Search results for: trade contractors

Authors: Ali Mohammadi

Abstract:

One of the concerns that employers and contractors have in creating long tunnels is that when the excavation is completed, the tunnel will be exited in the correct position according to designed, the deviation of the tunnel from its path can have many costs for the employer and the contractor, lack of correct calculations by the surveying engineer or the employer and contractors lack of importance to the surveying team in guiding the tunnel can cause the tunnel to deviate from its path and this deviation becomes a disaster. But employers are able to make the right decisions so that the tunnel is guided with the highest precision if they consider some points. We are investigating two tunnels with lengths of 12 and 18 kilometers that were dug by Tunnel boring machine machines to transfer water, how the contractor’s decision to control the 12 kilometer tunnel caused the most accuracy of one centimeter to the next part of the tunnel will be connected. We will also investigate the reasons for the deviation of axis in the 18 km tunnel about 20 meters. Also we review the calculations of surveyor engineers in both tunnels and what challenges there will be in the calculations and teach how to solve these challenges. Surveying calculations are the most important part in controlling long tunnels.

Keywords: UTM, localization, scale factor, traverse

Procedia PDF Downloads 38

Authors: Mohsen Qasemi

Abstract:

In the international economic order multilateral trading system which established by General Agreement on Tariffs and Trade 1947 (GATT) was dominant until about two decades ago. Regional Trade Agreements (RTAs) have changed this order and become an important phenomenon. One of the main objectives of the World Trade Organization (WTO) as a central institution of multilateral trading system is raising standards of living. There are many scholars who suggest that WTO should take steps to protect human rights in its activities. Although it has always been opposing views who declare that since WTO has no explicit rule for human rights, it has no human rights related obligations. At the time that the WTO was established, member states began to join RTAs and since then, the escalating growth of these agreements and their effects on multilateral trading system has been controversial. There are some aspects of RTAs that have received too little attention from scholars. It is important to take a different view and evaluate the RTAs based on non-commercial aspects. The present paper seeks to answer this question: which system could be more useful in protecting human rights, RTAs or WTO?

Keywords: WTO, RTAs, human rights, multilateral trading system, non discrimination

Procedia PDF Downloads 333

Authors: B. Seetanah, H. Neeliah

Abstract:

This paper investigates the relationship among energy, emissions and economic growth in Mauritius in the presence of trade activities, with capital and labour as other control variables. Using annual data from 1960 to 2011, it is found that the variables are non-stationary and cointegrated. The relationship among the various variables are thus examined in a dynamic VECM framework. Our empirical results comply with the growth hypothesis. Output elasticities of 0.17, 0.25 and 0.43 show that increases in energy consumption cause increases in economic growth, capital accumulation and trade in the long run. We also found that CO2 negatively affects output, but has no significant effect on trade. Findings for the long-run generally tend to tally with those in the short-run. Interestingly we found that energy consumption has a significant impact on CO2 emissions. Our results tend to suggest that implementing energy conservation strategies to mitigate the negative impact of CO2 emissions can dent economic growth, and that promoting cleaner energy production could be a better alternative for Mauritius.

Keywords: energy, emissions, economic growth, export, VECM

Procedia PDF Downloads 434

Authors: Amirreza Attarzadeh

Abstract:

This paper aims to investigate the relationship between economic variables, e.g., inflation rate, interest rate, trade openness and the growth rate of GDP, with domestic investment. The present study also draws on conceptual economy related theories to verify the negative effect of interest rates on domestic investment. However, trade openness and growth rate had a positive correlation, and the inflation rate may have a positive or negative impact on domestic investment.

Keywords: inflation rate, growth rate of GDP, interest rate and trade openness, domestic investment

Procedia PDF Downloads 376

Authors: Z. Hamed, K. Sa'deya, E. Abdelrasheed, I. Mahamid

Abstract:

The construction industry is one of the main sectors that play basic role in the urban and rural development of a society. It provides important ingredients for the development of an economy. However, many construction projects experience extensive cost overrun. This study was conducted to identify the causes of cost overrun in building construction contracts in Al Madinah, Saudi Arabia and test the importance of these causes from contractors' perspective. To achieve the study objectives, a questionnaire survey was conducted to identify and rank cost overrun causes from the perspective of contractors. The findings found that the top five cost overrun causes are: lack of experience in the line of work, lack of labor productivity, delay in payments, rework and material waste. It is hoped that the findings will guide efforts to improve the performance of construction industry in Saudi Arabia and other developing countries.

