Search results for: main contractors

Authors: Zhuoyuan Wang, Benson T. H. Lim, Imriyas Kamardeen

Abstract:

Effective service quality management has long been touted as a means of improving project and organisational performance. Particularly, in construction projects, main contractors are often seen as a broker between clients and subcontractors, and their service quality is thus associated with the overall project affinity and outcomes. While a considerable amount of research has focused on the aspect of clients-main contractors, very little research has been done to explore the effect of contractors’ service quality on subcontractors’ behaviours and so project outcomes. In addressing this gap, this study surveyed 97 subcontractors in the Chinese Construction industry and data was analysed using the Partial Least Square (PLS) Structural Equation Modelling (SEM) technique. The overall findings reveal that subcontractors categorised main contractors’ service quality into three dimensions: assurance; responsiveness; reliability and empathy. Of these, it is found that main contractors’ ‘assurance’ and ‘responsiveness’ positively influence subcontractors’ intention to engage in contractual behaviours. The results further show that the subcontractors’ intention to engage in organizational citizenship behaviours is associated with how flexible and committed the main contractors are in reliability and empathy. Collectively, both subcontractors’ contractual and organizational citizenship behaviours positively influence the overall project outcomes. In conclusion, the findings inform contractors different strategies towards managing and gaining subcontractors’ behaviour commitment in a socially connected, yet complex and uncertain, business environment.

Keywords: construction firms, organisational citizenship behaviour, service quality, social exchange theory

Procedia PDF Downloads 164

Authors: Kozik Renata, Leśniak Agnieszka, Plebankiewicz Edyta

Abstract:

Contracting authorities in the public sector are obligated to apply the principles provided for in the Polish law for the evaluation and selection of contractors. To analyze the methods of contractors, applied in practice by public clients, the notices of contract award results for construction works were analyzed. The analysis shows that the procedure selected more and more often is open to competitive bidding, where the assessment of the competence of contractors is not very precise, as well as non-competitive bidding, i.e. single source procurement. The share of procurement procedures, where the only criterion is price, is increasing. The solution to the problems existing here might be the introduction of one of the forms of pre-selection of contractors. The article also briefly discusses verification systems for companies applying for public contracts used in EU countries.

Keywords: certification, contractors selection, open tendering, public investors

Procedia PDF Downloads 256

Authors: Myunghoun Jang

Abstract:

A survey of small-size contractors in Jeju was conducted to investigate college graduate's computer-aided design (CAD) competence. Most of small-size contractors use CAD software to review and update drawings submitted from an architect. This research analyzed the curriculum of the architectural engineering in several national universities. The CAD classes have 4 or 6 hours per week and use AutoCAD primarily. This paper proposes that a CAD class needs 6 hours per week, 2D drawing is the main theme in the curriculum, and exercises to make 3D models are also included in the CAD class. An improved method, for example Internet cafe and real time feedbacks using smartphones, to evaluate the reports and exercise results is necessary.

Keywords: CAD (Computer Aided Design), CAD education, education improvement, small-size contractor

Procedia PDF Downloads 239

Authors: Sophia Hayes, Kenny L. Liang, Sahil Sharma, Austin Shema, Mahmoud Bader, Mohamed Elbarkouky

Abstract:

Despite being one of the most significant economic contributors of the country, Canada’s construction industry is lagging behind other sectors when it comes to labor productivity improvements. The construction industry is very collaborative as a general contractor, will hire trade contractors to perform most of a project’s work; meaning low productivity from one contractor can have a domino effect on the shared success of a project. To address this issue and encourage trade contractors to improve their productivity tracking methods, an investigative study was done on the productivity views and tracking methods of various trade contractors. Additionally, an in-depth review was done on four standard tracking methods used in the construction industry: cost codes, benchmarking, the job productivity measurement (JPM) standard, and WorkFace Planning (WFP). The four tracking methods were used as a baseline in comparing the trade contractors’ responses, determining gaps within their current tracking methods, and for making improvement recommendations. 15 interviews were conducted with different trades to analyze how contractors value productivity. The results of these analyses indicated that there seem to be gaps within the construction industry when it comes to an understanding of the purpose and value in productivity tracking. The trade contractors also shared their current productivity tracking systems; which were then compared to the four standard tracking methods used in the construction industry. Gaps were identified in their various tracking methods and using a framework; recommendations were made based on the type of trade on how to improve how they track productivity.

Keywords: labor productivity, productivity tracking methods, trade contractors, construction

Procedia PDF Downloads 157

Authors: Li Ma, Meishuang Ma, Mengying Huang

Abstract:

The quality of construction projects reflects the credit and responsibilities of construction contractors for the owners and the whole society. Because the construction contractors master more relevant information about the entrusted engineering project under construction while the owners are in unfavorable position of gaining information, asymmetric information may lead the contractors act against the owners in order to pursue their own interests. Building a powerful motivation mechanism is the key to guarantee investor economic interests and the life and property of users in construction projects. Based on principal-agent theory and game theory, the authors develop relevant mathematical models to analyze and compare the contractor’s utility functions under different combinations of contracts’ explicit incentive mechanism and reputation’s implicit incentive mechanism aiming at finding out the conditions for incentive validity. The research concludes that the most rational motivation way is to combine the explicit and implicit incentive effects of both contracts and reputation mechanism, and puts forth some measures for problems on account of China’s current situation.

