Search results for: Modern construction management

Authors: Samuel Capintero, Ole H. Petersen

Abstract:

This paper examines the utilization of public-private partnerships for the building and operation of wastewater treatment plants. Our research focuses on risk allocation in this kind of projects. Our analysis builds on more than hundred wastewater treatment plants built and operated through PPP projects in Aragon (Spain). The paper illustrates the consequences of an inadequate management of construction risk and an unsuitable transfer of demand risk in wastewater treatment plants. It also shows that the involvement of many public bodies at local, regional and national level further increases the complexity of this kind of projects and make time delays more likely.

Keywords: Wastewater, treatment plants, PPP, construction.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2288

Authors: Noor M. Abdulfattah, Ahmed M. Khalafallah, Nabil A. Kartam

Abstract:

Despite the evident benefits of building information modeling (BIM) to the construction industry, it faces significant implementation challenges in the State of Kuwait. This study investigates the awareness of construction stakeholders of BIM implementation challenges, and identifies various solutions to overcome these challenges. Specifically, the main objectives of this study are to: (1) characterize the barriers that deter utilization of BIM, (2) examine the awareness of engineers, architects, and construction stakeholders of these barriers, and (3) identify practical solutions to facilitate BIM utilization. A questionnaire survey was designed to collect data on the aforementioned objectives from local companies and senior BIM experts. It was found that engineers are highly aware of BIM implementation barriers. In addition, it was concluded from the questionnaire that the biggest barrier is the lack of BIM training. Based on expert feedback, the study concluded with a number of recommendations on how to overcome the barriers of BIM utilization. This should prove useful to the construction industry stakeholders and can lead to significant changes to design and construction practices.

Keywords: Building information modeling, construction, challenges, information technology.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2475

Authors: P. Ahern, D. Collery

Abstract:

The implementation of lean thinking in the manufacturing industry revolutionized the traditional approach to large-scale production through the process of identifying the waste in each task and putting in place mitigation measures to eliminate the waste in all its forms. The Irish construction industry, however, has been much slower to adopt the principles of lean, opting instead to stick with the traditional approach to construction project delivery which is inherently wasteful. Lean thinking holds the potential to revolutionize the construction industry in a similar manner to the adoption of lean manufacturing. Lean principles present opportunities for reduced project duration, reduced project cost, improved quality, and elimination of re-works and non-value-added activities. This research has been designed to accumulate research data through available literature, electronic surveys, and interviews. The results show an industry reluctant to accept change and an undefined path to successful lean construction implementation.

Keywords: Barriers, lean construction, lean implementation, lean manufacturing, lean philosophy.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 317

Authors: F. H. Abanda, B. Kamsu-Foguem, J. H. M. Tah

Abstract:

Construction cost estimation is one of the most important aspects of construction project design. For generations, the process of cost estimating has been manual, time-consuming and error-prone. This has partly led to most cost estimates to be unclear and riddled with inaccuracies that at times lead to over- or underestimation of construction cost. The development of standard set of measurement rules that are understandable by all those involved in a construction project, have not totally solved the challenges. Emerging Building Information Modelling (BIM) technologies can exploit standard measurement methods to automate cost estimation process and improve accuracies. This requires standard measurement methods to be structured in ontological and machine readable format; so that BIM software packages can easily read them. Most standard measurement methods are still text-based in textbooks and require manual editing into tables or Spreadsheet during cost estimation. The aim of this study is to explore the development of an ontology based on New Rules of Measurement (NRM) commonly used in the UK for cost estimation. The methodology adopted is Methontology, one of the most widely used ontology engineering methodologies. The challenges in this exploratory study are also reported and recommendations for future studies proposed.

Keywords: BIM, Construction projects, Cost estimation, NRM, Ontology.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 4444

Authors: H.Soussi, M.Hussain, H.Afifi, D.Seret

Abstract:

Key management is a vital component in any modern security protocol. Due to scalability and practical implementation considerations automatic key management seems a natural choice in significantly large virtual private networks (VPNs). In this context IETF Internet Key Exchange (IKE) is the most promising protocol under permanent review. We have made a humble effort to pinpoint IKEv2 net gain over IKEv1 due to recent modifications in its original structure, along with a brief overview of salient improvements between the two versions. We have used US National Institute of Technology NIIST VPN simulator to get some comparisons of important performance metrics.

