Search results for: contract system

Authors: Hamed Homaei, Iraj Mahdavi, Ali Tajdin

Abstract:

One of the main concerns of miners is to increase the quality level of their products because the mining metals price depends on their quality level; however, increasing the quality level of these products has different costs at different levels of the supply chain. These costs usually increase after extractor level. This paper studies the coordination issue of a decentralized three-level supply chain with one supplier (extractor), one mineral processor and one manufacturer in which the increasing product quality level cost at the processor level is higher than the supplier and at the level of the manufacturer is more than the processor. We identify the optimal product quality level for each supply chain member by designing a revenue sharing contract. Finally, numerical examples show that the designed contract not only increases the final product quality level but also provides a win-win condition for all supply chain members and increases the whole supply chain profit.

Keywords: three-stage supply chain, product quality improvement, channel coordination, revenue sharing

Procedia PDF Downloads 156

Authors: Lian Kösters, Wendy Smits, Raymond Montizaan

Abstract:

The number of solo self-employed in the Netherlands has been increasing for years. The relative increase is among the largest in the EU. To explain this increase, most studies have focused on the supply side, workers who offer themselves as solo self-employed. The number of studies that focus on the demand side, the employer who hires the solo self-employed, is still scarce. Studies into employer behaviour conducted until now show that employers mainly choose self-employed workers when they have a temporary need for specialist knowledge, but also during projects or production peaks. These studies do not provide insight into the employers’ considerations for different contract types. In this study, interviews with employers were conducted, and available literature was consulted to provide an overview of the several factors employers use to compare different contract types. That input was used to set up a vignette study. This was carried out at the end of 2021 among almost 1000 business owners, HR managers, and business leaders of Dutch companies. Each respondent was given two sets of five fictitious candidates for two possible positions in their organization. They were asked to rank these candidates. The positions varied with regard to the type of tasks (core tasks or support tasks) and the time it took to train new people for the position. The respondents were asked additional questions about the positions, such as the required level of education, the duration, and the degree of predictability of tasks. The fictitious candidates varied, among other things, in the type of contract on which they would come to work for the organization. The results were analyzed using a rank-ordered logit analysis. This vignette setup makes it possible to see which factors are most important for employers when choosing to hire a solo self-employed person compared to other contracts. The results show that there are no indications that employers would want to hire solo self-employed workers en masse. They prefer regular employee contracts. The probability of being chosen with a solo self-employed contract over someone who comes to work as a temporary employee is 32 percent. This probability is even lower than for on-call and temporary agency workers. For a permanent contract, this probability is 46 percent. The results provide indications that employers consider knowledge and skills more important than the solo self-employed contract and that this can compensate. A solo self-employed candidate with 10 years of work experience has a 63 percent probability of being found attractive by an employer compared to a temporary employee without work experience. This suggests that employers are willing to give someone a less attractive contract for the employer if the worker so wishes. The results also show that the probability that a solo self-employed person is preferred over a candidate with a temporary employee contract is somewhat higher in business economics, administrative and technical professions. No significant results were found for factors where it was expected that solo self-employed workers are preferred more often, such as for unpredictable or temporary work.

Keywords: employer behaviour, rank-ordered logit analysis, solo self-employment, temporary contract, vignette study

Procedia PDF Downloads 45

Authors: K. C. Iyer, Yogita Manan Bindal, Sumit Kumar Bakshi

Abstract:

Disputes and litigation are becoming inherent to the construction industry in India, and despite construction being one of the major drivers of growth, there have not been many reforms in the government construction contracts. Many of the disputes arising from the government contracts, can be avoided by the proper drafting of contracts and their administration. This study aims to 1) identify the best practices in the construction contract as reviewed from the research papers and additional literature on contract management, 2) obtain perspectives from the industry experts on the implementation of these best practices with regards to likely challenges and relative benefits for implementing the best practices in construction contracts. The best practices for disputes arising due to delay events have been identified through extensive literature survey. The industry perspective is gathered by way of a questionnaire survey to understand the applicability of the identified best practices, the benefits that are likely to be obtained and the challenges that are likely to be faced in the implementation of these practices. The study concludes with the recommended best practices that can be implemented based on the perspectives obtained from the survey. The findings of the study can be used by the industry professionals while drafting construction contracts with a view to avoid disputes related to delay events.

Keywords: best practices, construction contract, delay, dispute avoidance

Procedia PDF Downloads 158

Authors: Ons Triki, Fathi Abid

Abstract:

The basic objective of this paper is twofold. It resides in designing a model for a contingent convertible lease contract that can ensure the financial stability of a company and recover the losses of the parties to the lease in the event of default. It also aims to compare the convertible lease contract on inefficiencies resulting from the debt-overhang problem and asset substitution with other financing policies. From this perspective, this paper highlights the interaction between investments and financing policies in a dynamic model with existing assets and a growth option where the investment cost is financed by a contingent convertible lease and equity. We explore the impact of the contingent convertible lease on the capital structure. We also check the reliability and effectiveness of the use of the convertible lease contract as a means of financing. Findings show that the rental convertible contract with a sufficiently high conversion ratio has less severe inefficiencies arising from risk-shifting and debt overhang than those entailed by risky debt and pure-equity financing. The problem of underinvestment pointed out by Mauer and Ott (2000) and the problem of overinvestment mentioned by Hackbarth and Mauer (2012) may be reduced under contingent convertible lease financing. Our findings predict that the firm value under contingent convertible lease financing increases globally with asset volatility instead of decreasing with business risk. The study reveals that convertible leasing contracts can stand for a reliable solution to ensure the lessee and quickly recover the counterparties of the lease upon default.