Keywords: construction contractors, contract, reputation, incentive mechanism

Procedia PDF Downloads 478

Authors: Ibrahim Mahamid, A. Al-Ghonamy, M. Aichouni

Abstract:

This study is conducted to identify causes of cost deviations in public construction projects in Saudi Arabia from contractors’ perspective. 41 factors that might affect cost estimating accuracy were identified through literature review and discussion with some construction experts. The factors were tabulated in a questionnaire form and a field survey included 51 contractors from the Northern Province of Saudi Arabia was performed. The results show that the top five important causes are: wrong estimation method, long period between design and time of implementation, cost of labor, cost of machinary and absence of construction-cost data.

Keywords: cost deviation, public construction, cost estimating, Saudi Arabia, contractors

Procedia PDF Downloads 432

Authors: Fatemeh Jaferi, Moslem Parsa, Heshmatolah Shams Khorramabadi

Abstract:

In this modern fluctuating world, organizations need to outsource some parts of their activities (project) to providers in order to show a quick response to their changing requirements. In fact, a number of companies and institutes have contractors do their projects and have some specific criteria in contractor selection. Therefore, a set of scientific tools is needed to select the best contractors to execute the project according to appropriate criteria. Multi-criteria decision making (MCDM) has been employed in the present study as a powerful tool in ranking and selecting the appropriate contractor. In this study, devolving second-source (civil) project to contractors in the National Gas Company of Lorestan Province (Iran) has been found and therefore, 5 civil companies have been evaluated. Evaluation criteria include executive experience, qualification of technical staff, good experience and company's rate, technical interview, affordability, equipment and machinery. Criteria's weights are found through experts' opinions along with AHP and contractors ranked through TOPSIS and AHP. The order of ranking contractors based on MCDM methods differs by changing the formula in the study. In the next phase, the number of criteria and their weights has been sensitivity analysed through using AHP. Adding each criterion changed contractors' ranking. Similarly, changing weights resulted in a change in ranking. Adopting the stated strategy resulted in the facts that not only is an appropriate scientific method available to select the most qualified contractors to execute gas project, but also a great attention is paid to picking needed criteria for selecting contractors. Consequently, executing such project is undertaken by most qualified contractors resulted in optimum use of limited resource, accelerating the implementation of project, increasing quality and finally boosting organizational efficiency.

Keywords: multi-criteria decision making, project, management, contractor selection, gas company

Procedia PDF Downloads 370

Authors: Iruka C. Anugwo, Winston M. Shakantu

Abstract:

The objective of this study is to uncover the basic business-forces that necessitated the survival and sustainable performance of the medium scale contractors in the South African construction market. This study is essential as it set to contribute towards long-term strategic solutions for combating the incessant failure of start-ups construction organizations within South African. The study used a qualitative research methodology; as the most appropriate approach to elicit and understand, and uncover the phenomena that are basic business-forces for the active contractors in the market. The study also adopted a phenomenological study approach; and in-depth interviews were conducted with 20 medium scale contractors in Port Elizabeth, South Africa, between months of August to October 2015. This allowed for an in-depth understanding of the critical and basic business-forces that influenced their survival and performance beyond the first five years of business operation. Findings of the study showed that for potential contractors (startups), to survival in the competitive business environment such as construction industry, they must possess the basic business-forces. These forces are educational knowledge in construction and business management related disciplines, adequate industrial experiences, competencies and capabilities to delivery excellent services and products as well as embracing the spirit of entrepreneurship. Convincingly, it can be concluded that the strategic approach to minimize the endless failure of startups construction businesses; the potential construction contractors must endeavoring to access and acquire the basic educationally knowledge, training and qualification; need to acquire industrial experiences in collaboration with required competencies, capabilities and entrepreneurship acumen. Without these basic business-forces as been discovered in this study, the majority of the contractors gaining entrance in the market will find it difficult to develop and grow a competitive and sustainable construction organization in South Africa.

Keywords: basic business-forces, medium scale contractors, South Africa, sustainable organisations

Procedia PDF Downloads 250

Authors: Charles Poleni Mukumba, Kahilu Kajimo-Shakantu

Abstract:

Purpose: Principles of public procurement are the foundation of good public procurement, representing best practices in delivering public services by the government and its organs. They provide guidance in the public procurement cycle to achieve the best value for public resources. Tendering stage in the procurement cycle is the most critical, as tendering information is made available to bidders. The paper evaluates the implementation of public procurement principles at the tendering stage. Design/Methodology/Approach: The research was conducted by using qualitative methods with 18 SME contractors in Lusaka as the sample. The samples are business owners and managers of purposively selected SME contractors. The collected data was analysed using thematic and content analysis. Findings: The findings indicate inconsistency in accessing information critical for tendering success by bidders. Further, the findings suggest that adjustments to technical specifications are made to suit certain preferred bidders by procuring officials. Research Limitations/Implications: The interviews were limited to SME contractors registered with the national council for construction and involved in public sector construction works in Lusaka, Zambia. Practical Implications: Implementing principles of public procurement at the tendering stage creates equal, open, and fair competition for the bidders in cost terms to deliver standardised and quality works to the public sector. Original/Value: The findings reveal how principles of public procurement play a critical role in enhancing the efficient performance of the procurement cycle at the tendering stage.

