Search results for: contractor

Authors: Hailu Kebede Bekele

Abstract:

Construction delays are suitable where project events occur at a certain time expected due to causes related to the client, consultant, and contractor. Delay is the major cause of the cost overrun that leads to the poor efficiency of the project. The cost difference between completion and the originally estimated is known as cost overrun. The common ways of cost overruns are not simple issues that can be neglected, but more attention should be given to prevent the organization from being devastated to be failed, and financial expenses to be extended. The reasons that may raised in different studies show that the problem may arise in construction projects due to errors in budgeting, lack of favorable weather conditions, inefficient machinery, and the availability of extravagance. The study is focused on the pace of mega projects that can have a significant change in the cost overrun calculation.15 mega projects are identified to study the problem of the cost overrun in the site. The contractor, consultant, and client are the principal stakeholders in the mega projects. 20 people from each sector were selected to participate in the investigation of the current mega construction project. The main objective of the study on the construction cost overrun is to prioritize the major causes of the cost overrun problem. The methodology that was employed in the construction cost overrun is the qualitative methodology that mostly rates the causes of construction project cost overrun. Interviews, open-ended and closed-ended questions group discussions, and rating qualitative methods are the best methodologies to study construction projects overrun. The result shows that design mistakes, lack of labor, payment delay, old equipment and scheduling, weather conditions, lack of skilled labor, payment delays, transportation, inflation, and order variations, market price fluctuation, and people's thoughts and philosophies, the prior cause of the cost overrun that fail the project performance. The institute shall follow the scheduled activities to bring a positive forward in the project life.

Keywords: cost overrun, delay, mega projects, design

Procedia PDF Downloads 29

Authors: Y. Gholipour, E. Rezazadeh

Abstract:

Delay is one of the most serious and common problems of construction project that can affect project delivery unfavorably. This research presents the most important causes of delay in large dam projects based on a survey on some executed dam construction in Iran. In this survey a randomly selected samples of owners, consultants and contractors have been involved. The outcome of this survey revealed that scheduled payments, site management, shop drawing review process, unforeseen ground conditions and contractor experience as the most important factors affecting on delay in dam construction projects.

Keywords: delay, dam construction, project management, Iran

Procedia PDF Downloads 414

Authors: Omar Amoudi, Latifa Al Brashdi

Abstract:

Construction projects are always subject to risks and uncertainties due to its unique and dynamic nature, outdoor work environment, the wide range of skills employed, various parties involved in addition to situation of construction business environment at large. Altogether, these risks and uncertainties affect projects objectives and lead to cost overruns, delay, and poor quality. Construction projects in Oman often experience cost overruns and delay. Managing these risks and reducing their impacts on construction cost requires firstly identifying these risks, and then analyzing their severity on project cost to obtain deep understanding about these risks. This in turn will assist construction managers in managing and tacking these risks. This paper aims to investigate the main risk factors that affect construction projects cost in the Sultanate of Oman. In order to achieve the main aim, literature review was carried out to identify the main risk factors affecting construction cost. Thirty-three risk factors were identified from the literature. Then, a questionnaire survey was designed and distributed among construction professionals (i.e., client, contractor and consultant) to obtain their opinion toward the probability of occurrence for each risk factor and its possible impact on construction project cost. The collected data was analyzed based on qualitative aspects and in several ways. The severity of each risk factor was obtained by multiplying the probability occurrence of a risk factor with its impact. The findings of this study reveal that the most significant risk factors that have high severity impact on construction project cost are: Change of Oil Price, Delay of Materials and Equipment Delivery, Changes in Laws and Regulations, Improper Budgeting, and Contingencies, Lack of Skilled Workforce and Personnel, Delays Caused by Contractor, Delays of Owner Payments, Delays Caused by Client, and Funding Risk. The results can be used as a basis for construction managers to make informed decisions and produce risk response procedures and strategies to tackle these risks and reduce their negative impacts on construction project cost.