Keywords: Quantitative Analyses, IKEv1, IKEv2, NIIST.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 4593

Authors: S.B. Ahmadi, Z. Moradpour, Gh. Liaghat

Abstract:

In this article the accumulated results out of the effects and length of the manufacture and production projects in the university and research standard have been settled with the usefulness definition of the process of project management for the accessibility to the proportional pattern in the “time and action" stages. Studies show that many problems confronted by the researchers in these projects are connected to the non-profiting of: 1) autonomous timing for gathering the educational theme, 2) autonomous timing for planning and pattern, presenting before the construction, and 3) autonomous timing for manufacture and sample presentation from the output. The result of this study indicates the division of every manufacture and production projects into three smaller autonomous projects from its kind, budget and autonomous expenditure, shape and order of the stages for the management of these kinds of projects. In this case study real result are compared with theoretical results.

Keywords: Project management, Manufacturing, production.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1673

Authors: Rushi Tan, Yilun Xu, Xiaohui Wang

Abstract:

The restrained construction zoning, an important part in the urban master plan, is a necessary planning tool to control the city sprawl, to guarantee the reservation implementation of the various types of protective elements, and to realize the storage of the essential urban spatial resources. Simultaneously, owing to the diverse constitutes of restrained construction area and the various stakeholders involved in, its planning requires an overall consideration of all elements from the perspective of coordination+, balance and practicability to deal with the problems and conflicts in this process. Taking Yangzijin Ecological Restrained Construction Area in Yangzhou as an example, this study analyzes all the potential actors, agencies and stakeholders in this restrained construction area, as well as the relevant conflicts between each other. Besides, this study tries to build up a planning procedure based on the framework of governance theory, and proposes a possible planning method that combines "rigidity" and "flexibility" to protect the ecological limitation boundary, to take every interest into account, and to promote economic development in a harmonious society.

Keywords: Restrained construction area, governance, stakeholder, flexible stratagem, China.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1969

Authors: E. Harrer, M. Mauerhofer, T. Werginz

Abstract:

As a result of intensive competition, the building sector is suffering from a high degree of rivalry. Furthermore, there can be observed an unbalanced distribution of project risks. Clients are aimed to shift their own risks into the sphere of the constructors or planners. The consequence of this is that the number of conflicts between the involved parties is inordinately high or even increasing; an alternative approach to counter on that developments are cooperative project forms in the construction sector. This research compares conventional contract models and models with partnering agreements to examine the influence on project risks by an early integration of the involved parties. The goal is to show up deviations in different project stages from the design phase to the project transfer phase. These deviations are evaluated by a survey of experts from the three spheres: clients, contractors and planners. By rating the influence of the participants on specific risk factors it is possible to identify factors which are relevant for a smooth project execution.

Keywords: Collaborative work, construction industry, contract-models, influence, partnering, project management, risk.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 870

Authors: Mitansha, Suzanne Wilkinson, Regan Potangaroa

Abstract:

The built environment is designed, maintained, operated, and decommissioned by construction organisations, which play a significant role in providing physical resources and rebuilding infrastructures during major crises and disasters. It is evident that enhancing the resilience of construction organisations allows better responding ability and speedy recovery from disasters and acts as a boon for the nation in the face of significant disruptions. As individuals are the integral component of any organisation, hence, individual resilience is considered a critical aspect, which may boost organisational resilience of construction sector. It has been observed that individual resilience is indirectly supported by organisation’s citizenship behaviour, job performance, and career success. Not only this, it also tends to hold a directly proportional relation with job satisfaction, physical and emotional well-being affected by organisation’s work culture, whereas the resilience of organisation increases as a result of positive adaption, growth and collective learning of the employees as an entity. Moreover, indicators like situation awareness in staff and crisis related issues, effective vulnerability management, organisational leadership and culture ensured by approachable, encouraging and people-oriented leaders, are prominent for achieving organisational resilience. It, thus, becomes perceptible that both, organisational and individual resiliencies, have the potential to influence each other. Consequently, it arises a major question that how these characteristics are associated and tend to behave with respect to each other. The study, thus, aims to explore the overlapping dimensions of organisational and individual resilience to determine the impact boundaries. The research methodology of the paper would be based on systematic literature review specifically focused on the resilience of construction industry. This would provide a direct comparison of characteristics influencing individual and organisational resilience and will present the most significant indicators of individual resilience that can eventually help to enhance the resilience of construction organisations amidst any disaster or crisis.