Keywords: evaluating, implementation, public procurement principles, tendering stage, SME contractors

Procedia PDF Downloads 47

Authors: Sareh Rajabi, Taha Anjamrooz, Salwa Bheiry

Abstract:

Sustainability of construction projects is an important issue to be addressed since the sector will continue to be developed in the coming years, especially in developing countries. Thus, it is significant to discover approaches and solutions for improving sustainability. Currently, the construction industry is the largest consumer of natural resources. This is the same in other countries in the Gulf region, and the United Arab Emirates (UAE) has limited natural resources such as water, electricity, etc. Recently, the UAE has taken several actions in order to implement sustainable initiatives within its construction industry. Within the industry, the contractors’ role is significant in promoting sustainable development by taking the responsibility to minimize their negative impacts on the environment and society, and maximize their economic distribution. In this research, sustainability will be studied as an important key to bring competitive advantages to contracting organizations. The contractors should understand the need to improve their sustainable performance in order to expand their business competitiveness. Competitiveness at the construction project level refers to a contractor’s ability to compete for a project. There is less focus on how to improve contractors’ competitiveness by implementing sustainable construction practices. Based on an inclusive literature review on the relationship between sustainability performance and business competitiveness, this research will conduct a study of sustainable practice in the construction industry and the relationship between sustainability performance and business competitiveness in order to develop a framework for evaluating how contractors can improve their competitiveness in terms of more efficient processes, enhancements in productivity, and lower costs of compliance in order to reduce the initial project cost and obtain market opportunities in the UAE. The research findings will provide a framework that can be a useful guideline for contractors to develop their sustainability policy, strategy and practice for meeting the increased requirements for sustainable development in construction.

Keywords: sustainable construction practice, sustainability, competitiveness, construction industry, contractors

Procedia PDF Downloads 94

Authors: Z. Hamed, K. Sa'deya, E. Abdelrasheed, I. Mahamid

Abstract:

The construction industry is one of the main sectors that play basic role in the urban and rural development of a society. It provides important ingredients for the development of an economy. However, many construction projects experience extensive cost overrun. This study was conducted to identify the causes of cost overrun in building construction contracts in Al Madinah, Saudi Arabia and test the importance of these causes from contractors' perspective. To achieve the study objectives, a questionnaire survey was conducted to identify and rank cost overrun causes from the perspective of contractors. The findings found that the top five cost overrun causes are: lack of experience in the line of work, lack of labor productivity, delay in payments, rework and material waste. It is hoped that the findings will guide efforts to improve the performance of construction industry in Saudi Arabia and other developing countries.

Keywords: building, contractor, cost increase, cost overrun

Procedia PDF Downloads 121

Authors: Rawan A. Abdelrazeq, Ahmed M. Khalafallah, Nabil A. Kartam

Abstract:

Selection of competent contractors for construction projects is usually accomplished through competitive bidding or negotiated contracting in which the contract bid price is the basic criterion for selection. The evaluation of contractor’s safety performance is still not a typical criterion in the selection process, despite the existence of various safety prequalification procedures. There is a critical need for practical and automated systems that enable owners and decision makers to evaluate contractor safety performance, among other important contractor selection criteria. These systems should ultimately favor safety-conscious contractors to be selected by the virtue of their past good safety records and current safety programs. This paper presents an exploratory sequential mixed-methods approach to develop a framework for an automated decision support system that evaluates contractor safety performance based on a multitude of indicators and metrics that have been identified through a comprehensive review of construction safety research, and a survey distributed to domain experts. The framework is developed in three phases: (1) determining the indicators that depict contractor current and past safety performance; (2) soliciting input from construction safety experts regarding the identified indicators, their metrics, and relative significance; and (3) designing a decision support system using relational database models to integrate the identified indicators and metrics into a system that assesses and rates the safety performance of contractors. The proposed automated system is expected to hold several advantages including: (1) reducing the likelihood of selecting contractors with poor safety records; (2) enhancing the odds of completing the project safely; and (3) encouraging contractors to exert more efforts to improve their safety performance and practices in order to increase their bid winning opportunities which can lead to significant safety improvements in the construction industry. This should prove useful to decision makers and researchers, alike, and should help improve the safety record of the construction industry.