Keywords: construction cost, construction projects, Oman, risk factors, risk management

Procedia PDF Downloads 306

Authors: Sunaitan Al Mutairi

Abstract:

A perfect start is a key factor for project completion on time. The study examined the effects of delayed mobilization of resources during the initial phases of the project. This paper mainly highlights the identification and categorization of all delays during the initial construction phase and their root cause analysis with corrective/control measures for the Kuwait Oil Company oil and gas projects. A relatively good percentage of the delays identified during the project execution (Contract award to end of defects liability period) attributed to mobilization/preliminary activity delays. Data analysis demonstrated significant increase in average project delay during the last five years compared to the previous period. Contractors had delays/issues during the initial phase, which resulted in slippages and progressively increased, resulting in time and cost overrun. Delays/issues not mitigated on time during the initial phase had very high impact on project completion. Data analysis of the delays for the past five years was carried out using trend chart, scatter plot, process map, box plot, relative importance index and Pareto chart. Construction of any project inside the Gathering Centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. Delay affects completion of projects and compromises quality, schedule and budget of project deliverables. Works executed as per plan during the initial phase and start-up duration of the project construction activities resulted in minor slippages/delays in project completion. In addition, there was a good working environment between client and contractor resulting in better project execution and management. Mainly, the contractor was on the front foot in the execution of projects, which had minimum/no delays during the initial and construction period. Hence, having a perfect start during the initial construction phase shall have a positive influence on the project success. Our research paper studies each type of delay with some real example supported by statistic results and suggests mitigation measures. Detailed analysis carried out with all stakeholders based on impact and occurrence of delays to have a practical and effective outcome to mitigate the delays. The key to improvement is to have proper control measures and periodic evaluation/audit to ensure implementation of the mitigation measures. The focus of this research is to reduce the delays encountered during the initial construction phase of the project life cycle.

Keywords: construction activities delays, delay analysis for construction projects, mobilization delays, oil & gas projects delays

Procedia PDF Downloads 287

Authors: Christo Februanto Putra

Abstract:

This paper presents risk identification that affects investment feasibility on toll road infrastructure in Indonesia using qualitative methods survey based on the expert practitioner in investor, contractor, and state officials. The problems on infrastructure investment in Indonesia, especially on KPBU model contract, is many risk factors in the investment plan is not calculated in detail thoroughly. Risk factor is a value used to provide an overview of the risk level assessment of an event which is a function of the probability of the occurrence and the consequences of the risks that arise. As results of the survey which is to show which risk factors impacts directly to the investment feasibility and rank them by their impacts on the investment.

Keywords: risk identification, indonesia toll road, investment feasibility

Procedia PDF Downloads 246

Authors: Myunghoun Jang

Abstract:

A survey of small-size contractors in Jeju was conducted to investigate college graduate's computer-aided design (CAD) competence. Most of small-size contractors use CAD software to review and update drawings submitted from an architect. This research analyzed the curriculum of the architectural engineering in several national universities. The CAD classes have 4 or 6 hours per week and use AutoCAD primarily. This paper proposes that a CAD class needs 6 hours per week, 2D drawing is the main theme in the curriculum, and exercises to make 3D models are also included in the CAD class. An improved method, for example Internet cafe and real time feedbacks using smartphones, to evaluate the reports and exercise results is necessary.

Keywords: CAD (Computer Aided Design), CAD education, education improvement, small-size contractor

Procedia PDF Downloads 242

Authors: Hassan Abdelgadir

Abstract:

Cost overruns have harmed the economies and reputations of several construction companies around the world. Many project management systems have been developed to keep track of a project's budget. However, due to several cost overrun difficulties in the construction industry, cost management is still deemed inadequate. As a result, the goal of this term paper is to identify and group prospective construction project cost overrun reasons based on their origin groups.Basically, all potential cost overrun elements were rigorously checked through 1iterature analysis before being divided into seven (7) groups of originating components, including project, contract, client, contractor, consultant, labor, and external. Each potential factor was completely defined with examples.

Keywords: construction projects, cost overruns, construction company, factors effect costoverruns

Procedia PDF Downloads 39

Authors: Ibraheem A. K. Mahameed

Abstract:

The aim of this study is to identify the risks affecting time performance of building construction projects in the West Bank in Palestine from contractors’ viewpoint. 38 risks that might affect time performance of building construction projects were defined through a detailed literature review. These risks have been classified into 6 groups: project, managerial, consultant, financial, external, and construction items. A questionnaire survey was performed to rank the considered risks in terms of severity and frequency. The analysis of the survey indicated that the top five risks affecting time performance of building construction projects in Palestine are: award project to the lowest price, political situation, poor communication and coordination between construction parties, change orders, and financial status of contractor.

