Search results for: international construction joint venture

Authors: Riki Panchal, Debasis Sarkar

Abstract:

This paper describes the work done for the GIS-based project management for different infrastructure projects. It is a review paper which gives the idea of the trends in the construction project management and various models adopted for the betterment of the project planning and execution. Traditional scheduling and progress control techniques such as bar charts and the critical path method fail to provide information pertaining to the spatial aspects of a construction project. An integrated system was developed to represent construction progress not only in terms of a CPM schedule but also in terms of a graphical representation of the construction that is synchronized with the work schedule. Hence, it is suggested to work on the common platform from where all the data can be shared and analyzed.

Keywords: GIS, project management, integrated model, infrastructure project

Procedia PDF Downloads 519

Authors: Xiaoting Jing, Ling Huang

Abstract:

After the reform and opening up, Chongqing has formed far more high-rise residential areas than other cities in its more than 40 years of urban construction. High-rise residential areas have become one of the main modern living models in Chongqing and an important carrier reflecting the city's high quality of life. Reviewing the construction process and renewal work helps understand the characteristics of high-rise residential areas in Chongqing at different stages, clarify current development demands, and look forward to the focus of future renewal work. Based on socio-economic development and policy background, the article sorts the construction process of high-rise residential areas in Chongqing into four stages: the early experimental construction period of high-rise residential areas (1978-1996), the rapid start-up period of high-rise commodity housing construction (1997-2006), the large-scale construction period of high-rise commodity housing and public rental housing (2007-2014), and the period of renewal and renovation of high-rise residential areas and step-by-step construction of quality commodity housing (2015-present). Based on the construction demands and main construction types of each stage, the article summarizes that the construction of high-rise residential areas in Chongqing features large scale, high speed, and high density. It points out that a large number of high-rise residential areas built after 2000 will become important objects of renewal and renovation in the future. Based on existing renewal work experience, it is urgent to explore a path for sustainable renewal and development in terms of policy mechanisms, digital supervision, and renewal and renovation models, leading the high-rise living in Chongqing toward high-quality development.

Keywords: high-rise residential areas, construction process, renewal and renovation, Chongqing

Procedia PDF Downloads 67

Authors: H. Hakim, C. Kibert, C. Fabre, S. Monadizadeh

Abstract:

Construction industry is an industry saddled with chronic problems of high waste generation. Waste management that is to ensure materials are utilized in an efficient manner would make a major contribution to mitigating the negative environmental impacts of construction waste including finite resources depletion and growing occupied landfill areas to name a few. Furthermore, ‘material resource efficiency’ has been found an economically smart approach specially when considered during the design phase. One effective strategy is to utilizing off-site construction process which includes a series of prefabricated systems such as mobile, modular, and HUD construction (Department of Housing and Urban Development manufactured buildings). These types of buildings are by nature material and resource-efficient. Despite conventional construction that is exposed to adverse weather conditions, manufactured construction production line is capable of creating repetitive units in a factory controlled environment. A factory can have several parallel projects underway with a high speed and in a timely manner which simplifies the storage of excess materials and re-allocating to the next projects. The literature reports that prefabricated construction significantly helps reduce errors, site theft, rework, and delayed problems and can ultimately lead to a considerable waste reduction. However, there is not sufficient data to quantify this reduction when it comes to a regular modular house in the U.S. Therefore, this manuscript aims to provide an analysis of waste originated from a manufactured factory trend. The analysis was made possible with several visits and data collection of Homes of Merits, a Florida Manufactured and Modular Homebuilder. The results quantify and verify a noticeable construction waste reduction.

Keywords: construction waste, modular construction, prefabricated buildings, waste management

Procedia PDF Downloads 267

Authors: Abdulsamee Halahla, Emad Allout

Abstract:

The purpose of this research is to study the behavior of exterior beam-column joints (BCJs) strengthened with ultra-high performance concrete (UHPC), in terms of the shear strength and maximum displacement using pushover analysis at the tip of the beam. A finite element (F.E) analysis was performed to study three main parameters – the level of the axial load in the column (N), the beam shear reinforcement (Av/s)B, and the effect of using UHPC. The normal concrete at the studied joint region was replaced by UHPC. The model was verified by using experimental results taken from the literature. The results showed that the UHPC contributed to the transference of the plastic hinge from the joint to the beam-column interface. In addition, the strength of the UHPC-strengthened joints was enhanced dramatically from 8% to 38% for the joints subjected to 12.8MPa and zero axial loads, respectively. Moreover, the UHPC contributed in improving the maximum deflection. This improvement amounted to 1% and 176% for the joints subjected to zero and 12.8MPa axial load, respectively.