Keywords: construction safety, contractor selection, decision support system, relational database

Procedia PDF Downloads 249

Authors: B. Vikram, Y. Anu Leena, Y. Anu Neena, M. V. Krishna Rao, V. S. S. Kumar

Abstract:

The industry is often criticized for inefficiencies in outcomes such as time and cost overruns, low productivity, poor quality and inadequate customer satisfaction. To enhance the chances for construction projects to be successful, selecting an able contractor is one of the fundamental decisions to be made by clients. The selection of the most appropriate contractor is a multi-criteria decision making (MCDM) process. In this paper, multi-attribute utility theory (MAUT) is employed utilizing the multiplicative form of utility function for ranking the prequalified contractors. Performance assessment criteria covering contracting company attributes, experience record, past performance, performance potential, financial stability and project specific criteria are considered for contractor evaluation. A case study of multistoried building for which four contractors submitted bids is considered to illustrate the applicability of multiplicative approach of MAUT to rank the prequalified contractors. The proposed MAUT decision making methodology can also be employed to other decision making situations.

Keywords: multi-attribute utility theory, construction industry, prequalification, contractor

Procedia PDF Downloads 404

Authors: Hai Chien Pham, Thi Phuong Anh Vo, Chansik Park

Abstract:

Risks management in construction projects is important to ensure the positive feasibility of the projects in which financial risks are most concerned while construction projects always run on a credit basis. Credit risks, therefore, require unique and technical tools to be well managed. Underwriting technique in credit risks, in its most basic sense, refers to the process of evaluating the risks and the potential exposure of losses. Risks analysis and underwriting are applied as a must in banks and financial institutions who are supporters for constructions projects when required. Recently, construction organizations, especially contractors, have recognized the significant increasing of credit risks which caused negative impacts to project performance and profit of construction firms. Despite the successful application of underwriting in banks and financial institutions for many years, there are few contractors who are applying this technique to analyze and mitigate the credit risks of their potential owners before signing contracts with them for delivering their performed services. Thus, contractors have taken credit risks during project implementation which might be not materialized due to the bankruptcy and/or protracted default made by their owners. With this regard, this study proposes a model using the underwriting technique for contractors to analyze and assess credit risks of their owners before making final decisions for the potential construction contracts. Contractor’s underwriters are able to analyze and evaluate the subjects such as owner, country, sector, payment terms, financial figures and their related concerns of the credit limit requests in details based on reliable information sources, and then input into the proposed model to have the Overall Assessment Score (OAS). The OAS is as a benchmark for the decision makers to grant the proper limits for the project. The proposed underwriting model is validated by 30 subjects in Asia Pacific region within 5 years to achieve their OAS, and then compare output OAS with their own practical performance in order to evaluate the potential of underwriting model for analyzing and assessing credit risks. The results revealed that the underwriting would be a powerful method to assist contractors in making precise decisions. The contribution of this research is to allow the contractors firstly to develop their own credit risk management model for proactively preventing the credit risks of construction projects and continuously improve and enhance the performance of this function during project implementation.

Keywords: underwriting technique, credit risk, risk management, construction project

Procedia PDF Downloads 183

Authors: Syed Sohaib Bin Hasib, Hiyam Al-Kilidar

Abstract:

Meeting project deadlines is a major challenge for most construction projects. In this study, perceptions of contractors, clients, and consultants are compared relative to a list of factors derived from the review of the extant literature on project delay. 59 causes (categorized into 8 groups) of project delays were identified from the literature. A survey was devised to get insights and ranking of these factors from clients, consultants & contractors in the Australian construction industry. Findings showed that project delays in the Australian construction industry are mainly the result of skill shortages, interference in execution, and poor coordination and communication between the project stakeholders.

Keywords: construction, delay factors, time delay, australian construction industry

Procedia PDF Downloads 139

Authors: Jerry Gyimah, Ernest Kissi, Safowaa Osei-Tutu, Charles Dela Adobor, Theophilus Adjei-Kumi, Ernest Osei-Tutu

Abstract:

Price fluctuation contract is imperative and of paramount essence, in the construction industry as it provides adequate relief and cushioning for changes in the prices of input resources during construction. As a result, several methods have been devised to better help in arriving at fair recompense in the event of price changes. However, stakeholders often appear not to be satisfied with the existing methods of fluctuation evaluation, ostensibly because of the challenges associated with them. The aim of this study was to identify the challenges to the usage of building construction cost indices in Ghana. Data was gathered from contractors and quantity surveying firms. The study utilized a survey questionnaire approach to elicit responses from the contractors and the consultants. Data gathered was analyzed scientifically, using the relative importance index (RII) to rank the problems associated with the existing methods. The findings revealed the following, among others, late release of data, inadequate recovery of costs, and work items of interest not included in the published indices as the main challenges of the existing methods. Findings provide useful lessons for policymakers and practitioners in decision making towards the usage and improvement of available indices.

Keywords: building construction cost indices, challenges, usage, Ghana

Procedia PDF Downloads 115

Authors: Kittivate Boonyopakorn

Abstract:

The purposes of this study were to investigate the method of the English use of the businessmen and to study their behavior of the utilization for the ASEAN economic community. The participants were divided into the three types of the merchants including the construction contractors, the construction material traders, and SME entrepreneurs. Survey questionnaires and interviews were used in this study. The findings showed that in the type of traders, 23 of the participants are construction contractors, 121 are construction material traders, and 206 are SME entrepreneurs. The study of English in language institute is highly 51.4%. The use of Google in translating English into Thai is 41.7%. Learning English themselves is 41.1% respectively. The businessmen study English for readiness for their trade.