Keywords: Construction industry, individual resilience, organisational resilience, overlapping dimension.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 228

Authors: Anant Oonsivilai, Kenedy A. Greyson

Abstract:

The demand of the energy management systems (EMS) set forth by modern power systems requires fast energy management systems. Contingency analysis is among the functions in EMS which is time consuming. In order to handle this limitation, this paper introduces agent based technology in the contingency analysis. The main function of agents is to speed up the performance. Negotiations process in decision making is explained and the issue set forth is the minimization of the operating costs. The IEEE 14 bus system and its line outage have been used in the research and simulation results are presented.

Keywords: Agents, model, negotiation, optimal dispatch, powersystems.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2131

Authors: Maryam Kiani, Abdul Basit Kiani

Abstract:

To develop construction and infrastructure industry, sensors are highly desired to control building ventilation. Zinc doped magnesium ferrite nanoparticles (Z@MFO) (Zn = 0.0, 0.2, 0.3, 0.4) were prepared in this paper. Structural analyses confirmed the formation of spinel cubic nanostructures. X-Ray diffraction (XRD) data represent high reactive surface area due to small average particle size about 15 nm, which efficiently influences the gas sensing mechanism. The gas sensing property of Z@MFO for several gases was obtained by measuring the resistance as a function of different factors, such as composition and response time in air and in presence of gas. The sensitivity of spinel ferrite to CO2 at room temperature has been compared. The Z@MFO nano-structure exhibited high sensitivity represented good response time of (~1 min) to CO2, demonstrated that the material can be used in the field of gas sensors with high sensitivity and good selectivity at room temperature to control building ventilation. CO2 gas sensors play a vital role in ensuring the safety, comfort, and sustainability of modern building environments.

Keywords: MgFe2O4 nanoparticles, synthesis, gas sensing properties, X ray differentiation.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 202

Authors: Kenneth M. Oba

Abstract:

This study investigated factors affecting the price of cement in Nigeria, and developed a mathematical model that can predict future cement prices. Cement is key in the Nigerian construction industry. The changes in price caused by certain factors could affect economic and infrastructural development; hence there is need for proper proactive planning. Secondary data were collected from published information on cement between 2014 and 2019. In addition, questionnaires were sent to some domestic cement retailers in Port Harcourt in Nigeria, to obtain the actual prices of cement between the same periods. The study revealed that the most critical factors affecting the price of cement in Nigeria are inflation rate, population growth rate, and Gross Domestic Product (GDP) growth rate. With the use of data from United Nations, International Monetary Fund, and Central Bank of Nigeria databases, amongst others, a Multiple Linear Regression model was formulated. The model was used to predict the price of cement for 2020-2025. The model was then tested with 95% confidence level, using a two-tailed t-test and an F-test, resulting in an R² of 0.8428 and R² (adj.) of 0.6069. The results of the tests and the correlation factors confirm the model to be fit and adequate. This study will equip researchers and stakeholders in the construction industry with information for planning, monitoring, and management of present and future construction projects that involve the use of cement.

Keywords: Cement price, multiple linear regression model, Nigerian Construction Industry, price prediction.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 793

Authors: Chris Landorf, Stephen Ward

Abstract:

This paper addresses a virtual environment approach to work integrated learning for students in construction-related disciplines. The virtual approach provides a safe and pedagogically rigorous environment where students can apply theoretical knowledge in a simulated real-world context. The paper describes the development of a 4-dimensional digital construction environment and associated learning activities funded by the Australian Office for Learning and Teaching. The environment was trialled with over 1,300 students and evaluated through questionnaires, observational studies and coursework analysis. Results demonstrate a positive impact on students’ technical learning and collaboration skills, but there is need for further research in relation to critical thinking skills and work-readiness.

Keywords: Architectural education, construction industry, digital learning environments, immersive learning.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1010

Authors: Lars Laußat, Manfred Helmus, Kamil Szczesny, Markus König

Abstract:

As one result of the project “Reactive Construction Project Scheduling using Real Time Construction Logistic Data and Simulation”, a procedure for using data about uncertain resource availability assumptions in reactive scheduling processes has been developed. Prediction data about resource availability is generated in a formalized way using real-time monitoring data e.g. from auto-ID systems on the construction site and in the supply chains. The paper focusses on the formalization of the procedure for monitoring construction logistic processes, for the detection of disturbance and for generating of new and uncertain scheduling assumptions for the reactive resource constrained simulation procedure that is and will be further described in other papers.