Keywords: delay, time performance, construction, building

Procedia PDF Downloads 434

Authors: Islem Kedidi, Rihab Bedoui Bensalem, Faysal Manssouri

Abstract:

In traditional models of insurance data, the number and size of claims are assumed to be independent. Relaxing the independence assumption, this article explores the Vine copula to model dependence structure between multivariate frequency and average severity of insurance claim. To illustrate this approach, we use the Wisconsin local government property insurance fund which offers several insurance protections for motor vehicles, property and contractor’s equipment claims. Results show that the C-vine copula can better characterize the multivariate dependence structure between frequency and severity. Furthermore, we find significant dependencies especially between frequency and average severity among different coverage types.

Keywords: dependency modeling, government insurance, insurance claims, vine copula

Procedia PDF Downloads 172

Authors: Marius Nygaard, Ona Flindall

Abstract:

The Palisaden student housing project was completed in August 2013 and was, with its eight floors, Norway’s tallest timber building at the time of completion. It was the first time cross-laminated-timber (CLT) was utilized at this scale in Norway. The project was the result of a concerted effort by a newly formed management company to establish CLT as a sustainable and financially competitive alternative to conventional steel and concrete systems. The introduction of CLT onto the student housing market proved so successful that by 2017 more than 4000 individual student residences will have been built using the same model of development and construction. The aim of this paper is to identify the key factors that enabled this breakthrough for CLT. It is based on an in-depth study of a series of housing projects and the role of the management company who both instigated and enabled this shift of CLT from the margin to the mainstream. Specifically, it will look at how a new building system was integrated into a marketing strategy that identified a market potential within the existing structure of the construction industry and within the economic restrictions inherent to student housing in Norway. It will show how a key player established a project model that changed both the patterns of cooperation and the information basis for decisions. Based on qualitative semi-structured interviews with managers, contractors and the interdisciplinary teams of consultants (architects, structural engineers, acoustical experts etc.) this paper will trace the introduction, expansion and evolution of CLT-based building systems in the student housing market. It will show how the project management firm’s position in the value chain enabled them to function both as a liaison between contractor and client, and between contractor and producer. A position that allowed them to improve the flow of information. This ensured that CLT was handled on equal terms to other structural solutions in the project specifications, enabling realistic pricing and risk evaluation. Secondly, this paper will describe and discuss how the project management firm established and interacted with a growing network of contractors, architects and engineers to pool expertise and broaden the knowledge base across Norway’s regional markets. Finally, it will examine the role of the client, the building typology, and the industrial and technological factors in achieving this breakthrough for CLT in the construction industry. This paper gives an in-depth view of the progression of a single case rather than a broad description of the state of the art of large-scale timber building in Norway. However, this type of study may offer insights that are important to the understanding not only of specific markets but also of how new technologies should be introduced in big and well-established industries.

Keywords: cross-laminated-timber (CLT), industry breakthrough, student housing, timber market

Procedia PDF Downloads 198

Authors: Z. Hamed, K. Sa'deya, E. Abdelrasheed, I. Mahamid

Abstract:

The construction industry is one of the main sectors that play basic role in the urban and rural development of a society. It provides important ingredients for the development of an economy. However, many construction projects experience extensive cost overrun. This study was conducted to identify the causes of cost overrun in building construction contracts in Al Madinah, Saudi Arabia and test the importance of these causes from contractors' perspective. To achieve the study objectives, a questionnaire survey was conducted to identify and rank cost overrun causes from the perspective of contractors. The findings found that the top five cost overrun causes are: lack of experience in the line of work, lack of labor productivity, delay in payments, rework and material waste. It is hoped that the findings will guide efforts to improve the performance of construction industry in Saudi Arabia and other developing countries.

Keywords: building, contractor, cost increase, cost overrun

Procedia PDF Downloads 123

Authors: Kishen Prathivadi

Abstract:

The Sewer Authority Mid-Coastside (SAM) is a Joint Powers Authority formed in 1976 and provides secondary wastewater treatment to an average flow of 2.0 million gallons per day. SAM owns and operates a Wastewater Treatment Plant (WWTP) and a sanitary sewage collection system that collects sewage from its three member agencies: the City of Half Moon Bay, the Granada Community Services District and Montara Water and Sanitary District. The Sewer Authority Mid-Coastside (SAM) partnered with Pacific Gas & Electric, and its contractor GEL America, to review and replace all inefficient lighting fixtures and bulbs at the SAM treatment plant and administrative office. The project focused on replacing old and inefficient lighting fixtures and bulbs, reducing annual operating and maintenance costs, and reducing SAM’s carbon footprint. The project resulted in a 55% overall energy reduction, higher light quality and acuity, and a total operational savings of $495,000 over ten years.