Keywords: building, contractor, cost increase, cost overrun

Procedia PDF Downloads 121

Authors: Caroline S. Dutra, Tatiana C. Squeff

Abstract:

It is well known that the history between South Korea and Japan influences their international relations; thus, also encompassing their economic relations. In this sense, it is impossible to analyze the latter without understanding the development of the former, which is known for episodes of hostility, like on Japanese colonization, but also had moments of cultural and trade interexchange. Indeed, since 1965, with the establishment of diplomatic relations between both countries, their trade relations have improved, especially after both nations have signed the General Agreement on Tariffs and Trade (GATT). Thereafter, with the establishment of the World Trade Organization (WTO) in 1995, another chapter of their diplomatic and economic relations have been inaugurated. Hence, bearing in mind this history between both nations, this research intends to examine their relations through the analysis of the WTO panels they have engaged in between each other, which are, in chronological order, “DS323: Japan – Import Quotas on Dried Laver and Seasoned Laver”, “DS336: Japan - Countervailing Duties on Dynamic Random Access Memories from Korea”, “DS495: Korea - Import Band, and Testing and Certification Requirements for Radionuclides”, “DS553: Korea - Sunset Review of Anti-Dumping Duties on Stainless Steel Bars” and “DS571: Korea - Measures Affecting Trade in Commercial Vessels”. The objective of this case analysis is to point out what are the areas that are more conflictual between Japan and South Korea in regard to their economic relations so that it is possible to assert on their future (economic) relations and other possible outcomes. And in order to do so, bibliographic and documental research will be made, particularly those involving the WTO and the nations under consideration. Regarding the methods used, it is important to highlight that this is applied research in the field of international economic relations and international law, which follows a hypothetic-deductive model.

Keywords: international economic relations, Japan, South Korea, World Trade Organization

Procedia PDF Downloads 132

Authors: Moh’d A. AL-Shboul

Abstract:

Recently, and due to Arab spring and terrorism around the globe, pushing and driving most governments potentially to harmonize their border measures particularly the regional and an international transit trade within and among Customs Unions. The main purpose of this study is to investigate and provide an insight for monitoring and controlling the trade supply chain within and among different countries by using technological advancement (i.e. an electronic tracking system, etc.); furthermore, facilitate the local and intra-regional trade among countries through reviewing the recent trends and practical implementation of an electronic transit traffic and cargo that related to customs measures by introducing and supporting some case studies of several international and landlocked transit trade countries. The research methodology employed in this study was described as qualitative by conducting few interviews with managers, transit truck drivers, and traders and reviewing the related literature to collect qualitative data from secondary sources such as statistical reports, previous studies, etc. The results in this study show that Jordan and other countries around the globe that used an electronic tracking system for monitoring transit trade has led to a significant reduction in cost, effort and time in physical movement of goods internally and crossing through other countries. Therefore, there is no need to escort transit trucks by customs staff; hence, the rate of escort transit trucks is reduced by more than ninety percent, except the bulky and high duty goods. Electronic transit traffic has been increased; the average transit time journey has been reduced by more than seventy percent and has led to decrease in rates of smuggling up to fifty percent. The researcher recommends considering Jordan as regional and international office for tracking electronically and monitoring the transit trade for many considerations.

Keywords: electronic tracking system, facilitation system, regional and international corridor, supply chain security, transit trade

Procedia PDF Downloads 467

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 473

Authors: Luqman Afolabi

Abstract:

This paper measures the impacts of trade and institutions on environmental quality in Sub-Saharan Africa (SSA). To examine the direction and the magnitude of the effects, the study employs the pooled mean group (PMG) estimation technique on the panel data obtained from the World Bank’s World Development and Governance Indicators, between 1996 and 2018. The empirical estimates validate the environmental Kuznets curve hypothesis (EKC) for the region, even though there have been inconclusive results on the environment – growth nexus. Similarly, a positive coefficient is obtained on the impact of trade on the environment, while the impact of the institutional indicators produce mixed results. A significant policy implication is that the governments of the SSA countries pursue policies that tend to increase economic growth, so that pollutants may be reduced. Such policies may include the provision of incentives for sustainable growth-driven industries in the region. In addition, the governance infrastructures should be improved in such a way that appropriate penalties are imposed on the pollutants, while advanced technologies that have the potentials to reduce environmental degradation should be encouraged. Finally, it is imperative from these findings that the governments of the region should promote their trade relations and the competitiveness of their local industries in order to keep pace with the global markets.

