Search results for: two delays

Authors: Natalia Rudeli, Elisabeth Viles, Adrian Santilli

Abstract:

Delays in the construction industry are a global phenomenon. Many construction projects experience extensive delays exceeding the initially estimated completion time. The main purpose of this study is to identify construction projects typical behaviors in order to develop a prognosis and management tool. Being able to know a construction projects schedule tendency will enable evidence-based decision-making to allow resolutions to be made before delays occur. This study presents an innovative approach that uses Cluster Analysis Method to support predictions during Earned Value Analyses. A clustering analysis was used to predict future scheduling, Earned Value Management (EVM), and Earned Schedule (ES) principal Indexes behaviors in construction projects. The analysis was made using a database with 90 different construction projects. It was validated with additional data extracted from literature and with another 15 contrasting projects. For all projects, planned and executed schedules were collected and the EVM and ES principal indexes were calculated. A complete linkage classification method was used. In this way, the cluster analysis made considers that the distance (or similarity) between two clusters must be measured by its most disparate elements, i.e. that the distance is given by the maximum span among its components. Finally, through the use of EVM and ES Indexes and Tukey and Fisher Pairwise Comparisons, the statistical dissimilarity was verified and four clusters were obtained. It can be said that construction projects show an average delay of 35% of its planned completion time. Furthermore, four typical behaviors were found and for each of the obtained clusters, the interim milestones and the necessary rhythms of construction were identified. In general, detected typical behaviors are: (1) Projects that perform a 5% of work advance in the first two tenths and maintain a constant rhythm until completion (greater than 10% for each remaining tenth), being able to finish on the initially estimated time. (2) Projects that start with an adequate construction rate but suffer minor delays culminating with a total delay of almost 27% of the planned time. (3) Projects which start with a performance below the planned rate and end up with an average delay of 64%, and (4) projects that begin with a poor performance, suffer great delays and end up with an average delay of a 120% of the planned completion time. The obtained clusters compose a tool to identify the behavior of new construction projects by comparing their current work performance to the validated database, thus allowing the correction of initial estimations towards more accurate completion schedules.

Keywords: cluster analysis, construction management, earned value, schedule

Procedia PDF Downloads 262

Authors: Sabri Arik

Abstract:

In this paper, we study the global asymptotic robust stability of delayed neural networks with norm-bounded uncertainties. By employing the Lyapunov stability theory and Homeomorphic mapping theorem, we derive some new types of sufficient conditions ensuring the existence, uniqueness and global asymptotic stability of the equilibrium point for the class of neural networks with discrete time delays under parameter uncertainties and with respect to continuous and slopebounded activation functions. An important aspect of our results is their low computational complexity as the reported results can be verified by checking some properties symmetric matrices associated with the uncertainty sets of network parameters. The obtained results are shown to be generalization of some of the previously published corresponding results. Some comparative numerical examples are also constructed to compare our results with some closely related existing literature results.

Keywords: neural networks, delayed systems, lyapunov functionals, stability analysis

Procedia PDF Downloads 524

Authors: Nnadi Ezekiel Oluwaseun Ejiofor

Abstract:

This research investigates the effects of poor cost estimation, material cost variations, and payment punctuality on the financial health and execution of construction projects in Nigeria. To achieve the objectives of the study, a quantitative research approach was employed, and data was gathered through an online survey of 74 construction industry professionals consisting of quantity surveyors, contractors, and other professionals. The study surveyed input on cost estimation errors, price fluctuations, and payment delays, among other factors. The responses of the respondents were analyzed using a five-point Likert scale and the Relative Importance Index (RII). The findings demonstrated that the errors in cost estimating in the Bill of Quantity (BOQ) have a high degree of negative impact on the reputation and image of the participants in the projects. The greatest effect was experienced on the likelihood of obtaining future endeavors for contractors (mean value = 3.42), followed by the likelihood of obtaining new commissions by quantity surveyors (mean value = 3.40). The level of inaccuracy in costing that undershoots exposes them to risks was most serious in terms of easement of construction and effects of shortage of funds to pursue bankruptcy (hence fears of mean value = 3.78). There was also considerable financial damage as a result of cost underestimation, whereby contractors suffered the worst loss in profit (mean value = 3.88). Every expense comes with its own peculiar risk and uncertainty. Pressure on the cost of materials and every other expense attributed to the building and completion of a structure adds risks to the performance figures of a project. The greatest weight (mean importance score = 4.92) was attributed to issues like market inflation in building materials, while the second greatest weight (mean importance score = 4.76) was due to increased transportation charges. On the other hand, delays in payments arising from issues of the clients like poor availability of funds (RII=0.71) and contracting issues such as disagreements on the valuation of works done (RII=0.72) or other reasons were also found to lead to project delays and additional costs. The results affirm the importance of proper cost estimation on the health of organization finances and project risks and finishes within set time limits. As for the suggestions, it is proposed to progress on the methods of costing, engender better communications with the stakeholders, and manage the delays by way of contracting and financial control. This study enhances the existing literature on construction project management by suggesting ways to deal with adverse cost inaccuracies and availability of materials due to delays in payments which, if addressed, would greatly improve the economic performance of the construction business.