Keywords: energy savings, LED, lighting, electrical

Procedia PDF Downloads 109

Authors: Kherbache Radhwane

Abstract:

We currently live in the world pressed by technological developments necessary for the construction, where the concept of sustainable development is truly rooted in recent years. Construction or demolitions of buildings necessarily generate environmental pollution, both inside and outside the site. Depending on the size and nature of work and the context surrounding these problems can be more or less important as is the case here in Algeria. They may affect the smooth running of the site. Moreover, there are regulations exist or are under development and should be taken into account by the various players in the act of building. This is, for example, the case of new obligations in terms of sorting and recycling of construction waste. Given this situation, it appears increasingly necessary to integrate the building sites in an effort to better respect the environment and its regulation. Several operations were performed according to this principle. The success of a project is that respects its environment through the involvement of each actor of the operation of the site with a low nuisance. As such, the client assisted by his driver and its operating contractor and the company plays a central role as an initiator of the process. It must ensure the establishment of appropriate means of organizational plans and contract.

Keywords: evolution, sustainable development, construction, demolition, building, nuisance, environmental, tailings, construction, regulations

Procedia PDF Downloads 238

Authors: E. Kissi, V. K. Acheamfour, J. J. Gyimah, T. Adjei-Kumi

Abstract:

Factoring accounts receivable is widely accepted as an alternative financing source and utilized in almost every industry that sells business-to-business or business-to-government. However, its patronage in the construction industry is very limited as some barriers hinder its application in the construction industry. This study aims at assessing the barriers to the use of factoring accounts receivables in the Ghanaian construction industry. The study adopted the sequential exploratory research method where structured and unstructured questionnaires were conveniently distributed to D1K1 and D2K2 construction firms in Ghana. Using the one-sample t-test and Kendall’s Coefficient of concordance data was analyzed. The most severe challenge concluded is the high cost of factoring patronage. Other critical challenges identified were low knowledge on factoring processes, inadequate access to information on factoring, and high risks involved in factoring. Hence, it is recommended that contractors should be made aware of the prospects of factoring of accounts receivables in the construction industry. This study serves as basis for further rigorous research into factoring of accounts receivables in the industry.

Keywords: barriers, contractors, factoring accounts receivables, Ghanaian, perception

Procedia PDF Downloads 98

Authors: Li Ma, Meishuang Ma, Mengying Huang

Abstract:

The quality of construction projects reflects the credit and responsibilities of construction contractors for the owners and the whole society. Because the construction contractors master more relevant information about the entrusted engineering project under construction while the owners are in unfavorable position of gaining information, asymmetric information may lead the contractors act against the owners in order to pursue their own interests. Building a powerful motivation mechanism is the key to guarantee investor economic interests and the life and property of users in construction projects. Based on principal-agent theory and game theory, the authors develop relevant mathematical models to analyze and compare the contractor’s utility functions under different combinations of contracts’ explicit incentive mechanism and reputation’s implicit incentive mechanism aiming at finding out the conditions for incentive validity. The research concludes that the most rational motivation way is to combine the explicit and implicit incentive effects of both contracts and reputation mechanism, and puts forth some measures for problems on account of China’s current situation.

Keywords: construction contractors, contract, reputation, incentive mechanism

Procedia PDF Downloads 481

Authors: Yoke-Mui Lim, Yahaya Ahmad

Abstract:

Conservation works in Malaysia that is procured by public organisation usually follow the traditional approach where the works are tendered based on Bills of Quantities (BQ). One of the purposes of tendering is to enable the selection of a competent contractor that offers a competitive price. While competency of the contractors are assessed by their technical knowledge, experience and track records, the assessment of pricing will be dependent on the tender amount. However, the issue currently faced by the conservation works sector is the difficulty in assessing the competitiveness and reasonableness of the tender amount due to the high variance between the tenders amount. Thus, this paper discusses the factors that cause difficulty to the tenderers in pricing competitively in a bidding exercise for conservation tenders. Data on tendering is collected from interviews with conservation works contractors to gain in-depth understanding of the barriers faced in pricing tenders of conservation works. Findings from the study lent support to the contention that the variance of tender amount is very high amongst tenderers. The factors identified in the survey are the format of BQ, hidden works, experience and labour and material costs.