Keywords: environmental quality, institutional quality sustainable development goals, trade

Procedia PDF Downloads 115

Authors: Heeyong Noh, Seongryong Kang, Sungjoo Lee

Abstract:

As the world becomes increasingly interconnected, firms have tried to explore market opportunities not only in the domestic market but also abroad. In particular, transactions of intangible assets in the global market now take on great importance. Accordingly, technology transfer activities such as patent licensing, copyright transfer, or workforce trainings which are considered significant to leverage an organization’s internal capabilities, are occurring more frequently and briskly across the world than ever before. Though a number of studies have addressed the issues regarding technology transfer, most of them have focused on university-industry technology transfer. Of course, some have investigated international technology transfer phenomenon but used patent citations data as a proxy. In order to understand the phenomena more clearly, it would be necessary to collect and analyze data that can measure technology transfer activities between firms more directly. Therefore, this study aims to examine the patterns of international trade in technology by employing data about international technology in-licensing activities in Korean firms. We also investigate the effect of international technology in-licensing strategy on a firm’s innovation performance. The research findings are expected to help R&D managers understand how firms have absorbed technological knowledge from foreign firms in the form of licensing and further develop effective international collaboration strategies. In addition, significant implications can be offered for political decision-making regarding technology trade within increasing international interconnections.

Keywords: international technology trade, technology trade effect, technology transfer, R&D managers

Procedia PDF Downloads 335

Authors: Benard Omogo

Abstract:

The Kenyan Constitution 2010 introduced various commissions to devolve the powers that were previously centralized through the imperial Presidency. One of the commissions that directly determine the levels of remuneration and terms of service of Kenyan workers is the Salary and Remuneration Commission (SRC). Article 230 of the Kenyan Constitution 2010 mandates this commission to regularly review the remuneration and benefits of all the state officers and to advise the national and county governments on the remuneration and benefits of all other public officers. At the same time, article 54 of the Kenyan Labor Relations Act 2007 provides for the recognition of trade unions and collective bargaining agreements. The emerging challenges, therefore, originate from the conflicts of the mandate of the Salary and Remuneration Commission, whose advice is almost adopted as the order and this undermines the outcome of the Collective Bargaining Agreements. This has seen so many trade unions in Kenya being rendered irrelevant. This research paper is therefore going to sample the various trade unions of Kenya to assess the challenges that result from the position of the Salary and Remuneration Commission. We will also extend it by purposively sampling several trade unions in Africa to determine how they handle such challenges. The results from this paper will be useful to the Kenyan Lawmakers and Africa at large and may inform them to consider reviewing the laws and acts that relate to the trade unions for prosperity.

Keywords: salary, remuneration, collective, bargaining, labor laws

Procedia PDF Downloads 142

Authors: Dewan Ahsan

Abstract:

Denmark is well ahead in generating electricity from renewable sources. The offshore wind sector is playing the pivotal role to achieve this target. Though there is a rapid growth of offshore wind sector in Denmark, still there is a dearth of synchronization in OHS (occupational health and safety) regulation and standards. Therefore, this paper attempts to ascertain: i) what are the major challenges of the company specific OHS standards? ii) why does the offshore wind industry need a standardized OHS management system? and iii) who can play the key role in this process? To achieve these objectives, this research applies the interview and survey techniques. This study has identified several key challenges in OHS management system which are; gaps in coordination and communication among the stakeholders, gaps in incident reporting systems, absence of a harmonized OHS standard and blame culture. Furthermore, this research has identified eleven key stakeholders who are actively involve with the offshore wind business in Denmark. As noticed, the relationships among these stakeholders are very complex specially between operators and sub-contractors. The respondent technicians are concerned with the compliance of various third-party OHS standards (e.g. ISO 31000, ISO 29400, Good practice guidelines by G+) which are applying by various offshore companies. On top of these standards, operators also impose their own OHS standards. From the technicians point of angle, many of these standards are not even specific for the offshore wind sector. So, it is a big challenge for the technicians and sub-contractors to comply with different company specific standards which also elevate the price of their services offer to the operators. For instance, when a sub-contractor is competing for a bidding, it must fulfill a number of OHS requirements (which demands many extra documantions) set by the individual operator and/the turbine supplier. According to sub-contractors’ point of view these extra works consume too much time to prepare the bidding documents and they also need to train their employees to pass the specific OHS certification courses to accomplish the demand for individual clients and individual project. The sub-contractors argued that in many cases these extra documentations and OHS certificates are inessential to ensure the quality service. So, a standardized OHS management procedure (which could be applicable for all the clients) can easily solve this problem. In conclusion, this study highlights that i) development of a harmonized OHS standard applicable for all the operators and turbine suppliers, ii) encouragement of technicians’ active participation in the OHS management, iii) development of a good safety leadership, and, iv) sharing of experiences among the stakeholders (specially operators-operators-sub contractors) are the most vital strategies to overcome the existing challenges and to achieve the goal of 'zero accident/harm' in the offshore wind industry.