Keywords: Auto-ID, Construction Logistic, Fuzzy, Monitoring, RFID, Scheduling.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1778

Authors: G. Schuh, S. Aghassi

Abstract:

In order to bridge the gap between research and industry, promoting technology and knowledge transfer becomes increasingly important. Especially small- and medium-sized enterprises, having only little R&D resources themselves, depend on external technology development activities for remaining innovative. Academia research on the other hand needs potential industrial partners, who are capable and willing to commercialize their technologies as most public funding programs require some sort of technology transfer or dissemination activities. Modern web technologies offer more and more “social” functionalities and open up new ways of user interaction. In the past years several technology transfer platforms were developed, making use of modern web technologies in order to enable and support technology transfer. In this paper we report on the results of a state-of-the art analyses of existing technology transfer platforms, point out their advantages and deficits and give a perspective to the development of an improved technology transfer platform.

Keywords: Knowledge transfer, social software, technology management, technology transfer.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1698

Authors: Alba Barbarà Molinero, Rosalía Cascón Pereira

Abstract:

We assert here that there might be some factors that influence professional identity construction at the university/higher education stage. In accord, we propose a conceptual framework of intervening factors in professional identity construction at university from a literature review and preliminary data from a qualitative pilot study using focus groups. This model identifies several factors that might influence university students- professional identity construction and group them into categories. In turn, we describe how these factors might contribute in strengthening or weakening their professional identity. Finally, we discuss the implications of strengthening students- PI for the university, individuals and organizations and we provide a roadmap for future empirical work in this area.

Keywords: Professional Identity, Higher education, influencing factors.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 3385

Authors: C. Wan, A. Mita

Abstract:

This paper proposes a novel system for monitoring the health of underground pipelines. Some of these pipelines transport dangerous contents and any damage incurred might have catastrophic consequences. However, most of these damage are unintentional and usually a result of surrounding construction activities. In order to prevent these potential damages, monitoring systems are indispensable. This paper focuses on acoustically recognizing road cutters since they prelude most construction activities in modern cities. Acoustic recognition can be easily achieved by installing a distributed computing sensor network along the pipelines and using smart sensors to “listen" for potential threat; if there is a real threat, raise some form of alarm. For efficient pipeline monitoring, a novel monitoring approach is proposed. Principal Component Analysis (PCA) was studied and applied. Eigenvalues were regarded as the special signature that could characterize a sound sample, and were thus used for the feature vector for sound recognition. The denoising ability of PCA could make it robust to noise interference. One class SVM was used for classifier. On-site experiment results show that the proposed PCA and SVM based acoustic recognition system will be very effective with a low tendency for raising false alarms.

Keywords: One class SVM, pipeline monitoring system, principal component analysis, sound recognition, third party damage.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 2018

Authors: Dzul Fahmi Nordin, Rosmini Omar

Abstract:

This paper analyzed the perception of e-commerce application services by construction material traders in Malaysia. Five attributes were tested: usability, reputation, trust, privacy and familiarity. Study methodology consists of survey questionnaire and statistical analysis that includes reliability analysis, factor analysis, ANOVA and regression analysis. The respondents were construction material traders, including hardware stores in Klang Valley, Kuala Lumpur. Findings support that usability and familiarity with e-commerce services in Malaysia have insignificant influence on the acceptance of e-commerce application. However, reputation, trust and privacy attributes have significant influence on the choice of e-commerce acceptance by construction material traders. E-commerce applications studied included customer database, e-selling, emarketing, e-payment, e-buying and online advertising. Assumptions are made that traders have basic knowledge and exposure to ICT services. i.e. internet service and computers. Study concludes that reputation, privacy and trust are the three website attributes that influence the acceptance of e-commerce by construction material traders.

