Search results for: contractual risks

Authors: Imtiaz Ali, Imam Mansoor

Abstract:

Investigations as a part of the academic study were undertaken to identify and evaluate the significant risks associated with the construction of K-span buildings in the region of UAE. Primary field data was collected through questionnaires obtaining specific open and close-ended questions from carefully selected construction firms, civil engineers and, construction manager regarding risks associated to K-span building construction. Historical data available for other regions of the same construction technique was available which was compared for identifying various non-critical and critical risk parameters by comparative evaluation techniques to come up with important risks and potential sources for their control and minimization in K-Span buildings that is increasing in the region. The associated risks have been determined with their Relative Importance Index (RII) values of which Risk involved in Change of Design required by Owners carries the highest value (RII=0.79) whereas, Delayed Payment by Owner to Contractor is one of the least (RII=0.42) value. The overall findings suggest that most relative risks as quantified originate or associated with the contractors. It may be concluded that project proponents undertaking K-span projects in planning and budgeting the cost and delays should take into account of risks on high account if changes in design are also required any delays in the material by the supplier would then be a major risk in K-span project delay. Since projects are, less costly, so owners have limited budgets, then they hire small contractors, which are not highly competent contractors. So study suggests that owner should be aware of these types of risks associated with the construction of K-span buildings in order to make it cost effective.

Keywords: k-span buildings, k-span construction, risk management, relative improvement index (RII)

Procedia PDF Downloads 375

Authors: Shaya Alshahrani

Abstract:

Perceived risks play a major role in consumer intentions, behaviors, attitudes, and decisions about online shopping in the KSA. This paper investigates the influence of six perceived risk dimensions on Saudi consumers: product risk, information risk, financial risk, privacy and security risk, delivery risk, and terms and conditions risk empirically. To ensure the success of this study, a random survey was distributed to reflect the consumers’ perceived risk and to enable the generalization of the results. Data were collected from 323 respondents in the Kingdom of Saudi Arabia (KSA): 50 who had never shopped online and 273 who had done so. The results indicated that all six risks influenced the respondents’ perceptions of online shopping. The non-online shoppers perceived financial and delivery risks as the most significant barriers to online shopping. This was followed closely by performance, information, and privacy and security risks. Terms and conditions were perceived as less significant. The online consumers considered delivery and performance risks to be the most significant influences on internet shopping. This was followed closely by information and terms and conditions. Financial and privacy and security risks were perceived as less significant. This paper argues that introducing adequate legal solutions to addressing related problems arising from this study is an urgent need. This may enhance consumer trust in the KSA online market, increase consumers’ intentions regarding online shopping, and improve consumer protection.

Keywords: perceived risk, online contracts, Saudi Arabia, consumer protection

Procedia PDF Downloads 148

Authors: Saleh Alzahrani, Halim Boussabaine

Abstract:

The Public Private Partnership (PPP) contracts are produced taking into account the reason that the configuration, development, operation, and financing of an open undertaking is to be recompensed to a private gathering inside a solitary contractual structure. PPP venture dangers are ordinarily connected with the improvement and development of another resource and in addition its operation for a considerable length of time. Without a doubt, the most genuine outcomes of dangers amid the development period are value and time overwhelms. These occasions are amongst the most extensively utilized situations as a part of worth for cash investigation dangers. The wellsprings of danger change over the life cycle of a PPP venture. In customary acquirement, the general population segment ordinarily needs to cover all value trouble from these dangers. At any rate there is bounty confirmation to recommend that cost pain is a standard in a percentage of the tasks that are conveyed under customary obtainment. This paper means to research the effect of endogenous dangers on expense overwhelm in KSA PPP ventures. The paper displays a brief writing survey on PPP danger evaluating systems, and after that presents an affiliation model between danger occasions and expense invade in KSA. The paper finishes up with considerations for future examination.

Keywords: PPP, risk pricing, impact of risk, Endogenous risks

Procedia PDF Downloads 451

Authors: M. Ndaw, G. Mendy, S. Ouya

Abstract:

Risk management in banking sector is a key issue linked to financial system stability and its importance has been elevated by technological developments and emergence of new financial instruments. In this paper, we improve the model previously defined for quantifying internal control impact on banking risks by automatizing the residual criticality estimation step of FMECA. For this, we defined three equations and a maturity coefficient to obtain a mathematical model which is tested on all banking processes and type of risks. The new model allows an optimal assessment of residual criticality and improves the correlation rate that has become 98%.

