Search results for: transport projects

Authors: Sunaitan Al Mutairi

Abstract:

A perfect start is a key factor for project completion on time. The study examined the effects of delayed mobilization of resources during the initial phases of the project. This paper mainly highlights the identification and categorization of all delays during the initial construction phase and their root cause analysis with corrective/control measures for the Kuwait Oil Company oil and gas projects. A relatively good percentage of the delays identified during the project execution (Contract award to end of defects liability period) attributed to mobilization/preliminary activity delays. Data analysis demonstrated significant increase in average project delay during the last five years compared to the previous period. Contractors had delays/issues during the initial phase, which resulted in slippages and progressively increased, resulting in time and cost overrun. Delays/issues not mitigated on time during the initial phase had very high impact on project completion. Data analysis of the delays for the past five years was carried out using trend chart, scatter plot, process map, box plot, relative importance index and Pareto chart. Construction of any project inside the Gathering Centers involves complex management skills related to work force, materials, plant, machineries, new technologies etc. Delay affects completion of projects and compromises quality, schedule and budget of project deliverables. Works executed as per plan during the initial phase and start-up duration of the project construction activities resulted in minor slippages/delays in project completion. In addition, there was a good working environment between client and contractor resulting in better project execution and management. Mainly, the contractor was on the front foot in the execution of projects, which had minimum/no delays during the initial and construction period. Hence, having a perfect start during the initial construction phase shall have a positive influence on the project success. Our research paper studies each type of delay with some real example supported by statistic results and suggests mitigation measures. Detailed analysis carried out with all stakeholders based on impact and occurrence of delays to have a practical and effective outcome to mitigate the delays. The key to improvement is to have proper control measures and periodic evaluation/audit to ensure implementation of the mitigation measures. The focus of this research is to reduce the delays encountered during the initial construction phase of the project life cycle.

Keywords: construction activities delays, delay analysis for construction projects, mobilization delays, oil & gas projects delays

Procedia PDF Downloads 312

Authors: Adinarayana Badveeti, Mohammad Shafi Mir

Abstract:

In Srinagar City, in India, traffic congestion is a condition on transport networks that occurs as use increases and is characterized by slower speeds, longer trip times, and increased vehicular queuing. Traffic congestion is conventionally measured using indicators such as roadway level-of-service, the Travel Time Index and their variants. Several measures have been taken in order to counteract congestion like road pricing, car pooling, improved traffic management, etc. While new road construction can temporarily relieve congestion in the longer term, it simply encourages further growth in car traffic through increased travel and a switch away from public transport. The full paper report, on which this abstract is based, aims to provide policymakers and technical staff with the real-time data, conceptual framework and guidance on some of the engineering tools necessary to manage congestion in such a way as to reduce its overall impact on individuals, families, communities, and societies dynamic, affordable, liveable and attractive urban regions will never be free of congestion. Road transport policies, however, should seek to manage congestion on a cost-effective basis with the aim of reducing the burden that excessive congestion imposes upon travellers and urban dwellers throughout the urban road network.

Keywords: traffic congestion, modeling, traffic management, travel time index

Procedia PDF Downloads 310

Authors: Olivia Kurucz

Abstract:

Gamification is one of the outstanding new methodological possibilities of urban public participation processes to make the most informed decision possible for the future steps of urban development. This paper examines four Hungarian experimental projects in which gamified tools were applied during the public participation progresses by the Urban Future Laboratory (UFLab) research workshop of Budapest University of Technology and Economics (BUTE). The recently implemented future planning projects (in the cities of Pécel, Kistarcsa, Budapest, and Salgótarján) were initiated by various motives, but the multi-stakeholder dialogues were facilitated through physical gamified tools in all cases. Based on the urban gamification hypothesis, the use of gamified tools supported certain steps of participatory processes in several aspects: it helped to increase the attractiveness of public events, to create a more informal atmosphere, to ensure equal conditions for actors, to recall a design mindset, to bridge contrasting social or cultural differences, to fix opinions and to assist dialogue between city actors, designers, and residents. This statement is confirmed by assessing the applied tools, analyzing the case studies, and comparing them to perceive their effects and interrelations.

Keywords: experimental projects, future planning, gamification, gamified tools, Hungary, public participation, UFLab, urban gamification

Procedia PDF Downloads 131

Authors: Jimmy L. Caldoza, Erlito M. Albina

Abstract:

Information Systems are increasingly being used to monitor and assess government projects as well as improve transparency and combat corruption. With reference to existing information systems relevant to monitoring and evaluation systems adopted by various government agencies from other countries, this research paper aims to help the Philippine government, particularly the Department of Agriculture, in assessing the impact of their programs and projects on their target beneficiaries through the development of the web-based Monitoring and Evaluation Information System with the application of a short messaging system (sms) technology.