Keywords: cost estimation, construction project management, material price fluctuations, payment delays, financial impact

Procedia PDF Downloads 4

Authors: Masri Baharom

Abstract:

The purpose of the study is to identify the age group of children 9 who have experienced delays in gross motor development. Instrument used in this study is Test Gross Motor Development / TGMD-2 (Ulrich, 2000) which was adopted at the international level. Gross motor development data were obtained by video recording (Sony (DRC-SR42 with a 40x optical zoom capability, and software Ultimate Studio 14) on locomotor and manipulative skills. A total n = 192 persons, children of 9 years (9.30 ± .431) at Sekolah Kebangsaan Mutiara Perdana, Bayan Lepas, Penang were involved as subjects. Children age 9 years experienced delays AELS (4.61 ± .69), AEMS (5:52 ± .62) and GMDQ (7.26 ± .2.14). The findings based on descriptive rating indicated that the performance of children age 9 years acquired low levels of AELS, MSS, AEMS and very low in LSS and GMDS.

Keywords: gross motor development score, locomotor standard score, age equivalent locomotor score, manipulative standard score, age equivalent manipulative score

Procedia PDF Downloads 442

Authors: Mamoon M. Atout

Abstract:

The Middle East Gulf region has witnessed rapid growth and development in many areas over the last two decades. The development of the real-estate sector, construction industry and infrastructure projects are a major share of the development that has participated in the civilization of the countries of the Gulf. Construction industry projects were planned and managed by different types of experts, who came from all over the world having different types of experiences in construction management and industry. Some of these projects were completed on time, while many were not, due to many accumulating factors. Many accumulated factors are considered as the principle reason for the problem experienced at the project construction stage, which reflected negatively on the project success. Specific causes of delay have been identified by construction managers to avoid any unexpected delays through proper analysis and considerations to some implications such as risk assessment and analysis for many potential problems to ensure that projects will be delivered on time. Construction management implications were adopted and considered by project managers who have experience and knowledge in applying the techniques of the system of engineering construction management. The aim of this research is to determine the benefits of the implications of construction management by the construction team and level of considerations of the techniques and processes during the project development and construction phases to avoid any delay in the projects. It also aims to determine the factors that participate to project completion delays in case project managers are not well committed to their roles and responsibilities. The results of the analysis will determine the necessity of the applications required by the project team to avoid the causes of delays that help them deliver projects on time, e.g. verifying tender documents, quantities and preparing the construction method of the project.

Keywords: construction management, control process, cost control, planning and scheduling

Procedia PDF Downloads 245

Authors: Dongwon Lee, Sunmyeng Kim

Abstract:

Underwater acoustic networks (UANs) have become a very active research area in recent years. Compared with wireless networks, UANs are characterized by the limited bandwidth, long propagation delay and high channel dynamic in acoustic modems, which pose challenges to the design of medium access control (MAC) protocol. The characteristics severely affect network performance. In this paper, we study a MS-MAC (Multi-Sender MAC) protocol in order to improve network performance. The proposed protocol exploits temporal reuse by learning the propagation delays to neighboring nodes. A source node locally calculates the transmission schedules of its neighboring nodes and itself based on the propagation delays to avoid collisions. Performance evaluation is conducted using simulation, and confirms that the proposed protocol significantly outperforms the previous protocol in terms of throughput.

Keywords: acoustic channel, MAC, temporal reuse, UAN

Procedia PDF Downloads 347

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 507

Authors: Ahmad Hashim, Masri Baharom

Abstract:

The purpose of the study is to identify the age group of children 9 who have experienced delays in gross motor development. Instrument used in this study is Test Gross Motor Development / TGMD-2 (Ulrich, 2000) which was adopted at the international level. Gross motor development data were obtained by video recording (Sony (DRC-SR42 with a 40x optical zoom capability, and software Ultimate Studio 14) on locomotor and manipulative skills. A total n = 192 persons, children of 9 years (9.30 ± .431) at Sekolah Kebangsaan Mutiara Perdana, Bayan Lepas, Penang were involved as subjects. Children age 9 years experienced delays AELS (4.61 ± .69), AEMS (5:52 ± .62) and GMDQ (7.26 ± .2.14). The findings based on descriptive rating indicated that the performance of children age 9 years acquired low levels of AELS, MSS, AEMS and very low in LSS and GMDS.

Keywords: gross motor development score, locomotor standard score, age equivalent locomotor score, manipulative standard score, age equivalent manipulative score

Procedia PDF Downloads 408

Authors: Rolla Monib, Chris I. Goodier, Alistair Gibbs

Abstract:

The aim of this paper is to investigate the key drivers in planning the construction phase for infrastructure projects to reduce project delays. To achieve this aim, the research conducted three case studies using semi-structured and unstructured interviews (n=36). The results conclude that a lack of modularisation awareness is among the key factors attributed to project delays. The current emotive and ill-informed approach to decision-making, coupled with the lack of knowledge regarding appropriate construction method selection, prevents the potential benefits of modularisation being fully realised. To assist with decision-making for the best construction method, the research presents project management tools to help decision makers to choose the most appropriate construction approach through optimising the use of modularisation in EC. A decision-making checklist and diagram are presented in this paper. These checklist tools and diagrams assist the project team in determining the best construction method, taking into consideration the module type.

