Search results for: price gouging

Authors: Ibraheem A. K. Mahameed

Abstract:

The aim of this study is to identify the risks affecting time performance of building construction projects in the West Bank in Palestine from contractors’ viewpoint. 38 risks that might affect time performance of building construction projects were defined through a detailed literature review. These risks have been classified into 6 groups: project, managerial, consultant, financial, external, and construction items. A questionnaire survey was performed to rank the considered risks in terms of severity and frequency. The analysis of the survey indicated that the top five risks affecting time performance of building construction projects in Palestine are: award project to the lowest price, political situation, poor communication and coordination between construction parties, change orders, and financial status of contractor.

Keywords: delay, time performance, construction, building

Procedia PDF Downloads 470

Authors: Kozik Renata, Leśniak Agnieszka, Plebankiewicz Edyta

Abstract:

Contracting authorities in the public sector are obligated to apply the principles provided for in the Polish law for the evaluation and selection of contractors. To analyze the methods of contractors, applied in practice by public clients, the notices of contract award results for construction works were analyzed. The analysis shows that the procedure selected more and more often is open to competitive bidding, where the assessment of the competence of contractors is not very precise, as well as non-competitive bidding, i.e. single source procurement. The share of procurement procedures, where the only criterion is price, is increasing. The solution to the problems existing here might be the introduction of one of the forms of pre-selection of contractors. The article also briefly discusses verification systems for companies applying for public contracts used in EU countries.

Keywords: certification, contractors selection, open tendering, public investors

Procedia PDF Downloads 285

Authors: Mekdes Getu Chekol, Biniam Tedros Kahsay, Rahwa Berihu Haile

Abstract:

The main objective of this study is to investigate the marketing strategy practice in the Case of St. George Brewery Factory in Addis Ababa. One of the core activities in a Business Company to stay in business is having a well-developed marketing strategy. It assessed how the marketing strategies were practiced in the company to achieve its goals aligned with segmentation, target market, positioning, and the marketing mix elements to satisfy customer requirements. Using primary and secondary data, the study is conducted by using both qualitative and quantitative approaches. The primary data was collected through open and closed-ended questionnaires. Considering the size of the population is small, the selection of the respondents was carried out by using a census. The finding shows that the company used all the 4 Ps of the marketing mix elements in its marketing strategies and provided quality products at affordable prices by promoting its products by using high and effective advertising mechanisms. The product availability and accessibility are admirable with the practices of both direct and indirect distribution channels. On the other hand, the company has identified its target customers, and the company’s market segmentation practice is geographical location. Communication effectiveness between the marketing department and other departments is very good. The adjusted R2 model explains 61.6% of the marketing strategy practice variance by product, price, promotion, and place. The remaining 38.4% of variation in the dependent variable was explained by other factors not included in this study. The result reveals that all four independent variables, product, price, promotion, and place, have a positive beta sign, proving that predictor variables have a positive effect on that of the predicting dependent variable marketing strategy practice. Even though the marketing strategies of the company are effectively practiced, there are some problems that the company faces while implementing them. These are infrastructure problems, economic problems, intensive competition in the market, shortage of raw materials, seasonality of consumption, socio-cultural problems, and the time and cost of awareness creation for the customers. Finally, the authors suggest that the company better develop a long-range view and try to implement a more structured approach to attain information about potential customers, competitor’s actions, and market intelligence within the industry. In addition, we recommend conducting the study by increasing the sample size and including different marketing factors.

Keywords: marketing strategy, market segmentation, target marketing, market positioning, marketing mix

Procedia PDF Downloads 61

Authors: Zainab Atia, Hongwei He, Panagiotis Sarantopoulos

Abstract:

Over the past few years, firms have witnessed a massive increase in sophisticated algorithmic deployment, which has become quite pervasive in today’s modern society. With the wide availability of data for retailers, the ability to track consumers using algorithmic pricing has become an integral option in online platforms. As more companies are transforming their businesses and relying more on massive technological advancement, pricing algorithmic systems have brought attention and given rise to its wide adoption, with many accompanying benefits and challenges to be found within its usage. With the overall aim of increasing profits by organizations, algorithmic pricing is becoming a sound option by enabling suppliers to cut costs, allowing better services, improving efficiency and product availability, and enhancing overall consumer experiences. The adoption of algorithms in retail has been pioneered and widely used in literature across varied fields, including marketing, computer science, engineering, economics, and public policy. However, what is more, alarming today is the comprehensive understanding and focus of this technology and its associated ethical influence on consumers’ perceptions and behaviours. Indeed, due to algorithmic ethical concerns, consumers are found to be reluctant in some instances to share their personal data with retailers, which reduces their retention and leads to negative consumer outcomes in some instances. This, in its turn, raises the question of whether firms can still manifest the acceptance of such technologies by consumers while minimizing the ethical transgressions accompanied by their deployment. As recent modest research within the area of marketing and consumer behavior, the current research advances the literature on algorithmic pricing, pricing ethics, consumers’ perceptions, and price fairness literature. With its empirical focus, this paper aims to contribute to the literature by applying the distinction of the two common types of algorithmic pricing, dynamic and personalized, while measuring their relative effect on consumers’ behavioural outcomes. From a managerial perspective, this research offers significant implications that pertain to providing a better human-machine interactive environment (whether online or offline) to improve both businesses’ overall performance and consumers’ wellbeing. Therefore, by allowing more transparent pricing systems, businesses can harness their generated ethical strategies, which fosters consumers’ loyalty and extend their post-purchase behaviour. Thus, by defining the correct balance of pricing and right measures, whether using dynamic or personalized (or both), managers can hence approach consumers more ethically while taking their expectations and responses at a critical stance.