Keywords: way of rnglish use, businessmen, ASEAN economic community, Chonburi province

Procedia PDF Downloads 213

Authors: Shu-Hui Jan, Hui-Ping Tserng, Shih-Ping Ho

Abstract:

Construction project control attempts to obtain real-time as-built schedule information and to eliminate project delays by effectively enhancing dynamic schedule control and management. Suitable platforms for enhancing an as-built schedule visually during the construction phase are necessary and important for general contractors. As the application of building information modeling (BIM) becomes more common, schedule management integrated with the BIM approach becomes essential to enhance visual construction management implementation for the general contractor during the construction phase. To enhance visualization of the updated as-built schedule for the general contractor, this study presents a novel system called the Construction BIM-assisted Schedule Management (ConBIM-SM) system for general contractors in Taiwan. The primary purpose of this study is to develop a web ConBIM-SM system for the general contractor to enhance visual as-built schedule information sharing and efficiency in tracking construction as-built schedule. Finally, the ConBIM-SM system is applied to a case study of a commerce building project in Taiwan to verify its efficacy and demonstrate its effectiveness during the construction phase. The advantages of the ConBIM-SM system lie in improved project control and management efficiency for general contractors, and in providing BIM-assisted as-built schedule tracking and management, to access the most current as-built schedule information through a web browser. The case study results show that the ConBIM-SM system is an effective visual as-built schedule management platform integrated with the BIM approach for general contractors in a construction project.

Keywords: building information modeling (BIM), construction schedule management, as-built schedule management, BIM schedule updating mechanism

Procedia PDF Downloads 339

Authors: Ali Obaid Alyami

Abstract:

In Saudi Arabia, the pandemic of Coronavirus (COVID-19) has been affecting administrative contracts in many different ways. Lots of planned projects were stopped temporarily or implemented partially. Many contractors have suffered financial struggles and the absence of manpower. These administrative contracts are governed by Government Tenders and Procurement Law (GTPL) which was issued by a royal decree in 2019. This law addresses some challenges that could be stumbling blocks in the way of implementing a contract. One significant challenge is emergency circumstances that occur during the implementation of an administrative contract. The law provides some solutions for this disruption, but these solutions may not compensate for the whole damages that contractors suffer. This study will use the doctrinal methodology to analyze the rules of law and their application to the research problem. Most importantly, the issue that arises in this research is the possibility of governmental entities’ consideration, in administrative contracts, of the pandemic Coronavirus (COVID-19) as an emergency circumstance. This study points out the conditions for applying the theory of emergency circumstances on administrative contracts in addition to the definition of the theory and analyzing its elements. The other significant question is the limits on governmental entities to make a change in an administrative contract to achieve contractual rebalancing. GPTL and its implementing regulation set the conditions and limits of contractual rebalancing. However, this study finds that although GTPL provides rules for contractual rebalancing, there are some other mechanisms that contractors may take to fully compensate for the damages. For instance, when the loss cannot be minimized by GTPL, contractors might file lawsuits before the administrative judiciary. The study concludes that GTPL is a very comprehensive law system that stipulates specific rules for contractual rebalance and treats the emergency circumstances that obstruct the performance of administrative contracts.

Keywords: administrative contracts, emergency circumstances, balance of contract, administrative judiciary, government tenders, procurement law

Procedia PDF Downloads 42

Authors: Nida Iftikhar, Jamaluddin Thaheem, Bilal Iftikhar

Abstract:

In the construction industry, adequate and effective decision-making can mean the difference between success and failure. Bidding is the most important element of the construction business since it is a mean by which contractors obtain work. This is probably the only option for any contractor firm to sustain in the market and achieve its objective of earning the profits by winning tenders. The capability to select most appropriate ventures not only defines the success and wellbeing of contractor firms but also their survival and sustainability in the industry. The construction practitioners are usually on their own when it comes to deciding on bidding for a project or not. Usually, experience-based solutions are offered where a lot of subjectivity is involved. This research has been opted considering the local construction industry of Pakistan in order to examine the critical success factors from contractors’ perspective while making bidding decisions, listing and evaluating critical factors in order of their importance, categorization of these factors into decision support & decision oppose groups and to develop a framework to help contractors in the decision-making process. Literature review, questionnaires, and structured interviews are used for identification and quantification of factors affecting bid/no bid decision-making. Statistical methods of ranking analysis and analytical hierarchy process of multi-criteria decision-making method are used for analysis. It is found that profitability, need for work and financial health of client are the most decisive factors in bid/no bid decision-making while project size, project type, fulfilling the tender conditions imposed by the client and relationship, identity & reputation of the client are least impact factors in bid/no bid decision-making. Further, to verify the developed framework, case studies have been conducted to evaluate the bid/no bid decision-making in building procurement. This is the first of its nature study in the context of the local construction industry and recommends using a holistic decision-making framework for such business-critical deliberations.