Keywords: monitoring and evaluation system, web-based information system, short messaging system technology, database structure and management

Procedia PDF Downloads 132

Authors: Ahmed Kiani

Abstract:

The United Arab Emirates is clearly facing a multitude of challenges in curbing its greenhouse gas emissions to meet its pre-allotted framework of Kyoto protocol and COP21 targets due to its hunger for modernization, industrialization, infrastructure growth, soaring population and oil and gas activity. In this work, we focus on the bonafide zero emission electric vehicles market penetration in the country’s transport industry for emission reduction. We study the global electric vehicle market trends, the complementary battery technologies and the trends by manufacturers, emission standards across borders and prioritized advancements which will ultimately dictate the terms of future conditions for the United Arab Emirate transport industry. Based on our findings and analysis at every stage of current viability and state-of-transport-affairs, we postulate policy recommendations to local governmental entities from a supply and demand perspective covering aspects of technology, infrastructure requirements, change in power dynamics, end user incentives program, market regulators behavior and communications amongst key stakeholders. 

Keywords: electric vehicles, greenhouse gas emission reductions, market analysis, policy recommendations

Procedia PDF Downloads 305

Authors: Gopinath Rathod, Vinod Puranik

Abstract:

Sustainability is regarded as a key concept for survival in the competitive scenario. Industrial risk and diversification of risk type’s increases with industrial developments. In the context of sustainable manufacturing, the evaluation of risk is difficult because of the incomplete information and multiple indicators. Fuzzy Multiple Attribute Decision Method (FMADM) has been used with a three level hierarchical decision making model to evaluate aggregate risk for sustainable manufacturing projects. A case study has been presented to reflect the risk characteristics in sustainable manufacturing projects.

Keywords: sustainable manufacturing, decision making, aggregate risk, fuzzy logic, fuzzy multiple attribute decision method

Procedia PDF Downloads 512

Authors: Fatemeh Daneshvartarigh

Abstract:

New technologies and applications have radically altered construction techniques in recent years. In order to anticipate how the building will act, perform, and appear, these technologies encompass a wide range of visualization, simulation, and analytic tools. These new technologies and applications have a considerable impact on completing construction projects in today's (architecture, engineering and construction)AEC industries. The rate of changes in BIM-related topics is different worldwide, and it depends on many factors, e.g., the national policies of each country. Therefore, there is a need for comprehensive research focused on a specific area with common characteristics. Therefore, one of the necessary measures to increase the use of this new approach is to examine the challenges and obstacles facing it. In this research, based on the Delphi method, at first, the background and related literature are reviewed. Then, using the knowledge obtained from the literature, a primary questionnaire is generated and filled by experts who are selected using snowball sampling. It covered the experts' attitudes towards implementing BIM in renovation projects and their view of the benefits and obstacles in this regard. By analyzing the primary questionnaire, the second group of experts is selected among the participants to be interviewed. The results are analyzed using Theme analysis. Six themes, including Management support, staff resistance, client willingness, Cost of software and implementation, the difficulty of implementation, and other reasons, are obtained. Then a final questionnaire is generated from the themes and filled by the same group of experts. The result is analyzed by the Fuzzy Delphi method, showing the exact ranking of the obtained themes. The final results show that management support, staff resistance, and client willingness are the most critical barrier to BIM usage in renovation projects.

Keywords: building information modeling, BIM, BIM implementation, BIM barriers, BIM in renovation

Procedia PDF Downloads 156

Authors: Francisco J. Arias

Abstract:

Consideration is given to a mechanism of heat and mass transport in solutions similar than that of natural convection but with one important difference. Here the mechanism is not promoted by density differences in the fluid occurring due to temperature gradients (coefficient of thermal expansion) but rather by solubility differences due to the thermal dependence of the solubility (coefficient of thermal solubility). Utilizing a simplified physical model, it is shown that by the proper choice of the concentration of a given solution, convection might be induced by the alternating precipitation of the solute -when the solution becomes supersaturated, and its posterior recombination when changes in temperature occurs. The spontaneous change in the Gibbs free energy during the mixing is the driven force for the mechanism. The maximum extractable energy from this new type of thermal convection was derived. Experimental data from a closed-loop circuit was obtained demonstrating the feasibility for continuous separation and recombination of the solution. This type of heat and mass transport -which doesn’t depend on gravity, might potentially be interesting for heat and mass transport downwards (as in solar-roof collectors to inside homes), horizontal (e.g., microelectronic applications), and in microgravity (space technology). Also, because the coefficient of thermal solubility could be positive or negative, the investigated thermo-osmosis convection can be used either for heating or cooling.