Keywords: green energy, offshore, safety, Denmark

Procedia PDF Downloads 184

Authors: Theophilius Adekunle Tinuoye

Abstract:

Trade unions are groups formed essentially to promote, articulate and enhance the welfare of workers. They are expected to defend the workers interests and participate actively in workplace exchanges. But for trade unions to function effectively and actualize their lofty aspirations in the context of the current dynamic and ever-changing industrial relations context, they must not only have qualified and competent leaders, but also flexible and effective structure, systems, organograms, constitution, and administrative processes in place to compliment their policies and programmes. An important aspect of industrial relations is the existence of cordial tripartite or bipartite interactions between stakeholders and other social partners that are indispensable to the creation of positive and mutually beneficial exchanges and outcomes. This paper canvassed that unions must be structurally viable and administratively cohesive in order to be effective, pragmatic, functional and remain relevant. It also argued that weak, structurally deficient and less organized unions often find it immensely difficult to actualize workers goals. Finally, it outlined basic principles that will enhance union administration, guarantee that unions will continue to satisfy the yearnings of its members in these trying times and finally foster peaceful industrial relations climate and cordial labor relations between trade unions, employers /management and government.

Keywords: governance, labor relations, trade unions, workers

Procedia PDF Downloads 305

Authors: Mohamed El-Khateeb

Abstract:

Encompassing inventory, warehousing, and transportation management, logistics is a crucial predictor of firm performance. This has been extensively proven by extant literature in business and operations management. Logistics is also a fundamental determinant of a country's ability to access international markets. Available studies in international and transport economics have shown that limited transport infrastructure and underperforming transport services can severely affect international competitiveness. However, the evidence lacks the overall impact of logistics performance-encompassing all inventory, warehousing, and transport components- on global trade. In order to fill this knowledge gap, the paper uses a gravitational trade model with 155 countries from all geographical regions between 2007 and 2018. Data on logistics performance is obtained from the World Bank's Logistics Performance Index (LPI). First, the relationship between logistics performance and a country’s total trade is estimated, followed by a breakdown by the economic sector. Then, the analysis is disaggregated according to the level of technological intensity of traded goods. Finally, after evaluating the intensive margin of trade, the relevance of logistics infrastructure and services for the extensive trade margin is assessed. Results suggest that: (i) improvements in both logistics infrastructure and services are associated with export growth; (ii) manufactured goods can significantly benefit from these improvements, especially when both exporting and importing countries increase their logistics performance; (iii) the quality of logistics infrastructure and services becomes more important as traded goods are technology-intensive; and (iv) improving the exporting country's logistics performance is essential in the intensive margin of trade while enhancing the importing country's logistics performance is more relevant in the extensive margin.

Keywords: low-cost, recycling, reuse, solid waste, wastewater treatment

Procedia PDF Downloads 165

Authors: Ivana Yuniarti, Iwan Ridwansyah

Abstract:

This paper delivers a review of various methodologies for habitat assessment and a proposed methodology to assess an endemic fish species habitat in Lake Maninjau, Indonesia as a part of a Ph.D. project. This application is mainly aimed to assess the trade-off between the economic value of aquaculture and the fisheries. The proposed methodology is a generalized linear model (GLM) combined with GIS to assess presence-absence data or habitat suitability index (HSI) combined with the analytical hierarchy process (AHP). Further, a cost of habitat replacement approach is planned to be used to calculate the habitat value as well as its trade-off with the economic value of aquaculture. The result of the study is expected to be a scientific consideration in local decision making and to provide a reference for other areas in the country.

Keywords: AHP, habitat, GLM, HSI, Maninjau

Procedia PDF Downloads 122

Authors: E. Kissi, V. K. Acheamfour, J. J. Gyimah, T. Adjei-Kumi

Abstract:

Factoring accounts receivable is widely accepted as an alternative financing source and utilized in almost every industry that sells business-to-business or business-to-government. However, its patronage in the construction industry is very limited as some barriers hinder its application in the construction industry. This study aims at assessing the barriers to the use of factoring accounts receivables in the Ghanaian construction industry. The study adopted the sequential exploratory research method where structured and unstructured questionnaires were conveniently distributed to D1K1 and D2K2 construction firms in Ghana. Using the one-sample t-test and Kendall’s Coefficient of concordance data was analyzed. The most severe challenge concluded is the high cost of factoring patronage. Other critical challenges identified were low knowledge on factoring processes, inadequate access to information on factoring, and high risks involved in factoring. Hence, it is recommended that contractors should be made aware of the prospects of factoring of accounts receivables in the construction industry. This study serves as basis for further rigorous research into factoring of accounts receivables in the industry.