Keywords: Electronic Commerce (e-Commerce), Information and Communications Technology (ICT), Small Medium Enterprise (SME)

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1843

Authors: Dutescu Adriana, Amariei Corneliu, Sahlian Daniela, Stanila Aurelian, Stanila Oana

Abstract:

20 years of dentistry was a period of transition from communist to market economy but Romanian doctors have insufficient management knowledge. Recently, the need for modern management has increased due to technologies and superior materials appearance, as patient-s demands. Research goal is to increase efficiency by evaluating dental medical office cost categories in real pricing procedures. Empirical research is based on guided study that includes information about the association between categories of cost perception and therapeutic procedures commonly used in dental offices. Due to the obtained results to identify all the labours that make up a settled procedure costs were determined for each procedure. Financial evaluation software was created with the main functions: introducing and maintaining patient records, treatment and appointments made, procedures cost and monitoring office productivity. We believe that the study results can significantly improve the financial management of dental offices, increasing the effectiveness and quality of services.

Keywords: costs, financial methods, management.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1460

Authors: Gorana Jelic Mrcelic, Merica Sliskovic

Abstract:

Environmental responsibility includes improvement of environmental performance in order to reduce environmental impact. This paper gives a short review of some important environmental objectives, targets and actions that modern shipping company should follow.

Keywords: Environment, MARPOL, ships, pollutants.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1802

Authors: Kho Mei Ye, Hamzah Abdul Rahman

Abstract:

The purpose of this study is to identify the underlying causes of late payment from the contractors- perspective in the Malaysian construction industry and to recommend effective solutions to mitigate late payment problems. The target groups of respondents in this study were Grades G3, G5, G6 and G7 contractors with specialization in building works and civil engineering works registered with the Construction Industry Development Board (CIDB) in Malaysia. Results from this study were analyzed with Statistical Package for the Social Science (SPSS 15.0). From this study, it was found that respondents have highest ranked five significant variables out of a total of forty-one variables which can caused late payment problems: a) cash flow problems due to deficiencies in client-s management capacity (mean = 3.96); b) client-s ineffective utilization of funds (mean = 3.88); c) scarcity of capital to finance the project (mean = 3.81); d) clients failure to generate income from bank when sales of houses do not hit the targeted amount (mean=3.72); and e) poor cash flow because of lack of proper process implementation, delay in releasing of the retention monies to contractor and delay in the evaluation and certification of interim and final payment (mean = 3.66).

Keywords: Underlying causes, late payment, constructionindustry, Malaysia.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 7194

Authors: Omneya N. Mekhaimer, Elkhayam M. Dorra, A. Samer Ezeldin

Abstract:

Over the recent decades, studies on organizational culture have gained global attention in the business management literature, where it has been established that the cultural factors embedded in the organization have an implicit yet significant influence on the organization’s success. Unlike other industries, the construction industry is widely known to be operating in a dynamic and adversarial nature; considering the unique characteristics it denotes, thereby the level of disputes has propagated in the construction industry throughout the years. To that end, this paper aims to study the influence of organizational culture in the contractor’s organization on the frequency of disputes caused between the owner and the contractor in commercial projects based in Egypt. This objective is achieved by using a quantitative approach through a survey questionnaire to explore the dominant cultural attributes that exist in the contractor’s organization based on the Competing Value Framework (CVF) theory, which classifies organizational culture into four main cultural types: (1) clan, (2) adhocracy, (3) market, and (4) hierarchy. Accordingly, the collected data are statistically analyzed using Statistical Package for Social Sciences (SPSS 28) software, whereby a correlation analysis using Pearson Correlation is carried out to assess the relationship between these variables and their statistical significance using the p-value. The results show that there is an influence of organizational culture attributes on the frequency of disputes whereby market culture is identified to be the most dominant organizational culture that is currently practiced in contractor’s organization, which consequently contributes to increasing the frequency of disputes in commercial projects. These findings suggest that alternative management practices should be adopted rather than the existing ones with an aim to minimize dispute occurrence.

Keywords: Construction projects, correlation analysis, disputes, Egypt, organizational culture.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 161

Authors: Somayeh Farzin, Hossein Teimoori Nezhad

Abstract:

Procurement is an important component in the field of operating resource management and e-procurement is the golden key to optimizing the supply chains system. Global firms are optimistic on the level of savings that can be achieved through full implementation of e-procurement strategies. E-procurement is an Internet-based business process for obtaining materials and services and managing their inflow into the organization. In this paper, the subjects of supply chains and e-procurement and its benefits to organizations have been studied. Also, e-procurement in construction and its drivers and barriers have been discussed and a framework of supplier selection in an e-procurement environment has been demonstrated. This paper also has addressed critical success factors in adopting e-procurement in supply chains.