Keywords: contingent convertible lease, growth option, debt overhang, risk-shifting, capital structure

Procedia PDF Downloads 49

Authors: Fedorova Elena

Abstract:

In this article, we draw a distinction between two important functions of public policy in private international law. The first function is widely recognized and relates to the prevention of application of foreign laws and enforcement of foreign court judgments whenever their effects are incompatible with the domestic legal system of the forum. This effectively protects sovereign rights of the forum state as it allows to resist against the undesirable effects of foreign law-making and law-enforcement policies. The second function is less obvious, but not less important. As the internal private legal relationships, international private relationships are usually governed by rules of public policy, to which the parties can not derogate by mutual agreement. Thefore, for international private law relations public policy has a different function than previously mentioned: in this case, the public policy acts as a defense against unacceptable effects of the party autonomy. Thus, this second function of public policy consists in the limitation of the party autonomy wich effects would be unacceptable for the local legal system. In the frame of this second function the author will analyse two types of public policy which can limit the party autonomy: « substantial » public policy (which regulates the substance of international legal relationship) and « conflictual » public policy (which regulates the party autonomy to choose the law applicable for the substance of relationship). The author provides an analysis of these functions of the public policy in the field of international contract law because of the important role of the principle of party autonomy for international contract relations.

Keywords: public policy, general theory of private international law, substantial public policy, conflictual public policy

Procedia PDF Downloads 546

Authors: Chariton Christou, David Cornwell

Abstract:

Production Sharing Contract (PSC) is the type of contract that is being used widely in our time. The financial crisis made the governments tightfisted and they do not have the resources to participate in a development of a field. Therefore, more and more countries introduce the PSC. The companies have the power and the money to develop the field with their own way. The main problem is the transparency of oil and gas companies especially in the PSC and how this can be achieved. Many discussions have been made especially in the U.K. What we are suggesting is a dynamic financial simulation with the help of a flow meter. The flow meter will count the production of each field every day (it will be installed in a pipeline). The production will be the basic input of the simulation. It will count the profit, the costs and more according to the information of the flow meter. In addition it will include the terms of the contract and the costs that have been paid. By all these parameters the simulation will be able to present in real time the information of a field (taxes, employees, R-factor). By this simulation the company will share some information with the government but not all of them. The government will know the taxes that should be paid and what is the sharing percentage of it. All of the other information could be confidential for the company. Furthermore, oil company could control the R-factor by changing the production each day to maximize its sharing percentages and as a result of this the profit. This idea aims to change the way that governments 'control' oil companies and bring a transparency evolution in the industry. With the help of a simulation every country could be next to the company and have a better collaboration.

Keywords: production sharing contracts, transparency, simulation

Procedia PDF Downloads 343

Authors: Lo Kar Yin

Abstract:

In view of the increasing speed and quantity of the housing supply, building, and civil engineering infrastructure works triggered by the pandemic across the globe, contractors, professional services providers (PSP), including consultants (e.g., architect, project manager, civil/geotechnical/structural engineer, building services engineer, quantity surveyor/cost manager, etc.) and suppliers have faced tremendous challenges of the fierce market, limited manpower, and resources under contract prices fluctuation and competitive fee and price. With qualitative analysis, this paper is to review the available information from the industry stakeholders with a view to finding solutions for enhancing efficiency, safety, and quality of construction value chain services for public and private organizations/companies’ sustainable growth, not limited to checking the deliverables and data transfer from multi-disciplinary parties. Technology, contracts, and people are the key requirements for shaping the construction industry. With the integration of a modern engineering contract (e.g., NEC) collaborative approach, practical workflows are designed to address loopholes together with different levels of people employment/retention and technology adoption to achieve the best value for money.

Keywords: efficiency, safety, quality, technology, contract, people, sustainable solutions, construction, services, integration

Procedia PDF Downloads 92

Authors: Ibrahim Mahamid, A. Al-Ghonamy, M. Aichouni

Abstract:

This study aims at identifying the risk matrix for delay causes in construction projects in Saudi Arabia from consultants’ viewpoint. A questionnaire survey was undertaken of 51 consultants working on construction projects in the Northern Province of Saudi Arabia. 35 delay causes were identified through a literature review. The study concluded that the top delay causes in construction projects in Saudi Arabia from consultants’ perspective are: bid award for lowest price, changes in material types and specifications during construction, contract management, duration of contract period, fluctuation of prices of materials, frequent changes in design, improper planning, inflationary pressure, lack of adequate manpower, long period of design and time of implementation, payments delay, poor labor productivity, and rework.