Keywords: natural convection, thermal gradient, solubility, osmotic pressure

Procedia PDF Downloads 288

Authors: Lin Zhang

Abstract:

Neighborhood redevelopment is vital to improve residents’ living environment, and there has been a national neighborhood micro-redevelopment initiative in China since 2020, which is largely different from the previous large-scale demolition and reconstruction projects. Yet, few studies systematically examine the new interactions of multiple actors in this initiative. China’s neighborhood (micro-) redevelopment is a kind of governance network, and the complexity perspective could reflect the dynamic nature of multiple actors and their relationships in governance networks. In order to better understand the fundamental shifts of governance networks in China’s neighborhood micro-redevelopment, this paper adopted a theoretical framework of complexity in governance networks and analyzed the new governance networks of neighborhood micro-redevelopment projects in Haikou accordingly.

Keywords: neighborhood redevelopment, governance, networks, Haikou

Procedia PDF Downloads 81

Authors: Jerome Blackman, Pamela Franklin, Volha Roshchanka

Abstract:

The US coal mining sector accounts for 6% of total US Methane emissions (2021). 60% of US coal mining methane emissions come from active underground mine ventilation systems. Abandoned mines contribute about 13% of methane emissions from coal mining. While there are thousands of abandoned underground coal mines in the US, the Environmental Protection Agency (EPA) estimates that fewer than 100 have sufficient methane resources for viable methane recovery and use projects. Many abandoned mines are in remote areas far from potential energy customers and may be flooded, further complicating methane recovery. Because these mines are no longer active, recovery projects can be simpler to implement.

Keywords: abandoned mines, coal mine methane, coal mining, methane emissions, methane mitigation, recovery and use

Procedia PDF Downloads 71

Authors: Emmanuel U. Unuafe, Oyegoke T. Bukoye, Sandhya Sastry, Yanqing Duan

Abstract:

Globally, there is increasing interest in project management due to a shortage in infrastructure services supply capability. Hence, it is of utmost importance that organisations understand that choosing a particular project over another is an opportunity cost – tying up the organisations resources. In order to devise constructive ways to bring direction, structure, and oversight to the process of project selection has led to the development of tools and techniques by researchers and practitioners. However, despite the development of various frameworks to assist in the appraisal and selection of government projects, failures are still being recorded with government projects. In developing countries, where frameworks are rarely used, the problems are compounded. To improve the situation, this study will investigate the current practice of construction project selection processes within the Nigeria public sector in order to inform theories of decision making from the perspective of developing nations and project management practice. Unlike other research around construction projects in Nigeria this research concentrate on factors influencing the selection process within the Nigeria public sector, which has received limited study. The authors report the findings of semi-structured interviews of top management in the Nigerian public sector and draw conclusions in terms of decision making extant theory and current practice. Preliminary results from the data analysis show that groups make project selection decisions and this forces sub-optimal decisions due to pressure on time, clashes of interest, lack of standardised framework for selecting projects, lack of accountability and poor leadership. Consequently, because decision maker is usually drawn from different fields, religious beliefs, ethnic group and with different languages. The choice of a project by an individual will be greatly influence by experience, political precedence than by realistic investigation as well as his understanding of the desired outcome of the project, in other words, the individual’s ideology and their level of fairness.

Keywords: factors influencing project selection, public sector construction project selection, projects portfolio selection, strategic decision-making

Procedia PDF Downloads 325

Authors: Abubakar Mohammed Bakoji

Abstract:

The paper examine business ethics through it pursuit for corporate social responsibility to the society in which the business long existed, Zenith bank PLC was selected as case study for it longer period of its business in the state, in order to achieve the research objective of the paper which sought the following: i. To examine relationship between business ethics and corporate social responsibility in Zenith bank PLC Jalingo; ii. To establish whether or not such ethics statement that acclaim corporate social responsibility are adhere to by the Zenith bank PLC Jalingo; iii. To determine the benefit drive by the society on the corporate social responsibility of Zenith bank PLC Jalingo to the people of the state of their operation. The research was conducted using qualitative research design approach, where convenience sampling technique was adopted using semi structured interview to one of the key staff of Zenith bank PLC Jalingo and five other beneficiaries of Zenith bank PLC corporate social responsibility projects served as respondents. The data obtained was analyze using content analysis and the result of the findings revealed that Zenith bank PLC has a Good business ethics and they adhere to the ethics, that they have completed several viable projects to the state as their corporate social responsibility and the beneficiaries and the respondents beneficiaries has confirmed and have produced evidence of how the projects has assisted in stifle their hardship. Hence, business ethics has a significant relationship with corporate social responsibility in Zenith bank PLC Jalingo.