Keywords: algorithmic pricing, dynamic pricing, personalized pricing, price ethicality

Procedia PDF Downloads 91

Authors: Anandkumar Rshindhe

Abstract:

Patents are considered as good monopoly in India. It is a mechanism by which the inventor is encouraged to do invention and also to make available to the society at large with a new useful technology. Patent system does not provide any protection to the invention itself but to the claims (rights) which the patentee has identified in relation to his invention. Thus the patentee is granted monopoly to the extent of his recognition of his own rights in the form of utilities and all other utilities of invention are for the public. Thus we find both benefit to the inventor and the public at large that is the ultimate consumer. But developing any such technology is not free of cost. Inventors do a lot of investment in the coming out with a new technologies. One such example if of Pharmaceutical industries. These pharmaceutical Industries do lot of research and invest lot of money, time and labour in coming out with these invention. Once invention is done or process identified, in order to protect it, inventors approach Patent system to protect their rights in the form of claim over invention. The patent system takes its own time in giving recognition to the invention as patent. Even after the grant of patent the pharmaceutical companies need to comply with many other legal formalities to launch it as a drug (medicine) in market. Thus major portion in patent term is unproductive to patentee and whatever limited period the patentee gets would be not sufficient to recover the cost involved in invention and as a result price of patented product is raised very much, just to recover the cost of invent. This is ultimately a burden on consumer who is paying more only because the legislature has failed to provide for the delay and loss caused to patentee. This problem can be effectively remedied if Patent Term extension is done. Due to patent term extension, the inventor gets some more time in recovering the cost of invention. Thus the end product is much more cheaper compared to non patent term extension.The basic question here arises is that when the patent period granted to a patentee is only 20 years and out of which a major portion is spent in complying with necessary legal formalities before making the medicine available in market, does the company with the limited period of monopoly recover its investment made for doing research. Further the Indian patent Act has certain provisions making it mandatory on the part of patentee to make its patented invention at reasonable affordable price in India. In the light of above questions whether extending the term of patent would be a proper solution and a necessary requirement to protect the interest of patentee as well as the ultimate consumer. The basic objective of this paper would be to check the implications of Extending the Patent term on Indian Consumers. Whether it provides the benefits to the patentee, consumer or a hardship to the Generic industry and consumer.

Keywords: patent term extention, consumer interest, generic drug industry, pharmaceutical industries

Procedia PDF Downloads 451

Authors: Ibrahim Mahamid, A. Al-Ghonamy, M. Aichouni

Abstract:

This study aims at identifying the risk matrix for delay causes in construction projects in Saudi Arabia from consultants’ viewpoint. A questionnaire survey was undertaken of 51 consultants working on construction projects in the Northern Province of Saudi Arabia. 35 delay causes were identified through a literature review. The study concluded that the top delay causes in construction projects in Saudi Arabia from consultants’ perspective are: bid award for lowest price, changes in material types and specifications during construction, contract management, duration of contract period, fluctuation of prices of materials, frequent changes in design, improper planning, inflationary pressure, lack of adequate manpower, long period of design and time of implementation, payments delay, poor labor productivity, and rework.

Keywords: delays, construction, consultants, contributors, risk map

Procedia PDF Downloads 541

Authors: Alev Atak

Abstract:

We study the endogeneity in the cryptocurrency market over the branching ratio of the Hawkes process and evaluate the movement of self-excitability in the financial markets. We consider a semi-parametric self-exciting point process regression model where the excitation function is assumed to be smooth and decreasing but otherwise unspecified, and the baseline intensity is assumed to be a linear function of the regressors. We apply the empirical analysis to the three largest crypto assets, i.e. Bitcoin - Ethereum - Ripple, and provide a comparison with other financial assets such as SP500, Gold, and the volatility index VIX observed from January 2015 to December 2020. The results depict variable and high levels of endogeneity in the basket of cryptocurrencies under investigation, underlining the evidence of a significant role of endogenous feedback mechanisms in the price formation process.