Keywords: ultra high performance concrete, ductility, reinforced concrete joints, finite element modeling, nonlinear behavior; pushover analysis

Procedia PDF Downloads 136

Authors: Z. Hamed, K. Sa'deya, E. Abdelrasheed, I. Mahamid

Abstract:

The construction industry is one of the main sectors that play basic role in the urban and rural development of a society. It provides important ingredients for the development of an economy. However, many construction projects experience extensive cost overrun. This study was conducted to identify the causes of cost overrun in building construction contracts in Al Madinah, Saudi Arabia and test the importance of these causes from contractors' perspective. To achieve the study objectives, a questionnaire survey was conducted to identify and rank cost overrun causes from the perspective of contractors. The findings found that the top five cost overrun causes are: lack of experience in the line of work, lack of labor productivity, delay in payments, rework and material waste. It is hoped that the findings will guide efforts to improve the performance of construction industry in Saudi Arabia and other developing countries.

Keywords: building, contractor, cost increase, cost overrun

Procedia PDF Downloads 156

Authors: Kwok Tak Kit

Abstract:

Combating climate change is becoming a hot topic in various sectors. Building construction and infrastructure sectors contributed a significant proportion of waste and GHGs emissions in the economy of different countries and cities. Many types of research had conducted and discussed the topic of waste management and waste management being a macro-level control is well developed in the building and construction industry. However, there is little research and studies on the micro-level of waste management, “building construction material wastage management,” and fewer reviews about regulatory control in the building construction sector. In this paper, we will focus on the potentialities and importance of material wastage management and review the deficiencies of the current standard to take into account the reduction of material wastage in a systematic and quantitative approach.

Keywords: quantitative measurement, material wastage management plan, waste management, uncalculated waste, circular economy

Procedia PDF Downloads 153

Authors: Su-Hyun Cho, Chang-U Chae

Abstract:

Environmental impact assessment techniques have been developed as a result of the worldwide efforts to reduce the environmental impact of global warming. By using the quantification method in the construction industry, it is now possible to manage the greenhouse gas is to systematically evaluate the impact on the environment over the entire construction process. In particular, the proportion of greenhouse gas emissions at the production stage of construction material occupied is high, and efforts are needed in particular in the construction field. In this study, intended for concrete products for the construction materials, by using the LCA evaluation method, we compared the results of environmental impact assessment and carbon emissions of developing products that have been applied low-carbon technologies compared to existing products. As a results, by introducing a raw material of industrial waste, showed carbon reduction. Through a comparison of the carbon emission reduction effect of low-carbon technologies, it is intended to provide academic data for the evaluation of greenhouse gases in the construction sector and the development of low-carbon technologies of the future.

Keywords: CO₂ emissions, CO₂ reduction, ready-mixed concrete, environmental impact assessment

Procedia PDF Downloads 479

Authors: Lina Fernanda González

Abstract:

Through this essay, an attempt will be made to make visible the work of the international network of the Women in Black (henceforth WB), on the one hand. On the other hand, the work of Women International Courts as a political practice will be showed as well, focusing their work into generating a collective identity - becoming thusly a peace building space, rescuing in this way the symbolic value of their practices consisting in peaceful resistance as political scenarios, that serve, too, a pedagogical and healing purposes.

Keywords: collective actions, women, peace, human rights and humanitarian international law

Procedia PDF Downloads 396

Authors: Nahed Al-Hajeri

Abstract:

Time and cost is an integral part of every construction plan and can affect each party’s contractual obligations. The performance of both time and cost are usually important to the client and contractor during the project. Almost all construction projects are experiencing time overrun. These time overruns always contributed as expensive to both client and contractor. Construction of any project inside the gathering centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. It also involves many agencies interdependent on each other like the vendors, structural and functional designers including various types of specialized engineers and it includes support of contractors and specialized contractors. This paper mainly highlights the types of construction delays due to which project suffer time and cost overrun. This paper also speaks about the delay causes and factors that contribute to the construction sequence delay for the oil and gas projects. Construction delay is supposed to be one of the repeated problems in the construction projects and it has an opposing effect on project success in terms of time, cost and quality. Some effective methods are identified to minimize delays in construction projects such as: 1. Site management and supervision, 2. Effective strategic planning, 3. Clear information and communication channel. Our research paper studies the types of delay with some real examples with statistic results and suggests solutions to overcome this problem.

