrastructure, agricultural infrastructure, infrastructure related components like property, ownership, management, and other services. These can stimulate the Economic sector Infrastructure of EPWP, offer longer term and more sustained employment and rural enterprise development and further employment.

Keywords: Expanded Public Works Program (EPWP), VUKÚPHILE, youth, Public Works Programs (PWP), Infrastructure Sector of EPWP (EPWP Infrastructure)

Procedia PDF Downloads 187

Authors: Goutom K. Pall

Abstract:

At the very heart of the power system, power transmission (PT) acts as an essential link between power generation and distribution. Timely completion of PT infrastructures is therefore crucial to support the development of power system as a whole. Yet despite the importance, studies on PT infrastructure development projects are embryonic and, hence, PT projects undergoing widespread delays worldwide. These delay factors are idiosyncratic and identifying the critical delay factors is essential if the PT industry professionals are to complete their projects efficiently and within the expected timeframes. This study identifies and categorizes 46 causes of PT project delay under ten major groups using six sector expert’s recommendations studied by a preliminary questionnaire survey. Based on the experts’ strong recommendations, two new groups are introduced in the final questionnaire survey: sector specific factors (SSF) and general factors (GF). SSF pertain to delay factors applicable only to the PT projects, while GF represents less biased samples with shared responsibilities of all project parties involved in a project. The study then uses 112 data samples from the contractors to rank the delay factors using relative importance index (RII). The results reveal that SSF, GF and external factors are the most critical groups, while the highest ranked delay factors include the right of way (RoW) problems of transmission lines (TL), delay in payments, frequent changes in TL routes, poor communication and coordination among the project parties and accessibility to TL tower locations. Finally, recommendations are made to minimize the identified delay. The findings are expected to be of substantial benefit to professionals in minimizing time overrun in PT projects implementation, as well as power generation, power distribution, and non-power linear construction projects worldwide.

Keywords: delay, project delay, power transmission projects, time-overruns

Procedia PDF Downloads 149

Authors: A. Aljohani, D. Moore, D. D. Ahiaga-Dagbui

Abstract:

Cost overruns are endemic in the delivery of construction projects. The problem is global. It occurs irrespective of type and size of the project, its location, procurement method or client. The size of overruns can be as high as 200% in some cases. Projects thus unfortunately often make the news headlines, not for their immense socio-economic contribution to society, but for being poorly procured. In Saudi Arabia, two-thirds of construction projects are publicly procured by the Saudi government, which has been invested Billions of dollars in infrastructure projects each year as part of an ambitious strategic development agenda to shift from mainly oil dependency to multi-source dependency. However, reports show that about 3,000 public projects face diverse issues related to time and cost overrun. As part of an on-going study to develop a framework for effective public procurement for the Saudi Arabian construction industry, this paper reports the initial findings of the causes of cost overruns in the context of the Gulf State. It also evaluates the interface between some of the front-end loading issues in public procurement in Saudi and their effects on project performance. A systematic review of the existing literature on construction cost overruns, with focus on the Saudi Arabian construction industry has been used. One of the initial findings is that a fixed-price contract is usually used by the client in an attempt to transfer all financial risks to the contractors. This has the unintended consequence of creating a turbulent environment for the delivery of the project which leads to project abandonment by contractors, poor quality of work and substantial rework. Further work is being undertaken to empirically verify the initial findings reported in this paper and their generalizability for the construction industry as a whole.

Keywords: cost overrun, public procurement, Saudi Arabia, construction projects

Procedia PDF Downloads 242

Authors: Michael Salib, Samer Ezeldin, Ahmed Waly

Abstract:

There are numerous challenges and problems facing the construction industry in several countries in the Middle East, as a result of numerous economic and political effects. As an example in Egypt, several construction companies have shut down and left the market since 2016. The closure of these companies occurred, as they did not respond with the suitable techniques and strategies that will enable them to survive during this economic turmoil period. A research is conducted in order to identify adequate strategies to be implemented by the Egyptian contractors that could allow them survive and keep competing during such economic hardship period. Two different techniques were used in order to identify these startegies. First, a deep research were conducted on the companies located in countries that suffered similar economic harship to identify the strategies they used in order to survive. Second, interviews were conducted with experts in the construction field in order to list the effective strategies they used that allowed them to survive. Moreover, at the end of each interview, the experts were asked to rate the applicability of the previously identified strategies used in the foreign countries, then the efficiency of each strategy if used in Egypt. A framework model is developed in order to assist the construction companies in choosing the suitable techniques to their company size, through identifying the top ranked strategies and techniques that should be adopted by the company based on the parameters given to the model. In order to verify this framework, the financial statements of two leading companies in the Egyptian construction market were studied. The first Contractor has applied nearly all the top ranked strategies identified in this paper, while the other contractor has applied only few of the identified top ranked strategies. Finally, another expert interviews were conducted in order to validate the framework. These experts were asked to test the model and rate through a questionnaire its applicability and effectiveness.