Keywords: bidding, bid decision-making, construction procurement, contractor

Procedia PDF Downloads 154

Authors: Imtiaz Ali, Imam Mansoor

Abstract:

Investigations as a part of the academic study were undertaken to identify and evaluate the significant risks associated with the construction of K-span buildings in the region of UAE. Primary field data was collected through questionnaires obtaining specific open and close-ended questions from carefully selected construction firms, civil engineers and, construction manager regarding risks associated to K-span building construction. Historical data available for other regions of the same construction technique was available which was compared for identifying various non-critical and critical risk parameters by comparative evaluation techniques to come up with important risks and potential sources for their control and minimization in K-Span buildings that is increasing in the region. The associated risks have been determined with their Relative Importance Index (RII) values of which Risk involved in Change of Design required by Owners carries the highest value (RII=0.79) whereas, Delayed Payment by Owner to Contractor is one of the least (RII=0.42) value. The overall findings suggest that most relative risks as quantified originate or associated with the contractors. It may be concluded that project proponents undertaking K-span projects in planning and budgeting the cost and delays should take into account of risks on high account if changes in design are also required any delays in the material by the supplier would then be a major risk in K-span project delay. Since projects are, less costly, so owners have limited budgets, then they hire small contractors, which are not highly competent contractors. So study suggests that owner should be aware of these types of risks associated with the construction of K-span buildings in order to make it cost effective.

Keywords: k-span buildings, k-span construction, risk management, relative improvement index (RII)

Procedia PDF Downloads 350

Authors: Badr A. Al-Jehani

Abstract:

Nowadays, contractor selection is a critical activity of the project owner. Selecting the right contractor is essential to the project manager for the success of the project, and this cab happens by using the proper selecting method. Traditionally, the contractor is being selected based on his offered bid price. This approach focuses only on the price factor and forgetting other essential factors for the success of the project. In this research paper, the Analytic Network Process (ANP) method is used as a decision tool model to select the most appropriate contractor. This decision-making method can help the clients who work in the construction industry to identify contractors who are capable of delivering satisfactory outcomes. Moreover, this research paper provides a case study of selecting the proper contractor among three contractors by using ANP method. The case study identifies and computes the relative weight of the eight criteria and eleven sub-criteria using a questionnaire.

Keywords: contractor selection, project management, decision-making, bidding

Procedia PDF Downloads 68

Authors: Zeynep Yazicioglu

Abstract:

Project development is a complex process where many stakeholders work together. Employers and main contractors are the base stakeholders, whereas designers, engineers, sub-contractors, suppliers, supervisors, and consultants are other stakeholders. A combination of the complexity of the building process with a large number of stakeholders often leads to time and cost overruns and irregular resource utilization. Failure to comply with the work schedule and inefficient use of resources in the construction processes indicate that it is necessary to accelerate production and increase productivity. The development of computer software called Building Information Modeling, abbreviated as BIM, is a major technological breakthrough in this area. The use of BIM enables architectural, structural, mechanical, and electrical projects to be drawn in coordination. BIM is a tool that should be considered by every stakeholder with the opportunities it offers, such as minimizing construction errors, reducing construction time, forecasting, and determination of the final construction cost. It is a process spreading over the years, enabling all stakeholders associated with the project and construction to use it. The main goal of this paper is to explore the problems associated with the adoption of BIM in multi-stakeholder projects. The paper is a conceptual study, summarizing the author’s practical experience with design offices and construction firms working with BIM. In the transition period to BIM, three of the challenges will be examined in this paper: 1. The compatibility of supplier companies with BIM, 2. The need for two-dimensional drawings, 3. Contractual issues related to BIM. The paper reviews the literature on BIM usage and reviews the challenges in the transition stage to BIM. Even on an international scale, the supplier that can work in harmony with BIM is not very common, which means that BIM's transition is continuing. In parallel, employers, local approval authorities, and material suppliers still need a 2-D drawing. In the BIM environment, different stakeholders can work on the same project simultaneously, giving rise to design ownership issues. Practical applications and problems encountered are also discussed, providing a number of suggestions for the future.

Keywords: BIM opportunities, collaboration, contract issues about BIM, stakeholders of project

Procedia PDF Downloads 85

Authors: Khaled Hesham Hyari, Amjad Almani

Abstract:

Construction projects in the public sector are commonly awarded through competitive bidding. In the last decade, the Construction projects environment in the Middle East went through many changes. These changes have been caused by different factors including the economic crisis, delays in monthly payments, international competition and reduced number of projects. These factors had a great impact on the bidding behaviors of contractors and their pricing strategies. This paper examines the competition characteristics in public construction projects through an analysis of bidding results of contractors in public construction projects over a period of 6 years (2006-2011) in Jordan. The analyzed projects include all categories of projects such as infrastructure, buildings, transportation and engineering services (design and supervision contracts). Data for the projects were obtained from the General Tender’s Directorate in Jordan and includes 462 projects. The analysis performed in this projects includes, studying the bid spread in all projects as it is an indication of the level of competition in the analyzed bids. The analysis studied the factors that affect bid spread such as number of bidders, Value of the project, Project category and years. It also studying the “Signal to Noise Ratio” in all projects as it is an indication of the accuracy of cost estimating performed by competing bidders and bidder´s evaluation of project risks. The analysis performed includes the relationship between signal to noise ratio and different parameters such as project category, number of bidders and changes over years. Moreover, the analysis includes determining the bidder´s aggressiveness in bidding as it is an indication of competition level in such projects. This was performed by determining the pack price which can be considered as the true value of the project and comparing it with the lowest bid submitted for each project to determine the level of aggressiveness in submitted bids. The analysis performed in this project should prove to be useful to owners in understanding bidding behaviors of contractors and pointing out areas that needs improvement in preparing bidding documents. Also the project should be useful to contractors in understanding the competitive bidding environment and should help them to improve their bidding strategies to maximize the success rate in obtaining contracts.