Keywords: infrastructure, modularization, decision support, decision-making

Procedia PDF Downloads 59

Authors: Zarabizan Zakaria, Syuhaida Ismail, Aminah Md. Yusof

Abstract:

Project management process starts from the planning stage up to the stage of completion (handover of buildings, preparation of the final accounts and the closing balance). This process is not easy to implement efficiently and effectively. The issue of delays in construction is a major problem for construction projects. These delays have been blamed mainly on inefficient traditional construction practices that continue to dominate the current industry. This is due to several factors, such as environments of construction technology, sophisticated design and customer demands that are constantly changing and influencing, either directly or indirectly, the practice of management. Among the identified influences are physical environment, social environment, information environment, political and moral atmosphere. Therefore, this paper is emerged to determine the problem and issues in the final account closing in construction projects, and it establishes the need to embrace Supply Chain Management (SCM) and then elucidates the need and strategies for the development of a delay reduction framework. At the same time, this paper provides effective measures to avoid or at least reduce the delay to the optimum level. Allowing problems in the closure declaration to occur without proper monitoring and control can leave negative impact on the cost and time of delivery to the end user. Besides, it can also affect the reputation or image of the agency/department that manages the implementation of a contract and consequently may reduce customer's trust towards the agencies/departments. It is anticipated that the findings reported in this paper could address root delay contributors and apply SCM tools for their mitigation for the better development of construction project.

Keywords: final account closing, construction project, construction delay, supply chain management

Procedia PDF Downloads 365

Authors: Khan Farhan Rafat, Riaz Ahmed

Abstract:

Renowned offshore organizations are drifting towards collaborative exertion to win and implement international projects for business gains. However, devoid of financial constraints, with the availability of skilled professionals, and despite improved project management practices through state-of-the-art tools and techniques, project delays have become a norm these days. This situation calls for exploring the factor(s) affecting the bonding between project management performance and project success. In the context of the well-known 3M’s of project management (that is, manpower, machinery, and materials), machinery and materials are dependent upon manpower. Because the body of knowledge inveterate on the influence of national culture on men, hence, the realization of the impact on the link between project management performance and project success need to be investigated in detail to arrive at the possible cause(s) of project delays. This research initiative was, therefore, undertaken to fill the research gap. The unit of analysis for the proposed research excretion was the individuals who had worked on skyscraper construction projects. In reverent studies, project management is best described using construction examples. It is due to this reason that the project oriented city of Dubai was chosen to reconnoiter on causes of project delays. A structured questionnaire survey was disseminated online with the courtesy of the Project Management Institute local chapter to carry out the cross-sectional study. The Construction Industry Institute, Austin, of the United States of America along with 23 high-rise builders in Dubai were also contacted by email requesting for their contribution to the study and providing them with the online link to the survey questionnaire. The reliability of the instrument was warranted using Cronbach’s alpha coefficient of 0.70. The appropriateness of sampling adequacy and homogeneity in variance was ensured by keeping Kaiser–Meyer–Olkin (KMO) and Bartlett’s test of sphericity in the range ≥ 0.60 and < 0.05, respectively. Factor analysis was used to verify construct validity. During exploratory factor analysis, all items were loaded using a threshold of 0.4. Four hundred and seventeen respondents, including members from top management, project managers, and project staff, contributed to the study. The link between project management performance and project success was significant at 0.01 level (2-tailed), and 0.05 level (2-tailed) for Pearson’s correlation. Before initiating the moderator analysis test for linearity, multicollinearity, outliers, leverage points and influential cases, test for homoscedasticity and normality were carried out which are prerequisites for conducting moderator review. The moderator analysis, using a macro named PROCESS, was performed to verify the hypothesis that national culture has an influence on the said link. The empirical findings, when compared with Hofstede's results, showed high power distance as the cause of construction project delays in Dubai. The research outcome calls for the project sponsors and top management to reshape their project management strategy and allow for low power distance between management and project personnel for timely completion of projects.