Keywords: building conservation, Malaysia, bill of quantities, tender

Procedia PDF Downloads 346

Authors: J. Koiso-Kanttila, A. Soikkeli, A. Aapaoja

Abstract:

Construction in Finland is focusing increasingly on renovation instead of conventional new construction, and this trend will continue to grow in the coming years and decades. Renovation of the large number of suburban residential apartment buildings built in the 1960s and 1970s poses a particular challenge. However, renovation projects are demanding for the residents of these buildings, since they usually are uninitiated in construction issues. On the other hand, renovation projects generally apply the operating models of new construction. Nevertheless, the residents of an existing residential apartment building are some of the best experts on the site. Thus, in this research project we applied a relational model in developing and testing at case sites a planning process that employs interactive planning methods. Current residents, housing company managers, the city zoning manager, the contractor’s and prefab element supplier’s representatives, professional designers and researchers all took part in the planning. The entire interactive planning process progressed phase by phase as the participants’ and designers’ concerted discussion and ideation process, so that the end result was a renovation plan desired by the residents.

Keywords: apartment building renovation, interactive planning, project alliance, user-orientedness

Procedia PDF Downloads 353

Authors: Abdulaziz Alnajem, Amit Sharma

Abstract:

Business Case: Project delivery and enhancing activities' completion in the shortest possible time is critical during execution to proceed with the subsequent phases of Procurement, C & C phases of Contracts to have the required Production facilities/Infrastructure in place to achieve the Company strategic objective of 4.0 MBOPD oil production. SOR (Statement of requirement): Design and Engineering phase of Projects execution takes a long time. It is observed that, in most of the cases, company has crossed the Project Design Submittals review time as per the Contract/Company Standards, resulting into delays in projects completion, and cost impact to the company. Study Scope: Scope of the study covers the process from date of first submission of D & E documents by the contractor to final approval by the controlling team to proceed with the procurement of materials. This scope covers projects handled by the company’s project management teams and includes only the internal review process by the company.

Keywords: business management system, project management, oil and gas, analysis, improvement, design, delays

Procedia PDF Downloads 187

Authors: Shahin Shabani, Pouya Pourmadadi

Abstract:

Tunnel boring machines (TBMs) have been used for the construction of various tunnels for mining projects for the purpose of access, conveyance of ore and waste, drainage, exploration, water supply and water diversion. Several mining projects have seen the successful and economic beneficial use of TBMs, and there is an increasing awareness of the benefits of TBMs for mining projects. Key technical considerations for the use of TBMs for the construction of tunnels for mining projects include geological issues (rock type, rock alteration, rock strength, rock abrasivity, durability, ground water inflows), depth of cover and the potential for overstressing/rockbursts, site access and terrain, portal locations, TBM constraints, minimum tunnel size, tunnel support requirements, contractor and labor experience, and project schedule demands. This study focuses on tunnelling mining, with the goal to develop methods and tools to be used to gain understanding of these processes, and to analyze metro of Tehran. The Metro Line 7 of Tehran is one of the Longest (26 Km) and deepest (27m) of projects that’s under implementation. Because of major differences like passing under all geotechnical layers of the town and encountering part of it with underground water table and also using mechanized excavation system, is one of special metro projects.

Keywords: TBM, tunnel boring machines economic, metro, line 7

Procedia PDF Downloads 353

Authors: S. U. Kunya, S. Abdulkadir, M. A. Anas, L. Z. Adam

Abstract:

Procurement methods is described as systems of contractual arrangements used by the contractor in order to secure the design and construction services based on the stipulated cost and within the required time and quality. Despite that, major projects in the Nigerian construction industry failed because of wrong procurement methods with major consequences leads to cost overrun which needs to find lasting solution. The aim of the study is to evaluate the influence of procurement methods on cost performance of building projects in Gombe State, Nigeria. Study adopts descriptive and explorative design approach. Data were collected through administering of one hundred questionnaire using convenient sampling techniques. Data analyses using percentages, mean value and Anova analysis. Major finding show that more than fifty percent (50%) of procurement methods available are mainly utilized in the study area and the top procurement methods that have high impacts on cost performance as compare with the other methods is project management and direct labour procurement methods. The results of hypothesis’ tests with pvalue 0.12 and 0.07 validated that there was no significant variation in the perception of stakeholders’ on the impacts of procurements methods on cost performance. Therefore, the study concluded that projects management and direct labour are the most appropriate procurement methods that will ensure successful completion of project at stipulated cost in building projects.