Keywords: delays, construction, consultants, contributors, risk map

Procedia PDF Downloads 504

Authors: Anshar Ajatasatru

Abstract:

The decline of coal prices over past years have been significantly increasing the awareness of effective mining operation. A viable step must be undertaken in becoming more cost competitive while striving for best mining practice especially at Melak Coal Mine in East Kalimantan, Indonesia. This paper aims to show how effective dozer push measurement method can be implemented as it is controlled by contract rate on the unit basis of USD ($) per bcm. The method emerges from an idea of daily dozer push activity that continually shifts the overburden until final target design by mine planning. Volume calculation is then performed by calculating volume of each time overburden is removed within determined distance using cut and fill method from a high precision GNSS system which is applied into dozer as a guidance to ensure the optimum result of overburden removal. Accumulation of daily to weekly dozer push volume is found 95 bcm which is multiplied by average sell rate of $ 0,95, thus the amount monthly revenue is $ 90,25. Furthermore, the payment mechanism is then based on push distance and push grade. The push distance interval will determine the rates that vary from $ 0,9 - $ 2,69 per bcm and are influenced by certain push slope grade from -25% until +25%. The amount payable rates for dozer push operation shall be specifically following currency adjustment and is to be added to the monthly overburden volume claim, therefore, the sell rate of overburden volume per bcm may fluctuate depends on the real time exchange rate of Jakarta Interbank Spot Dollar Rate (JISDOR). The result indicates that dozer push measurement can be one of the surface mining alternative since it has enabled to refine method of work, operating cost and productivity improvement apart from exposing risk of low rented equipment performance. In addition, payment mechanism of contract rate by dozer push operation scheduling will ultimately deliver clients by almost 45% cost reduction in the form of low and consistent cost.

Keywords: contract rate, cut-fill method, dozer push, overburden volume

Procedia PDF Downloads 287

Authors: Laura Ramona Nae

Abstract:

The issue of risks faced by companies providing tourist and hotel services in the HoReCa field, related to the goods belonging to consumer tourists left in hotel storage, has acquired a new dimension in the context of the economic and geo-political influences that have recently intervened at the global level. Thus, hoteliers and not only had to create contractual mechanisms regarding the risks and to protect the businesses in this field of activity. This situation has led to a reassessment of the importance of insurance, in particular with regard to hotel liability insurance-premises liability, safety, and security of goods. Interpretation of clauses in contracts concluded between hoteliers and tourists consuming hotel services and products, all the more so in the current pandemic context of Covid 19, stressed the increase in the number of disputes generated by them. This article presents a general picture of the significance of the risks related to the activity carried out in the hospitality industry, tourism, respectively within the HoReCa field. The study mainly marks the specificities of the hotel deposit contract, as well as the related insurance specific to the field, as a way to cover these risks. The article also refers to alternative methods of out-of-court settlement of disputes (ADR) in the HoReCa domain, generally used in both Romania and the European Union.

Keywords: consumer tourist, disputes and ADR methods, deposit contract, hotel warehouse and hotelier insurance, hotel services and tourist products, HoReCa

Procedia PDF Downloads 28

Authors: Chris Ewe, Naoum Jamous, Holger Schrödl

Abstract:

Like most entrepreneurs, data center operators pursue goals such as profit-maximization, improvement of the company’s reputation or basically to exist on the market. Part of those aims is to guarantee a given quality of service. Quality characteristics are specified in a contract called the service level agreement. Central part of this agreement is non-functional properties of an IT service. The system availability is one of the most important properties as it will be shown in this paper. To comply with availability requirements, data center operators can use virtualization technologies. A clear model to assess the effect of virtualization functions on the parts of a data center in relation to the system availability is still missing. This paper aims to introduce a basic model that shows these connections, and consider if the identified effects are positive or negative. Thus, this work also points out possible disadvantages of the technology. In consequence, the paper shows opportunities as well as risks of data center virtualization in relation to system availability.

Keywords: availability, cloud computing IT service, quality of service, service level agreement, virtualization

Procedia PDF Downloads 507

Authors: Anthony Townley

Abstract:

Contract negotiation is fundamental to commercial law practice. For this study, genre and discourse analytical methodology was used to examine the legal negotiation of a Merger & Acquisition (M&A) deal undertaken by legal and business professionals in English across different jurisdictions in Europe. While some of the most delicate negotiations involved in this process were carried on face-to-face or over the telephone, these were generally progressed more systematically – and on the record – in the form of emails, email attachments, and as comments and amendments recorded in successive ‘marked-up’ versions of the contracts under negotiation. This large corpus of textual data was originally obtained by the author, in 2012, for the purpose of doctoral research. For this study, the analysis is particularly concerned with the use of emails and covering letters to exchange legal advice about the negotiations. These two genres help to stabilize and progress the negotiation process and account for negotiation activities. Swalesian analysis of functional Moves and Steps was able to identify structural similarities and differences between these text types and to identify certain salient discursive features within them. The analytical findings also indicate how particular linguistic strategies are more appropriately and more effectively associated with one legal genre rather than another. The concept of intertextuality is an important dimension of contract negotiation discourse and this study also examined how the discursive relationships between the different texts influence the way that texts are constructed. In terms of materials development, the research findings can contribute to more authentic English for Legal & Business Purposes pedagogies for students and novice lawyers and business professionals. The findings can first be used to design discursive maps that provide learners with a coherent account of the intertextual nature of the contract negotiation process. These discursive maps can then function as a framework in which to present detailed findings about the textual and structural features of the text types by applying the Swalesian genre analysis. Based on this acquired knowledge of the textual nature of contract negotiation, the authentic discourse materials can then be used to provide learners with practical opportunities to role-play negotiation activities and experience professional ways of thinking and using language in preparation for the written discourse challenges they will face in this important area of legal and business practice.