Keywords: construction management, economic hardship, recession, survive

Procedia PDF Downloads 106

Authors: Olufunmilayo Folaranmi

Abstract:

This research was carried out to examine the impact of socio-cultural factors on the management and utilization of solid waste in Ibadan Metropolis. A descriptive survey research design was adopted for the study while a systematic and stratified random sampling technique was used to select 300 respondents which were categorized into high, middle and low-density areas. Four hypothesis were tested using chi-square test on variables of unavailability of waste disposal facilities and waste management, negligence of contractors to liaise with community members, lack of adequate environmental education and waste management and utilization, low level of motivation of sanitation workers with solid wastes management, lack of community full participation with solid waste management and utilization. Results showed that significant effect of waste disposal facilities on solid waste management and utilization (X2 +16.6, P < .05). Also, there is a significant relationship between negligence of the contractors to liaise with community elites with improper disposal (X2 = 87.5, P < .05). The motivation of sanitation workers is significantly related to solid waste management (X2 = 70.4, P < .05). Adequate environmental education and awareness influenced solid waste management. There was also a significant relationship between lack of community participation with waste management disposal and improper waste disposal. Based on the findings from the study it was recommended that the quality of life in urban centers should be improved, social welfare of the populace enhanced and environment should be adequately attended to. Poverty alleviation programmes should be intensified and made to live beyond the life of a particular administration, micro-credit facilities should be available to community members to promote their welfare. Lastly, sustained environmental education programmes for citizens at all levels of education, formal and informal through the use of agencies like Ethical and Attitudinal Reorientation Commission (EARCOM) and the National Orientation Agency (NOA).

Keywords: management, social welfare, socio-cultural factors, solid waste

Procedia PDF Downloads 196

Authors: Mohammad Abbas Nejad

Abstract:

Tuka Sabz service production company (private shares), with more than 30 years of history, is considered as one of the first holding companies of Tuka Foulad, which takes steps in the direction of increasing service quality and customer satisfaction. Manpower supply is one of the most important activities of Tuka Sabz company, in addition to car supply services; light and heavy transportation services; management of entertainment, sports, tourism and accommodation centers; design, creation and maintenance services of land space; preparing, cooking, distributing and serving all kinds of personal and ceremonial foods; design, construction, repair and reconstruction of non-industrial buildings; industrial laundry services; public and industrial cleaning services are also among other activities of Tuka Sabz. This company has a high capacity of specialized and committed human resources as the main pillar of its success and spent most of its years of activity in Mobarakeh steel company as one of the reliable contractors in the field of automotive service contracts, green space, industrial cleaning, management cultural, recreational and tourism places, consulting, maintenance and repair of buildings and facilities, industrial laundry, management of cooking centers and personnel transportation. The final result of this article states that Tuka Sabz company is trying to get the satisfaction of three main groups of stakeholders, i.e., employees, customers, and shareholders, for this purpose, by improving the competence and competence of employees, trying to establish a system of meritocracy and respecting the human status of employees. On the one hand, the implementation of quality management and assurance to employers with the timely and favorable implementation of contracts takes a step in this direction.

Keywords: Mubarakeh steel company, Tuka Sabz company, human resources, industrial laundry services

Procedia PDF Downloads 32

Authors: Theophilus O. Odunlami, Hasan Haroglu, Nader Saleh-Matter

Abstract:

The challenges facing the construction industry are often worsened by the compounded nature of projects coupled with the complexity of key stakeholders involved at different stages of the project. Projects are planned to achieve outlined benefits in line with the business case; however, a lack of effective management of key stakeholders can result in unrealistic delivery aspirations, unnecessary re-works, and overruns. The aim of this study is to examine the early stages of a project lifecycle and investigate the stakeholder management and involvement processes and their impact on the successful delivery of the project. The research engaged with conventional construction organisations and project personnel and stakeholders on diverse projects, using a research strategy to analyse existing project case studies, narrative enquiries, interviews, and surveys using a combined qualitative, quantitative, and mixed method of analysis. Research findings have shown that the involvement of stakeholders at different levels during the early stages has pronounced effects on project delivery; it helps to forge synergy and promotes a clear understanding of individual responsibilities, strengths, and weaknesses. This has often fostered a positive sense of productive collaboration right through the early stages of the project. These research findings intend to contribute to the development of a process framework for stakeholder and project team involvement in the early stages of a project. This framework will align with the selection criteria for stakeholders, contractors, and resources, ultimately contributing to the successful completion of projects. The primary question addressed in this study is stakeholder involvement and management of the early stages of a building project life cycle impacts project delivery. Findings showed that early-stage stakeholder involvement and collaboration between project teams and contractors significantly contribute to project success. However, a strong and healthy communication strategy would be required to maintain the flow of value-added ideas among stakeholders at the early stages to benefit the project at the execution stage.