Keywords: cost, effects, performance, procurement, projects

Procedia PDF Downloads 198

Authors: K.Ishii, T. Furuichi, A. Fujiyama, S. Hariya

Abstract:

Rice straw pellets are a promising fuel as a renewable energy source. Financial analysis is needed to make a utilization system using rise straw pellets financially feasible, considering all regional conditions including stakeholders related to the collection and storage, production, transportation and heat utilization. We conducted the financial analysis of feasibility for a heat utilization system using rice straw pellets which has been developed for the first time in Nanporo, Hokkaido, Japan. Especially, we attempted to clarify the effect of factors required for the system to be financial feasibility, such as the heating energy demand and collection and storage method of rice straw. The financial feasibility was found to improve when increasing the heating energy demand and collecting wheat straw in August separately from collection of rice straw in November because the costs of storing rice straw and producing pellets were reduced. However, the system remained financially unfeasible. This study proposed a contractor program funded by a subsidy from Nanporo local government where a contracted company, instead of farmers, collects and transports rice straw in order to ensure the financial feasibility of the system, contributing to job creation in the region.

Keywords: rice straw, pellets, heating energy demand, collection, storage

Procedia PDF Downloads 379

Authors: Kamal Bahrin Jaafar

Abstract:

The study area is located at Bukit Kukus, Penang where the construction of twin road project in ongoing. A landslide event has occurred on 19th October 2018, which causes fatal deaths. The purpose of this study is to figure out the causes of failure, the estimated volume of failure, and its balance. The study comprises of unmanned aerial vehicle (UAV) sensing and resistivity survey. The resistivity method includes spreading three lines of 200m length resistivity survey with the depth of penetration in the subsurface not exceeding 35m. The result of UAV shows the current view of the site condition. Based on resistivity result, the dominant layer in the study area consists of residual soil/filling material with a thickness of more than 35m. Three selected cross sections from construction drawing are overlain with the current cross sections to understand more on the condition of the subsurface profile. By comparison, there is a difference between past and present topography. The combination of result from the previous data and current condition shows the calculated volume of failure is 85,000 m³, and its balance is 50,000 m³. In conclusion, the failure occurs since the contractor has conducted the construction works without following the construction drawing supplied by the consultant. Besides, the cause of failure is triggered by the geology condition, such as a fault that should be considered prior to the commencement of work.

Keywords: UAV, landslide, resistivity survey, cause of failure

Procedia PDF Downloads 89

Authors: Safitri W. Nur, Prathisto Panuntun L. Unggul, M. Ivan Adi Perdana, R. Dary Wira Mahadika

Abstract:

On soft soil areas, high embankment as a preloading needed to improve the bearing capacity of the soil. For sustainable development, the construction of embankment must not disturb the area around of them. So, the influence area must be known before the contractor applied their embankment design. For several cases in Indonesia, the area around of embankment construction is housing resident and other building. So that, the influence area must be identified to avoid the differential settlement occurs on the buildings around of them. Differential settlement causes the building crack. Each building has a limited tolerance for the differential settlement. For concrete buildings, the tolerance is 0,002 – 0,003 m and for steel buildings, the tolerance is 0,006 – 0,008 m. If the differential settlement stands on the range of that value, building crack can be avoided. In fact, the settlement around of embankment is assumed as zero. Because of that, so many problems happen when high embankment applied on soft soil area. This research used the superposition method combined with plaxis analysis to know the influences area around of embankment in some location with the differential characteristic of the soft soil. The undisturbed soil samples take on 55 locations with undisturbed soil samples at some soft soils location in Indonesia. Based on this research, it was concluded that the effects of embankment variation are if more gentle the slope, the influence area will be greater and vice versa. The largest of the influence area with h initial embankment equal to 2 - 6 m with slopes 1:1, 1:2, 1:3, 1:4, 1:5, 1:6, 1:7, 1:8 is 32 m from the edge of the embankment.

Keywords: differential settlement, embankment, influence area, slope, soft soil

Procedia PDF Downloads 380

Authors: Abdul Aziz Abdullah, Anuar Alias, Khor Hooi Ting, Guan Ngah Mei

Abstract:

One of the major sectors which contribute significant growth to socio-economic development is the construction and development industry. This industry is most badly hurt during the 1997 and 2008 economic crisis thus causing many government and private projects to be deferred and abandoned. The purpose of this study is to examine the causes and effects of housing project abandonment in Malaysia. This objective is achieved through rigorous review of literatures and documents related to housing and abandoned housing project. The finding revealed there are several causes of housing project abandonment. The significant causes are: economic recession, inadequacy of finance, poor marketing and sales strategies, technical problems faced during construction, problems caused by compensations demanded by squatters for resettlement, insolvency of contractor, cost overrun and currency fluctuation amongst others. However the alarming effect of housing project is: house buyers of abandoned project have the monthly payment although the house is delivered to house buy. In other case house buyers have to entangle in many legal action with the financial institution. This finding provides the various ministries in the Government some insights on real causes and effects of abandoned project. Perhaps this finding can enhance the current solution the Ministry of Housing Local Government on addressing the prevailing issue of reviving existing abandoned project in the country.