Keywords: English for legal and business purposes, discourse analysis, genre analysis, intertextuality, pedagogical materials

Procedia PDF Downloads 121

Authors: Adelina Vrancianu

Abstract:

A public procurement procedure starts with the publication of the contract notice and the tender documentation. The documentation provides bidders with general guidelines and rules governing the tender process. At this stage, the interested economic operators start to prepare their bid. During this process, they may encounter unclear elements that, if are not clarified, may have a negative impact on the future bid with the ultimate sanction of exclusion. Until the opening of the bids, the potential bidders have the right to ask questions in order to clarify certain aspects of the tender documentation. In correlation, the contracting authorities have the obligation to answer these questions in a reasoned time and with clarity. In practice, the two conditions are not met due to a number of factors. This essay tries to outline the general principles regarding the clarifications during the phase of tender preparation. The provisions of the new directive on public procurement will be taken in consideration in this process in regard to the old directive.

Keywords: tender preparation, tender documentation, clarifications, contract notice

Procedia PDF Downloads 272

Authors: Juhan Kim, Jinsoo Kim

Abstract:

South Korea cannot import natural gas in any form other than LNG because of the division of South and North Korea. Further, the high proportion of natural gas in the national energy mix makes this resource crucial for energy security in Korea. Expansion of Panama Canal will allow for reducing the cost of shipping between the Far East and U.S East. Panama Canal expansion can have significant impacts on South Korea. Due to this situation, we review the natural gas optimal portfolio by considering the uniqueness of the Korean Natural gas market and expansion of Panama Canal. In order to assess Korea’s natural gas optimal portfolio, we developed natural gas portfolio model. The model comprises two steps. First, to obtain the optimal long-term spot contract ratio, the study examines the price level and the correlation between spot and long-term contracts by using the Markowitz, portfolio model. The optimal long-term spot contract ratio follows the efficient frontier of the cost/risk level related to this price level and degree of correlation. Second, by applying the obtained long-term contract purchase ratio as the constraint in the linear programming portfolio model, we determined the natural gas optimal import portfolio that minimizes total intangible and tangible costs. Using this model, we derived the optimal natural gas portfolio considering the expansion of Panama Canal. Based on these results, we assess the portfolio for natural gas import to Korea from the perspective of energy security and present some relevant policy proposals.

Keywords: natural gas, Panama Canal, portfolio analysis, South Korea

Procedia PDF Downloads 262

Authors: Rawan K. Al-Duaij, Salem A. Al-Salem

Abstract:

Projects, the unique and temporary process of achieving a set of requirements have always been challenging; Planning the schedule and budget, managing the resources and risks are mostly driven by a similar past experience or the technical consultations of experts in the matter. With that complexity of Projects in Scope, Time, and execution environment, Adjustment Orders are tools to reflect changes to the original project parameters after Contract signature. Adjustment Orders are the official/legal amendments to the terms and conditions of a live Contract. Reasons for issuing Adjustment Orders arise from changes in Contract scope, technical requirement and specification resulting in scope addition, deletion, or alteration. It can be as well a combination of most of these parameters resulting in an increase or decrease in time and/or cost. Most business leaders (handling projects in the interest of the owner) refrain from using Adjustment Orders considering their main objectives of staying within budget and on schedule. Success in managing the changes results in uninterrupted execution and agreed project costs as well as schedule. Nevertheless, this is not always practically achievable. In this paper, a detailed study through utilizing Industrial Engineering & Systems Management tools such as Six Sigma, Data Analysis, and Quality Control were implemented on the organization’s five years records of the issued Adjustment Orders in order to investigate their prevalence, and time and cost impact. The analysis outcome revealed and helped to identify and categorize the predominant causations with the highest impacts, which were considered most in recommending the corrective measures to reach the objective of minimizing the Adjustment Orders impacts. Data analysis demonstrated no specific trend in the AO frequency in past five years; however, time impact is more than the cost impact. Although Adjustment Orders might never be avoidable; this analysis offers’ some insight to the procedural gaps, and where it is highly impacting the organization. Possible solutions are concluded such as improving project handling team’s coordination and communication, utilizing a blanket service contract, and modifying the projects gate system procedures to minimize the possibility of having similar struggles in future. Projects in the Oil and Gas sector are always evolving and demand a certain amount of flexibility to sustain the goals of the field. As it will be demonstrated, the uncertainty of project parameters, in adequate project definition, operational constraints and stringent procedures are main factors resulting in the need for Adjustment Orders and accordingly the recommendation will be to address that challenge.