Keywords: barriers, contractors, factoring accounts receivables, Ghanaian, perception

Procedia PDF Downloads 97

Authors: Rishabh Garg

Abstract:

Traditionally, business parties build trust with a centralized operating mechanism, such as payment by letter of credit. However, the increase in cyber-attacks and malicious hacking has jeopardized business operations and finance practices. Emerging markets, owing to their higher banking risks and bigger presence of digital financing, are looking forward to technology-driven solutions, financial inclusion and innovative working paradigms. Blockchain has the potential to enhance transaction transparency and supply chain traceability. It has captured a vast landscape with 200 million crypto users worldwide. Fintech and blockchain products are popping up across brokerage, digital wallets, exchanges, post-trade clearance, settlement, middleware, infrastructure, and base protocols.

Keywords: blockchain, distributed ledger technology, decentralized applications, ethereum, smart contracts, trade finance

Procedia PDF Downloads 122

Authors: Pornpimol Chaiwuttisak

Abstract:

The study aims to compare the performance of the logistics for Thailand’s wholesale and retail trade industries (except motor vehicles, motorcycle, and stalls) by using data (data envelopment analysis). Thailand Standard Industrial Classification in 2009 (TSIC - 2009) categories that industries into sub-group no. 45: wholesale and retail trade (except for the repair of motor vehicles and motorcycles), sub-group no. 46: wholesale trade (except motor vehicles and motorcycles), and sub-group no. 47: retail trade (except motor vehicles and motorcycles. Data used in the study is collected by the National Statistical Office, Thailand. The study consisted of four input factors include the number of companies, the number of personnel in logistics, the training cost in logistics, and outsourcing logistics management. Output factor includes the percentage of enterprises having inventory management. The results showed that the average relative efficiency of small-sized enterprises equals to 27.87 percent and 49.68 percent for the medium-sized enterprises.

Keywords: DEA, wholesales and retails, logistics, Thailand

Procedia PDF Downloads 392

Authors: Gor Muradyan

Abstract:

The paper is about friction and wear, including mechanisms, modeling, characterization, measurement and testing case in Bangladesh. Bangladesh is a country under development, A lot of people live here, approximately 145 million. The territory of this country is very small. Therefore buildings are very close to each other. As the pipe lines are very old, and people get almost dirty water, there are a lot of ongoing projects under ADB. In those projects the contractors using HDD machines (Horizontal Directional Drilling ) and grundoburst. These machines are working underground. As ground in Bangladesh is very sludge, machine can't work relevant because of big friction in the soil. When drilling works are finished machine is pulling the pipe underground. Very often the pulling of the pipes becomes very complicated because of the friction. Therefore long section of the pipe laying can’t be done because of a big friction. In that case, additional problems rise, as well as additional work must be done. As we mentioned above it is not possible to do big section of the pipe laying because of big friction in the soil, Because of this it is coming out that contractors must do more joints, more pressure test. It is always connected with additional expenditure and losing time. This machine can pull in 75 mm to 500 mm pipes connected with the soil condition. Length is possible till 500m related how much friction it will had on the puller. As less as much it can pull. Another machine grundoburst is not working at this soil condition at all. The machine is working with air compressor. This machine are using for the smaller diameter pipes, 20 mm to 63 mm. Most of the cases these machines are being used for the installing of the house connection pipes, for making service connection. To make a friction less contractors using bigger pulling had then the pipe. It is taking down the friction, But the problem of this machine is that it can't work at sludge. Because of mentioned reasons the friction has a big mining during this kind of works. There are a lot of ways to reduce the friction. In this paper we'll introduce the ways that we have researched during our practice in Bangladesh.

Keywords: Bangladesh, friction and wear, HDD machines, reducing friction

Procedia PDF Downloads 276

Authors: Sakapas Saengchai

Abstract:

A Study on Strengthening the Security of the Thai-Myanmar Border Trade Area of the people in the Mae Sot customs checkpoint area, Tak province, was designed as a qualitative research study. Its objectives were to study the principles of strengthening border trade security and enhancing people's participation. To develop a border trade model that enhances the spatial economy and improves people's quality of life by collecting data using a participant observation method. In-depth interview group chats border checkpoint administrators, Mae Sot customs checkpoint, Tak province, private entrepreneurs, community leaders, and the opening of a community forum to exchange opinions with people in the area. The results of the study found that 1. Security development is to promote crime reduction. Reduce drug trafficking problems Smuggling and human trafficking have been reduced. Including planning and preparation to protect people from terrorism, epidemics, and communicable diseases, including cooperation with Burma on border rules for people and workers, 2. Wealth development is to promote investment. Transport links value chain logistics Cross-border goods and services on the Thai-Myanmar border Both amending regulations and laws to promote fair trade. Emphasis on convenient and fast service as well as promoting the Thai border area to be a tourist attraction that can create prosperity and income for the community in the area By using balanced natural resources, with production and consumption that are environmentally friendly, and emphasizes the participation of the public sector, the private sector, and people from all sectors in the sustainable development of the Thai border.