Keywords: risk, control, banking, FMECA, criticality

Procedia PDF Downloads 332

Authors: M. Bokhtiar Hasan, M. Delowar Hossain, Abu N. M. Wahid

Abstract:

The principal aim of the study is to find out a way to effectively manage the agricultural risks like price volatility, weather risks, and fund shortage. To hedge price volatility, farmers sometimes make contracts with agro-traders but fail to protect themselves effectively due to not having legal framework for such contracts. The study extensively reviews existing literature and find evidence that the majority studies either deal with price volatility or weather risks. If we could address these risks through a single model, it would be more useful to both the farmers and traders. Intrinsically, the authors endeavor in this regard, and the key contribution of this study basically lies in it. Initially, we conduct a small survey aspiring to identify the shortcomings of existing contracts. Later, we propose a model encompassing forward and insurance contracts together where forward contract will be used to hedge price volatility and insurance contract will be used to protect weather risks. Contribution/Originality: The study adds to the existing literature through proposing an integrated model comprising of forward contract and crop insurance which will support both farmers and traders to cope with the agricultural risks like price volatility, weather hazards, and fund shortage. JEL Classifications: O13, Q13

Keywords: agriculture, forward contract, insurance contract, risk management, model

Procedia PDF Downloads 154

Authors: Zhuoyuan Wang, Benson T. H. Lim, Imriyas Kamardeen

Abstract:

Effective service quality management has long been touted as a means of improving project and organisational performance. Particularly, in construction projects, main contractors are often seen as a broker between clients and subcontractors, and their service quality is thus associated with the overall project affinity and outcomes. While a considerable amount of research has focused on the aspect of clients-main contractors, very little research has been done to explore the effect of contractors’ service quality on subcontractors’ behaviours and so project outcomes. In addressing this gap, this study surveyed 97 subcontractors in the Chinese Construction industry and data was analysed using the Partial Least Square (PLS) Structural Equation Modelling (SEM) technique. The overall findings reveal that subcontractors categorised main contractors’ service quality into three dimensions: assurance; responsiveness; reliability and empathy. Of these, it is found that main contractors’ ‘assurance’ and ‘responsiveness’ positively influence subcontractors’ intention to engage in contractual behaviours. The results further show that the subcontractors’ intention to engage in organizational citizenship behaviours is associated with how flexible and committed the main contractors are in reliability and empathy. Collectively, both subcontractors’ contractual and organizational citizenship behaviours positively influence the overall project outcomes. In conclusion, the findings inform contractors different strategies towards managing and gaining subcontractors’ behaviour commitment in a socially connected, yet complex and uncertain, business environment.

Keywords: construction firms, organisational citizenship behaviour, service quality, social exchange theory

Procedia PDF Downloads 214

Authors: Yeukai Mupangavanhu

Abstract:

The paper examines the concept of ubuntu and the extent to which it can play a role in ensuring fairness and justice in contractual relationships. Courts are expected to balance sanctity of contract and fairness. Public policy is currently a mechanism which is used by courts when balancing the above two competing interests. It, however, generally favours the freedom and sanctity of contract. The question which is addressed in this paper is whether the concept of ubuntu is an alternative mechanism that may be used to mitigate the sometimes harsh and unfair consequences of the doctrine of freedom and sanctity of contract. A comparative study and case analysis is the methodology that is used in this article. Unfairness in contracts is generally related to the problem of inequality in bargaining power underscored by deeply entrenched social and economic inequalities that are a consequence of apartheid and patriarchy. The transformative nature of the constitution demands the inclusion of African legal ideas and values in the legal order. There is a need for the harmonisation of western ideals which are based on the classical model of law of contract with relevant African principles. In order to attain a transformative legal order that promotes a societal transformation and enhances the lives of everyone courts cannot continue to frown upon African values. Ubuntu has the potential of steering the law of contract in a more equitable direction. The substantive rules of contract law undoubtedly need to be infused with the notion of ubuntu. The reconciliation of Western and African values is at the heart of legal transformation.

Keywords: fairness, sanctity of contract, contractual justice, transformative constitutionalism

Procedia PDF Downloads 253

Authors: Kenneth O. Otasowie, Matthew Ikuabe, Clinton Aigbavboa, Ayodeji Oke

Abstract:

Construction project cost are not only made up of production costs. This cost comprises of many other elements such as the preparation of a bidding document, cost estimations, drafting contractual agreements and monitoring that contractual obligations are met. Several studies have stressed the need for transaction costs (TC) to be defined in a way that covers all phases of a project and not only the pre-contract phase. Hence, this study aims to appraise transaction cost in South African (SA) construction projects by assessing what constitutes transaction cost, influencing factors and possible optimisation measures. A survey design was adopted. A total number of eighty (80) questionnaires were administered to quantity surveyors, procurement managers and project managers in Guateng Province, SA and seventy-two (72) were returned and found suitable for analysis. Collected data was analysed using percentage, mean item score, standard deviation, one-sample t-test. The findings show that external technical interaction, uncertainty, human factors are the most significant constituents of TC in SA, while technical competency, experience in similar project type and project characteristics are the leading influencing factors. Furthermore, understanding project characteristics, clear communication and technically competent project teams are most of the significant measures for optimising TC in SA construction projects. Therefore, this study recommends that a competent project team and a clear communication are fundamental to proper management of TC in SA construction projects.