Keywords: adjustment orders, data analysis, oil and gas sector, systems management

Procedia PDF Downloads 131

Authors: Ons Triki, Fathi Abid

Abstract:

Along with the increase in the use of leasing contracts in corporate finance, multiple studies aim to model the credit risk of the lease in order to cover the losses of the lessor of the asset if the lessee goes bankrupt. In the current research paper, a convertible lease contract is elaborated in a continuous time stochastic universe aiming to ensure the financial stability of the firm and quickly recover the losses of the counterparties to the lease in case of default. This work examines the term structure of the lease rates taking into account the credit default risk and the capital structure of the firm. The interaction between the lessee's capital structure and the equilibrium lease rate has been assessed by applying the competitive lease market argument developed by Grenadier (1996) and the endogenous structural default model set forward by Leland and Toft (1996). The cumulative probability of default was calculated by referring to Leland and Toft (1996) and Yildirim and Huan (2006). Additionally, the link between lessee credit risk and lease rate was addressed so as to explore the impact of convertible lease financing on the term structure of the lease rate, the optimal leverage ratio, the cumulative default probability, and the optimal firm value by applying an endogenous conversion threshold. The numerical analysis is suggestive that the duration structure of lease rates increases with the increase in the degree of the market price of risk. The maximal value of the firm decreases with the effect of the optimal leverage ratio. The results are indicative that the cumulative probability of default increases with the maturity of the lease contract if the volatility of the asset service flows is significant. Introducing the convertible lease contract will increase the optimal value of the firm as a function of asset volatility for a high initial service flow level and a conversion ratio close to 1.

Keywords: convertible lease contract, lease rate, credit-risk, capital structure, default probability

Procedia PDF Downloads 51

Authors: Ghaleb Y. Abbasi, Sufyan Al-Mrayat

Abstract:

This study examined the contribution of thirty-six factors to building construction project’s cost overrun in Jordan. A questionnaire was distributed to a random sample of 350 stakeholders comprised of owners, consultants, and contractors, of which 285 responded. SPSS analysis was conducted to identify the top five causes of cost overrun, which were a large number of variation orders, inadequate quantities provided in the contract, misunderstanding of the project plan, incomplete bid documents, and choosing the lowest price in the contract bidding. There was an agreement among the study participants in ranking the factors contributing to cost overrun, which indicated that these factors were very commonly encountered in most construction projects in Jordan. Thus, it is crucial to enhance the collaboration among the different project stakeholders to understand the project’s objectives and set a realistic plan that takes into consideration all the factors that might influence the project cost, which might eventually prevent cost overrun.

Keywords: cost, overrun, building construction projects, Jordan

Procedia PDF Downloads 65

Authors: Puti F. Marzuki, Adrianto Oktavianus, Almerinda Regina

Abstract:

Interface problems among interacting parties in Indonesian construction projects have most often led to low productivity and completion delay. In the midst of this country’s needs to accelerate construction of public infrastructure providing connectivity among regions and supporting economic growth as well as better living quality, project delays have to be seriously addressed. This paper identifies potential causes factors of interface problems experienced by construction projects in Indonesia. Data are collected through a survey involving the main actors of six important public infrastructure construction projects including railway, LRT, sports stadiums, apartment, and education building construction projects. Five of these projects adopt the design-build project delivery method and one applies the design-bid-build scheme. Interface problems’ potential causes are categorized into contract, management, technical experience, coordination, financial, and environmental factors. Research results reveal that, especially in railway and LRT projects, potential causes of interface problems are mainly technical and managerial in nature. These relate to complex construction execution in highly congested areas. Meanwhile, coordination cause factors are mainly found in the education building construction project with loan from a foreign donor. All of the six projects have to resolve interface problems caused by incomplete or low-quality contract documents. This research also shows that the design-bid-build delivery method involving more parties in construction projects tends to induce more interface problem cause factors than the design-build scheme.

Keywords: cause factors, construction delays, project delivery method, contract documents

Procedia PDF Downloads 225

Authors: Yash Ambekar, Kapil Vhatkar, Prathamesh Swami, Kartikey Singh, Yashovardhan Kaware

Abstract:

The rise of online courses and certifications has created new opportunities for individuals to enhance their skills. However, this digital transformation has also given rise to coun- terfeit certificates. To address this multifaceted issue, we present a comprehensive certificate management system founded on blockchain technology and strengthened by smart contracts. Our system comprises three pivotal components: certificate generation, authenticity verification, and a user-centric digital locker for certificate storage. Blockchain technology underpins the entire system, ensuring the immutability and integrity of each certificate. The inclusion of a cryptographic hash for each certificate is a fundamental aspect of our design. Any alteration in the certificate’s data will yield a distinct hash, a powerful indicator of potential tampering. Furthermore, our system includes a secure digital locker based on cloud storage that empowers users to efficiently manage and access all their certificates in one place. Moreover, our project is committed to providing features for certificate revocation and updating, thereby enhancing the system’s flexibility and security. Hence, the blockchain and smart contract-based certificate management system offers a robust and one-stop solution to the escalating problem of counterfeit certificates in the digital era.