Keywords: non-compensable delay, delays caused by force majeure, compensable delay, delays caused by the owner or the owner’s representative, non-excusable delay, delay caused by the contractor or the contractor’s representative, concurrent delay, delays resulting from two separate causes at the same time

Procedia PDF Downloads 242

Authors: Kasra HosseinMostofi, Mohamadamin Oyar Hossein, Reza Mehdizadeh Anvigh

Abstract:

BIM is an innovative concept for the majority of firms operating in industry. BIM offers a new paradigm to design, construct, operate, and maintain a facility. However, even with the most conscientious use, stakeholders can run into trouble during its implementation on a project or within an organization. At times, project stakeholders are unaware of the challenges that they can face with the implementation at the project level or an organizational level. Therefore, the study aimed to identify and compile barriers associated with the BIM implementation at the project and organizational level, as per the literature. Despite the fact that innumerable advantageous involved in exploiting BIM, there are some barriers to implement it properly. These barriers have been proved as impediments for academicians and members of construction team project to take the maximum advantage of its utilization. Although some research has been conducted to identify these barriers regarding BIM implementation in construction industry, more research is needed to be carried out among academicians to identify these barriers in institutions, and most importantly, to make suggestions for eliminating these obstacles.

Keywords: building information modelling, construction, design and construction, designers

Procedia PDF Downloads 184

Authors: Hugo M. Gonzales, Ke Ni Chai, Deanne Mary King

Abstract:

International students are underrepresented in Australian health literature, and this population is especially vulnerable to the well-documented negative impacts associated with racial microaggressions in their adjustment to settling in the new society, as well as to the many challenges they already face as international students. This study investigated the prevalence of racial microaggressions among international students and their impact on stress and psychological well-being. This research was conducted during the COVID-19 pandemic, which has been documented to contribute to anti-Asian racism. Participants included 54 international students, of which 72% were Asian. The Racial and Ethnic Microaggressions Scale (REMS), Perceived Stress Scale (PSS), and the Perceived General Wellbeing Indicator (PGWBI) were used to measure the participants’ responses. All participants reported experiencing racial microaggression in the last six months, and significant correlations and regression models were found between REMS, certain elements of the PSS scale, and time in Australia. Despite the small sample size, this research corroborated outcomes from recent studies and provided insight into the prevalence and impact of racial microaggressions among such populations, highlighting the need for further exploration.

Keywords: racial microaggressions, international students, racism, REMS, microaggressions in Australia, stress, psychological wellbeing

Procedia PDF Downloads 129

Authors: F. H. Abanda, B. Kamsu-Foguem, J. H. M. Tah

Abstract:

Construction cost estimation is one of the most important aspects of construction project design. For generations, the process of cost estimating has been manual, time-consuming and error-prone. This has partly led to most cost estimates to be unclear and riddled with inaccuracies that at times lead to over- or under-estimation of construction cost. The development of standard set of measurement rules that are understandable by all those involved in a construction project, have not totally solved the challenges. Emerging Building Information Modelling (BIM) technologies can exploit standard measurement methods to automate cost estimation process and improves accuracies. This requires standard measurement methods to be structured in ontologically and machine readable format; so that BIM software packages can easily read them. Most standard measurement methods are still text-based in textbooks and require manual editing into tables or Spreadsheet during cost estimation. The aim of this study is to explore the development of an ontology based on New Rules of Measurement (NRM) commonly used in the UK for cost estimation. The methodology adopted is Methontology, one of the most widely used ontology engineering methodologies. The challenges in this exploratory study are also reported and recommendations for future studies proposed.