Keywords: business ethics, Corporate Social Responsibility, Zenith Bank PLC, business ethics

Procedia PDF Downloads 460

Authors: Agnieszka Misztal

Abstract:

The popularity of the quality management system models continues to grow despite the transitional crisis in 2008. Their development is associated with the demands of the new requirements for entrepreneurs, such as risk analysis projects and more emphasis on supervision of outsourced processes. In parallel appropriate to focus attention on the selection of companies aspiring to quality management system. This is particularly important in the automotive supplier industry, where requirements transferred to the levels in the supply chain should be clear, transparent and fairly satisfied. The author has carried out series of researches aimed at finding the factors that allow for the effective implementation of the quality management system in automotive companies. The research was focused on four groups of companies: 1) manufacturing (parts and assemblies for the purpose of sale or for vehicle manufacturers), 2) service (repair and maintenance of the car), 3) services for the transport of goods or people, 4) commercial (auto parts and vehicles). Identified determinants were divided in two types of criteria into: internal and external, as well as: hard and soft. The article presents hard - technical factors that automotive company must meet in order to achieve the goal of the quality management system implementation.

Keywords: automotive industry, quality management system, automotive technology, automotive company

Procedia PDF Downloads 394

Authors: Ouafa Sakka, Henri Barki, Louise Cote

Abstract:

Uncertainty and equivocality are defined in the information processing literature as two task characteristics that require different information processing responses from managers. As uncertainty often stems from a lack of information, addressing it is thought to require the collection of additional data. On the other hand, as equivocality stems from ambiguity and a lack of understanding of the task at hand, addressing it is thought to require rich communication between those involved. Past research has provided weak to moderate empirical support to these hypotheses. The present study contributes to this literature by defining uncertainty and equivocality at the project level and investigating their moderating effects on the association between several project information processing constructs and project performance. The information processing constructs considered are the amount of information collected by the project team, and the richness and frequency of formal communications among the team members to discuss the project’s follow-up reports. Data on 93 information system development (ISD) project managers was collected in a questionnaire survey and analyzed it via the Fisher Test for correlation differences. The results indicate that the highest project performance levels were observed in projects characterized by high uncertainty and low equivocality in which project managers were provided with detailed and updated information on project costs and schedules. In addition, our findings show that information about user needs and technical aspects of the project is less useful to managing projects where uncertainty and equivocality are high. Further, while the strongest positive effect of interactive use of follow-up reports on performance occurred in projects where both uncertainty and equivocality levels were high, its weakest effect occurred when both of these were low.

Keywords: uncertainty, equivocality, information processing model, management control systems, project control, interactive use, diagnostic use, information system development

Procedia PDF Downloads 286

Authors: Nirali Shukla, Neel Shah

Abstract:

The World Bank Institute (WBI) is undertaking a review of government interventions aimed at facilitating sustainable investment in public private partnerships (PPPs) in various under developed countries. The study presents best practice for applying financial model to make PPPs financially viable. The lessons presented here, if properly implemented, can help countries use limited funds to attract more private investment, get more infrastructure built and, as a result, achieve greater economic growth. The four countries Brazil, Colombia, Mexico, and India in total develop an average of nearly US$50 billion in PPPs per year. There are a range of policies and institutional arrangements governments use to provide subsidies to PPPs. For example, some countries have created dedicated agencies, or ‘funds’, capitalized with money from the national budget to manage and allocate subsidies. Other countries have established well-defined policies for appropriating subsidies on an ad hoc basis through an annual budget process. In this context, subsidies are direct fiscal contributions or grants paid by the government to a project when revenues from user fees are insufficient to cover all capital and operating costs while still providing private investors with a reasonable rate of return. Without subsidies, some infrastructure projects that would provide economic or social gains, but are not financially viable, would go undeveloped. But the Financial model of BOLT (PPP) model described in this study suggests that it is most feasible option rather than going for subsidy schemes for making infrastructure projects financially viable. The major advantage for implementing this model is the government money is saved and can be used for other projects as well as the private investors are getting better rate of return than subsidized schemes.

Keywords: PPP, BOLT, subsidy schemes, financial model

Procedia PDF Downloads 746

Authors: Zhaopeng Zhu, Xianzhi Song, Gensheng Li

Abstract:

Transports of solid particles through the drill pipe, drill string-hole annulus and hydraulically generated fractures are important dynamic processes encountered in oil and gas well drilling and completion operations. Different from particle transport in infinite space, the transports of cuttings, proppants and formation sand are hindered by a finite boundary. Therefore, an accurate description of the particle transport behavior under the bounded wall conditions encountered in drilling and hydraulic fracturing operations is needed to improve drilling safety and efficiency. In this study, the particle settling experiments were carried out to investigate the particle settling behavior in the pipe, annulus and between the parallel plates filled with power-law fluids. Experimental conditions simulated the particle Reynolds number ranges of 0.01-123.87, the dimensionless diameter ranges of 0.20-0.80 and the fluid flow behavior index ranges of 0.48-0.69. Firstly, the wall effect of the annulus is revealed by analyzing the settling process of the particles in the annular geometry with variable inner pipe diameter. Then, the geometric continuity among the pipe, annulus and parallel plates was determined by introducing the ratio of inner diameter to an outer diameter of the annulus. Further, a unified dimensionless diameter was defined to confirm the relationship between the three different geometry in terms of the wall effect. In addition, a dimensionless term independent from the settling velocity was introduced to establish a unified explicit settling velocity model applicable to pipes, annulus and fractures with a mean relative error of 8.71%. An example case study was provided to demonstrate the application of the unified model for predicting particle settling velocity. This paper is the first study of annulus wall effects based on the geometric continuity concept and the unified model presented here will provide theoretical guidance for improved hydraulic design of cuttings transport, proppant placement and sand management operations.