Keywords: blockchain technology, smart contracts, counterfeit certificates, authenticity verification, cryptographic hash, digital locker

Procedia PDF Downloads 16

Authors: Olga C. Rodrigue

Abstract:

Long-term care and skilled nursing facilities experience ebbs and flows of nursing staffing, a problem compounded by the perception of the facilities as undesirable workplaces and competition for staff from other healthcare entities. Travel nurses are contracted to fill staffing needs due to increased admissions, increased and unexpected attrition of nurses, or facility expansion of services. Prior to beginning the contracted assignment, the travel nurse must meet industry, company, and regulatory requirements (The Joint Commission and CMS) for skills and knowledge. Travel nurses, however, inconsistently receive the pre-assignment orientation needed to work at the contracted facility, if any information is given at all. When performance expectations are not met, travel nurses may subsequently choose to leave the position without completing the terms of the contract, and some facilities may choose to terminate the contract prior to the expected end date. The overarching goal of the Doctor of Nursing Practice evidence-based practice improvement project is to provide travel nurses with the basic and necessary information to prepare them to begin a long-term and skilled nursing assignment. The project involves the identification of travel nurse learning needs through a survey and the development and provision of web-based learning modules to address those needs prior to arrival for a long-term and skilled nursing assignment.

Keywords: nurse staffing, travel nurse, travel staff, contract staff, contracted assignment, long-term care, skilled nursing, onboarding, orientation, staff development, supplemental staff

Procedia PDF Downloads 142

Authors: Xiu Zhang

Abstract:

The Merchant of Venice focuses on identity anxiety through the contract of “a pound of flesh” and refers to the economic, legal and religious issues related to identity. The development of the emerging capitalist economy in Venetian society prompted Shylock to become a usurer. The social identity of Shylock’s lender enabled him to use the power of money to consolidate the interdependent relationship with Christians and strive for his position and living space in Venetian society. However, there have long been economical and religious conflicts between Jews and Christians. Therefore, in order to take vengeance on Antonio and take his life, so as to revenge the whole Christian society, Shylock insists on taking a pound of Antonio’s flesh in the name of abiding by the contract and the law. The choice of “a pound of flesh” is essentially the representation of human materialization and commercialization under the background of the rise of capitalism and economic transformation. At the same time, it also symbolizes Shylock’s efforts and attempts to reshape himself and his racial identity.

Keywords: merchant of Venice, ethical choices, Shylock, a pound of flesh, identity anxiety

Procedia PDF Downloads 107

Authors: Thelma Maria Melo Pinheiro, Guilherme Raposo Diniz Vieira, Sidney Matos da Silva, Leonardo Mendonça de Oliveira Queiroz, Mateus Sousa Pinheiro, Danyllo Wenceslau de Oliveira Lopes

Abstract:

The present article has the objective to describe the regulatory impact analysis (RIA) of the contracting efficiency of the Brazilian transmission system usage. This contracting is made by users connected to the main transmission network and is used to guide necessary investments to supply the electrical energy demand. Therefore, an inefficient contracting of this energy amount distorts the real need for grid capacity, affecting the sector planning accuracy and resources optimization. In order to provide this efficiency, the Brazilian Electricity Regulatory Agency (ANEEL) homologated the Normative Resolution (NR) No. 666, from July 23th of 2015, which consolidated the procedures for the contracting of transmission system usage and the contracting efficiency verification. Aiming for a more efficient and rational transmission system contracting, the resolution established economic incentives denominated as Inefficiency installment for excess (IIE) and inefficiency installment for over-contracting (IIOC). The first one, IIE, is verified when the contracted demand exceeds the established regulatory limit; it is applied to consumer units, generators, and distribution companies. The second one, IIOC, is verified when the distributors over-contract their demand. Thus, the establishment of the inefficiency installments IIE and IIOC intends to avoid the agent contract less energy than necessary or more than it is needed. Knowing that RIA evaluates a regulatory intervention to verify if its goals were achieved, the results from the application of the above-mentioned normative resolution to the Brazilian transmission sector were analyzed through indicators that were created for this RIA to evaluate the contracting efficiency transmission system usage, using real data from before and after the homologation of the normative resolution in 2015. For this, indicators were used as the efficiency contracting indicator (ECI), excess of demand indicator (EDI), and over-contracting of demand indicator (ODI). The results demonstrated, through the ECI analysis, a decrease of the contracting efficiency, a behaviour that was happening even before the normative resolution of 2015. On the other side, the EDI showed a considerable decrease in the amount of excess for the distributors and a small reduction for the generators; moreover, the ODI notable decreased, which optimizes the usage of the transmission installations. Hence, with the complete evaluation from the data and indicators, it was possible to conclude that IIE is a relevant incentive for a more efficient contracting, indicating to the agents that their contracting values are not adequate to keep their service provisions for their users. The IIOC also has its relevance, to the point that it shows to the distributors that their contracting values are overestimated.