Keywords: BIM, construction projects, cost estimation, NRM, ontology

Procedia PDF Downloads 551

Authors: S. Ping Ho, R. Dahal

Abstract:

The global economy has drastically changed how firms operate and compete. Although the construction industry is ‘local’ by its nature, the internationalization of the construction industry has become an inevitable reality. As a result of global competition, staying domestic is no longer safe from competition and, on the contrary, to grow and become an MNE (multi-national enterprise) becomes one of the important strategies for a firm to survive in the global competition. For the successful entrance into competing markets, the firms need to re-define their competitive advantages and re-identify the sources of the competitive advantages. A firm’s initiation of internationalization is not necessarily a result of strategic planning but also involves certain idiosyncratic events that pave the path leading to a firm’s internationalization. For example, a local firm’s incidental or unintentional collaboration with an MNE can become the initiating point of its internationalization process. However, because of the intensive competition in today’s global movement, many firms were compelled to initiate their internationalization as a strategic response to the competition. Understandingly stepping in in the process of internationalization and appropriately implementing the strategies (in the process) at different stages lead the construction firms to a successful internationalization journey. This study is carried out to develop a model of the internationalization process, which derives appropriate strategies that the construction firms can implement at each stage. The proposed model integrates two major and complementary views of internationalization and expresses the dynamic process of internationalization in three stages, which are the pre-international (PRE) stage, the foreign direct investment (FDI) stage, and the multi-national enterprise (MNE) stage. The strategies implied in the proposed model are derived, focusing on capability building, market locations, and entry modes based on the resource-based views: value, rareness, imitability, and substitutability (VRIN). With the proposed dynamic process model the potential construction firms which are willing to expand their business market area can be benefitted. Strategies for internationalization, such as core competence strategy, market selection, partner selection, and entry mode strategy, can be derived from the proposed model. The internationalization process is expressed in two different forms. First, we discuss the construction internationalization process, identify the driving factor/s of the process, and explain the strategy formation in the process. Second, we define the stages of internationalization along the process and the corresponding strategies in each stage. The strategies may include how to exploit existing advantages for the competition at the current stage and develop or explore additional advantages appropriate for the next stage. Particularly, the additionally developed advantages will then be accumulated and drive forward the firm’s stage of internationalization, which will further determine the subsequent strategies, and so on and so forth, spiraling up the stages of a higher degree of internationalization. However, the formation of additional strategies for the next stage does not happen automatically, and the strategy evolution is based on the firm’s dynamic capabilities.

Keywords: construction industry, dynamic capabilities, internationalization process, internationalization strategies, strategic management

Procedia PDF Downloads 62

Authors: Noor M. Abdulfattah, Ahmed M. Khalafallah, Nabil A. Kartam

Abstract:

Despite the evident benefits of building information modeling (BIM) to the construction industry, it faces significant implementation challenges in the State of Kuwait. This study investigates the awareness of construction stakeholders of BIM implementation challenges, and identifies various solutions to overcome these challenges. Specifically, the main objectives of this study are to: (1) characterize the barriers that deter utilization of BIM, (2) examine the awareness of engineers, architects, and construction stakeholders of these barriers, and (3) identify practical solutions to facilitate BIM utilization. A questionnaire survey was designed to collect data on the aforementioned objectives from local companies and senior BIM experts. It was found that engineers are highly aware of BIM implementation barriers. In addition, it was concluded from the questionnaire that the biggest barrier is the lack of BIM training. Based on expert feedback, the study concluded with a number of recommendations on how to overcome the barriers of BIM utilization. This should prove useful to the construction industry stakeholders and can lead to significant changes to design and construction practices.

Keywords: building information modeling (BIM), construction, information technology, challenges

Procedia PDF Downloads 261

Authors: S. Vlasyan

Abstract:

The article deals with the implementation of the right to self-determination of peoples on the example of Nagorno-Karabakh Republic. The problem of correlation of two fundamental principles of international law i. e. territorial integrity and the right to self-determination of peoples is considered to be one of the vital issues in the field of international law for several decades. So, in this article, the author analyzes the decision of the Supreme Court of Canada regarding specific issues of secession of Quebec from Canada, as well as the decision of the International Court of Justice in the case concerning East Timor (Portugal v. Australia), and in the case of Western Sahara. The author formulates legal conditions of Nagorno-Karabakh secession.