Keywords: wall effect, particle settling velocity, cuttings transport, proppant transport in fracture

Procedia PDF Downloads 156

Authors: Hasan Taştan, Ayşen Ciravoğlu

Abstract:

The rapid growth of the human population and the environmental degradation associated with increased consumption of resources raises concerns on sustainability. Social sustainability constitutes one of the three dimensions of sustainability together with environmental and economic dimensions. Even though there is not an agreement on what social sustainability consists of, it is a well known fact that it necessitates user participation. The fore, this study aims to observe and analyze the role of user participation on social sustainability. In this paper, the links between user participation and indicators of social sustainability have been searched. In order to achieve this, first of all a literature review on social sustainability has been done; accordingly, the information obtained from researches has been used in the evaluation of the projects conducted in the developing countries considering user participation. These examples are taken as role models with pros and cons for the development of the checklist for the evaluation of the case studies. Furthermore, a case study over the post earthquake residential settlements in Turkey have been conducted. The case study projects are selected considering different building scales (differing number of residential units), scale of the problem (post-earthquake settlements, rehabilitation of shanty dwellings) and the variety of users (differing socio-economic dimensions). Decisionmaking, design, building and usage processes of the selected projects and actors of these processes have been investigated in the context of social sustainability. The cases include: New Gourna Village by Hassan Fathy, Quinta Monroy dwelling units conducted in Chile by Alejandro Aravena and Beyköy and Beriköy projects in Turkey aiming to solve the problem of housing which have appeared after the earthquake happened in 1999 have been investigated. Results of the study possible links between social sustainability indicators and user participation and links between user participation and the peculiarities of place. Results are compared and discussed in order to find possible solutions to form social sustainability through user participation. Results show that social sustainability issues depend on communities' characteristics, socio-economic conditions and user profile but user participation has positive effects on some social sustainability indicators like user satisfaction, a sense of belonging and social stability.

Keywords: housing projects, residential areas, social sustainability, user participation

Procedia PDF Downloads 384

Authors: R. M. Rajapaksa

Abstract:

Construction industry is one of the key players in driving the economy of a country to achieve its prosperity. However, a dispute is one of the crucial factors which prevent the completion of construction contracts within the budgeted cost, scheduled time, and accepted quality. Disputes are inevitable in the construction contract. Accordingly, a study has been undertaken to identify the factors affecting contractual disputes in construction projects in Sri Lanka. The study was a mixed approach with major qualitative and minor quantitative. Qualitative study was set in the form of in-depth interviews with eighteen participants, and quantitative study was conducted using a questionnaire with twenty-four respondents from previously implemented projects by the National Water Supply & Drainage Board representing the employer, engineer and the Contractor to identify the factors affecting contractual disputes and to verify most critical factors respectively. Data analysis for qualitative and quantitative studies was carried out by means of transcribing, code & categorizeand average score methods, respectively. The study reveals that there are forty factors affecting the contractual disputes in construction contracts in Sri Lanka. The finding further illustrates that conflicting decisions by inexperience personnel in the higher position of the Employer, ambiguities resulting inadequate descriptions of the preliminary/general items in price schedule, unfair valuation and late confirmation of variations, unfair determination due to lack of experience of the Engineer/Consultant, under certification of progress payments, unfair grant of EOT & application of delay damages, unreasonable claims for variation of works, errors/discrepancies/ambiguities in the contract conditions and discrepancies & errors in designs & specifications are the most critical factors affecting contractual disputes. Finally, the study proposed remedial measures to most critical factors affecting contractual disputes.

Keywords: dispute, contractual, factors, employer, engineer, contractor, construction projects

Procedia PDF Downloads 207

Authors: Aftab Hameed Memon, Shadab Noor, Muhammad Akram Akhund

Abstract:

Lean construction is a philosophy adopted in the construction industry to increase the value of a project by reducing waste and improving construction productivity. Lean emphasizes on maximizing the value of a project with less expenditure. Globally, lean philosophy has received wider popularity in construction sector. Lean construction has supported the practitioners with several tools and techniques to implement at various stages of a construction project. Following the global trends, this study has investigated the lean practice in Pakistan. The level of implementation of different lean tools and techniques altogether with potential benefits experienced by its implementation in construction projects of Pakistan is analyzed. To achieve the targets, the opinion was sought by the practitioners involved in handling construction projects representing four stakeholders that are a client, consultant, contractors and material suppliers through a structured questionnaire. A total of 34 completed questionnaires were collected and then statistically analyzed. The findings of the analysis have highlighted that pull approach, work standardization, just in time, increase visualization tools, integrated project delivery method and fail-safe for quality are common lean techniques implemented in the local construction industry. While reduction in waste, client’s satisfaction, improved communication, visual control and proper task management are major benefits of the lean construction application.