Keywords: construction projects, project cost, South Africa, transaction cost

Procedia PDF Downloads 98

Authors: Sasan Aryaee, Mahdi Ravanshadnia

Abstract:

Naturally, any activity is associated with risk, and humans have understood this concept from very long times ago and seek to identify its factors and sources. On the one hand, proper risk management can cause problems such as delays and unforeseen costs in the development projects, temporary or permanent loss of services, getting lost or information theft, complexity and limitations in processes, unreliable information caused by rework, holes in the systems and many such problems. In the present study, a model has been presented to rank the environmental risks of oil and gas projects. The statistical population of the study consists of all executives active in the oil and gas fields, that the statistical sample is selected randomly. In the framework of the proposed method, environmental risks of oil and gas projects were first extracted, then a questionnaire based on these indicators was designed based on Likert scale and distributed among the statistical sample. After assessing the validity and reliability of the questionnaire, environmental risks of oil and gas projects were ranked using the VIKOR method of multiple-criteria decision-making. The results showed that the best options for HSE planning of oil and gas projects that caused the reduction of risks and personal injury and casualties and less than other options is costly for the project and it will add less time to the duration of implementing the project is the entering of dye to the environment when painting the generator pond and the presence of the rigger near the crane.

Keywords: ranking, multi-criteria decision making, oil and gas projects, HSEmanagement, environmental risks

Procedia PDF Downloads 157

Authors: Shih-Kuei Lin

Abstract:

The characterization of the arbitrage-free dynamics of interest rates is developed in this study under the presence of Markov jump risks, when the term structure of the interest rates is modeled through simple forward rates. We consider Markov jump risks by allowing randomness in jump sizes, independence between jump sizes and jump times. The Markov jump diffusion model is used to capture empirical phenomena and to accurately describe interest jump risks in a financial market. We derive the arbitrage-free model of simple forward rates under the spot measure. Moreover, the analytical pricing formulas for a cap and a floor are derived under the forward measure when the jump size follows a lognormal distribution. In our empirical analysis, we find that the LIBOR market model with Markov jump risk better accounts for changes from/to different states and different rates.

Keywords: arbitrage-free, cap and floor, Markov jump diffusion model, simple forward rate model, volatility smile, EM algorithm

Procedia PDF Downloads 421

Authors: Ezgi Nevruz, Kasirga Yildirak, Ashis SenGupta

Abstract:

Comparing or ranking risks is the main motivating factor behind the human trait of making choices. Cumulative prospect theory (CPT) is a preference theory approach that evaluates perception and bias in decision making under risk and uncertainty. We aim to investigate the aggregate claims of different risk classes in terms of their comparability and amenability to ordering when the impact of risk perception is considered. For this aim, we prioritize the aggregate claims taken as actuarial risks by using various stochastic ordering relations. In order to prioritize actuarial risks, we use stochastic relations such as stochastic dominance and stop-loss dominance that are proposed in the frame of partial order theory. We take into account the dependency of the individual claims exposed to similar environmental risks. At first, we modify the zero-utility premium principle in order to obtain a solution for the stop-loss premium under CPT. Then, we propose a stochastic stop-loss dominance of the aggregate claims and find a relation between the stop-loss dominance and the first-order stochastic dominance under the dependence assumption by using properties of the familiar as well as some emerging multivariate claim distributions.

Keywords: cumulative prospect theory, partial order theory, risk perception, stochastic dominance, stop-loss dominance

Procedia PDF Downloads 321

Authors: Érick Aragão Ribeiro, George André Pereira Thé, José Marques Soares

Abstract:

Several problems in industrial supervision software development projects may lead to the delay or cancellation of projects. These problems can be avoided or contained by using identification methods, analysis and control of risks. These procedures can give an overview of the possible problems that can happen in the projects and what are the immediate solutions. Therefore, we propose a risk management method applied to the teaching and development of industrial supervision software. The method is developed through a literature review and previous projects can be divided into phases of management and have basic features that are validated with experimental research carried out by mechatronics engineering students and professionals. The management is conducted through the stages of identification, analysis, planning, monitoring, control and communication of risks. Programmers use a method of prioritizing risks considering the gravity and the possibility of occurrence of the risk. The outputs of the method indicate which risks occurred or are about to happen. The first results indicate which risks occur at different stages of the project and what risks have a high probability of occurring. The results show the efficiency of the proposed method compared to other methods, showing the improvement of software quality and leading developers in their decisions. This new way of developing supervision software helps students identify design problems, evaluate software developed and propose effective solutions. We conclude that the risk management optimizes the development of the industrial process control software and provides higher quality to the product.