Keywords: causes of construction project delays, construction industry, construction management, power distance

Procedia PDF Downloads 212

Authors: A. Van Staden, N. Purcell

Abstract:

Spelling development is complex and multifaceted and relies on several cognitive-linguistic processes. This paper explored the spelling difficulties of English second language learners with auditory processing delays. This empirical study aims to address these issues by means of an intervention design. Specifically, the objectives are: (a) to develop and implement a multi-sensory spelling program for second language learners with auditory processing difficulties (APD) for a period of 6 months; (b) to assess the efficacy of the multi-sensory spelling program and whether this intervention could significantly improve experimental learners' spelling, phonological awareness, and processing (PA), rapid automatized naming (RAN), working memory (WM), word reading and reading comprehension; and (c) to determine the relationship (or interplay) between these cognitive and linguistic skills (mentioned above), and how they influence spelling development. Forty-four English, second language learners with APD were sampled from one primary school in the Free State province. The learners were randomly assigned to either an experimental (n=22) or control group (n=22). During the implementation of the spelling program, several visual, tactile and kinesthetic exercises, including the utilization of fingerspelling were introduced to support the experimental learners’ (N = 22) spelling development. Post-test results showed the efficacy of the multi-sensory spelling program, with the experimental group who were trained in utilising multi-sensory coding and fingerspelling outperforming learners from the control group on the cognitive-linguistic, spelling and reading measures. The results and efficacy of this multi-sensory spelling program and the utilisation of fingerspelling for hearing second language learners with APD open up innovative perspectives for the prevention and targeted remediation of spelling difficulties.

Keywords: English second language spellers, auditory processing delays, spelling difficulties, multi-sensory intervention program

Procedia PDF Downloads 134

Authors: Amadou Banda Ndione, Charles Awono Onana

Abstract:

In this paper the compartmental approach is applied to build a macroeconomic model characterized by countries. We consider a total of N countries that are subdivided into three compartments according to their economic status: D(t) denotes the compartment of developing countries at time t, E(t) stands for the compartment of emerging countries at time t while A(t) represents advanced countries at time t. The model describes the process of economic development and includes the notion of openness through collaborations between countries. Two delays appear in this model to describe the average time necessary for collaborations between countries to become efficient for their development process. Our model represents the different stages of development. It further gives the conditions under which a country can change its economic status and demonstrates the short-term positive effect of openness on economic growth. In addition, we investigate bifurcation by considering the delay as a bifurcation parameter and examine the onset and termination of Hopf bifurcations from a positive equilibrium. Numerical simulations are provided in order to illustrate the theoretical part and to support discussion.

Keywords: compartmental systems, delayed dynamical system, economic development, fiscal policy, hopf bifurcation

Procedia PDF Downloads 136

Authors: Vahid Khadjeh Anvary, Hamideh Karimi Yazdi

Abstract:

Generally, the tool of comparison between performance of each stage in the life of a project, is the number of project progress during that period, which in most cases is only determined as one-dimensional with referring to one of three factors (physical, time, and financial). In many projects in developing countries there are controversies on accuracy and the way of analyzing progress report of projects that hinders getting definitive and engineering conclusions on the status of project.Identifying weakness points of this kind of one-dimensional look on project and determining a reliable and engineering approach for multi-dimensional decoding information receivable from project is of great importance in project management.This can be a tool to help identification of hidden diseases of project before appearing irreversible symptoms that are usually delays or increased costs of execution. The method used in this paper is defining and evaluating a hypothetical project as an example analyzing different scenarios and numerical comparison of them along with related graphs and tables. Finally, by analyzing different possible scenarios in the project, possibility or impossibility of predicting their occurrence is examine through the evidence.

Keywords: physical progress, time progress, financial progress, delays, critical path

Procedia PDF Downloads 371

Authors: Vincent King Soon Wong, Hong Seng Ng, Florinna Sim

Abstract:

Negative Bias Temperature Instability (NBTI) is one of the critical degradation mechanisms in semiconductor device reliability that causes shift in the threshold voltage (Vth). However, thorough understanding of this reliability failure mechanism is still unachievable due to a recovery characteristic known as NBTI recovery. This paper will demonstrate the severity of NBTI recovery as well as one of the effective methods used to mitigate, which is the minimization of measurement system delays. Comparison was done in between two measurement systems that have significant differences in measurement delays to show how NBTI recovery causes result deviations and how fast measurement systems can mitigate NBTI recovery. Another method to minimize NBTI recovery without the influence of measurement system known as Fast Wafer Level Reliability (FWLR) NBTI was also done to be used as reference.

Keywords: fast vs slow BTI, fast wafer level reliability (FWLR), negative bias temperature instability (NBTI), NBTI measurement system, metal-oxide-semiconductor field-effect transistor (MOSFET), NBTI recovery, reliability

Procedia PDF Downloads 423

Authors: Sanat Ramesh, Tarun Dutt, Abhilasha Aswal, Anushka Chandrababu, G. N. Srinivasa Prasanna

Abstract:

Optimal Schedule Generation for a large national railway network operating thousands of passenger trains with tens of thousands of kilometers of track is a grand computational challenge in itself. We present heuristics based on a Mixed Integer Program (MIP) formulation for local optimization. These methods provide flexibility in scheduling new trains with varying speed and delays and improve utilization of infrastructure. We propose methods that provide a robust solution with hundreds of trains being scheduled over a portion of the railway network without significant increases in delay. We also provide techniques to validate the nominal schedules thus generated over global correlated variations in travel times thereby enabling us to detect conflicts arising due to delays. Our validation results which assume only the support of the arrival and departure time distributions takes an order of few minutes for a portion of the network and is computationally efficient to handle the entire network.