Keywords: construction projects, competitive bidding, public construction, competition

Procedia PDF Downloads 303

Authors: Ali Mohammadi

Abstract:

One of the concerns that employers and contractors have in creating long tunnels is that when the excavation is completed, the tunnel will be exited in the correct position according to designed, the deviation of the tunnel from its path can have many costs for the employer and the contractor, lack of correct calculations by the surveying engineer or the employer and contractors lack of importance to the surveying team in guiding the tunnel can cause the tunnel to deviate from its path and this deviation becomes a disaster. But employers are able to make the right decisions so that the tunnel is guided with the highest precision if they consider some points. We are investigating two tunnels with lengths of 12 and 18 kilometers that were dug by Tunnel boring machine machines to transfer water, how the contractor’s decision to control the 12 kilometer tunnel caused the most accuracy of one centimeter to the next part of the tunnel will be connected. We will also investigate the reasons for the deviation of axis in the 18 km tunnel about 20 meters. Also we review the calculations of surveyor engineers in both tunnels and what challenges there will be in the calculations and teach how to solve these challenges. Surveying calculations are the most important part in controlling long tunnels.

Keywords: UTM, localization, scale factor, traverse

Procedia PDF Downloads 36

Authors: Hannan Al-Qanai, Haitham Mustafa, Rajeswaran Sivasankar

Abstract:

Kuwait Integrated Petroleum Industries Company (KIPIC, Company), established in 2016 as a subsidiary to Kuwait Petroleum Corporation (KPC), is responsible for operating and managing the largest grassroots integrated complex for refining, petrochemicals manufacture businesses, and liquefied natural gas import facilities at Al-Zour, Kuwait. KIPIC and its Contractors/sub-contractors employ over 69,000 staff in its current projects at Al-Zour during peak construction activity. KIPIC holds a unique responsibility to the society, which includes all stakeholders, and demonstrates its social commitment in developing an integrated environment & social management system (ESMS) and ensuring sustainability. This paper mainly demonstrates the knowledge on corporate branding from a corporate social responsibility (CSR) perspective and presents the achievements and best practices of KIPIC in the field of CSR and the challenges faced in handling social issues. Moreover, the study is based on qualitative data abstracted from KIPIC Health, Safety, Security & Environment Management System (HSSE MS) procedures, audit reports, the outcome of counseling sessions, national and international laws and regulations, and International Guidelines on Environment and Social Management System (ESMS). KIPIC has committed to caring for the environmental concerns and acting on social as they do on profits and economic growth. The main findings of this paper are that the successful implementation and operationalization of CSR within an organization depends on a simple but stringent process with both top-down and bottom-up commitment.

Keywords: welfare, corporate social responsibility, social management, sustainability

Procedia PDF Downloads 180

Authors: Ibrahim A. Alhammad, Suleiman A. Al-Otaibi, Khalid S. Al-Gahtani, Naïf Al-Otaibi, Abdulaziz A. Bubshait

Abstract:

In the last decade, the use of project delivery system of design build engineering contracts is increasing in North America due to the reasons of reducing the project duration and minimizing costs. The shift from traditional approach of Design-Bid-Build to Design-Build contracts have been attributed to many factors such as evolution of the regulatory and legal frameworks governing the engineering contracts and improvement in integrating design and construction. The aforementioned practice of contracting is more appropriate in North America; yet, it may not be the case in Saudi Arabia where the traditional approach of construction contracting remains dominant. The authors believe there are number of factors related to the gaps in the level of sophistication of the engineering and management of the construction projects in both countries. A step towards improving the Saudi construction practice by adopting the new trend of construction contracting, this paper identifies the reasons why Design/Build form of contracting are not frequently utilized. A field survey, which includes the questionnaire addressing the research problem, is distributed to three main parties of the construction contracts: clients, consultants, and contractors. The analyzed collected data were statistically sufficient to finding the reasons of not adopting the new trend of good practice of deign build approach in Saudi Arabia. In addition, the reasons are: (1) lack of regulation and legal framework; (2) absence of clear criteria of the owner for the trade-off between competing contractors, (3) and lack of experience, knowledge and skill.