Keywords: supervision software, risk management, industrial supervision, project management

Procedia PDF Downloads 355

Authors: Ritsuko Kawasaki (Aiba), Takeshi Hiromatsu

Abstract:

Management is required to understand all information security risks within an organization, and to make decisions on which information security risks should be treated in what level by allocating how much amount of cost. However, such decision-making is not usually easy, because various measures for risk treatment must be selected with the suitable application levels. In addition, some measures may have objectives conflicting with each other. It also makes the selection difficult. Moreover, risks generally have trends and it also should be considered in risk treatment. Therefore, this paper provides the extension of the model proposed in the previous study. The original model supports the selection of measures by applying a combination of weighted average method and goal programming method for multi-objective analysis to find an optimal solution. The extended model includes the notion of weights to the risks, and the larger weight means the priority of the risk.

Keywords: information security risk treatment, selection of risk measures, risk acceptance, multi-objective optimization

Procedia PDF Downloads 461

Authors: Alfred Kamate Siviri, Angelus Mafikiri Tsongo, Jean Robert Kala Kamdjoug

Abstract:

Digitalization and information systems well organized have been selected as relevant measures to mitigate operational risks within organizations. Unfortunately, information system comes with new threats that can cause severe damage and quick organization lockout. This study aims to measure perceived information system risks and their effects on operational risks within the microfinance institution in D.R. Congo. Also, the factors influencing the operational risk are identified, and the link between operational risk with other risks and performance is to be assessed. The study proposes a research model drawn on the combination of Resources-Based-View, dynamic capabilities, the agency theory, the Information System Security Model, and social theories of risk. Therefore, we suggest adopting a mixed methods research with the sole aim of increasing the literature that already exists on perceived operational risk assessment and its link with other risk and performance, a focus on IT risk.

Keywords: Democratic Republic Congo, information system risk, microfinance performance, operational risk

Procedia PDF Downloads 224

Authors: E. Harrer, M. Mauerhofer, T. Werginz

Abstract:

As a result of intensive competition, the building sector is suffering from a high degree of rivalry. Furthermore, there can be observed an unbalanced distribution of project risks. Clients are aimed to shift their own risks into the sphere of the constructors or planners. The consequence of this is that the number of conflicts between the involved parties is inordinately high or even increasing; an alternative approach to counter on that developments are cooperative project forms in the construction sector. This research compares conventional contract models and models with partnering agreements to examine the influence on project risks by an early integration of the involved parties. The goal is to show up deviations in different project stages from the design phase to the project transfer phase. These deviations are evaluated by a survey of experts from the three spheres: clients, contractors and planners. By rating the influence of the participants on specific risk factors it is possible to identify factors which are relevant for a smooth project execution.

Keywords: building projects, contract models, partnering, project risks

Procedia PDF Downloads 274

Authors: Julinda Keçi

Abstract:

In many countries, governments have been promoting the involvement of private sector entities to enter into long-term agreements for the development and delivery of large infrastructure projects, with a focus on overcoming the limitations upon public fund of the traditional approach. The involvement of private sector through public-private partnerships (PPP) brings in new capital investments, value for money and additional risks to handle. Worldwide research studies have shown that an objective, systematic, reliable and user-oriented risk assessment process and an optimal allocation mechanism among different stakeholders is crucial to the successful completion. In this framework this paper, which is the first stage of a research study, aims to identify the main risks for the delivery of PPP projects. A review of cross-countries research projects and case studies was performed to map the key risks affecting PPP infrastructure delivery. The matrix of mapping offers a summary of the frequency of factors, clustered in eleven categories: Construction, Design, Economic, Legal, Market, Natural, Operation, Political, Project finance, Project selection and Relationship. Results will highlight the most critical risk factors, and will hopefully assist the project managers in directing the managerial attention in the further stages of risk allocation.

Keywords: construction, infrastructure, public private partnerships, risks

Procedia PDF Downloads 438

Authors: Ragi Poyyara, V. Vivek, Ashish Khaparde

Abstract:

The Product Development Process (PDP) in the technology group plays a very important role in the launch of any product. While a manufacturing process encourages the use of certain measures to reduce Health, Safety and Environmental (HSE) risks on the shop floor, the PDP concentrates on the use of Geometric Dimensioning and Tolerancing (GD&T) to develop a flawless design. Furthermore, PDP distributes and coordinates activities between different departments such as marketing, purchasing, and manufacturing. However, it is seldom realized that PDP makes a significant contribution to developing a product that reduces HSE risks by encouraging the Technology group to use effective GD&T. The GD&T is a precise communication tool that uses a set of symbols, rules, and definitions to mathematically define parts to be manufactured. It is a quality assurance method widely used in the oil and gas sector. Traditionally it is used to ensure the interchangeability of a part without affecting its form, fit, and function. Parts that do not meet these requirements are rejected during quality audits. This paper discusses how the Technology group integrates this quality assurance tool into the PDP and how the tool plays a major role in helping the HSE department in its goal towards eliminating HSE incidents. The PDP involves a thorough risk assessment and establishes a method to address those risks during the design stage. An illustration shows how GD&T helped reduce safety risks by ergonomically improving assembling operations. A brief discussion explains how tolerances provided on a part help prevent finger injury. This tool has equipped Technology to produce fixtures, which are used daily in operations as well as manufacturing. By applying GD&T to create good fits, HSE risks are mitigated for operating personnel. Both customers and service providers benefit from reduced safety risks.

Keywords: HSE risks, product development process, geometric dimensioning and tolerances, mechanical engineering

Procedia PDF Downloads 226

Authors: J. K. Visser, H. T. Malan

Abstract:

A need exists to identify the sources of risks associated with the process automation systems within petrochemical companies or similar energy related industries. These companies use many different process automation technologies in its value chain. A crucial part of the process automation system is the information technology component featuring in the supervisory control layer. The ever-changing technology within the process automation layers and the rate at which it advances pose a risk to safe and predictable automation system performance. The age of the automation equipment also provides challenges to the operations and maintenance managers of the plant due to obsolescence and unavailability of spare parts. The main objective of this research was to determine the risk sources associated with the equipment that is part of the process automation systems. A secondary objective was to establish whether technology managers and technicians were aware of the risks and share the same viewpoint on the importance of the risks associated with automation systems. A conceptual model for risk sources of automation systems was formulated from models and frameworks in literature. This model comprised six categories of risk which forms the basis for identifying specific risks. This model was used to develop a questionnaire that was sent to 172 instrument technicians and technology managers in the company to obtain primary data. 75 completed and useful responses were received. These responses were analyzed statistically to determine the highest risk sources and to determine whether there was difference in opinion between technology managers and technicians. The most important risks that were revealed in this study are: 1) the lack of skilled technicians, 2) integration capability of third-party system software, 3) reliability of the process automation hardware, 4) excessive costs pertaining to performing maintenance and migrations on process automation systems, and 5) requirements of having third-party communication interfacing compatibility as well as real-time communication networks.

Keywords: distributed control system, identification of risks, information technology, process automation system

Procedia PDF Downloads 139

Authors: Spanova Yerkezhan, Amantay Ayan, Alimzhanova Laura

Abstract:

This article discusses the concept of rebranding and its relationship to cybersecurity. Rebranding is the process of changing the appearance and image of a company or organization in order to appeal to new customers or change the perception of a company. It can be a powerful tool for businesses looking to renew their reputation or expand into new markets. In today's digital age, companies increasingly rely on technology and the internet to conduct business; rebranding can also present significant cybersecurity risks. This is because a rebranding effort can create new vulnerabilities for companies, particularly in terms of their online presence. This article explores the potential hazards associated with rebranding and provides recommendations for mitigating those risks. It also highlights the importance of considering cybersecurity in the rebranding process and how it can be integrated into the overall strategy for a successful and secure rebranding.

Keywords: rebranding, cybersecurity, cyberattack, logo, vulnerability

Procedia PDF Downloads 166

Authors: Emma Carr, Bilal Aslam-Pervez, David Laraway

Abstract:

Litigation against surgeons and hospitals continues to increase in Western countries. While verbal consent is all that is required legally, it has for a long time been considered that written consent offers proof of discussion and interaction between the surgeon and the patient. Inadequate consenting of patients continues in the United Kingdom leaving surgeons and Health Trusts open to litigation. We present a standardised consent form which improves patient autonomy and engagement. The General Medical Council recommends that all material risks relevant to the patient are discussed and recorded prior to undergoing surgery, regardless of how likely they are to occur. Current literature was reviewed to evaluate complications associated with surgical management of mandible fractures. Analysis of risks on 52 consent forms were analysed within the Glasgow OMFS department, leading to a procedure-specific form being designed and implemented. This audit showed that the documentation of risks on consent forms was extremely variable- with uncommon risks not being recorded. Interestingly, not a single consent form was found which highlighted all the risks associated with mandible fractures. Our re-audit data confirms 100% of risks being discussed when a procedure specific form is utilised. Our hope, is to introduce further forms for inclusion on the BAOMS website and peripheral distribution. The forms are quick and easy to print and leave more time for consultation with the patient. Whilst we are under no illusion that the forms may not decrease the incidence of intended litigation, we feel confident that they will decrease the chances of it being successful.