Keywords: lean construction, lean tools and techniques, lean benefits, waste reduction, Pakistan

Procedia PDF Downloads 284

Authors: Ross Calvert, Colin Whittaker, Alison Raby, Alistair G. L. Borthwick, Ton S. van den Bremer

Abstract:

Large concentrations of plastic have polluted the seas in the last half century, with harmful effects on marine wildlife and potentially to human health. Plastic pollution will have lasting effects because it is expected to take hundreds or thousands of years for plastic to decay in the ocean. The question arises how waves transport plastic in the ocean. The predominant motion induced by waves creates ellipsoid orbits. However, these orbits do not close, resulting in a drift. This is defined as Stokes drift. If a particle is infinitesimally small and the same density as water, it will behave exactly as the water does, i.e., as a purely Lagrangian tracer. However, as the particle grows in size or changes density, it will behave differently. The particle will then have its own inertia, the fluid will exert drag on the particle, because there is relative velocity, and it will rise or sink depending on the density and whether it is on the free surface. Previously, plastic pollution has all been considered to be purely Lagrangian. However, the steepness of waves in the ocean is small, normally about α = k₀a = 0.1 (where k₀ is the wavenumber and a is the wave amplitude), this means that the mean drift flows are of the order of ten times smaller than the oscillatory velocities (Stokes drift is proportional to steepness squared, whilst the oscillatory velocities are proportional to the steepness). Thus, the particle motion must have the forces of the full motion, oscillatory and mean flow, as well as a dynamic buoyancy term to account for the free surface, to determine whether inertia is important. To track the motion of a floating inertial particle under wave action requires the fluid velocities, which form the forcing, and the full equations of motion of a particle to be solved. Starting with the equation of motion of a sphere in unsteady flow with viscous drag. Terms can added then be added to the equation of motion to better model floating plastic: a dynamic buoyancy to model a particle floating on the free surface, quadratic drag for larger particles and a slope sliding term. Using perturbation methods to order the equation of motion into sequentially solvable parts allows a parametric equation for the transport of inertial finite-sized floating particles to be derived. This parametric equation can then be validated using numerical simulations of the equation of motion and flume experiments. This paper presents a parametric equation for the transport of inertial floating finite-size particles by ocean waves. The equation shows an increase in Stokes drift for larger, less dense particles. The equation has been validated using numerical solutions of the equation of motion and laboratory flume experiments. The difference in the particle transport equation and a purely Lagrangian tracer is illustrated using worlds maps of the induced transport. This parametric transport equation would allow ocean-scale numerical models to include inertial effects of floating plastic when predicting or tracing the transport of pollutants.

Keywords: perturbation methods, plastic pollution transport, Stokes drift, wave flume experiments, wave-induced mean flow

Procedia PDF Downloads 112

Authors: Tina Melkoshvili

Abstract:

Drastic development of information and communication technologies in Georgia has led to the necessity of launching conceptually new, effective, flexible, transparent and society oriented form of government that is e-government. Through applying information technologies, the electronic system enables to raise the efficacy of state governance and increase citizens’ participation in the process. Focusing on the topic of e-government allows us to analyze success stories, attributed benefits and, at the same time, observes challenges hampering the government development process. There are number of methodologies elaborated to study the conditions in the field of electronic governance. They enable us to find out if the government is ready to apply broad opportunities of information and communication technologies and if the government is apt to improve the accessibility and quality of delivering mainly social services. This article seeks to provide comparative analysis of widely spread methodologies used for Electronic government projects’ assessment. It has been concluded that applying current methods of assessment in Georgia is related to difficulties due to inaccessible data and the necessity of involving number of experts. The article presents new indicators for e-government development assessment that reflect efficacy of e-government conception realization in the regions of Georgia and enables to provide quantitative evaluation of regional e-government projects including all significant aspects of development.

Keywords: development methodology, e-government in Georgia, information and communication technologies, regional government

Procedia PDF Downloads 269

Authors: Saeed Zeinali, Nasser Talebbeydokhti, Mehdi Saeidian, Shahrad Vosough

Abstract:

In this article, bathymetry changes have been studied as a case study for Larak Island, located in The South of Iran. The advanced 2D model of Mike21 has been used for this purpose. A simple procedure has been utilized in this model. First, the hydrodynamic (HD) module of Mike21 has been used to obtain the required output for sediment transport model (ST module). The ST module modeled the area for tidal currents only. Bed level changes are resulted by series of modeling for both HD and ST module in 3 months time step. The final bathymetry in each time step is used as the primary bathymetry for next time step. This consecutive procedure been continued until bathymetry for the year 2020 is obtained.