Keywords: hawkes process, cryptocurrency, endogeneity, reflexivity

Procedia PDF Downloads 81

Authors: Muhammad Mustafizur Rahaman

Abstract:

Social business is a new concept in the field of Business Economics and Capitalist Economy. It has increased the importance in economic and social development in emerging economies. Professor Muhammad Yunus is the founding father of the notion. While conventional business underscores profit maximization as a core business principle, social business calls for addressing social problems at the expense of profit. This underlying principle gives social business advantageous position over conventional businesses to serve those who live at the bottom of the pyramid. It also poses grave challenges to the social business because social business sacrifices profit at one hand and seeks financial sustainability on the other. For the sake of its financial sustainability, the social business might increase the price of its product or service which might lower its social impact, thus, makes the business self-defeating. Therefore, social business should be more innovative in every business process including production, marketing, and management. Otherwise, the business is unlikely to be driven out from the society.

Keywords: innovativeness, self-defeat, social business, social problem

Procedia PDF Downloads 619

Authors: B. F. Nteumagne, E. Pindza, E. Mare

Abstract:

We apply Lie symmetries analysis to price and hedge options in the fractional Brownian framework. The reputation of Lie groups is well spread in the area of Mathematical sciences and lately, in Finance. In the presence of transactions costs and under fractional Brownian motions, analytical solutions become difficult to obtain. Lie symmetries analysis allows us to simplify the problem and obtain new analytical solution. In this paper, we investigate the use of symmetries to reduce the partial differential equation obtained and obtain the analytical solution. We then proposed a hedging procedure and calibration technique for these types of options, and test the model on real market data. We show the robustness of our methodology by its application to the pricing of digital options.

Keywords: fractional brownian model, symmetry, transaction cost, option pricing

Procedia PDF Downloads 399

Authors: Seetanah Boopen, R. V. Sannassee

Abstract:

The objective of the present study is two-fold. Firstly, to assess the impact of air access liberalization on tourism demand for Mauritius and secondly to analyses the dual impact of the interplay between air access liberalization and marketing promotion efforts on tourism demand. Using an Autoregressive Distributed Lag model, the results suggest that air access liberalization is an important ingredient, albeit to a lesser extent as compared to other classical explanatory variables, of tourism demand. The results also highlight the fact that Mauritius is perceived as a luxurious destination and tourists are deemed price sensitive. Moreover, our dynamic approach interestingly confirms the presence of repeat tourism in the island. Finally, the findings also uncover the positive impact of the interplay between air access liberalization and marketing promotion efforts on fostering tourism demand.

Keywords: air access liberalization, ARDL, SIDS, time series

Procedia PDF Downloads 310

Authors: Marina Chavleishvili

Abstract:

Introduction: Today, the study of monopolies, including natural monopolies, is topical. In real life, pure monopolies are natural monopolies. Natural monopolies are used widely and are regulated by the state. In particular, the prices and rates are regulated. The paper considers the problems associated with the operation of natural monopolies in Georgia, in particular, their microeconomic analysis, pricing mechanisms, and legal mechanisms of their operation. The analysis was carried out on the example of the power industry. The rates of natural monopolies in Georgia are controlled by the Georgian National Energy and Water Supply Regulation Commission. The paper analyzes the positive role and importance of the regulatory body and the issues of improving the legislative base that will support the efficient operation of the branch. Methodology: In order to highlight natural monopolies market tendencies, the domestic and international markets are studied. An analysis of monopolies is carried out based on the endogenous and exogenous factors that determine the condition of companies, as well as the strategies chosen by firms to increase the market share. According to the productivity-based competitiveness assessment scheme, the segmentation opportunities, business environment, resources, and geographical location of monopolist companies are revealed. Main Findings: As a result of the analysis, certain assessments and conclusions were made. Natural monopolies are quite a complex and versatile economic element, and it is important to specify and duly control their frame conditions. It is important to determine the pricing policy of natural monopolies. The rates should be transparent, should show the level of life in the country, and should correspond to the incomes. The analysis confirmed the significance of the role of the Antimonopoly Service in the efficient management of natural monopolies. The law should adapt to reality and should be applied only to regulate the market. The present-day differential electricity tariffs varying depending on the consumed electrical power need revision. The effects of the electricity price discrimination are important, segmentation in different seasons in particular. Consumers use more electricity in winter than in summer, which is associated with extra capacities and maintenance costs. If the price of electricity in winter is higher than in summer, the electricity consumption will decrease in winter. The consumers will start to consume the electricity more economically, what will allow reducing extra capacities. Conclusion: Thus, the practical realization of the views given in the paper will contribute to the efficient operation of natural monopolies. Consequently, their activity will be oriented not on the reduction but on the increase of increments of the consumers or producers. Overall, the optimal management of the given fields will allow for improving the well-being throughout the country. In the article, conclusions are made, and the recommendations are developed to deliver effective policies and regulations toward the natural monopolies in Georgia.