Keywords: consent, litigation, mandible fracture, surgery

Procedia PDF Downloads 188

Authors: Negar Ganjouhaghighi, Amirali Dolatshahi

Abstract:

The origin of most risks of a mega project usually takes place in the phases before closing the contract. As a practical point of view, using project risk management techniques for preparing a proposal is not a total solution for managing the risks of a contract. The objective of this paper is to cover all those activities associated with risk management of a mega project sale’s processes; from entrance to a new market to awarding activities and the review of contract performance. In this study, the risk management happens in six consecutive steps that are divided into three distinct but interdependent phases upstream of the award of the contract: pre-tendering, tendering and closing. In the first step, by preparing standard market risk report, risks of the new market are identified. The next step is the bid or no bid decision making based on the previous gathered data. During the next three steps in tendering phase, project risk management techniques are applied for determining how much contingency reserve must be added or reduced to the estimated cost in order to put the residual risk to an acceptable level. Finally, the last step which happens in closing phase would be an overview of the project risks and final clarification of residual risks. The sales experience of more than 20,000 MW turn-key power plant projects alongside this framework, are used to develop a software that assists the sales team to have a better project risk management.

Keywords: project marketing, risk management, tendering, project management, turn-key projects

Procedia PDF Downloads 329

Authors: Azola Agrienette Mayeza, Madifedile Thasi

Abstract:

Due to the contractual nature of jobs and employment opportunities in the construction industry and the seeming surplus of potential employees in South Africa, there is a little interest on the part of employers to put in place policies to retain experienced workers. Ironically these are the workers that the companies have expended significant resources on, in terms of training and capabilities development. The construction industry has been experiencing high materials wastages and health and safety issues to score very low on the sustainability agenda as regards resources management and safety. This study carried out an assessment of the poor retention of experienced workers in the construction industry on the capacity to deliver sustainable housing in South Africa. It highlights the economic, safety and resources conservation and other benefits accruable from a high retention of key employees to the South African construction industry towards the delivery of sustainable housing. It presents data that strongly support the hypothesis that high turnover of skilled employees as a result of the industry belief of zero incentive to retain employees beyond the contractual period, is responsible for the high wastages of resources in the industry and the safety issues. A high turnover of experienced employees in the construction industry was found to impact on the industry performance in terms of timely, cost effective and quality delivery of construction projects, particularly when measured against the government sustainable housing agenda. It also results in unplanned expenses required to train replacing employees during project executions as well as company goodwill which ultimately has a huge impact on sustainable housing delivery in South Africa.

Keywords: labour turnover, construction industry, sustainable housing, materials wastage, housing delivery, South Africa

Procedia PDF Downloads 370

Authors: Abdelrhman Elagez, Rolla Monib

Abstract:

This empirical study investigates the observed risks associated with adopting Artificial Intelligence (AI) technologies in the construction industry and proposes potential mitigation strategies. While AI has transformed several industries, the construction industry is slowly adopting advanced technologies like AI, introducing new risks that lack critical analysis in the current literature. A comprehensive literature review identified a research gap, highlighting the lack of critical analysis of risks and the need for a framework to measure and mitigate the risks of AI implementation in the construction industry. Consequently, an online survey was conducted with 24 project managers and construction professionals, possessing experience ranging from 1 to 30 years (with an average of 6.38 years), to gather industry perspectives and concerns relating to AI integration. The survey results yielded several significant findings. Firstly, respondents exhibited a moderate level of familiarity (66.67%) with AI technologies, while the industry's readiness for AI deployment and current usage rates remained low at 2.72 out of 5. Secondly, the top-ranked barriers to AI adoption were identified as lack of awareness, insufficient knowledge and skills, data quality concerns, high implementation costs, absence of prior case studies, and the uncertainty of outcomes. Thirdly, the most significant risks associated with AI use in construction were perceived to be a lack of human control (decision-making), accountability, algorithm bias, data security/privacy, and lack of legislation and regulations. Additionally, the participants acknowledged the value of factors such as education, training, organizational support, and communication in facilitating AI integration within the industry. These findings emphasize the necessity for tailored risk assessment frameworks, guidelines, and governance principles to address the identified risks and promote the responsible adoption of AI technologies in the construction sector.

Keywords: risk management, construction, artificial intelligence, technology

Procedia PDF Downloads 98

Authors: Yousef S. Al-Othman

Abstract:

The growth and expansion of the industrial facilities comes proportional to the market increasing demand of products and services. Furthermore, raw material producers such as oil companies usually undergo massive revamping projects to maintain a synchronized supply. These revamping projects are usually delivered through challenging construction projects held and associated with daily site risks related to the construction process. Henceforth, a case study related to these risks and corresponding on-spot corrective measurements has been made on a certain number of construction project contractors at Kuwait Oil Company (KOC) to derive the benefits and overall effectiveness of the on-spot corrective measurements during the construction phase of a project, and how would the same help in avoiding major incidents, ensuring a smooth, cost effective and on time delivery of the project. Findings of this case study shall have an added value to the overall risk management process by minimizing the daily site risks that may affect the project lead time, resulting in an undisturbed on-site construction process.