Keywords: security, border trade, customs, participation, people

Procedia PDF Downloads 147

Authors: Abdulkadir Adamu Shehu

Abstract:

Company’s reputation is an elusive asset. The reputation gained by companies must be preserved for sustainability of the company. However, the construction project is still suffering from declination of character due to the factors that affect their reputation. The problem led to the loss of projects, abandoning of the projects and many more. This contributed to negative impact on the contractors in the construction industry. As for today, previous studies have not investigated in this regards yet. For that reason, this paper examines the factors which could promote contractor’s reputation in the construction industry in Nigeria. To achieve this aim, 140 questionnaires were distributed to the Nigerian contractors. Based on the 67% response rate, descriptive analysis and analysis of variance (ANOVA) were the tools applied for the data obtained to be analysed. The result shows that, good communication system and improve quality of output of products are the most significant variables that can promote contractor’s reputation. The homogenous analyses indicate that there are significant different perceptions of respondents in term of the significant effects. The research concluded that contractor’s reputation in construction industry must be maintained and further research was suggested to focus on the qualitative method to have in-depth knowledge on contractor’s reputation in the construction industry.

Keywords: construction industry, contractor’s reputation, effects of delay, Nigeria

Procedia PDF Downloads 398

Authors: S. U. Kunya, S. A. Mohammad

Abstract:

Construction projects in Nigeria are characterized with risks emanating from delays and accompanying cost-overruns. The aim of the study was to identify and assess factors constraining the utilization of risk management strategies in the execution of public construction project in North-East Nigeria. Data was collected with the aid of a well-structured questionnaire administered to three identified projects in the North-east. Data collected were analysed using the severity index. Findings revealed political involvement, selection of inexperienced contractors and lack of coordinated public sector strategy as the most severe factors constraining the utilization of risk management strategies. The study recommended that: formulation of laws to prevent negative political meddling in construction projects; selection of experienced, risk-informed contractors; and comprehensive risk assessment and planning on all public construction projects.

Keywords: factors, Nigeria, north-east, public projects, risk management, strategies, utilization

Procedia PDF Downloads 480

Authors: Jang-Hwan Jo

Abstract:

The supply management of ecosystem services of local forests is an essential issue as it is linked to the ecological welfare of local residents. This study aims to estimate the supply, trade-offs, and synergies of local forest regulating ecosystem services using a land cover classification map (LCCM) and a forest types map (FTM). Rigorous literature reviews and Expert Delphi analysis were conducted using the detailed variables of 1:5,000 LCCM and FTM. Land-use scoring method and Getis-Ord Gi* Analysis were utilized on detailed variables to propose a method for estimating supply, trade-offs, and synergies of the local forest regulating ecosystem services. The analysis revealed that the rank order (1st to 5th) of supply of regulating ecosystem services was Erosion prevention, Air quality regulation, Heat island mitigation, Water quality regulation, and Carbon storage. When analyzing the correlation between defined services of the entire city, almost all services showed a synergistic effect. However, when analyzing locally, trade-off effects (Heat island mitigation – Air quality regulation, Water quality regulation – Air quality regulation) appeared in the eastern and northwestern forest areas. This suggests the need to consider not only the synergy and trade-offs of the entire forest between specific ecosystem services but also the synergy and trade-offs of local areas in managing the regulating ecosystem services of local forests. The study result can provide primary data for the stakeholders to determine the initial conditions of the planning stage when discussing the establishment of policies related to the adjustment of the supply of regulating ecosystem services of the forests with limited access. Moreover, the study result can also help refine the estimation of the supply of the regulating ecosystem services with the availability of other forms of data.