Keywords: monopolies, natural monopolies, regulation, antimonopoly service

Procedia PDF Downloads 86

Authors: Nabila Louai, Fouad Khaldi, Houria Benharchache

Abstract:

In this paper, the case of meeting a household’s electrical energy demand with hybrid systems has been examined. The objective is to study technological feasibility and economic viability of the electrification project by a hybrid system (PV/ wind) of a residential home located in Batna-Algeria and to reduce the emissions from traditional power by using renewable energy. An autonomous hybrid wind/photovoltaic (PV)/battery power system and a PV/Wind grid connected system, has been carried out using Hybrid Optimization Model for Electric Renewable (HOMER) simulation software. As a result, it has been found that electricity from the grid can be supplied at a lower price than electricity from renewable energy at this moment.

Keywords: batna, household, hybrid system, renewable energy, techno-economy

Procedia PDF Downloads 601

Authors: Rong-Tsorng Wang

Abstract:

In this paper, we derive a pricing formula for catastrophe equity put options (or CatEPut) with non-homogeneous loss and approximated compound distributions. We assume that the loss claims arrival process is a nonhomogeneous Poisson process (NHPP) representing the clustering occurrences of loss claims, the size of loss claims is a sequence of independent and identically distributed random variables, and the accumulated loss distribution forms a compound distribution and is approximated by a heavy-tailed distribution. A numerical example is given to calibrate parameters, and we discuss how the value of CatEPut is affected by the changes of parameters in the pricing model we provided.

Keywords: catastrophe equity put options, compound distributions, nonhomogeneous Poisson process, pricing model

Procedia PDF Downloads 167

Authors: Maher Agi, Hardik Soni

Abstract:

This paper presents a deterministic model for optimized control of the inventory of a perishable product subject to both physical deterioration and degradation of its freshness condition. The demand for the product depends on its current inventory level and freshness condition. Our model allows for any positive amount of end of cycle inventory. Some useful conditions that characterize the optimal solution of the model are derived and an algorithm is presented for finding the optimal values of the price, the inventory cycle, the end of cycle inventory level and the order quantity. Numerical examples are then given. Our work shows how the product freshness in conjunction with the inventory deterioration affects the inventory management decisions.

Keywords: inventory management, lot sizing, perishable products, deteriorating inventory, age-dependent demand, stock-dependent demand

Procedia PDF Downloads 234

Authors: Z. S. Yip, T. K. Tan, C. C. Geh, T. T. Ting

Abstract:

The mobile phone is an indispensable device in today’s daily living. The arising new brands in the market with different specification are targeting at the different population. The most promising market would be the younger generation who are IT savvy. Therefore, it is beneficial to find out their factors of consideration in purchasing a mobile phone. A survey is carried out in Malaysia to discover the current youngster’s mobile phone buying behavior. This study has found that the most influencing factor of consideration is Price, followed by Feature, and Battery Lifespan. Gender and Income have no relationship with certain factors of consideration. It is important to discover the factors of consideration in order to provide industry insight into the current trend of smartphone in Malaysia.

Keywords: buying behavior, smart phone, mobile brand, mobile operating system, specification, battery lifespan

Procedia PDF Downloads 355

Authors: Mohammadreza Bakhtiari, Mehrdad Maghsoudi, Hamidreza Bakhtiari

Abstract:

This study investigates consumer behavior in the notebook computer market by integrating social media sentiment analysis with expert evaluations. The rapid evolution of the notebook industry has intensified competition among manufacturers, necessitating a deeper understanding of consumer priorities. Social media platforms, particularly Twitter, have become valuable sources for capturing real-time user feedback. In this research, sentiment analysis was performed on Twitter data gathered in the last two years, focusing on seven major notebook brands. The PyABSA framework was utilized to extract sentiments associated with various notebook components, including performance, design, battery life, and price. Expert evaluations, conducted using fuzzy logic, were incorporated to assess the impact of these sentiments on purchase behavior. To provide actionable insights, the TOPSIS method was employed to prioritize notebook features based on a combination of consumer sentiments and expert opinions. The findings consistently highlight price, display quality, and core performance components, such as RAM and CPU, as top priorities across brands. However, lower-priority features, such as webcams and cooling fans, present opportunities for manufacturers to innovate and differentiate their products. The analysis also reveals subtle but significant brand-specific variations, offering targeted insights for marketing and product development strategies. For example, Lenovo's strong performance in display quality points to a competitive edge, while Microsoft's lower ranking in battery life indicates a potential area for R&D investment. This hybrid methodology demonstrates the value of combining big data analytics with expert evaluations, offering a comprehensive framework for understanding consumer behavior in the notebook market. The study emphasizes the importance of aligning product development and marketing strategies with evolving consumer preferences, ensuring competitiveness in a dynamic market. It also underscores the potential for innovation in seemingly less important features, providing companies with opportunities to create unique selling points. By bridging the gap between consumer expectations and product offerings, this research equips manufacturers with the tools needed to remain agile in responding to market trends and enhancing customer satisfaction.