Keywords: oil and gas, risk management, construction projects, project lead time

Procedia PDF Downloads 107

Authors: Onyekachi Onwudike, Russell Lock, Iain Phillips

Abstract:

The variability that exists across governments, her departments and the provisioning of services has been areas of concern in the E-Government domain. There is a need for reuse and integration across government departments which are accompanied by varying degrees of risks and threats. There is also the need for assessment, prevention, preparation, response and recovery when dealing with these risks or threats. The ability of a government to cope with the emerging changes that occur within it is known as resilience. In order to forge ahead with concerted efforts to manage reuse and integration induced risks or threats to governments, the ambiguities contained within resilience must be addressed. Enhancing resilience in the E-Government domain is synonymous with reducing risks governments face with provisioning of services as well as reuse of components across departments. Therefore, it can be said that resilience is responsible for the reduction in government’s vulnerability to changes. In this paper, we present the use of the ontology to measure the resilience of governments. This ontology is made up of a well-defined construct for the taxonomy of resilience. A specific class known as ‘Resilience Requirements’ is added to the ontology. This class embraces the concept of resilience into the E-Government domain ontology. Considering that the E-Government domain is a highly complex one made up of different departments offering different services, the reliability and resilience of the E-Government domain have become more complex and critical to understand. We present questions that can help a government access how prepared they are in the face of risks and what steps can be taken to recover from them. These questions can be asked with the use of queries. The ontology focuses on developing a case study section that is used to explore ways in which government departments can become resilient to the different kinds of risks and threats they may face. A collection of resilience tools and resources have been developed in our ontology to encourage governments to take steps to prepare for emergencies and risks that a government may face with the integration of departments and reuse of components across government departments. To achieve this, the ontology has been extended by rules. We present two tools for understanding resilience in the E-Government domain as a risk analysis target and the output of these tools when applied to resilience in the E-Government domain. We introduce the classification of resilience using the defined taxonomy and modelling of existent relationships based on the defined taxonomy. The ontology is constructed on formal theory and it provides a semantic reference framework for the concept of resilience. Key terms which fall under the purview of resilience with respect to E-Governments are defined. Terms are made explicit and the relationships that exist between risks and resilience are made explicit. The overall aim of the ontology is to use it within standards that would be followed by all governments for government-based resilience measures.

Keywords: E-Government, Ontology, Relationships, Resilience, Risks, Threats

Procedia PDF Downloads 337

Authors: Elisabeth Maidl

Abstract:

The interdependence of climate change and natural hazard goes along with large uncertainties regarding future risks. Regional stakeholders, experts in natural hazards management and scientists have specific knowledge, resp. mental models on such risks. This diversity of views makes it difficult to find common and broadly accepted prevention measures. If the specific knowledge of these types of actors is shared in an interactive knowledge production process, this enables a broader and common understanding of complex risks and allows to agree on long-term solution strategies. Previous studies on mental models confirm that actors with specific vulnerabilities perceive different aspects of a topic and accordingly prefer different measures. In bringing these perspectives together, there is the potential to reduce uncertainty and to close blind spots in solution finding. However, studies that examine the mental models of regional actors on future concrete mass movement risks are lacking so far. The project tests and evaluates the feasibility of knowledge co-creation for the anticipatory prevention of climate change-induced mass movement risks in the Alps. As a key element, mental models of the three included groups of actors are compared. Being integrated into the research program Climate Change Impacts on Alpine Mass Movements (CCAMM2), this project is carried out in two Swiss mountain regions. The project is structured in four phases: 1) the preparatory phase, in which the participants are identified, 2) the baseline phase, in which qualitative interviews and a quantitative pre-survey are conducted with actors 3) the knowledge-co-creation phase, in which actors have a moderated exchange meeting, and a participatory modelling workshop on specific risks in the region, and 4) finally a public information event. Results show that participants' mental models are based on the place of origin, profession, believes, values, which results in narratives on climate change and hazard risks. Further, the more intensively participants interact with each other, the more likely is that they change their views. This provides empirical evidence on how changes in opinions and mindsets can be induced and fostered.