Keywords: mixed integer programming, optimization, railway network, train scheduling

Procedia PDF Downloads 158

Authors: Awad Khireldin, Colin Law

Abstract:

Runways are the major infrastructure of airports around the world. Efficient operations of runways are key to ensure that airports are running smoothly with minimal delays. There are many factors that affect the efficiency of runway operations, such as the aircraft wake separation, runways system configuration, the fleet mix, and the runways separation distance. This paper aims to address how to maximize runway operations using a Discrete Event Simulation model. A case study of Cairo International Airport (CIA) is developed to maximize the utilizing of three parallel runways using a simulation model. Different scenarios have been designed where every runway could be assigned for arrival, departure, or mixed operations. A benchmarking study was also included to compare the actual to the proposed results to spot the potential improvements. The simulation model shows that there is a significant difference in utilization and delays between the actual and the proposed ones, there are several recommendations that can be provided to airport management, in the short and long term, to increase the efficiency and to reduce the delays. By including the recommendation with different operations scenarios, such as upgrading the airport slot Coordination from Level 1 to Level 2 in the short term. In the long run, discuss the possibilities to increase the International Air Transport association (IATA) slot coordination to Level 3 as more flights are expected to be handled by the airport. Technological advancements such as radar in the approach full airside simulation model could improve the airport performance where the airport is recommended to review the standard operations procedures with the appropriate authorities. Also, the airport can adopt a future operational plan to accommodate the forecasted additional traffic density in case of adding a fourth terminal building to increase the airport capacity.

Keywords: airport performance, runway, discrete event simulation, capacity, airside

Procedia PDF Downloads 128

Authors: Swati Tyagi, Syed Abbas

Abstract:

Fractional-order Hopfield neural networks are generally used to model the information processing among the interacting neurons. To show the constancy of the processed information, it is required to analyze the stability of these systems. In this work, we perform Mittag-Leffler stability for the corresponding Caputo fractional-order bidirectional associative memory (BAM) neural networks with various time-delays. We derive sufficient conditions to ensure the existence and uniqueness of the equilibrium point by using the theory of topological degree theory. By applying the fractional Lyapunov method and Mittag-Leffler functions, we derive sufficient conditions for the global Mittag-Leffler stability, which further imply the global asymptotic stability of the network equilibrium. Finally, we present two suitable examples to show the effectiveness of the obtained results.

Keywords: bidirectional associative memory neural network, existence and uniqueness, fractional-order, Lyapunov function, Mittag-Leffler stability

Procedia PDF Downloads 362

Authors: Abdulaziz Alnajem, Amit Sharma

Abstract:

Business Case: Project delivery and enhancing activities' completion in the shortest possible time is critical during execution to proceed with the subsequent phases of Procurement, C & C phases of Contracts to have the required Production facilities/Infrastructure in place to achieve the Company strategic objective of 4.0 MBOPD oil production. SOR (Statement of requirement): Design and Engineering phase of Projects execution takes a long time. It is observed that, in most of the cases, company has crossed the Project Design Submittals review time as per the Contract/Company Standards, resulting into delays in projects completion, and cost impact to the company. Study Scope: Scope of the study covers the process from date of first submission of D & E documents by the contractor to final approval by the controlling team to proceed with the procurement of materials. This scope covers projects handled by the company’s project management teams and includes only the internal review process by the company.

Keywords: business management system, project management, oil and gas, analysis, improvement, design, delays

Procedia PDF Downloads 215

Authors: S. Aneeka, S.M. Phyoe, R. Guo, Z.W. Zhong

Abstract:

Arrival flights tend to spend long waiting times at holding stacks if the arrival airport is congested. However, the waiting time spent in the air in the vicinity of the arrival airport may be reduced if the delays are distributed to the cruising phase of the arrival flights by means of speed control. Here, a case study was conducted for the flights arriving at Changi Airport. The flights that were assigned holdings were simulated to fly at a reduced speed during the cruising phase. As the study involves a single airport and is limited to imposing speed constraints to arrivals within 200 NM from its location, the simulation setup in this study could be considered as an application of the Extended Arrival Management (E-AMAN) technique, which is proven to result in considerable fuel savings and more efficient management of delays. The objective of this experiment was to quantify the benefits of imposing cruise speed constraints to arrivals at Changi Airport and to assess the effects on controllers’ workload. The simulation results indicated considerable fuel savings, reduced aircraft emissions and reduced controller workload.