Keywords: abandoned project, abandonment, housing project, ministry of housing and local government, causes and effect

Procedia PDF Downloads 506

Authors: Maryam Kamali Nezhad

Abstract:

As part of the project to rehabilitate the main spillway ("main") of the Rapides-des-Îles development in 2019, it was noted that there is a difference between the water level of the intake gauge and the level measured at the main spillway. The Rapides-des-Îles Generating Station is a Hydro-Québec hydroelectric generating station and dam located on the Ottawa River in the Abitibi-Témiscamingue administrative region of Québec. This plant, with an installed capacity of 176 MW, was commissioned in 1966. During the start-up meeting held at the site in May 2019, it was noticed that the water level upstream of the main spillway was considerably higher than the water level at the powerhouse intake. Measurements showed that the level was 229.46 m, whereas the normal operating level (NOL) and the critical maximum level (CML) used in the design were 228.60 m and 229.51 m, respectively. Considering that the water level had almost reached the maximum critical level of the structure despite a flood with a recurrence period of about 100 years, the work was suspended while the project was being decided. This is the first time since the Rapides des îles project was commissioned that a significant difference in elevation between the water level at the powerhouse (intake) and the main spillway has been observed. Following this observation, the contractor's work was suspended. The objective of this study is to identify the reason(s) for this problem and find solutions. Then determine the new upstream levels at the main spillway at which the safety of the structure is ensured and then adjust the engineering of the main spillway in the rehabilitation project accordingly.

Keywords: spillway, rehabilitation, water level, powerhouse, normal operating level, critical maximum level, safety of the structure

Procedia PDF Downloads 42

Authors: S. Abdulkadir, I. Y. Moh’d, S. U. Kunya, U. Nuruddeen

Abstract:

The basis of any contract formation between the client and contractor is the budgeted cost and the estimated duration of projects. These variables are paramount important to project's sponsor in a construction projects and in assessing the success or viability of construction projects. Despite the availability of various techniques of cost and time control, many projects failed to achieve their initial estimated cost and time. The paper evaluate the inhibiting factors of cost and time control in Nigerian construction practice and comparing the result with the United Kingdom practice as identified by one researcher. The populations of the study are construction professionals within Bauchi and Gombe state, Nigeria, a judgmental sampling employed in determining the size of respondents. Descriptive statistics used in analyzing the data in SPSS. Design change, project fraud and corruption, financing and payment of completed work found to be common among the top five inhibiting factors of cost and time control in the study area. Furthermore, the result had shown some comprising with slight contrast as in the case of United Kingdom practice. Study recommend the adaptation of mitigation measures developed in the UK prior to assessing its effectiveness and so also developing a mitigating measure for other top factors that are not within the one developed in United Kingdom practice. Also, it recommends a wider assessing comparison on the modify inhibiting factors of cost and time control as revealed by the study to cover almost all part of Nigeria.

Keywords: comparison, cost, inhibiting factor, United Kingdom, time

Procedia PDF Downloads 412

Authors: Sim Nee Ting, Lan Eng Ng

Abstract:

Standard forms of contract in Malaysia are pre-written, printed contractual documents drafted by recognised authoritative bodies in order to describe the rights and obligations of the contracting parties in all construction projects in Malaysia. Studies and form revisions are usually conducted in a relatively random and qualitative manner, but the search of contractual documents idealization remains. It is not clear how these qualitative findings could be helpful for contractual documents improvements and re-drafting. This study aims to quantitatively and systematically analyse and evaluate the rights and obligations of the contracting parties as stated in the standard forms of contract. The Institution of Engineers Malaysia (IEM) published a new standard form of contract in 2012 with a total of 63 classes but the improvements and changes in the newly revised form that are yet to be analysed. IEM form will be used as the case study for this study. Every clause in this said form were interpreted and analysed according to the involved parties including contractor, engineer and employer. Modified from Matrix Method and Likert Scale, the result analysis were conducted based on a scale from 0 to 1 with five ratings namely “Very Unbalance”, “Unbalance”, “Balance”, “Good Balance” and “Very Good Balance”. It is hoped that quantitative method of form study can be used for future form revisions and any new forms drafting so to reduce on any subjectivity in standard forms of contract studies.