Keywords: right of self-determination, territorial integrity, the principles of International Law, Nagorno-Karabakh Republic

Procedia PDF Downloads 408

Authors: Ratih Indraswari

Abstract:

As it occupies a new status in international relations, Indonesia needs to re-organize its resources in projecting the preferred image internationally. Attractiveness becomes crucial as Indonesia needs to maintain its posture as a reliable contributor to the world. This paper tries to scrutinize the un-tap potential of ideational powers Indonesia possesses. Herein the ideational power is assumed to be translated into a soft power, intangible and rely on its influential degree to persuade and attract other countries, through its public diplomacy activities. A specific correlation will be dedicated to the effort of Indonesia public diplomacy on international education. It is believed that international education progresses mutual understanding in disseminating Indonesia values and engages public audience. As a result these exchanges and engagements support the attainment of Indonesia’s interests and forwarding Indonesia’s foreign policies. A case study on KNB (Kemitraan Negara berkembang) scholarship scheme will be provided and its impact towards building people-to-people connections.

Keywords: Indonesia, international education, KNB (Kemitraan Negara Berkembang), public diplomacy

Procedia PDF Downloads 369

Authors: Mehdi Ghaemi

Abstract:

In principle, foreign investment security is enshrined in International Investment Agreements (IIAs) and Bilateral Investment Treaties (BITs) in the form of protection standards such as the Full Protection and Security Standard (FPS). Accordingly, the host countries undertake to provide the necessary security for the economic activities of foreign investment. With the outbreak of coronavirus, the international community called COVID-19 a threat to international peace security, as well as to the public interest and national security of nations; and to deal with, they proposed several solutions, generally including quarantine, creating social distances, and restricting businesses. This article first studies the security of foreign investment in international investment law. In the following, it analyzes the consequences of the COVID-19 pandemic for foreign investment security so that if there is a threat to that security, solutions could be offered to reduce it.

Keywords: foreign investment, FPS standard, host country, public health, COVID-19

Procedia PDF Downloads 105

Authors: A. Danbaba

Abstract:

Samurai Sudoku consists of five Sudoku square designs each having nine treatments in each row (column or sub-block) only once such the five Sudoku designs overlaps. Two or more Samurai designs can be joint together to give an extended Samurai design. In addition, two Samurai designs, each containing five Sudoku square designs, are mutually orthogonal (Graeco). If we superimpose two Samurai designs and obtained a pair of Latin and Greek letters in each row (column or sub-block) of the five Sudoku designs only once, then we have Graeco Samurai design. In this paper, simple method of constructing Samurai designs and mutually orthogonal Samurai design are proposed. In addition, linear models and methods of data analysis for the designs are proposed.

Keywords: samurai design, graeco samurai design, sudoku design, row or column swap

Procedia PDF Downloads 268

Authors: Hanan Anwar

Abstract:

All systems recycle. The construction industry has not only become a major consumer of natural materials along with a source of pollution. Environmental integrated production, reusing and recycling is of great importance in Egypt nowadays. Governments should ensure that the technical, environmental and economic feasibility of alternative systems is considered and is taken into account before construction starts. Hereby this paper focuses on the recycle of building materials as a way for environment protection and sustainable development. Environmental management integrates the requirements of sustainable development. There are many methods used to reduce waste and increase profits through salvage, reuse, and the recycling of construction waste. Sustainable development as a tool to continual improvement cycle processes innovations to save money.

Keywords: environment, management, reuse, recycling, sustainable development

Procedia PDF Downloads 314

Authors: Ranjini Ramanath, Nanjunda P. Swamy

Abstract:

Construction has existed in our lives since time immemorial. However, unlike any other industry, construction projects have their own unique challenges – project type, purpose and end use of the project, geographical conditions, logistic arrangements, largely unorganized manpower and requirement of diverse skill sets, etc. These unique characteristics bring in their own level of risk and uncertainties to the project, which cause the project to deviate from its planned objectives of time, cost, quality, etc. over the many years, there have been significant developments in the way construction projects are conceptualized, planned, and managed. With the rapid increase in the population, increased rate of urbanization, there is a growing demand for infrastructure development, and it is required that the projects are delivered timely, and efficiently. In an age where ‘Time is Money,' implementation of new techniques of project management is required in leading to successful projects. This paper proposes a different approach to project management, which if applied in construction projects, can help in the accomplishment of the project objectives in a faster manner.