Keywords: aircraft emissions, air traffic flow management, controller workload, fuel consumption

Procedia PDF Downloads 143

Authors: Elyce Cardonick, Shistri Dhar, Linsdey Seidman

Abstract:

Background: When breast cancer is diagnosed during pregnancy, the prognosis is comparable to non-pregnant women matched for prognostic indicators when pregnant women receive treatment without delay. Chemotherapy, including taxanes, can be given during pregnancy with normal neonatal development in exposed fetuses. Methods: Cases of primary breast cancer were extracted from the Cancer and Pregnancy Registry and longitudinal study at Cooper Medical School, which collects cases of pregnant women diagnosed and treated for cancer into a single database. Obstetrical, oncology and pediatric records were reviewed, including annual neonatal developmental, behavioral and medical assessments. Results: 270 pregnant women were diagnosed with primary breast cancer at a mean gestational age of 14.7+9weeks. Mean maternal age at diagnosis 34.5+4.5 years. Receptor status is comparable to non-pregnant women of reproductive age. Forty-nine women were advised to terminate. Two hundred two women underwent surgery;244 women received chemotherapy in pregnancy after the first trimester; the majority of Doxorubucin/Cytoxan; 81 of the cases included a taxane. At a mean of 90 months, follow up obtained on 255 newborns.192/255 newborns are meeting developmental milestones. Respiratory illnesses, including asthma, and bronchiolitis, were reported in 64 newborns, the most common medical condition reported. Thirty-one children are undergoing treatment for GERD, 11 for urinary tract infections, and 7 are undergoing treatment for anemia. Twenty-six children with expressive or articulation language delays, 21/26 are mild. Eleven children with gross/ 7 with fine motor delays. Eight children are treated for ADHD, 4 for anxiety and 4 have social skill impairment. The majority of children with developmental, language or motor delays were born preterm. Conclusion: After chemotherapy exposure in utero for breast cancer, the majority of newborns are meeting developmental milestones and are medically healthy. The goal for treating pregnant women with breast cancer is to aim for delivery close to the term.

Keywords: breast cancer, pregnancy, chemotherapy, newborn

Procedia PDF Downloads 115

Authors: Robert Pellerin, Michel Gamache, Remi Trudeau, Nathalie Perrier

Abstract:

The context of large engineering projects is particularly favorable to the appearance of engineering changes and contractual modifications. These elements are potential causes for claims. In this paper, we investigate one of the critical components of the claim management process: the calculation of the impacts of changes in terms of losses of productivity due to the need to accelerate some project activities. When project changes are initiated, delays can arise. Indeed, project activities are often executed in fast-tracking in an attempt to respect the completion date. But the acceleration of project execution and the resulting rework can entail important costs as well as induce productivity losses. In the past, numerous methods have been proposed to quantify the duration of delays, the gains achieved by project acceleration, and the loss of productivity. The calculation related to those changes can be divided into two categories: direct cost and indirect cost. The direct cost is easily quantifiable as opposed to indirect costs which are rarely taken into account during the calculation of the cost of an engineering change or contract modification despite several research projects have been made on this subject. However, proposed models have not been accepted by companies yet, nor they have been accepted in court. Those models require extensive data and are often seen as too specific to be used for all projects. These techniques are also ignoring the resource constraints and the interdependencies between the causes of delays and the delays themselves. To resolve this issue, this research proposes a simulation model that mimics how major engineering changes or contract modifications are handled in large construction projects. The model replicates the use of overtime in a reactive scheduling mode in order to simulate the loss of productivity present when a project change occurs. Multiple tests were conducted to compare the results of the proposed simulation model with statistical analysis conducted by other researchers. Different scenarios were also conducted in order to determine the impact the number of activities, the time of occurrence of the change, the availability of resources, and the type of project changes on productivity loss. Our results demonstrate that the number of activities in the project is a critical variable influencing the productivity of a project. When changes occur, the presence of a large number of activities leads to a much lower productivity loss than a small number of activities. The speed of reducing productivity for 30-job projects is about 25 percent faster than the reduction speed for 120-job projects. The moment of occurrence of a change also shows a significant impact on productivity. Indeed, the sooner the change occurs, the lower the productivity of the labor force. The availability of resources also impacts the productivity of a project when a change is implemented. There is a higher loss of productivity when the amount of resources is restricted.

Keywords: engineering changes, indirect costs overtime, productivity, scheduling, simulation

Procedia PDF Downloads 237

Authors: Omar Amoudi, Latifa Al Brashdi

Abstract:

Construction projects are always subject to risks and uncertainties due to its unique and dynamic nature, outdoor work environment, the wide range of skills employed, various parties involved in addition to situation of construction business environment at large. Altogether, these risks and uncertainties affect projects objectives and lead to cost overruns, delay, and poor quality. Construction projects in Oman often experience cost overruns and delay. Managing these risks and reducing their impacts on construction cost requires firstly identifying these risks, and then analyzing their severity on project cost to obtain deep understanding about these risks. This in turn will assist construction managers in managing and tacking these risks. This paper aims to investigate the main risk factors that affect construction projects cost in the Sultanate of Oman. In order to achieve the main aim, literature review was carried out to identify the main risk factors affecting construction cost. Thirty-three risk factors were identified from the literature. Then, a questionnaire survey was designed and distributed among construction professionals (i.e., client, contractor and consultant) to obtain their opinion toward the probability of occurrence for each risk factor and its possible impact on construction project cost. The collected data was analyzed based on qualitative aspects and in several ways. The severity of each risk factor was obtained by multiplying the probability occurrence of a risk factor with its impact. The findings of this study reveal that the most significant risk factors that have high severity impact on construction project cost are: Change of Oil Price, Delay of Materials and Equipment Delivery, Changes in Laws and Regulations, Improper Budgeting, and Contingencies, Lack of Skilled Workforce and Personnel, Delays Caused by Contractor, Delays of Owner Payments, Delays Caused by Client, and Funding Risk. The results can be used as a basis for construction managers to make informed decisions and produce risk response procedures and strategies to tackle these risks and reduce their negative impacts on construction project cost.