Keywords: design built projects, Saudi Arabia, GCC, mega projects

Procedia PDF Downloads 187

Authors: Hamideh Sadat Zekri, Seyed Mojtaba Hosseinalipour, Mohammadreza Hafezi

Abstract:

Nowadays, an organization cannot usually overcome all tasks singly due to the increasing complexity and vast expanse of projects, increment in uncertainty of activities, fast advances in technology, advent and influence of various factors in decision-making and implication of projects, and competitive atmosphere of different affairs. Thus, firms proceed to outsource the tasks to subcontractors. Nevertheless, large Iranian contracting companies suffer from extra consumed costs and time owing to conflicts between the activities of suppliers and subcontractors. The paucity of coordination in planning and execution, scarcity of coordination among suppliers, subcontractors, and the main contractor during the implementation of construction activities and also the lack of proper management of the aforesaid situation result in the growth of contradictions, number of claims, and legal issues in a project and consequently impose enormous expenses on those companies. Regarding the prosperity of supply chain management in other industries, its importance is increasingly getting appreciated in the field of construction. The ultimate aim of supply chain management is an effective delivery of the best value for customers, which is achievable by encouraging the members to interact and collaborate. In the present research, there was an effort to obtain a set of relevant challenges in the managing of subcontractors by identifying the main contractors and subcontractors and their role in the execution of projects and the supply chain management in the construction industry. Then, some of those challenges were selected in accordance with the views of industry professionals and academic experts. In the next step, a questionnaire was prepared and completed based on the analytic hierarchy process (AHP) and the challenges were prioritized. When it comes to subcontractors, the findings of the research demonstrate that difficulties in timely payments, alterations in approved drawings and the lack of rectification of job after completion by the subcontractor, paucity of a predetermined and legal process for qualifications of subcontractors, neglecting the supply chain processes in material procurement from producers, and delays in delivery of works by a subcontractor are the most significant problems. Finally, some solutions for encountering, eradicating, or reducing of mentioned problems are presented in accordance with previous studies and a survey from specialists.

Keywords: main contractors, subcontractors, supply chain management, construction supply chain, analytic hierarchy process, solution

Procedia PDF Downloads 23

Authors: K.T Alade, A.F Lawal, A.A Omonori

Abstract:

Construction is an everlasting activity across the globe. Likewise, the problem of delay in the construction industry is a global phenomenon. Although there are several reasons that may be responsible for delay during construction, this may vary from place to place and can be reduced to the minimum when identified. This study considered the major causes and effects of delay in the execution of construction projects in Akure, Ondo State, Nigeria. Using literatures, a total number of 30 causes of construction delays were identified. The convenient sampling technique was used to select sixty respondents for a survey. The respondents comprise twenty-two (22) clients, eighteen consultants (18) and twenty (20) contractors. The analyses of the primary data revealed that the three most important causes of delay in construction projects in Akure, Ondo State Nigeria are poor site management and supervision, inadequate contractors experience and client’s financial difficulties. Based on the findings of this study, recommendations were given on how the causes and effects of delay in construction can be mitigated.

Keywords: Akure, causes, construction projects, delay, effects

Procedia PDF Downloads 473

Authors: Dewan Ahsan

Abstract:

Denmark is well ahead in generating electricity from renewable sources. The offshore wind sector is playing the pivotal role to achieve this target. Though there is a rapid growth of offshore wind sector in Denmark, still there is a dearth of synchronization in OHS (occupational health and safety) regulation and standards. Therefore, this paper attempts to ascertain: i) what are the major challenges of the company specific OHS standards? ii) why does the offshore wind industry need a standardized OHS management system? and iii) who can play the key role in this process? To achieve these objectives, this research applies the interview and survey techniques. This study has identified several key challenges in OHS management system which are; gaps in coordination and communication among the stakeholders, gaps in incident reporting systems, absence of a harmonized OHS standard and blame culture. Furthermore, this research has identified eleven key stakeholders who are actively involve with the offshore wind business in Denmark. As noticed, the relationships among these stakeholders are very complex specially between operators and sub-contractors. The respondent technicians are concerned with the compliance of various third-party OHS standards (e.g. ISO 31000, ISO 29400, Good practice guidelines by G+) which are applying by various offshore companies. On top of these standards, operators also impose their own OHS standards. From the technicians point of angle, many of these standards are not even specific for the offshore wind sector. So, it is a big challenge for the technicians and sub-contractors to comply with different company specific standards which also elevate the price of their services offer to the operators. For instance, when a sub-contractor is competing for a bidding, it must fulfill a number of OHS requirements (which demands many extra documantions) set by the individual operator and/the turbine supplier. According to sub-contractors’ point of view these extra works consume too much time to prepare the bidding documents and they also need to train their employees to pass the specific OHS certification courses to accomplish the demand for individual clients and individual project. The sub-contractors argued that in many cases these extra documentations and OHS certificates are inessential to ensure the quality service. So, a standardized OHS management procedure (which could be applicable for all the clients) can easily solve this problem. In conclusion, this study highlights that i) development of a harmonized OHS standard applicable for all the operators and turbine suppliers, ii) encouragement of technicians’ active participation in the OHS management, iii) development of a good safety leadership, and, iv) sharing of experiences among the stakeholders (specially operators-operators-sub contractors) are the most vital strategies to overcome the existing challenges and to achieve the goal of 'zero accident/harm' in the offshore wind industry.

Keywords: green energy, offshore, safety, Denmark

Procedia PDF Downloads 184