Keywords: contracting, electricity regulation, evaluation, regulatory impact analysis, transmission power system

Procedia PDF Downloads 88

Authors: Fatin Fadhilah Hasib, Puji Sucia Sukmaningrum, Imron Mawardi, Achsania Hendratmi

Abstract:

Murabaha is the most popular contract by the Islamic banks in Indonesia, since there is opinion stating that the risk level of mudharaba and musyaraka are higher and the return is uncertain. This research aims to analyze the difference of return, risk, and variation coefficient between profit sharing-based and trading-based financing in Islamic bank. This research uses quantitative approach using Wilcoxon signed rank test with data sampled from 13 Indonesian Islamic banks, collected from their quarterly financial reports from 2011 to 2015. The result shows the significant difference in return, while risk and variation coefficient are almost same. From the analysis, it can be concluded that profit sharing-based financing is less desirable not because of its risk. Trading-based financing is more desirable than the profit sharing because of its return.

Keywords: financing, Islamic bank, return, risk

Procedia PDF Downloads 348

Authors: Ming-Jen Huang, Chun-Fang Huang, Chiching Wei

Abstract:

With the recent advance of the deep neural network, we observe new applications of NLP (natural language processing) and CV (computer vision) powered by deep neural networks for processing business documents. However, creating a real-world document processing system needs to integrate several NLP and CV tasks, rather than treating them separately. There is a need to have a unified approach for processing documents containing textual and graphical elements with rich formats, diverse layout arrangement, and distinct semantics. In this paper, a framework that fulfills this unified approach is presented. The framework includes a representation model definition for holding the information generated by various tasks and specifications defining the coordination between these tasks. The framework is a blueprint for building a system that can process documents with rich formats, styles, and multiple types of elements. The flexible and lightweight design of the framework can help build a system for diverse business scenarios, such as contract monitoring and reviewing.

Keywords: document processing, framework, formal definition, machine learning

Procedia PDF Downloads 184

Authors: Antonio Abatemarco, Francesca Stroffolini

Abstract:

In the economic literature, Rawls’ Theory of Justice is usually interpreted in a two-stage setting, where a priority to the worst off individual is imposed as a distributive value judgment. In this paper, instead, we model Rawls’ Theory in a three-stage setting, that is, a separating line is drawn between the original position, the educational stage, and the working life. Hence, in this paper, we challenge the common interpretation of Rawls’ Theory of Justice as Fairness by showing that this Theory goes well beyond the definition of a distributive value judgment, in such a way as to embrace efficiency issues as well. In our model, inequalities are shown to be permitted as far as they stimulate a greater effort in education in the population, and so economic growth. To our knowledge, this is the only possibility for the inequality to be ‘bought’ by both the most-, and above all, the least-advantaged individual as suggested by the Difference Principle. Finally, by recalling the old tradition of ‘universal ex-post efficiency’, we show that a unique optimal social contract does not exist behind the veil of ignorance; more precisely, the sole set of potentially Rawls-optimal social contracts can be identified a priori, and partial justice orderings derived accordingly.

Keywords: justice, Rawls, inequality, social contract

Procedia PDF Downloads 190

Authors: E. Harrer, M. Mauerhofer, T. Werginz

Abstract:

As a result of intensive competition, the building sector is suffering from a high degree of rivalry. Furthermore, there can be observed an unbalanced distribution of project risks. Clients are aimed to shift their own risks into the sphere of the constructors or planners. The consequence of this is that the number of conflicts between the involved parties is inordinately high or even increasing; an alternative approach to counter on that developments are cooperative project forms in the construction sector. This research compares conventional contract models and models with partnering agreements to examine the influence on project risks by an early integration of the involved parties. The goal is to show up deviations in different project stages from the design phase to the project transfer phase. These deviations are evaluated by a survey of experts from the three spheres: clients, contractors and planners. By rating the influence of the participants on specific risk factors it is possible to identify factors which are relevant for a smooth project execution.

Keywords: building projects, contract models, partnering, project risks

Procedia PDF Downloads 245

Authors: Alena Nesterenko, Svetlana Petrikova

Abstract:

Research evaluation is one of the most important elements of self-regulation and development of researchers as it is impartial and independent process of assessment. The method of expert evaluations as a scientific instrument solving complicated non-formalized problems is firstly a scientifically sound way to conduct the assessment which maximum effectiveness of work at every step and secondly the usage of quantitative methods for evaluation, assessment of expert opinion and collective processing of the results. These two features distinguish the method of expert evaluations from long-known expertise widespread in many areas of knowledge. Different typical problems require different types of expert evaluations methods. Several issues which arise with these methods are experts’ selection, management of assessment procedure, proceeding of the results and remuneration for the experts. To address these issues an on-line system was created with the primary purpose of development of a versatile application for many workgroups with matching approaches to scientific work management. Online documentation assessment and statistics system allows: - To realize within one platform independent activities of different workgroups (e.g. expert officers, managers). - To establish different workspaces for corresponding workgroups where custom users database can be created according to particular needs. - To form for each workgroup required output documents. - To configure information gathering for each workgroup (forms of assessment, tests, inventories). - To create and operate personal databases of remote users. - To set up automatic notification through e-mail. The next stage is development of quantitative and qualitative criteria to form a database of experts. The inventory was made so that the experts may not only submit their personal data, place of work and scientific degree but also keywords according to their expertise, academic interests, ORCID, Researcher ID, SPIN-code RSCI, Scopus AuthorID, knowledge of languages, primary scientific publications. For each project, competition assessments are processed in accordance to ordering party demands in forms of apprised inventories, commentaries (50-250 characters) and overall review (1500 characters) in which expert states the absence of conflict of interest. Evaluation is conducted as follows: as applications are added to database expert officer selects experts, generally, two persons per application. Experts are selected according to the keywords; this method proved to be good unlike the OECD classifier. The last stage: the choice of the experts is approved by the supervisor, the e-mails are sent to the experts with invitation to assess the project. An expert supervisor is controlling experts writing reports for all formalities to be in place (time-frame, propriety, correspondence). If the difference in assessment exceeds four points, the third evaluation is appointed. As the expert finishes work on his expert opinion, system shows contract marked ‘new’, managers commence with the contract and the expert gets e-mail that the contract is formed and ready to be signed. All formalities are concluded and the expert gets remuneration for his work. The specificity of interaction of the examination officer with other experts will be presented in the report.