Keywords: early stages, project lifecycle, stakeholders, decision-making strategy, project framework

Procedia PDF Downloads 57

Authors: Y. Gholipour, E. Rezazadeh

Abstract:

Delay is one of the most serious and common problems of construction project that can affect project delivery unfavorably. This research presents the most important causes of delay in large dam projects based on a survey on some executed dam construction in Iran. In this survey a randomly selected samples of owners, consultants and contractors have been involved. The outcome of this survey revealed that scheduled payments, site management, shop drawing review process, unforeseen ground conditions and contractor experience as the most important factors affecting on delay in dam construction projects.

Keywords: delay, dam construction, project management, Iran

Procedia PDF Downloads 415

Authors: Amin Padash, Javad Kazem Zadeh Khoiy, Hossein Vahidi

Abstract:

Purpose: The mechanization system for the urban services was implemented in Tehran City in the year 2004 to promote the collection of domestic wastes; in 2010, in order to achieve the objectives of the project of urban services mechanization and qualitative promotion and improve the urban living environment, sustainable development and optimization of the recyclable solid wastes collection systems as well as other dry and non-organic wastes and conformity of the same to the modern urban management methods regarding integration of the mechanized urban services contractors and recycling contractors and in order to better and more correct fulfillment of the waste separation and considering the success of the mechanization plan of the dry wastes in most of the modern countries. The aim of this research is analyzing of Environmental Risk Assessment of the mechanization waste collection scheme in Tehran. Case Study: Tehran, the capital of Iran, with the population of 8.2 million people, occupies 730 km land expanse, which is 4% of total area of country. Tehran generated 2,788,912 ton (7,641 ton/day) of waste in year 2008. Hospital waste generation rate in Tehran reaches 83 ton/day. Almost 87% of total waste was disposed of by placing in a landfill located in Kahrizak region. This large amount of waste causes a significant challenge for the city. Methodology: To conduct the study, the methodology proposed in the standard Mil-St-88213 is used. This method is an efficient method to examine the position in opposition to the various processes and the action is effective. The method is based on the method of Military Standard and Specialized in the military to investigate and evaluate options to locate and identify the strengths and weaknesses of powers to decide on the best determining strategy has been used. Finding and Conclusion: In this study, the current status of mechanization systems to collect waste and identify its possible effects on the environment through a survey and assessment methodology Mil-St-88213, and then the best plan for action and mitigation of environmental risk has been proposed as Environmental Management Plan (EMP).

Keywords: environmental risk assessment, mechanization waste collection scheme, Mil-St-88213

Procedia PDF Downloads 407

Authors: Khaing Yadana Swe, Lillie Dewan

Abstract:

At present, the cascade PID control is widely used to control the super-heating temperature (main steam temperature). As the main steam temperature has the characteristics of large inertia, large time-delay, and time varying, etc., conventional PID control strategy can not achieve good control performance. In order to overcome the bad performance and deficiencies of main steam temperature control system, Model Free Adaptive Control (MFAC) P cascade control system is proposed in this paper. By substituting MFAC in PID of the main control loop of the main steam temperature control, it can overcome time delays, non-linearity, disturbance and time variation.

Keywords: model-free adaptive control, cascade control, adaptive control, PID

Procedia PDF Downloads 578

Authors: Adedayo Jeremiah Adeyekun, Samuel Oluwagbemiga Ishola,

Abstract:

This paper is an assessment of factors influencing the cost and time performance of subcontractors and the need for effective performance of subcontractors at the project sites. The factors influencing the performance of subcontractors are grouped, similar to those identified with the project or an organization and on another hand, there are significant factors influencing the performance of the subcontractors. These factors incorporate management level leadership, time required to complete the project, profit, staff capability/expertise, reputation, installment method, organization history, and project procurement method strategy, security, bidding technique, insurance, bond and relationship with the major contractors. The factors influencing the management of subcontractors in building development projects includes performance of significant past projects, standard of workmanship, consistence with guidelines, regular payment to labourers, adherence to program, regularity and viability of communication with main contractor, adherence to subcontract necessities. Other factors comprise adherence to statutory environmental regulations, number of experienced sites administrative staff, inspection and maintenance of good workplace, number of artisans and workers, quality of as-built and shop drawings and ability to carry out the quantity of work and so on. This study also aimed to suggest a way forward to improve the performance of subcontractors which is the reason for exceeding budget at the project sites. To carry out this study, a questionnaire was drafted to derive information on the causes of low performance of subcontractors and the implication to cost.

Keywords: performance, contractor, subcontractors, construction

Procedia PDF Downloads 46

Authors: Heng Han, Zhilei Liang, Xiangong Zhou

Abstract:

In this paper, the finite element method is used to study the temperature field of the main cable of the suspension bridge, and the calculation method of the average temperature of the cross-section of the main cable suitable for the construction control of the cable system is proposed; By comparing and analyzing the temperature field of the main cable with five diameters, a reasonable diameter limit for calculating the average temperature of the cross section of the main cable by finite element method is proposed. The results show that the maximum error of this method is less than 1℃, which meets the requirements of construction control accuracy; For the main cable with a diameter greater than 400mm, the surface temperature measuring points combined with the finite element method shall be used to calculate the average cross-section temperature.

Keywords: suspension bridge, main cable, temperature field, finite element

Procedia PDF Downloads 122