Keywords: critical chain project management methodology, critical chain, project management, construction management

Procedia PDF Downloads 423

Authors: T. M. Al Muhareb

Abstract:

Any organization should take into consideration the customers’ satisfaction while providing any service to their customers. The quality of services is always considered as the main aspect that attracts the customers’ attention and helps the airports to develop their services and operations. King Khalid International Airport is considered as the gateway of the Kingdom of Saudi Arabia. Therefore, the aim of this paper was to identify the quality service in the departure area at in King Khalid Airport. The SERVQUAL questionnaire was distributed among the passengers in King Khalid International Airport and the respondents have reached to 500 passengers. The results that are obtained from the SERVQUAL questionnaire showed that the quality of airport’s services is low.

Keywords: service quality, SERVQUAL methodology, King Khalid International Airport (KKIA), customers’ satisfaction

Procedia PDF Downloads 802

Authors: T. R. Sreeram, S. Natarajan, C. Jena

Abstract:

Civil engineering construction is a network of tasks involving varying degree of complexity and streamlining, and standardization is the only way to establish a systemic approach to design. While there are off the shelf tools such as AutoCAD that play a role in the realization of design, the repeatable process in which these tools are deployed often is ignored. The present paper addresses this challenge through a sustainable design process and effective standardizations at all stages in the design workflow. The same is demonstrated through a case study in the context of construction, and further improvement points are highlighted.

Keywords: syste, lean, value stream, process improvement

Procedia PDF Downloads 123

Authors: R. K. Yadav, S. Baral, H. R. Paudel, R. Basnet

Abstract:

The Public-Private Mix (PPM) approach is a strategic initiative that involves engaging all private and public healthcare providers in the fight against tuberculosis using international healthcare standards. For tuberculosis control in Nepal, the PPM approach could be a milestone. This study aimed to explore the barriers to a public-private mix approach in the management of tuberculosis cases in Nepal. A total of 20 respondents participated in the study. Barriers to PPM were identified in the following three themes: 1) Obstacles related to TB case detection, 2) Obstacles related to patients, and 3) Obstacles related to the healthcare system. PPM implementation was challenged by following subthemes that included staff turnover, low private sector participation in workshops, a lack of training, poor recording and reporting, insufficient joint monitoring and supervision, poor financial benefit, lack of coordination and collaboration, and non-supportive TB-related policies and strategies. The study concludes that numerous barriers exist in the way of effective implementation of the PPM approach, including TB cases detection barriers such as knowledge of TB diagnosis and treatment, HW attitude, workload, patient-related barriers such as knowledge of TB, self-medication practice, stigma and discrimination, financial status, and health system-related barriers such as staff turnover and poor engagement of the private sector in workshops, training, recording, and re-evaluation. Government stakeholders must work together with private sector stakeholders to perform joint monitoring and supervision. Private practitioners should receive training and orientation, and presumptive TB patients should be given adequate time and counseling as well as motivation to visit a government health facility.

Keywords: barrier, tuberculosis, case finding, PPM, nepal

Procedia PDF Downloads 110

Authors: Chang He, Hiroshi Tamura, Hiroshi Katsuchi, Jiaqi Wang

Abstract:

In this study, the aim is to infer the slip limit (static friction limit) of contact interfaces in bolt friction joints by analyzing other bolt friction joints with the same contact surface but in a different shape. By using the Weibull distribution to deal with microelements on the contact surface statistically, the slip limit of a certain type of bolt joint was predicted from other types of bolt joint with the same contact surface. As a result, this research succeeded in predicting the slip limit of bolt joins with different numbers of contact surfaces and with different numbers of bolt rows.