Keywords: contracting parties, Malaysia, obligations, quantitative measurement, rights, standard form of contract

Procedia PDF Downloads 240

Authors: Imtiaz Ali, Imam Mansoor

Abstract:

Investigations as a part of the academic study were undertaken to identify and evaluate the significant risks associated with the construction of K-span buildings in the region of UAE. Primary field data was collected through questionnaires obtaining specific open and close-ended questions from carefully selected construction firms, civil engineers and, construction manager regarding risks associated to K-span building construction. Historical data available for other regions of the same construction technique was available which was compared for identifying various non-critical and critical risk parameters by comparative evaluation techniques to come up with important risks and potential sources for their control and minimization in K-Span buildings that is increasing in the region. The associated risks have been determined with their Relative Importance Index (RII) values of which Risk involved in Change of Design required by Owners carries the highest value (RII=0.79) whereas, Delayed Payment by Owner to Contractor is one of the least (RII=0.42) value. The overall findings suggest that most relative risks as quantified originate or associated with the contractors. It may be concluded that project proponents undertaking K-span projects in planning and budgeting the cost and delays should take into account of risks on high account if changes in design are also required any delays in the material by the supplier would then be a major risk in K-span project delay. Since projects are, less costly, so owners have limited budgets, then they hire small contractors, which are not highly competent contractors. So study suggests that owner should be aware of these types of risks associated with the construction of K-span buildings in order to make it cost effective.

Keywords: k-span buildings, k-span construction, risk management, relative improvement index (RII)

Procedia PDF Downloads 352

Authors: Balimu Mwiya, Mundia Muya, Chabota Kaliba, Peter Mukalula

Abstract:

Factors affecting construction unit cost vary depending on a country’s political, economic, social and technological inclinations. Factors affecting construction costs have been studied from various perspectives. Analysis of cost factors requires an appreciation of a country’s practices. Identified cost factors provide an indication of a country’s construction economic strata. The purpose of this paper is to identify the essential factors that affect unit cost estimation and their breakdown using artificial neural networks. Twenty-five (25) identified cost factors in road construction were subjected to a questionnaire survey and employing SPSS factor analysis the factors were reduced to eight. The 8 factors were analysed using the neural network (NN) to determine the proportionate breakdown of the cost factors in a given construction unit rate. NN predicted that political environment accounted 44% of the unit rate followed by contractor capacity at 22% and financial delays, project feasibility, overhead and profit each at 11%. Project location, material availability and corruption perception index had minimal impact on the unit cost from the training data provided. Quantified cost factors can be incorporated in unit cost estimation models (UCEM) to produce more accurate estimates. This can create improvements in the cost estimation of infrastructure projects and establish a benchmark standard to assist the process of alignment of work practises and training of new staff, permitting the on-going development of best practises in cost estimation to become more effective.

Keywords: construction cost factors, neural networks, roadworks, Zambian construction industry

Procedia PDF Downloads 332

Authors: K. Raja Rajan, D. Nagarajan

Abstract:

Bored cast in-situ pile is a popular choice amongst consultant and contractor due to the ability to adjust the pile length suitably in case if any variation found in the actual geological strata. Bangladesh geological strata are dominated by silt content. Design is normally based on field test such as Standard Penetration test N-values. Initially, pile capacity estimated through static formula with co-relation of N-value and angle of internal friction. Initial pile load test was conducted in order to validate the geotechnical parameters assumed in design. Initial pile load test was conducted on 1.5m diameter bored cast in-situ pile. Kentledge method is used to load the pile for 2.5 times of its working load. Initially, safe working load of pile has been estimated as 570T, so test load is fixed to 1425T. Max load applied is 777T for which the settlement reached around 155mm which is more than 10% of diameter of piles. Pile load test results was not satisfactory and compelled to increase the pile length approximately 20% of its total length. Due to unpredictable geotechnical parameters, length of each pile has been increased which is having a major impact on the project cost and as well as in project schedule. Extra bore holes have been planned along with lab test results in order to redefine the assumed geotechnical parameters. This article presents detailed design assumptions of geotechnical parameters in the design stage and the results of pile load test which made to redefine the assumed geotechnical properties.

Keywords: end bearing, pile load test, settlement, shaft friction

Procedia PDF Downloads 230