Keywords: construction cost, construction projects, Oman, risk factors, risk management

Procedia PDF Downloads 343

Authors: Osalina Toemapa, Rika Susanti, Husna Yetti

Abstract:

In criminal offense case, such as homicide, investigators may request for an autopsy to the victim without family approval in Indonesia. Generally, there has been decreasing in autopsy rate in the world over past years. Family’s refusal is one of the most common problems. The purpose of this study is to find the correlation between knowledge level and public perception of autopsy on criminal offense victim. This cross-sectional study was done from April to May 2017 in subdistrict Pulau Punjung. Participants were asked to fill the questionnaire. There are 15 questions to asses knowledge level, perception, and factors influencing autopsy refusal. The chi-square test was used for the statistical analysis. Out of the total of 436 respondents, 54,5% were found to have poor knowledge level, and 56,7% were found to have poor perception. There was a significant correlation between knowledge level and public perception (p<0,001). There are 153 respondents who decline autopsy on criminal offense victim with the most factors influencing autopsy refusal is delays in victim’s funeral (92,2%). Conclusion, knowledge level is correlated with public perception in subdistrict of Pulau Punjung, district of Dharmasraya, West Sumatra, Indonesia. Most influencing factor in autopsy refusal is delays in victim’s funeral.

Keywords: knowledge level, public perception, autopsy on criminal offense victim, autopsy refusal

Procedia PDF Downloads 300

Authors: Sulaiman Al-Hinai, Setyawan Widyarto

Abstract:

The aim of this study is to identify the critically dominating factors on the delays of road constructions in the GCC countries and their effects on project delivery in Arab countries. Towards the achieved of the objectives the study used the empirical literature from the all relevant online sources and database as many as possible. The findings of this study have summarized and short listed of the success factors in the two categories such as internal and external factors have caused to be influenced to delay of road constructions in the Arab regions. However, in the category of internal factors, there are 63 factors short listed from seven group of factors which has revealed to effects on the delay of road constructions especially, the consultant related factors, the contractor related factors, designed related factors, client related factors, labor related factors, material related issues, equipment related issues respectively. Moreover, for external related factors are also considered to summarized especially natural disaster (flood, hurricanes and cyclone etc.), conflict, war, global financial crisis, compensation delay to affected property owner, price fluctuated, unexpected ground conditions (soil and high-water level), changing of government regulations and laws, delays in obtaining permission from municipality, loss of time by traffic control and restrictions at job site, problem with inhabitant of community, delays in providing service from utilities (water and electricity’s) and accident during constructions accordingly. The present study also concluded the effects of above factors which has delay road constructions through increasing of cost and overrun it, taken overtime, creating of disputes, going for lawsuits, finally happening of abandon of projects. Thus, the present study has given the following recommendations to overcome of above problems by increasing of detailed site investigations, ensure careful monitoring and regular meetings, effective site management, collaborative working and effective coordination’s, proper and comprehensive planning and scheduling and ensure full and intensive commitment from all parties accordingly.

Keywords: Arab GCC countries, critical success factors, road constructions delay, project management

Procedia PDF Downloads 126

Authors: Shobha Ramalingam

Abstract:

The majority of the infrastructure projects are affected by time overrun, resulting in project delays and subsequently cost overruns. Time overrun may vary from a few months to as high as five or more years, placing the project viability at risk. One of the probable reasons noted in the literature for this outcome in projects is due to poor productivity. Researchers contend that productivity in construction has only marginally increased over the years. While studies in the literature have extensively focused on time and cost parameters in projects, there are limited studies that integrate time and cost with productivity to assess project performance. To this end, a study was conducted to understand the project delay factors concerning cost, time and productivity. A case-study approach was adopted to collect rich data from a nuclear power plant project site for two months through observation, interviews and document review. The data were analyzed using three different approaches for a comprehensive understanding. Foremost, a root-cause analysis was performed on the data using Ishikawa’s fish-bone diagram technique to identify the various factors impacting the delay concerning time. Based on it, a questionnaire was designed and circulated to concerned executives, including project engineers and contractors to determine the frequency of occurrence of the delay, which was then compiled and presented to the management for a possible solution to mitigate. Second, a productivity analysis was performed on select activities, including rebar bending and concreting through a time-motion study to analyze product performance. Third, data on cost of construction for three years allowed analyzing the cost performance using earned value management technique. All three techniques allowed to systematically and comprehensively identify the key factors that deter project performance and productivity loss in the construction of the nuclear power plant project. The findings showed that improper planning and coordination between multiple trades, concurrent operations, improper workforce and material management, fatigue due to overtime were some of the key factors that led to delays and poor productivity. The findings are expected to act as a stepping stone for further research and have implications for practitioners.