Keywords: bolt joints, slip coefficient, finite element method, Weibull distribution

Procedia PDF Downloads 170

Authors: Mas Pertiwi I. G. AG Istri, Sri Kristinayanti Wayan, Oka Aryawan I. Gede Made

Abstract:

Ability of government to meet the needs of infrastructure investment constrained by the size of the budget commitments for other sectors. Another barrier is the complexity of the process of land acquisition. Public Private Partnership can help bridge the investment gap by including the amount of funding from the private sector, shifted the responsibility of financing, construction of the asset, and the operation and post-project design and care to them. In principle, a construction project implementation always requires the investor as a party to provide resources in the form of funding which it must be contained in a successor agreement in the form of a contract. In general, construction contracts consist of contracts which passed in Indonesia and contract International. One source of funding used in the implementation of construction projects comes from funding that comes from the collaboration between the government and the private sector, for example with the system: BLT (Build Lease Transfer), BOT (Build Operate Transfer), BTO (Build Transfer Operate) and BOO (Build Operate Own). And form of payment under a construction contract can be distinguished several ways: monthly payment, payments based on progress and payment after completed projects (Turn Key). One of the tools used to analyze the feasibility of the investment is to use financial models. The financial model describes the relationship between different variables and assumptions used. From a financial model will be known how the cash flow structure of the project, which includes revenues, expenses, liabilities to creditors and the payment of taxes to the government. Net cash flow generated from the project will be used as a basis for analyzing the feasibility of investment source of project financing Public Private Partnership could come from equity or debt. The proportion of funding according to its source is a comparison of a number of investment funds originating from each source of financing for a total investment cost during the construction period by selected the contract system and several alternative financing percentage ratio determined according to sources will generate cash flow structure that is different. Of the various possibilities for the structure of the cash flow generated will be analyzed by software is to test T Paired to compared the contract system used by various alternatives comparison of financing to determine the effect of the contract system and the comparison of such financing for the feasibility of investment toll road construction project for the economic life of 20 (twenty) years. In this use case studies of toll road contruction project Bali Mandara. And in this analysis only covered two systems contracts, namely Build Operate Transfer and Turn Key. Based on the results obtained by analysis of the variable investment feasibility of the NPV, BCR and IRR between the contract system Build Operate Transfer and contract system Turn Key on the interest rate of 9%, 12% and 15%.

Keywords: contract system, financing, internal rate of return, net present value

Procedia PDF Downloads 227

Authors: H. Pasternak, T. Krausche

Abstract:

The Porsche Pavilion is an innovative stainless steel construction using the principle, often used in ship and car design, as an advantage for building a light but stiff structure. The Pavilion is a one of a kind and outstanding construction that you can find. It fits right in the existing parts of the Autostadt within the lagoon landscape and was built in only eight months. With its curving lines and exiting bends the structure is an extraordinary work which was designed by Henn architects, Munich. The monocoque has a good balance between material and support structure. The stiffness is achieved by the upper and lower side sheathing plates and the intermediate formers. Also the roof shell has no joints and a smooth surface. The assembling of the structure requires a large time and effort cost due to many welds which are necessary to connect all section to one large shell.

Keywords: construction welding, exhibition building, light steel construction, monocoque

Procedia PDF Downloads 523

Authors: Lu Ren, You-Liang Fang, Yan-Gang Zhao

Abstract:

In recent years, the application of BIM (Building Information Modelling) to construction schedule plan has been the focus of more and more researchers. In order to assess the reasonable level of the BIM-based construction schedule plan, that is whether the schedule can be completed on time, some researchers have introduced reliability theory to evaluate. In the process of evaluation, the uncertain factors affecting the construction schedule plan are regarded as random variables, and probability distributions of the random variables are assumed to be normal distribution, which is determined using two parameters evaluated from the mean and standard deviation of statistical data. However, in practical engineering, most of the uncertain influence factors are not normal random variables. So the evaluation results of the construction schedule plan will be unreasonable under the assumption that probability distributions of random variables submitted to the normal distribution. Therefore, in order to get a more reasonable evaluation result, it is necessary to describe the distribution of random variables more comprehensively. For this purpose, cubic normal distribution is introduced in this paper to describe the distribution of arbitrary random variables, which is determined by the first four moments (mean, standard deviation, skewness and kurtosis). In this paper, building the BIM model firstly according to the design messages of the structure and making the construction schedule plan based on BIM, then the cubic normal distribution is used to describe the distribution of the random variables due to the collecting statistical data of the random factors influencing construction schedule plan. Next the reliability analysis of the construction schedule plan based on BIM can be carried out more reasonably. Finally, the more accurate evaluation results can be given providing reference for the implementation of the actual construction schedule plan. In the last part of this paper, the more efficiency and accuracy of the proposed methodology for the reliability analysis of the construction schedule plan based on BIM are conducted through practical engineering case.