Keywords: climate change, knowledge-co-creation, participatory process, natural hazard risks

Procedia PDF Downloads 69

Authors: G. A. Gevorgyan, K. A. Ghazaryan, T. H. Derdzyan

Abstract:

The heavy metal pollution of the soils around the mining area near Shamlugh town and related risks to human health were assessed. The investigations showed that the soils were polluted with heavy metals that can be ranked by anthropogenic pollution degree as follows: Cu>Pb>As>Co>Ni>Zn. The main sources of the anthropogenic metal pollution of the soils were the copper mining area near Shamlugh town, the Chochkan tailings storage facility and the trucks transferring are from the mining area. Copper pollution degree in some observation sites was unallowable for agricultural production. The total non-carcinogenic chronic hazard index (THI) values in some places, including observation sites in Shamlugh town, were above the safe level (THI<1) for children living in this territory. Although the highest heavy metal enrichment degree in the soils was registered in case of copper, the highest health risks to humans especially children were posed by cobalt which is explained by the fact that heavy metals have different toxicity levels and penetration characteristics.

Keywords: Armenia, copper mine, heavy metal pollution of soil, health risks

Procedia PDF Downloads 416

Authors: C. V. Pietreanu, S. E. Zaharia, C. Dinu

Abstract:

Hazard assessment and risks quantification are key components for estimating the impact of existing regulations. But since regulatory compliance cannot cover all risks in aviation, the authors point out that by studying causal factors and eliminating uncertainty, an accurate analysis can be outlined. The research debuts by making delimitations on notions, as confusion on the terms over time has reflected in less rigorous analysis. Throughout this paper, it will be emphasized the fact that the variation in human performance and organizational factors represent the biggest threat from an operational perspective. Therefore, advanced risk assessment methods analyzed by the authors aim to understand vulnerabilities of the system given by a nonlinear behavior. Ultimately, the mathematical modeling of existing hazards and risks by eliminating uncertainty implies establishing an optimal solution (i.e. risk minimization).

Keywords: control, human factor, optimization, risk management, uncertainty

Procedia PDF Downloads 249

Authors: Jingwen Shi, Qi Wu

Abstract:

We study the role played interest rate risk in carry trade return in order to understand the forward premium puzzle. In this study, our goal is to investigate to what extent carry trade return is indeed due to compensation for risk taking and, more important, to reveal the nature of these risks. Using option data not only on exchange rates but also on interest rate swaps (swaptions), our first finding is that, besides the consensus currency risks, interest rate risks also contribute a non-negligible portion to the carry trade return. What strikes us is our second finding. We find that large downside risks of future exchange rate movements are, in fact, priced significantly in option market on interest rates. The role played by interest rate risk differs structurally from the currency risk. There is a unique premium associated with interest rate risk, though seemingly small in size, which compensates the tail risks, the left tail to be precise. On the technical front, our study relies on accurately retrieving implied distributions from currency options and interest rate swaptions simultaneously, especially the tail components of the two. For this purpose, our major modeling work is to build a new international asset pricing model where we use an orthogonal setup for pricing kernels and specify non-Gaussian dynamics in order to capture three sets of option skew accurately and consistently across currency options and interest rate swaptions, domestic and foreign, within one model. Our results open a door for studying forward premium anomaly through implied information from interest rate derivative market.

Keywords: carry trade, forward premium anomaly, FX option, interest rate swaption, implied volatility skew, uncovered interest rate parity

Procedia PDF Downloads 445

Authors: Bruno Valverde Chahaira, Matheus Jeronimo Low Lopes, Marta Beatriz Tanaka Ferdinandi

Abstract:

This paper proposes to dissect the meanings and / or directions of the State, in order, to present the State models to elaborate a conceptual framework about its function in the legal scope. To do so, it points out the possible contracts established between the State and the Society, since the general principles immanent in them can guide the models of society in force. From this orientation arise the contracts, whose purpose is by the effect to modify the status (the being and / or the opinion) of each of the subjects in presence - State and Society. In this logic, this paper announces the fiduciary contracts and “veredicção”(portuguese word) contracts, from the perspective of semiotics discourse (or greimasian). Therefore, studies focus on the issue of manifest language in unilateral and bilateral or reciprocal relations between the State and Society. Thus, under the biases of the model of the communicative situation and discourse, the guidelines of these contractual relations will be analyzed in order to see if there is a pragmatic sanction: positive when the contract is signed between the subjects (reward), or negative when the contract between they are broken (punishment). In this way, a third path emerges which, in this specific case, passes through the subject-third sector. In other words, the proposal, which is systemic in nature, is to analyze whether, since the contract of the welfare state is not carried out in the constitutional program on fundamental rights: education, health, housing, an others. Therefore, in the structure of the exchange demanded by the society according to its contractual obligations (others), the third way (Third Sector) advances in the empty space left by the State. In this line, it presents the modalities of action of the third sector in the social scope. Finally, the normative communication organization of these three subjects is sought in the pragmatic model of discourse, namely: State, Society and Third Sector, in an attempt to understand the constant dynamics in the Law and in the language of the relations established between them.

Keywords: access to justice, state, social rights, third sector

Procedia PDF Downloads 145