Keywords: E-Procurement, Supply Chain, Benefits, Construction, Drivers, Barriers, Supplier Selection, CFSs.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 3234

Authors: Asif Husain, Majid Matouq Assas

Abstract:

In recent years demolished concrete waste handling and management is the new primary challenging issue faced by the countries all over the world. It is very challenging and hectic problem that has to be tackled in an indigenous manner, it is desirable to completely recycle demolished concrete waste in order to protect natural resources and reduce environmental pollution. In this research paper an experimental study is carried out to investigate the feasibility and recycling of demolished waste concrete for new construction. The present investigation to be focused on recycling demolished waste materials in order to reduce construction cost and resolving housing problems faced by the low income communities of the world. The crushed demolished concrete wastes is segregated by sieving to obtain required sizes of aggregate, several tests were conducted to determine the aggregate properties before recycling it into new concrete. This research shows that the recycled aggregate that are obtained from site make good quality concrete. The compressive strength test results of partial replacement and full recycled aggregate concrete and are found to be higher than the compressive strength of normal concrete with new aggregate.

Keywords: Demolished, concrete waste, recycle, new concrete, fresh coarse aggregate.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 5845

Authors: Sareh Rajabi, Taha Anjamrooz, Salwa Bheiry

Abstract:

Sustainability of construction projects is an important issue to be addressed since the sector will continue to be developed in the coming years, especially in developing countries. Thus, it is significant to discover approaches and solutions for improving sustainability. Currently, the construction industry is the largest consumer of natural resources. This is the same in other countries in the Gulf region, and the United Arab Emirates (UAE) has limited natural resources such as water, electricity, etc. Recently, the UAE has taken several actions in order to implement sustainable initiatives within its construction industry. Within the industry, the contractors’ role is significant in promoting sustainable development by taking the responsibility to minimize their negative impacts on the environment and society, and maximize their economic distribution. In this research, sustainability will be studied as an important key to bring competitive advantages to contracting organizations. The contractors should understand the need to improve their sustainable performance in order to expand their business competitiveness. Competitiveness at the construction project level refers to a contractor’s ability to compete for a project. There is less focus on how to improve contractors’ competitiveness by implementing sustainable construction practices. Based on an inclusive literature review on the relationship between sustainability performance and business competitiveness, this research will conduct a study of sustainable practice in the construction industry and the relationship between sustainability performance and business competitiveness in order to develop a framework for evaluating how contractors can improve their competitiveness in terms of more efficient processes, enhancements in productivity, and lower costs of compliance in order to reduce the initial project cost and obtain market opportunities in the UAE. The research findings will provide a framework that can be a useful guideline for contractors to develop their sustainability policy, strategy and practice for meeting the increased requirements for sustainable development in construction.

Keywords: Sustainable construction practice, sustainability, competitiveness, construction industry, contractors.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1120

Authors: V.R Gannapathy, S.K Subramaniam, A.B Mohamad Diah, M.K Suaidi, A.H Hamidon

Abstract:

The picture of a perfect road construction site is the one that utilizes conventional vertical road signs and a flagman to optimize the traffic flow with minimum hazel to the public. Former research has been carried out by Department of Occupational Safety and Health (DOSH) and Ministry of Works to further enhance smoothness in traffic operations and particularly in safety issues within work zones. This paper highlights on hazardous zones in a certain road construction or road maintenance site. Most cases show that the flagman falls into high risk of fatal accidents within work zone. Various measures have been taken by both the authorities and contractors to overcome such miseries, yet it-s impossible to eliminate the usage of a flagman since it is considered the best practice. With the implementation of new technologies in automating the traffic flow in road construction site, it is possible to eliminate the usage of a flagman. The intelligent traffic light system is designed to solve problems which contribute hazardous at road construction site and to be inline with the road safety regulation which is taken into granted.