Keywords: ecosystem service, getis ord gi* analysis, land use scoring method, regional forest, regulating service, synergies, trade-offs

Procedia PDF Downloads 42

Authors: Emmanuel Dele Balogun

Abstract:

This paper analyzes, using descriptive statistics and econometrics data which span the period 1981 to 2014 to gauge the effects of trade policy incentives on economic growth in Nigeria. It argues that the provided incentives penalize economic growth during pre-trade liberalization eras, but stimulated a rapid increase in total factor productivity during the post-liberalization period of 2000 to 2014. The trend analysis shows that Nigeria maintained high tariff walls in economic regulation eras which became low in post liberalization era. The protections were in favor of infant industries, which were mainly appendages of multinationals but against imports of competing food and finished consumer products. The trade openness index confirms the undue exposure of Nigeria’s economy to the vagaries of international market shocks; while banking sector recapitalization and new listing of telecommunications companies deepened the financial markets in post-liberalization era. The structure of economic incentives was biased in favor of construction, trade and services, but against the real sector despite protectionist policies. Total Factor Productivity (TFP) estimates show that the Nigerian economy suffered stagnation in pre-liberalization eras, but experienced rapid growth rates in post-liberalization eras. The regression results relating trade policy incentives to TFP growth rate yielded a significant but negative intercept suggesting that a non-interventionist policy could be detrimental to economic progress, while protective tariff which limits imports of competing products could spur productivity gains in domestic import substitutes beyond factor growth with market liberalization. The main constraint to the effectiveness of trade policy incentives is the failure of benefiting industries to leverage on the domestic factor endowments of the nation. This paper concludes that there is the need to review the current economic transformation strategies urgently with a view to provide policymakers with a better understanding of the most viable options that could make for rapid success.

Keywords: economic growth, macroeconomic incentives, total factor productivity, trade policies

Procedia PDF Downloads 294

Authors: Shehu Usman Rano Aliyu

Abstract:

Despite the significance of finance as a major trade lubricant, evidence in the literature alludes to its scarcity and increasing cost, especially in developing countries where small and medium-scale enterprises are worst affected. The creation of the African Continental Free Trade Area (AFCFTA) in 2018, an organ of the African Union (AU), was meant to serve as a beacon for deepening economic integration through the removal of trade barriers inhibiting intra-African trade and movement of persons, among others. Hence, this research explores the role Islamic trade finance (ITF) could play in spurring intra- and inter-African trade. The study involves six countries; Egypt, Kenya, Malaysia, Morocco, Nigeria, and Saudi Arabia, and employs survey research, a total of 430 sample data, and SmartPLS Structural Equation Modelling (SEM) techniques in its analyses. We find strong evidence that Shari’ah, legal and regulatory compliance issues of the ITF institutions rhythm with the internal, national, and international compliance requirements equally as the unique instruments applied in ITF. In addition, ITF was found to be largely driven by global economic and political stability, socially responsible finance, ethical and moral considerations, risk-sharing, and resilience of the global Islamic finance industry. Further, SMEs, Governments, and Importers are the major beneficiary sectors. By and large, AfCFTA’s protocols align with the principles of ITF and are therefore suited for the proliferation of Islamic finance in the continent. And, while AML/KYC and BASEL requirements, compliance to AAOIFI and IFSB standards, paucity of Shari'ah experts, threats to global security, and increasing global economic uncertainty pose as major impediments, the future of ITF would be shaped by a greater need for institutional and policy support, global economic cum political stability, robust regulatory framework, and digital technology/fintech. The study calls for the licensing of more ITF institutions in the continent, participation of multilateral institutions in ITF, and harmonization of Shariah standards.

Keywords: AfCFTA, islamic trade finance, murabaha, letter of credit, forwarding

Procedia PDF Downloads 23

Authors: Sanpetchuda Krutkrua, Suphawatchara Malanond

Abstract:

Throughout the history of Antitrust regimes in Thailand, Thailand has been trying to prevent collusive practices in the market through the amendments of the Trade Competition Act, and Thailand just passed the current Trade Competition Act of B.E. 2560 in 2017 of which several aspects of the law were amended in order to enhance the prevention of collusive outcome through both vertical trade restraints and horizontal trade restraints. An agreement is vertical when it involves arrangements that are in a complementary relationship. In Section 55 of the Act, any agreements to reduce the price, quantity, or quality of the goods, agreements to assign a sole retailer for the goods, and the agreement to impose conditions on the retailers are not allowed. However, Section 56 provides exemptions for the vertical relationship between the business operators, the franchise agreement, and the licensing agreement as long as such agreements do not surpass the necessity to do so, create monopolization, or affect the consumers in terms of price, quality, quantity, or options. The paper aims to explore the extent of the exemption under Section 56 and sequential regulations in terms of the vertical trade restraints regarding intellectual property licensing, and, at the same time, compare with the exemptions under the European Union competition law, and Singapore competition law. Comparative legal analysis with leading jurisdiction will illustrate the application of the newly enacted Thai Competition Act in terms of its enforcement in the global impact of IP rights, which, by nature are de jure or de facto international protection.