Keywords: earned value analysis, time performance, project costs, project delays, construction productivity

Procedia PDF Downloads 96

Authors: Maryam Razmjoee

Abstract:

Physical aggression is one of the most common behavioural problems among children with intellectual disabilities. Behaviours such as hitting, kicking, and threatening with the intent to harm others are examples of physical aggression. Identified language delays are related to physically aggressive behaviours, as children with poor language skills are often frustrated by socially interactions with their peers, leaving them at risk engaging in acts of physical aggression. As a result of this concern, physical aggression and language skills of children with mild intellectual disabilities was investigated. In the current study, 102 students, from years 1-3, with mild intellectual disabilities (51 girls and 51 boys) have been recruited from five educational centres which cater for children with mild intellectual disabilities in the city of Shiraz (a major city in Iran). The Test of Language Development-Primary: 3rd Edition (TOLD-3) and Overt and Relational Aggression Questionnaire were used to assess these children. Results showed that physical aggression had a significant negative association with expressive (p = 0.008), and receptive (p = 0.019) language skills. In addition, boys demonstrated more physically aggressive behaviours than girls (p = 0.014). No difference was found in expressive and receptive language skills between girls and boys with mild intellectual disabilities. The overall findings suggest that improving the language skills of children with intellectual disabilities experiencing language delays will help them to avoid exhibiting antisocial behaviours in social interactions.

Keywords: behaviour, language skills, mild intellectual disabilities, physical aggression, primary school students

Procedia PDF Downloads 229

Authors: Muhammad Ridho Fakhrin, Leni Sagita Riantini, Yusuf Latief

Abstract:

Based on the 2015-2019 RPJMN data, the realization of toll road infrastructure development in Indonesia experienced a delay of 49% or 904 km of the total plan. One of the major causes of delays in development is caused by institutional factors. The case study taken in this research is the construction of the Trans Sumatra Toll Road (JTTS). The purpose of this research is to identify the institutional forms, functions, roles, duties, and responsibilities of each stakeholder and the risks that occur in the Trans Sumatra Toll Road Infrastructure Development. Risk analysis is implemented on functions, roles, duties, responsibilities of each existing stakeholder and is carried out at the Funding Stage, Technical Planning Stage, and Construction Implementation Stage in JTTS. This research is conducted by collecting data through a questionnaire survey, then processed using statistical methods, such as homogeneity, data adequacy, validity, and reliability test, continued with risk assessment based on a risk matrix. The results of this study are the evaluation and development of institutional functions in risk-based JTTS development can improve time performance and minimize delays in the construction process.

Keywords: institutional, risk management, time performance, toll road

Procedia PDF Downloads 162

Authors: Fahad Alhussein, Huaping Liu

Abstract:

This paper compares the multipath mitigation performance of code correlation reference waveform receivers with variable and fixed window width, for binary offset carrier and multiplexed binary offset carrier signals typically used in global navigation satellite systems. In the variable window width method, such width is iteratively reduced until the distortion on the discriminator with multipath is eliminated. This distortion is measured as the Euclidean distance between the actual discriminator (obtained with the incoming signal), and the local discriminator (generated with a local copy of the signal). The variable window width have shown better performance compared to the fixed window width. In particular, the former yields zero error for all delays for the BOC and MBOC signals considered, while the latter gives rather large nonzero errors for small delays in all cases. Due to its computational simplicity, the variable window width method is perfectly suitable for implementation in low-cost receivers.

Keywords: correlation reference waveform receivers, binary offset carrier, multiplexed binary offset carrier, global navigation satellite systems

Procedia PDF Downloads 129

Authors: Panupong Makvichian

Abstract:

Global Navigation Satellite System (GNSS) is nowadays a common technology that improves navigation functions in our life. Additionally, GNSS is also being employed on behalf of an accurate atmospheric sensor these times. Meteorology is a practical application of GNSS, which is unnoticeable in the background of people’s life. GNSS Precise Point Positioning (PPP) is a positioning method that requires data from a single dual-frequency receiver and precise information about satellite positions and satellite clocks. In addition, careful attention to mitigate various error sources is required. All the above data are combined in a sophisticated mathematical algorithm. At this point, the research is going to demonstrate how GNSS and PPP method is capable to provide high-precision estimates, such as 3D positions or Zenith tropospheric delays (ZTDs). ZTDs combined with pressure and temperature information allows us to estimate the water vapor in the atmosphere as precipitable water vapor (PWV). If the process is replicated for a network of GNSS sensors, we can create thematic maps that allow extract water content information in any location within the network area. All of the above are possible thanks to the advances in GNSS data processing. Therefore, we are able to use GNSS data for climatic trend analysis and acquisition of the further knowledge about the atmospheric water content.

Keywords: GNSS, precise point positioning, Zenith tropospheric delays, precipitable water vapor

Procedia PDF Downloads 196