Keywords: bed level changes, Larak Island, hydrodynamic, sediment transport

Procedia PDF Downloads 256

Authors: L. Horňák

Abstract:

The aim of the paper is to analyze a longstanding problem in Slovakia – the effective education of Roma students coming from socially disadvantaged backgrounds. Although it is a relatively small country, there are over 630 communities in the Slovak Republic. The efficiency of the projects was verified by interviews with participants; questionnaires; and direct observations. Evaluation reports which summarized and evaluated the outcomes of the projects only confirmed their success. Slovakia realizes that appropriate social inclusion of marginalized citizens coming from the Roma ethnic group can only be achieved through education based on equality of all students and acceptance of diversity.

Keywords: inclusive education, marginalized communities, Roma pupil, equity in education, socially disadvantaged backgrounds, social inclusion

Procedia PDF Downloads 221

Authors: Hanyu Wei

Abstract:

The last two decades have witnessed a significant number of regeneration practices in historical Chinese cities with the context of rapid urbanisation and economic development. As a response to the possible loss of place identity in the redevelopment process, city makers recognise the potentials of places with cultural significance for maintaining the original landscape. In Chongqing, the prosperities of human settlement history together with the anti-war and post-industrial culture bring this riverside city with its unique urban landscape. Great amounts of historical sites are identified and subjected to conservation planning approaches for urban revitalisation while also maintaining the historic urban landscape. This paper reviews three practices of cultural-led regeneration projects (Hongyadong, Ciqikou, Danzishi) in Chongqing, detailing the urban design and planning principals for the case sites. The paper also presents the conflicting opinions from groups with different interests. By carrying a systematical sustainability evaluation assessment on those projects, the paper critically analyzes the influence of these projects on the broad socio-economic aspects. Although these regeneration cases are thought to achieve the general success in abstaining economic benefits, they are criticised for the over-tourism issues and damages on the authenticity, which further fails to achieve sustainable development.

Keywords: Chongqing, historic urban landscape, sustainable development, urban regeneration

Procedia PDF Downloads 217

Authors: Dermot O'Brien, Vasileios Christaras, Georgios Fontaras, Igor Nai Fovino, Ioannis Kounelis

Abstract:

With the rise of the Internet of Things (IoT), 5G, and blockchain (BC) technologies, vehicles are becoming ever increasingly connected and are already transmitting substantial amounts of data to the original equipment manufacturers (OEMs) servers. This data could be used to help detect mileage fraud and enable more accurate vehicle emissions monitoring. This would not only help regulators but could enable applications such as permitting efficient drivers to pay less tax, geofencing for air quality improvement, as well as pollution tolling and trading platforms for transport-related businesses and EU citizens. Other applications could include traffic management and shared mobility systems. BC enables the transmission of data with additional security and removes single points of failure while maintaining data provenance, identity ownership, and the possibility to retain varying levels of privacy depending on the requirements of the applied use case. This research performs simulations of vehicles interacting with European member state authorities and European Commission BC nodes that are running hyperleger fabric and explores whether the technology is currently feasible for transport applications such as the emission monitoring use-case.

Keywords: future transportation systems, technological innovations, policy approaches for transportation future, economic and regulatory trends, blockchain

Procedia PDF Downloads 168

Authors: Lukas Vierus, Thomas Schuster

Abstract:

A general framework is examined for dynamic tensor field tomography within an inhomogeneous medium characterized by refraction and absorption, treated as an inverse source problem concerning the associated transport equation. Guided by Fermat’s principle, the Riemannian metric within the specified domain is determined by the medium's refractive index. While considerable literature exists on the inverse problem of reconstructing a tensor field from its longitudinal ray transform within a static Euclidean environment, limited inversion formulas and algorithms are available for general Riemannian metrics and time-varying tensor fields. It is established that tensor field tomography, akin to an inverse source problem for a transport equation, persists in dynamic scenarios. Framing dynamic tensor tomography as an inverse source problem embodies a comprehensive perspective within this domain. Ensuring well-defined forward mappings necessitates establishing existence and uniqueness for the underlying transport equations. However, the bilinear forms of the associated weak formulations fail to meet the coercivity condition. Consequently, recourse to viscosity solutions is taken, demonstrating their unique existence within suitable Sobolev spaces (in the static case) and Sobolev-Bochner spaces (in the dynamic case), under a specific assumption restricting variations in the refractive index. Notably, the adjoint problem can also be reformulated as a transport equation, with analogous results regarding uniqueness. Analytical solutions are expressed as integrals over geodesics, facilitating more efficient evaluation of forward and adjoint operators compared to solving partial differential equations. Certainly, here's the revised sentence in English: Numerical experiments are conducted using a Nesterov-accelerated Landweber method, encompassing various fields, absorption coefficients, and refractive indices, thereby illustrating the enhanced reconstruction achieved through this holistic modeling approach.