Keywords: antitrust, competition law, vertical restraint, intellectual property, IP licensing

Procedia PDF Downloads 127

Authors: Yoke-Mui Lim, Yahaya Ahmad

Abstract:

Conservation works in Malaysia that is procured by public organisation usually follow the traditional approach where the works are tendered based on Bills of Quantities (BQ). One of the purposes of tendering is to enable the selection of a competent contractor that offers a competitive price. While competency of the contractors are assessed by their technical knowledge, experience and track records, the assessment of pricing will be dependent on the tender amount. However, the issue currently faced by the conservation works sector is the difficulty in assessing the competitiveness and reasonableness of the tender amount due to the high variance between the tenders amount. Thus, this paper discusses the factors that cause difficulty to the tenderers in pricing competitively in a bidding exercise for conservation tenders. Data on tendering is collected from interviews with conservation works contractors to gain in-depth understanding of the barriers faced in pricing tenders of conservation works. Findings from the study lent support to the contention that the variance of tender amount is very high amongst tenderers. The factors identified in the survey are the format of BQ, hidden works, experience and labour and material costs.

Keywords: building conservation, Malaysia, bill of quantities, tender

Procedia PDF Downloads 344

Authors: Arunas Burinskas, Manuela Tvaronavičienė

Abstract:

Although the new trade theories, unlike the theories of an industrial organisation, see the structure of the market and competition between enterprises through their heterogeneity according to various parameters, they do not pay any particular attention to the analysis of the market structure and its development. In this article, although we relied mainly on models developed by the scholars of new trade theory, we proposed a different approach. In our simulation model, we model market demand according to normal distribution function, while on the supply side (as it is in the new trade theory models), productivity is modeled with the Pareto distribution function. The results of the simulation show that companies with higher productivity (lower marginal costs) do not pass on all the benefits of such economies to buyers. However, even with higher marginal costs, firms can choose to offer higher value-added goods to stay in the market. In general, the structure of the market is formed quickly enough and depends on the skills available to firms.

Keywords: market, structure, simulation, heterogenous firms

Procedia PDF Downloads 112

Authors: Fernando Seabra, Giulia P. Flores, Karolina C. Gomes

Abstract:

Trade liberalizations measures, as import tariff cuts, are not a sufficient trigger for trade growth. Given that price margins are narrow, traders and cargo operators tend to opt out of markets where the process of goods clearance is slow and costly. Excess paperwork and slow customs dispatch not only lead to institutional breakdowns and corruption but also to increasing transaction cost and trade constraints. The objective of this paper is, therefore, two-fold: First, to evaluate the relationship between institutional and infrastructural performance indexes and trade growth in container throughput; and, second, to investigate the causes for differences in container demurrage and detention fees in Latin American countries (using other emerging countries as benchmarking). The analysis is focused on manufactured goods, typically transported by containers. Institutional and infrastructure bottlenecks and, therefore, the country logistics efficiency – measured by the Logistics Performance Index (LPI, World Bank-WB) – are compared with other indexes, such as the Doing Business index (WB) and the Corruption Perception Index (Transparency International). The main results based on the comparison between Latin American countries and the others emerging countries point out in that the growth in containers trade is directly related to LPI performance. It has also been found that the main hypothesis is valid as aspects that more specifically identify trade facilitation and corruption are significant drivers of logistics performance. The exam of port efficiency (demurrage and detention fees) has demonstrated that not necessarily higher level of efficiency is related to lower charges; however, reductions in fees have been more significant within non-Latin American emerging countries.

Keywords: corruption, logistics performance index, container throughput, Latin America

Procedia PDF Downloads 216

Authors: Mujahid S. Alturais

Abstract:

The construction of process plants in oil and gas-producing countries, such as Saudi Arabia, necessitates substantial investment in design and building. Each new plant, while unique, includes common building types, suggesting an opportunity for design standardization. This study investigates the adoption of standardized Issue For Construction (IFC) packages for non-process buildings in Saudi Aramco. A SWOT analysis presents the strengths, weaknesses, opportunities, and threats of this approach. The approach's benefits are illustrated using the Hawiyah Unayzah Gas Reservoir Storage Program (HUGRSP) as a case study. Standardization not only offers significant cost savings and operational efficiencies but also expedites project timelines, reduces the potential for change orders, and fosters local economic growth by allocating building tasks to local contractors. Standardization also improves project management by easing interface constraints between different contractors and promoting adaptability to future industry changes. This research underscores the standardization of non-process buildings as a powerful strategy for cost optimization, efficiency enhancement, and local economic development in process plant construction within the oil and gas sector.

Keywords: building, construction, management, project, standardization

Procedia PDF Downloads 32