Keywords: consumer behavior, customer preferences, laptop industry, notebook computers, social media analytics, TOPSIS

Procedia PDF Downloads 24

Authors: Manel Youssef, Lotfi Belkacem

Abstract:

This paper employs multivariate long memory GARCH models to simultaneously estimate mean and conditional variance spillover effects between oil prices and different financial markets. Since different financial assets are traded based on these market sector returns, it’s important for financial market participants to understand the volatility transmission mechanism over time and across these series in order to make optimal portfolio allocation decisions. We examine weekly returns from January 1, 2003 to November 30, 2012 and find evidence of significant transmission of shocks and volatilities between oil prices and some of the examined financial markets. The findings support the idea of cross-market hedging and sharing of common information by investors.

Keywords: oil prices, stock indices returns, oil volatility, contagion, DCC-multivariate (FI) GARCH

Procedia PDF Downloads 533

Authors: Olufunke Olufunmilayo Ilemobayo, Barakat. O Abdulazeez

Abstract:

Profit making among poultry egg farmers has been a challenge to efficient distribution of scarce farm resources over the years, due majorly to low capital base, inefficient management, technical inefficiency, economic inefficiency, thus poultry egg production has moved into an underperformed situation, characterised by low profit margin. Though previous studies focus mainly on broiler production and efficiency of its production, however, paucity of information exist in the areas of profit efficiency in the study area. Hence, determinants of profit efficiency among poultry egg farmers in Ondo State, Nigeria were investigated. A purposive sampling technique was used to obtain primary data from poultry egg farmers in Owo and Akure local government area of Ondo State, through a well-structured questionnaire. socio-economic characteristics such as age, gender, educational level, marital status, household size, access to credit, extension contact, other variables were input and output data like flock size, cost of feeder and drinker, cost of feed, cost of labour, cost of drugs and medications, cost of energy, price of crate of table egg, price of spent layers were variables used in the study. Data were analysed using descriptive statistics, budgeting analysis, and stochastic profit function/inefficiency model. Result of the descriptive statistics shows that 52 per cent of the poultry farmers were between 31-40 years, 62 per cent were male, 90 per cent had tertiary education, 66 per cent were primarily poultry farmers, 78 per cent were original poultry farm owners and 55 per cent had more than 5 years’ work experience. Descriptive statistics on cost and returns indicated that 64 per cent of the return were from sales of egg, while the remaining 36 per cent was from sales of spent layers. The cost of feeding take the highest proportion of 69 per cent of cost of production and cost of medication the lowest (7 per cent). A positive gross margin of N5, 518,869.76, net farm income of ₦ 5, 500.446.82 and net return on investment of 0.28 indicated poultry egg production is profitable. Equipment’s cost (22.757), feeding cost (18.3437), labour cost (136.698), flock size (16.209), drug and medication cost (4.509) were factors that affecting profit efficiency, while education (-2.3143), household size (-18.4291), access to credit (-16.027), and experience (-7.277) were determinant of profit efficiency. Education, household size, access to credit and experience in poultry production were the main determinants of profit efficiency of poultry egg production in Ondo State. Other factors that affect profit efficiency were cost of feeding, cost of labour, flock size, cost of drug and medication, they positively and significantly influenced profit efficiency in Ondo State, Nigeria.

Keywords: cost and returns, economic inefficiency, profit margin, technical inefficiency

Procedia PDF Downloads 129

Authors: M. Farhaoui, M. Derraz

Abstract:

In the drinking water treatment processes, the optimization of the treatment is an issue of particular concern. In general, the process consists of many units as settling, coagulation, flocculation, sedimentation, filtration and disinfection. The optimization of the process consists of some measures to decrease the managing and monitoring expenses and improve the quality of the produced water. The objective of this study is to provide water treatment operators with methods and practices that enable to attain the most effective use of the facility and, in consequence, optimize the of the cubic meter price of the treated water. This paper proposes a review on optimization of drinking water treatment process by analyzing all of the water treatment units and gives some solutions in order to maximize the water treatment performances without compromising the water quality standards. Some solutions and methods are performed in the water treatment plant located in the middle of Morocco (Meknes).

Keywords: coagulation process, optimization, turbidity removal, water treatment

Procedia PDF Downloads 423

Authors: Tzu-Ching Weng, Hsin-Yi Chi

Abstract:

This study examines the effect of family succession on the cost of bank loans and non-price contractual terms. We use a unique dataset from China and find that lending banks are likely to charge high-interest rates and offer tight contractual terms, such as loan maturity and collateral requirement, for family succession firms. These findings indicate that information and default risks may arise after subsequent family successions. We also find that family succession firms can reduce the cost of bank loans by hiring top-tier auditors to enhance financial reporting credibility. This finding suggests that professional and high-quality auditors can provide extremely valuable services to family succession firms.