Keywords: attenuated refractive dynamic ray transform of tensor fields, geodesics, transport equation, viscosity solutions

Procedia PDF Downloads 40

Authors: Thanaa M. Sulaiman

Abstract:

The Iraqi education system has suffered greatly as a result of wars, political instability, and economic problems. After the fall of Saddam’s regime in 2003, the Iraqi education system was proportionally the most impacted sector. The new administration prioritized educational reforms. International organizations, as well as foreign countries, were in the lead to achieve educational reforms. The current study aims to shed light on the reformation process and the roles of different stakeholders, especially international organizations. It also aims to explore the current problems facing the Iraqi education system. Additionally, it aims to explore the different programs and projects that are funded and implemented by international organizations and the impact of these programs and projects.

Keywords: Iraq, Iraqi education system, educational reform, international organizations

Procedia PDF Downloads 123

Authors: Shiliang Wu, Huanxin Zhang

Abstract:

Mercury has been well-known for its negative effects on wildlife, public health as well as the ecosystem. Once emitted into atmosphere, mercury can be transformed into different forms or enter the ecosystem through dry deposition or wet deposition. Some fraction of the mercury will be reemitted back into the atmosphere and be subject to the same cycle. In addition, the relatively long lifetime of elemental mercury in the atmosphere enables it to be transported long distances from source regions to receptor regions. Global change such as climate change and land use/land cover change impose significant challenges for mercury pollution control besides the efforts to regulate mercury anthropogenic emissions. In this study, we use a global chemical transport model (GEOS-Chem) to examine the potential impacts from changes in climate and land use/land cover on the global budget of mercury as well as its atmospheric transport, chemical transformation, and deposition. We carry out a suite of sensitivity model simulations to separate the impacts on atmospheric mercury associated with changes in climate and land use/land cover. Both climate change and land use/land cover change are found to have significant impacts on global mercury budget but through different pathways. Land use/land cover change primarily increase mercury dry deposition in northern mid-latitudes over continental regions and central Africa. Climate change enhances the mobilization of mercury from soil and ocean reservoir to the atmosphere. Also, dry deposition is enhanced over most continental areas while a change in future precipitation dominates the change in mercury wet deposition. We find that 2000-2050 climate change could increase the global atmospheric burden of mercury by 5% and mercury deposition by up to 40% in some regions. Changes in land use and land cover also increase mercury deposition over some continental regions, by up to 40%. The change in the lifetime of atmospheric mercury has important implications for long-range transport of mercury. Our case study shows that changes in climate and land use and cover could significantly affect the source-receptor relationships for mercury.

Keywords: mercury, toxic pollutant, atmospheric transport, deposition, climate change

Procedia PDF Downloads 484

Authors: Abdulrahman S. Shryan Aldossary

Abstract:

Globally, artificial intelligence (AI) is already performing legitimate tasks on behalf of humans. In Saudi Arabia, large-scale national projects, primarily based on AI technologies and receiving billions of dollars of funding, are projected for completion by 2030. However, the legal aspect of these projects is seriously vulnerable, given AI’s unprecedented ability to self-learn and act independently. This paper, therefore, identifies the critical legal aspects of AI that authorities and policymakers should be aware of, specifically whether AI can possess identity and be liable for the risk of public harm. The article begins by identifying the problematic characteristics of AI and what should be considered by legal experts when dealing with it. Also discussed are the possible competent institutions that could regulate AI in Saudi Arabia. Finally, a procedural proposal is presented for controlling AI, focused on Saudi Arabia but potentially of interest to other jurisdictions facing similar concerns about AI safety.

Keywords: regulation, artificial intelligence, tech law, automated systems

Procedia PDF Downloads 167

Authors: Ilkay Ozsev Yuksek, Nuray Ucar, Zeynep Esma Soygur, Yasemin Kucuk

Abstract:

In this study, composite fabrics with polyacrylonitrile electrospun nanofiber deposited onto quilted polyester fabric have been produced in order to control the isolation properties such as water vapor permeability, air permeability and thermal conductivity. Different nanofiber webs were manufactured by changing polymer concentration from 10% to 16% and by changing the deposition time from 1 to 3 hours. Presence of nanofiber layer on the quilted fabric results to an increase of an isolation, i.e., a decrease of the moisture vapor transport rates at 20%, decrease of thermal conductivity at 15% and a decrease of air permeability values at 50%.

Keywords: nanofiber/fabric composites, electrospinning, isolation, thermal conductivity, moisture vapor transport, air permeability

Procedia PDF Downloads 306