Keywords: expertise, management of research evaluation, method of expert evaluations, research evaluation

Procedia PDF Downloads 182

Authors: Imran Mehboob Shaikh, Kamaruzaman Noordin

Abstract:

Musharakah Mutanaqisah or Diminishing Partnership is a derivative of Musharakah contract, which is used by Islamic banks for housing finance facility. Most of the banks offer housing finance based on the concept of Musharakah Mutanaqisah, apart from few which still offer housing finance using BBA, Tawarruq (commodity Murabahah) and Istisna. This research attempts to compare the practice of DP housing finance offered in Malaysia. This paper will further look into challenges in Musharakah Mutanaqisah practice and its sustainability as a mortgage product. In practice there are certain issues related to Musharakah Mutanaqisah also known as Musharakah al Muntaiah bi tamlik, widely accepted and mostly used for housing finance by the Islamic banks. In Malaysia, it is in transforming stage from Bay bithamman Ajil, which is mostly used for housing finance in ASEAN region i.e., Malaysia, Indonesia and Brunei. In order to conduct this study, a discussion was carried out with few researchers who had worked on the topic previously and some Islamic bank officers attached to a full-fledged Islamic bank in Malaysia. Apart from that previous literature on Musharakah Mutanaqisah was also reviewed and various books, as well as online data, was considered for this study, and websites of different Islamic banks with information for Diminishing partnership, home financing were retrieved. This paper will highlight issues surrounding Diminishing Partnership contract and its conformity to Maqasid al Shariah (objectives of Shariah). Diminishing Partnership is widely accepted in different parts of the world and is mostly used for housing finance. The future prospect of DP is believed to be affirmative. As the product is a better substitute for BBA and most of the Islamic banks around the world have utilized their housing portfolio using the contract but at the same time, there are certain issues that need to be overcome. Even though Islamic banks are striving to sustain and compete the conventional banks but securing the customers from Gharar and other issues should be the primary objective of Islamic financial institutions.

Keywords: BBA, home financing, musharakah mutanaqisah, tawarruq

Procedia PDF Downloads 306

Authors: Jorge M. Uribe

Abstract:

We propose a methodology for setting the price of an insurance contract targeted to manage the risk associated with weather conditions that affect variable renewable energy generation. The methodology relies on conditional quantile regressions to estimate the weather risk of a solar panel. It is illustrated using real daily radiation and weather data for three cities in Spain (Valencia, Barcelona and Madrid) from February 2/2004 to January 22/2019. We also adapt the concepts of value at risk and expected short fall from finance to this context, to provide a complete panorama of what we label as weather risk. The methodology is easy to implement and can be used by insurance companies to price a contract with the aforementioned characteristics when data about similar projects and accurate cash flow projections are lacking. Our methodology assigns a higher price to an insurance product with the stated characteristics in Madrid, compared to Valencia and Barcelona. This is consistent with Madrid showing the largest interquartile range of operational deficits and it is unrelated to the average value deficit, which illustrates the importance of our proposal.

Keywords: insurance, weather, vre, risk

Procedia PDF Downloads 120

Authors: Xiaoman Dong

Abstract:

The refugee problem has a long history, but the scale and severity of modern refugee crises demand us to consider if the progress of political history exacerbates the refugee problem. This paper argues that although sovereignty owes its legitimacy to the protection of human rights, the modern state system complicates the refugee problem by first introducing then blurring the line between human rights and civil rights, and making national identity indispensable to basic livelihood and dignity. This paper first explains the source of the modern state system’s legitimacy by putting it in the context of social contract theories and the politics of nation-building. It then discusses how states create the concept of statelessness, which leads to more violations on human rights. Using historical records of the League of Nations High Commission for Refugees and the United Nations High Commissioner for Refugees, this paper reveals that neither the refugee problem of the Cold-War period nor the current refugee crisis is collateral damage of war, but rather the consequence of intentional exclusionary policies produced out of political interests. Finally, it contends that if the modern state system is to sustain, it cannot prioritize the protection of civil rights of a particular group over the protection of basic human rights of all.

Keywords: burden sharing, human rights, legitimacy of state, positive externality, sovereignty

Procedia PDF Downloads 160