Keywords: family succession, cost of bank loans, loan contract terms, top-tier auditor

Procedia PDF Downloads 86

Authors: Joseph Ndegwa

Abstract:

Changes are required if energy systems are to foster long-term growth. The main problems are increasing access to inexpensive, dependable, and sufficient energy supply while addressing environmental implications at all levels. Policies can help to promote sustainable development by providing adequate and inexpensive energy sources to underserved regions, such as liquid and gaseous fuels for cooking and electricity for household and commercial usage. Promoting energy efficiency. Increased utilization of new renewables. Spreading and implementing additional innovative energy technologies. Markets can achieve many of these goals with the correct policies, pricing, and regulations. However, if markets do not work or fail to preserve key public benefits, tailored government policies, programs, and regulations can achieve policy goals. The main strategies for promoting sustainable energy systems are simple. However, they need a broader recognition of the difficulties we confront, as well as a firmer commitment to specific measures. Making markets operate better by minimizing pricing distortions, boosting competition, and removing obstacles to energy efficiency are among the measures. Complementing the reform of the energy industry with policies that promote sustainable energy. Increasing investments in renewable energy. Increasing the rate of technical innovation at each level of the energy innovation chain. Fostering technical leadership in underdeveloped nations by transferring technology and enhancing institutional and human capabilities. promoting more international collaboration. Governments, international organizations, multilateral financial institutions, and civil society—including local communities, business and industry, non-governmental organizations (NGOs), and consumers—all have critical enabling roles to play in the problem of sustainable energy. Partnerships based on integrated and cooperative approaches and drawing on real-world experience will be necessary. Setting the required framework conditions and ensuring that public institutions collaborate effectively and efficiently with the rest of society are common themes across all industries and geographical areas in order to achieve sustainable development. Powerful tools for sustainable development include energy. However, significant policy adjustments within the larger enabling framework will be necessary to refocus its influence in order to achieve that aim. Many of the options currently accessible will be lost or the price of their ultimate realization (where viable) will grow significantly if such changes don't take place during the next several decades and aren't started right enough. In any case, it would seriously impair the capacity of future generations to satisfy their demands.

Keywords: sustainable development, reliable, price, policy

Procedia PDF Downloads 65

Authors: Mohammad Aldubyan, Fateh Belaid, Anwar Gasim

Abstract:

This paper aims at linking to link residential energy efficiency to the rebound effect concept, a well-known behavioral phenomenon in which service consumption increases when consumers notice a reduction in monetary spending on energy due to improvements in energy efficiency. It provides insights on into how and why the rebound effect happens when energy efficiency improves and whether this phenomenon is positive or negative. It also shows one technique to estimate the rebound effect on the national residential level. The paper starts with a bird’s eye view of the rebound effect and then dives in in-depth into measuring the rebound effect and evaluating its impact. Finally, the paper estimates the rebound effect in the Saudi residential sector through by linking pre-estimated price elasticities of demand to the Saudi residential building stock.

Keywords: energy efficiency, rebound effect, energy consumption, residential electricity demand

Procedia PDF Downloads 108

Authors: Ezrah Kipkirui Tonui, George Otieno Orwa

Abstract:

A survey of 138 farmers was conducted in Rift valley, Kenya, in November and December 2013 in three counties (Uasin-gishu, Elgeyo-marakwet, and Tranzoia) to determine public knowledge and attitude towards genetically modified (GM) maize. Above two third (70%) of the respondents had knowledge of GM maize, mostly those educated and male. Female was found to be having low knowledge on GM maize. Public acknowledged the technology’s potential positive impacts, with more than 90% willing to adopt and more than 98% willing to buy GM seedlings at any given price. A small percentage less than 3% were of a negative opinion about willing to buy and adopt GM seeds. We conclude that GM technology has a role to play in food security in Kenya. However, the public needs more information about the technology, which can be provided through established sources of information and training. Finally, public knowledge and attitude on GM maize should be studied on a regular basis, and the survey population broadened to 47 counties.

Keywords: public, knowledge, attitudes, GM maize, Kenya

Procedia PDF Downloads 309

Authors: Trikhun Rotkasem

Abstract:

This research paper aimed to investigate hotel customers’ attitudes towards the service marketing, service behavior and perceived brand value. The focus of the study was on the Suan Sunandha Rajabhat University’s hotel. It is a small hotel which aims to provide service to mainly university’s guests. A simple random sampling technique was conducted to obtain a sample group that included 200 respondents. The research question was established as follows: What are customers’ attitudes towards the service marketing mix of hotel customers? The findings revealed the respondents’ attitudes towards the service marketing mix indicated high level in the area of product, place or distribution channel, people, and physical evidence, whereas, the respondents’ attitude towards the service marketing mix indicated medium level in the area of price, promotion, and process.