Keywords: BIM, construction schedule plan, cubic normal distribution, reliability analysis

Procedia PDF Downloads 147

Authors: Chantarat Manvichien

Abstract:

The purpose of this research paper was aimed to examine the bird strike prevention in the vicinity of Suvarnabhumi Airport, Thailand. A bird strike event occurs when a bird or a flock of birds collide with an operating airplane and results in flight interruption. This is the reason why International Civil Aviation Organization (ICAO), a part of the United Nations, has an assumption that birds, including other wildlife, are a serious hazard to aircraft and attempts should be accomplished to overcome this hazard. ICAO requires all airports worldwide to set up proactive countermeasures in order to reduce the risk from bird strike and wildlife hazard. In Thailand, the Airports of Thailand Public Company Limited which manages Suvarnabhumi Airport, also known as Bangkok International Airport, responds to the requirements and spends a lot of effort to ensure this hazard is manageable. An intensive study on the countermeasures to prevent aircraft accident from bird strike and other wildlife have been continuously executed since the early construction of the Airport until nowadays.

Keywords: bird strike, flight safety, wildlife hazard, Suvarnabhumi airport

Procedia PDF Downloads 364

Authors: Daniil Chernov

Abstract:

In the modern world, the number of conventional interstate wars is declining while the number of military interventions is rising. States no longer initiate conflicts by declaring war but actively intervene in existing military confrontations, often using a comparable number of coercive means. According to existing scholarly understanding, the decision to use force in international relations (in any form) is influenced by roughly the same set of factors: the dynamics of domestic political processes, national interests, international law, and ethical considerations. In the database on armed intervention to be presented in the report, the multifactor model of decision-making is developed. The database describes more than 200 different parameters for armed interventions between 1992 and 2022. The report will present the structure of the database, descriptive statistics, and its key advantages over other sources.

Keywords: conflict resolution, international relations, military intervention, database

Procedia PDF Downloads 34

Authors: A. Stifi, S. Gentes

Abstract:

Undoubtedly from construction's perspective, the use of explosives will remove a large facility such as a 40-storey building , that took almost 3 to 4 years for construction, in few minutes. Usually, the reconstruction or decommissioning, the last phase of life cycle of any facility, is considered to be the shortest. However, this is proved to be wrong in the case of nuclear power plant. Statistics says that in the last 30 years, the construction of a nuclear power plant took an average time of 6 years whereas it is estimated that decommissioning of such plants may take even a decade or more. This paper is all about the decommissioning phase of a nuclear power plant which needs to be given more attention and encouragement from the research institutes as well as the nuclear industry. Currently, there are 437 nuclear power reactors in operation and 70 reactors in construction. With around 139 nuclear facilities already been shut down and are in different decommissioning stages and approximately 347 nuclear reactors will be in decommissioning phase in the next 20 years (assuming the operation time of a reactor as 40 years), This fact raises the following two questions (1) How far is the nuclear and construction Industry ready to face the challenges of decommissioning project? (2) What is required for a safety and reliable decommissioning project delivery? The decommissioning of nuclear facilities across the global have severe time and budget overruns. Largely the decommissioning processes are being executed by the force of manual labour where the change in regulations is respectively observed. In term of research and development, some research projects and activities are being carried out in this area, but the requirement seems to be much more. The near future of decommissioning shall be better through a sustainable development strategy where all stakeholders agree to implement innovative technologies especially for dismantling and decontamination processes and to deliever a reliable and safety decommissioning. The scope of technology transfer from other industries shall be explored. For example, remotery operated robotic technologies used in automobile and production industry to reduce time and improve effecincy and saftey shall be tried here. However, the innovative technologies are highly requested but they are alone not enough, the implementation of creative and innovative management methodologies should be also investigated and applied. Lean Management with it main concept "elimination of waste within process", is a suitable example here. Thus, the cooperation between international organisations and related industries and the knowledge-sharing may serve as a key factor for the successful decommissioning projects.

Keywords: decommissioning of nuclear facilities, innovative technology, innovative management, sustainable development

Procedia PDF Downloads 471