Keywords: Intelligent Traffic Light, Critical Zones, Safety Regulation, Flagman

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 6367

Authors: Junqi Zhao, Yongqiang Chen

Abstract:

Preference for different conflict resolution styles is influenced by cultural background and power distance of two parties involving in conflict. This research put forward 7 hypotheses and tested the preference differences of the five conflict resolution styles between Chinese owner and contractor as well as the preference differences concerning the same style between two parties. The research sample includes 202 practitioners from construction enterprises in mainland China. Research result found that theories concerning conflict resolution styles could be applied in the Chinese construction industry. Some results of this research were not in line with former research, and this research also gave explanation to the differences from the characteristics of construction projects. Based on the findings, certain suggestions were made to serve as a guidance for managers to choose appropriate conflict resolution styles for a better handling of conflict.

Keywords: Chinese Owner and Contractor, Conflict, Construction Project, Conflict Resolution Styles.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1787

Authors: Balimu Mwiya, Mundia Muya, Chabota Kaliba, Peter Mukalula

Abstract:

Factors affecting construction unit cost vary depending on a country’s political, economic, social and technological inclinations. Factors affecting construction costs have been studied from various perspectives. Analysis of cost factors requires an appreciation of a country’s practices. Identified cost factors provide an indication of a country’s construction economic strata. The purpose of this paper is to identify the essential factors that affect unit cost estimation and their breakdown using artificial neural networks. Twenty five (25) identified cost factors in road construction were subjected to a questionnaire survey and employing SPSS factor analysis the factors were reduced to eight. The 8 factors were analysed using neural network (NN) to determine the proportionate breakdown of the cost factors in a given construction unit rate. NN predicted that political environment accounted 44% of the unit rate followed by contractor capacity at 22% and financial delays, project feasibility and overhead & profit each at 11%. Project location, material availability and corruption perception index had minimal impact on the unit cost from the training data provided. Quantified cost factors can be incorporated in unit cost estimation models (UCEM) to produce more accurate estimates. This can create improvements in the cost estimation of infrastructure projects and establish a benchmark standard to assist the process of alignment of work practises and training of new staff, permitting the on-going development of best practises in cost estimation to become more effective.

Keywords: Construction cost factors, neural networks, roadworks, Zambian Construction Industry.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 3826

Authors: Zaza Tabagari, Zaza Sanikidze, George Giorgobiani

Abstract:

Abovepresented work deals with the new scope of application of information and communication technologies for the improvement of the election process in the biased environment. We are introducing a new concept of construction of the information-communication system for the election participant. It consists of four main components: Software, Physical Infrastructure, Structured Information and the Trained Stuff. The Structured Information is the bases of the whole system and is the collection of all possible events (irregularities among them) at the polling stations, which are structured in special templates, forms and integrated in mobile devices.The software represents a package of analytic modules, which operates with the dynamic database. The application of modern communication technologies facilities the immediate exchange of information and of relevant documents between the polling stations and the Server of the participant. No less important is the training of the staff for the proper functioning of the system. The e-training system with various modules should be applied in this respect. The presented methodology is primarily focused on the election processes in the countries of emerging democracies.It can be regarded as the tool for the monitoring of elections process by the political organization(s) and as one of the instruments to foster the spread of democracy in these countries.

Keywords: ICT, elections, structured information, dynamic databases, e-training.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 1745

Authors: E. Kissi, V. K. Acheamfour, J. J. Gyimah, T. Adjei-Kumi

Abstract:

Factoring accounts receivable is widely accepted as an alternative financing source and utilized in almost every industry that sells business-to-business or business-to-government. However, its patronage in the construction industry is very limited as some barriers hinder its application in the construction industry. This study aims at assessing the barriers to the use of factoring accounts receivables in the Ghanaian construction industry. The study adopted the sequential exploratory research method where structured and unstructured questionnaires were conveniently distributed to D1K1 and D2K2 construction firms in Ghana. Using the one-sample t-test and Kendall’s Coefficient of concordance data were analyzed. The most severe challenge concluded is the high cost of factoring patronage. Other critical challenges identified were low knowledge on factoring processes, inadequate access to information on factoring, and high risks involved in factoring. Hence, it is recommended that contractors should be made aware of the prospects of factoring of accounts receivables in the construction industry. This study serves as basis for further rigorous research into factoring of accounts receivables in the industry.

Keywords: Barriers, contractors, factoring accounts receivables, Ghanaian, perception.

Procedia APA BibTeX Chicago EndNote Harvard JSON MLA RIS XML ISO 690 PDF Downloads 551