Keywords: marketing mix, perceived brand value, service behavior, hotel customers

Procedia PDF Downloads 442

Authors: C. Fúnez Guerra, B. Nieto Calderón, M. Jaén Caparrós, L. Reyes-Bozo, A. Godoy-Faúndez, E. Vyhmeister

Abstract:

The global energy system is experiencing a change of scenery. Unstable energy markets, an increasing focus on climate change and its sustainable development is forcing businesses to pursue new solutions in order to ensure future economic growth. This has led to the interest in using hydrogen as an energy carrier in transportation and industrial applications. As an energy carrier, hydrogen is accessible and holds a high gravimetric energy density. Abundant in hydrocarbons, hydrogen can play an important role in the shift towards low-emission fossil value chains. By combining hydrogen production by natural gas reforming with carbon capture and storage, the overall CO2 emissions are significantly reduced. In addition, the flexibility of hydrogen as an energy storage makes it applicable as a stabilizer in the renewable energy mix. The recent development in hydrogen fuel cells is also raising the expectations for a hydrogen powered transportation sector. Hydrogen value chains exist to a large extent in the industry today. The global hydrogen consumption was approximately 50 million tonnes (7.2 EJ) in 2013, where refineries, ammonia, methanol production and metal processing were main consumers. Natural gas reforming produced 48% of this hydrogen, but without carbon capture and storage (CCS). The total emissions from the production reached 500 million tonnes of CO2, hence alternative production methods with lower emissions will be necessary in future value chains. Hydrogen from electrolysis is used for a wide range of industrial chemical reactions for many years. Possibly, the earliest use was for the production of ammonia-based fertilisers by Norsk Hydro, with a test reactor set up in Notodden, Norway, in 1927. This application also claims one of the world’s largest electrolyser installations, at Sable Chemicals in Zimbabwe. Its array of 28 electrolysers consumes 80 MW per hour, producing around 21,000 Nm3/h of hydrogen. These electrolysers can compete if cheap sources of electricity are available and natural gas for steam reforming is relatively expensive. Because electrolysis of water produces oxygen as a by-product, a system of Autothermal Reforming (ATR) utilizing this oxygen has been analyzed. Replacing the air separation unit with electrolysers produces the required amount of oxygen to the ATR as well as additional hydrogen. The aim of this paper is to evaluate the technical and economic potential of large-scale production of hydrogen for oil refining industry. Sensitivity analysis of parameters such as investment costs, plant operating hours, electricity price and sale price of hydrogen and oxygen are performed.

Keywords: autothermal reforming, electrolyser, hydrogen, natural gas, steam methane reforming

Procedia PDF Downloads 211

Authors: Saeed Yazdani, F. Nekoofar

Abstract:

Considering the importance and scarcity of water resources, the efficient management of water resources is of great importance. In the agriculture sector, farmers are facilitated with various practices and technologies to encounter water insufficiency. This study aims to assess socio-economic factors affecting the application of water-saving technologies. A Logit method was employed to examine the impact of different variables on the use of water-saving technology. The required data was gathered from a sample of 204 farmers in 2021 in Alborz Province in Iran. The results indicate that different variables such as crop price variability, water sources, farm size, income, education, experience, membership in cooperatives have positive effects, and variables such as age and number of plots have negative effects on the probability of applying modern water-saving technologies.

Keywords: socio-economics, water, irrigation, water saving technologies, scarcity

Procedia PDF Downloads 21

Authors: Anocha Rojanapanich

Abstract:

This research aimed to identify important factors that effect customer satisfaction in boutique hotels and the important factors effecting customer loyalty in returning to boutique hotels. Furthermore, this study also aimed to study demographics, which effect variable factors. Four hundred questionnaires were completed by customers of the boutique hotels. The descriptive statistics used in this paper were percentages, means, and standard deviation (S.D.), while hypothesis testing was done using T-test, Anova, Correlation and Regression to analyze the relationship among those factors. In terms of the purpose in staying, it was found that the largest respondent was for ‘leisure purposes’. While the frequency indicated that most of the customers who stayed ‘once’in the last two years in the hotels had less concern in the hotel’s image than other groups. For customer’s perceived value and income levels had an influence on customer perceived values in both functional value price and emotional value.

Keywords: boutique hotels, customer attitude, customer satisfaction, customer loyalty

Procedia PDF Downloads 308

Authors: Rasha Waheeb, Bjorn Andersen, Rafa Shakir

Abstract:

Purpose The purpose of this study is to avoid delays that occur in emergency reconstruction projects especially in post disaster circumstances whether if they were natural or manmade due to their particular national and humanitarian importance. We presented a theoretical and practical concepts for projects management in the field of construction industry that deal with a range of global and local trails. This study aimed to identify the factors of effective delay in construction projects in Iraq that affect the time and the specific quality cost, and find the best solutions to address delays and solve the problem by setting parameters to restore balance in this study. 30 projects were selected in different areas of construction were selected as a sample for this study. Design/methodology/approach This study discusses the reconstruction strategies and delay in time and cost caused by different delay factors in some selected projects in Iraq (Baghdad as a case study).A case study approach was adopted, with thirty construction projects selected from the Baghdad region, of different types and sizes. Project participants from the case projects provided data about the projects through a data collection instrument distributed through a survey. Mixed approach and methods were applied in this study. Mathematical data analysis was used to construct models to predict delay in time and cost of projects before they started. The artificial neural networks analysis was selected as a mathematical approach. These models were mainly to help decision makers in construction project to find solutions to these delays before they cause any inefficiency in the project being implemented and to strike the obstacles thoroughly to develop this industry in Iraq. This approach was practiced using the data collected through survey and questionnaire data collection as information form. Findings The most important delay factors identified leading to schedule overruns were contractor failure, redesigning of designs/plans and change orders, security issues, selection of low-price bids, weather factors, and owner failures. Some of these are quite in line with findings from similar studies in other countries/regions, but some are unique to the Iraqi project sample, such as security issues and low-price bid selection. Originality/value we selected ANN’s analysis first because ANN’s was rarely used in project management , and never been used in Iraq to finding solutions for problems in construction industry. Also, this methodology can be used in complicated problems when there is no interpretation or solution for a problem. In some cases statistical analysis was conducted and in some cases the problem is not following a linear equation or there was a weak correlation, thus we suggested using the ANN’s because it is used for nonlinear problems to find the relationship between input and output data and that was really supportive.

Keywords: construction projects, delay factors, emergency reconstruction, innovation ANN, post disasters, project management

Procedia PDF Downloads 165

Authors: Hande Begum Bumin Doyduk, Elif Okan Yolbulan

Abstract:

Innovation is very important for success and competitiveness of countries, as well as business sectors and individuals' firms. In order to have successful and sustainable innovations, the other side of the game, consumers, should be aware of the innovations and appreciate them. In this study, the consumer innovativeness is focused and the relationship between motivated consumer innovativeness and consumer shopping styles is analyzed. Motivated consumer innovativeness scale by (Vandecasteele & Geuens, 2010) and consumer shopping styles scale by (Sproles & Kendall, 1986) is used. Data is analyzed by SPSS 20 program through realibility, factor, and correlation analysis. According to the findings of the study, there are strong positive relationships between hedonic innovativeness and recreational shopping style; social innovativeness and brand consciousness; cognitive innovativeness and price consciousness and functional innovativeness and perfectionistic high-quality conscious shopping styles.

Keywords: consumer innovativeness, consumer decision making, shopping styles, innovativeness

Procedia PDF Downloads 431

Authors: Nnadi Ezekiel Oluwaseun Ejiofor

Abstract:

This research investigates the effects of poor cost estimation, material cost variations, and payment punctuality on the financial health and execution of construction projects in Nigeria. To achieve the objectives of the study, a quantitative research approach was employed, and data was gathered through an online survey of 74 construction industry professionals consisting of quantity surveyors, contractors, and other professionals. The study surveyed input on cost estimation errors, price fluctuations, and payment delays, among other factors. The responses of the respondents were analyzed using a five-point Likert scale and the Relative Importance Index (RII). The findings demonstrated that the errors in cost estimating in the Bill of Quantity (BOQ) have a high degree of negative impact on the reputation and image of the participants in the projects. The greatest effect was experienced on the likelihood of obtaining future endeavors for contractors (mean value = 3.42), followed by the likelihood of obtaining new commissions by quantity surveyors (mean value = 3.40). The level of inaccuracy in costing that undershoots exposes them to risks was most serious in terms of easement of construction and effects of shortage of funds to pursue bankruptcy (hence fears of mean value = 3.78). There was also considerable financial damage as a result of cost underestimation, whereby contractors suffered the worst loss in profit (mean value = 3.88). Every expense comes with its own peculiar risk and uncertainty. Pressure on the cost of materials and every other expense attributed to the building and completion of a structure adds risks to the performance figures of a project. The greatest weight (mean importance score = 4.92) was attributed to issues like market inflation in building materials, while the second greatest weight (mean importance score = 4.76) was due to increased transportation charges. On the other hand, delays in payments arising from issues of the clients like poor availability of funds (RII=0.71) and contracting issues such as disagreements on the valuation of works done (RII=0.72) or other reasons were also found to lead to project delays and additional costs. The results affirm the importance of proper cost estimation on the health of organization finances and project risks and finishes within set time limits. As for the suggestions, it is proposed to progress on the methods of costing, engender better communications with the stakeholders, and manage the delays by way of contracting and financial control. This study enhances the existing literature on construction project management by suggesting ways to deal with adverse cost inaccuracies and availability of materials due to delays in payments which, if addressed, would greatly improve the economic performance of the construction business.

Keywords: cost estimation, construction project management, material price fluctuations, payment delays, financial impact

Procedia PDF Downloads 8